中英文对照工程施工合同模板协议模板.doc

建筑施工合同中英文对照版本

xxxx施工合同Construction Contract of xxxx发包方（甲方）xxxxParty A: xxxx承包方（乙方）xxxxParty B: xxxx本合同由如上列明的甲、乙双方按照《中华人民共和国合同法》、《建筑安装工程承包合同条例》以及国家相关法律法规的规定，结合本合同具体情况，于xx年x月x日在xx签订。

This contract is signed by the two Parties in xxxx on xxxx according to the “Contract Law of the People’s Republic of China”, the “Regulation on Building and Installation Contracting Contract”, and other relevant national laws and regulations, as well as the specific nature of this project第一条总则Article 1 General Principles1.1合同文件Contract Documents本合同包含合同、展示、施工图纸、作法说明、招投标文件以及合同所指的其他文件，它们均被视为合同的一部分。

合同文件应该能够相互解释，互为说明。

组成本合同的文件及优先解释的顺序如下：本合同、中标通知书、投标书及其附件、标准、规范及有关技术文件、图纸、工程量清单及工程报价单或预算书。

合同履行中，发包人承包人有关工程的洽商、变更等书面下一或文件视为本合同的组成部分。

This contract includes the contract itself, exhibits, construction drawings, explanations of work procedures, tender documents, as well as other documents specified by the contract. The contract documents should be mutually explainable and mutually descriptive. The documents that constituted the contract and the priority hierarchy of explanations of the documents are as follows: this contract; the official letter of winning the tender; Letter of bidding and its annex, standards, guidelines, and relevant technical documents, drawings, Bill of Quantity (BOQ), quotation of prices, and project budget. During the implementation of the contract, any written agreements or documents between two parties such as change-orders are also regarded will be deemed as part of this contract.1.1.1项目概况Project Introduction1.1.2工程名称：xxxxName of Project: xxxx1.1.3工程地点：xxxxLocation of Project: xxxx1.1.3.1工程范围：除了本合同其他条款另有说明外，乙方应提供为履行合同所需的所有服务，用品以及其他保障工程进行所需的必要花费以完成下列工作：Scope of the project: unless otherwise explained by other articles in this contract, Party B shall provide all services, utensils, and other necessary cost for the implementation of this contract; the scope of project includes, but not limited to:※室内装饰工程，详见附件一和附件二Inner decoration, see appendix 1 & 2※室外装饰工程（门窗、屋面、台阶等），详见附件一和附件二Fa?ade(including doors, windows, roof and stairs) see appendix 1 & 2※电器工程，详见附件一和附件二Electronic Engineering, see appendix 1 & 2※空调工程，详见附件一和附件二Air Conditioning System, see appendix 1 & 2※给排水及采暖工程，详见附件一和附件二Water Supply, Sewage and Heating System, see appendix 1 & 2※消防工程Fire Control System, see appendix 1 & 2※其他图纸上所列项目（任何对原定设计的变更应提供新的图纸并有甲方的签字确认）以上所有的工程项目以下统称为“工程”。

建设工程施工合同中英文对照版

建设工程施工合同中英文对照版中英文建设工程施工合同Contract for Construction Project本合同是由承包人（以下简称“甲方”）和业主（以下简称“乙方”）共同订立，旨在规定双方在建设工程项目中的权益和义务。

This contract is entered into by and between the Contractor (hereinafter referred to as "Party A") and the Owner (hereinafter referred to as "Party B") to regulate the rights and obligations of both parties in the construction project.总则 General Provisions第一条项目名称及工程地点：本工程名称为_________，位于_________。

Article 1: Project Name and Location: The name of the project is__________, located in __________.第二条总承包范围：甲方应按照乙方的要求，完成工程项目的设计、施工、验收等工作。

Article 2: Scope of General Contracting: Party A shall complete the design, construction, and acceptance of the project in accordance with PartyB's requirements.第三条施工期限：本工程的施工期限为_________，甲方必须按时完成工程，并交付乙方使用。

Article 3: Construction Period: The construction period of this project is __________. Party A must complete the project on time and deliver it to Party B for use.义务与责任 Obligations and Responsibilities第四条甲方责任：甲方应根据乙方的要求，制定合理的工程施工方案，并保证工程按照合同和法律法规的要求进行。

施工合同中英文模板

合同协议模板Construction Contract工程合同PO No.: XXXXXXXBuyer:. Date of signature:甲方:签约日期：Seller:乙方:This Purchase Order is made by and between the Buyer and the Seller: Whereby the Buyer agrees to buy and the Seller agrees to sell the under mentioned commodity according to the terms and conditions stipulated below:甲乙双方经友好协商，一致就供应下列产品，达成如下条款：1. Scope of Supply and Price工作范围及价格明细2. Technical Requirement, Quality Requirement, Standard & Warranty Period:Seller shall carried out the construction in strict accordance with the National Standard and the requirements stipulated in the Technical Agreement No. ________which both party signed (see attached documents). The warranty period shall be 1 year after placement of Goods in service.技术要求、质量要求、技术标准和质保期限: 按国家标准和双方签定的技术协议（编号：______见附件）施工，质保期为投产后1年。

3. Job Sites:施工地点：4. Construction Equipment, Tools & Field Personnel Management:施工设备工具及现场人员管理：可编辑可修改，欢迎下载。

施工合同中英文模板

施工合同中英文模板CONSTRUCTION CONTRACTTHIS CONTRACT is made and entered into as of [Insert Date], by and between [Insert Client Name], hereinafter referred to as "Client," and [Insert Contractor Name], hereinafter referred to as "Contractor."1. SCOPE OF WORKThe Contractor agrees to perform the construction services described in the attached Statement of Work (SOW) for the project identified as [Insert Project Name].2. CONTRACT AMOUNTThe total contract price for the work described in the SOW is [Insert Total Contract Price]. This price includes all labor, materials, equipment, and services necessary to complete the work.3. PAYMENT TERMSThe Client shall make payments to the Contractor as follows: a. [Insert Percentage] percent of the total contract price upon signing of this contract.b. [Insert Percentage] percent of the total contract price upon completion of [Insert Milestone].c. The remaining balance upon satisfactory completion of the work and acceptance by the Client.4. SCHEDULEThe work shall commence on [Insert Start Date] and be completed by [Insert Completion Date].5. PERFORMANCE BONDThe Contractor shall provide a performance bond in the amount of [Insert Bond Amount] to guarantee the completion of the work.6. WARRANTYThe Contractor warrants that all work will be performed in a professional and workmanlike manner and in accordance with the SOW.7. TERMINATIONEither party may terminate this contract for cause upon written notice to the other party if there is a material breach of any of the terms of this contract.8. DISPUTESAny disputes arising out of or in connection with this contract shall be resolved by [Insert Method of Dispute Resolution, e.g., arbitration, mediation, etc.].9. APPLICABLE LAWThis contract shall be governed by and construed in accordance with the laws of [Insert Jurisdiction].10. ENTIRE AGREEMENTThis contract, including the attached SOW and any exhibits, constitutes the entire agreement between the parties andsupersedes all prior negotiations, representations, and agreements.11. AMENDMENTSThis contract may be amended only in writing signed by both parties.12. NOTICESAll notices required or permitted by this contract shall be in writing and delivered to the addresses set forth below or to such other addresses as either party may designate in writing.Client: [Insert Client Name and Address]Contractor: [Insert Contractor Name and Address]IN WITNESS WHEREOF, the parties have executed this contract as of the date first above written.CLIENT[Insert Client Name]By: [Insert Authorized Signature]CONTRACTOR[Insert Contractor Name]By: [Insert Authorized Signature]Title: [Insert Title]STATEMENT OF WORK (SOW)1. PROJECT DESCRIPTIONA detailed description of the project, including the objectives, deliverables, and any specific requirements.2. WORK SCHEDULEA detailed schedule of the work, including milestones and deadlines.3. QUALITY REQUIREMENTSThe quality standards that the work must meet.4. SAFETY REQUIREMENTSSafety protocols and procedures that must be followed during the project.5. SUBMISSIONSA list of all documents, reports, or other submissions required from the Contractor.6. INSPECTION AND ACCEPTANCEProcedures for the Client's inspection of the work and acceptance of the project.7. CHANGE ORDERSProcedures for requesting and implementing changes to the scope of work.8. COMPLETION AND FINAL PAYMENTCriteria for determining when the work is complete and the conditions for final payment.9. WARRANTY AND MAINTENANCEDetails of any warranties provided by the Contractor and any maintenance services included.10. ADDITIONAL TERMSAny other specific terms and conditions relevant to the project.Please note that this is a template and should be reviewed by a legal professional to ensure it meets the specific needs and legal requirements of your project.。

中英文对照-工程施工合同范本-精选.docx

工程施工合同Contract合同编号( Contract NO. )：签订日期( Date )：发包方（简称甲方）Party A:承包方（简称乙方）：Party B:根据《中华人民共和国合同法》以及其他有关法律法规规定的原则，结合本工程的具体情况，甲、乙双方在平等、自愿、协商一致的基础上达成如下协议，共同遵守。

According to “P.R.C Contract Law”,and other relevant laws and regulations to the specific circumstances of this project, parties A and B have hereby equally and voluntarily entered into the following agreement executed on the basis of mutual respect.1.工程概况Project overview1.1工程名称：Project name:1.2工程地点：Project location:1.3工程范围：A. 新研发中心和新厂房的网络综合布线系统的施工；B. 数据中心的建设，主要包含：数据中心的装饰工程、电气系统、空调系统、机房闭路监控系统、机房门禁系统、消防系统改造、机柜系统等。

Project contents:A. The new R & D and new plant construction of network cabling systems;B. Data Center, mainly includes: data center decoration and electrical systems, air-conditioning systems, CCTV systems, access control systems, firefighting system reform, server rack systems.1.4开工条件：合同生效后，甲方预付款到位和现场具备开工条件。

工程合同中英双语

工程合同中英双语【合同名称】Contract Name: 建设工程合同Construction Contract【甲方（发包方）】arty A (Emloyer): ______________________【乙方（承包方）】arty (Contractor): ______________________鉴于甲乙双方根据平等自愿的原则，就以下工程项目的施工达成如下协议：Whereas arty A and arty have reached the following agreement ased on the rincile of equality and voluntariness regarding the construction of the roject elow:第一条合同项目及范围Article 1 Scoe of the Contract roject1.1 本合同项目为[具体项目名称]，位于[具体地点]。

The contract roject is [secific roject name], located at [secific location].1.2 工程范围包括[详细描述工程内容和范围]。

The scoe of the roject includes [detailed descrition of the roject content and scoe].第二条合同金额Article 2 Contract Amount2.1 本合同总金额为[金额数额]人民币/美元。

The total amount of this contract is [amount in RM/USD].2.2 合同金额包含所有施工成本及乙方预期利润。

The contract amount covers all construction costs and arty 's exected rofits.第三条工期要求Article 3 Construction eriod Requirements3.1 工程开工日期为[具体日期]，竣工日期为[具体日期]。

中英文版施工合同：建筑施工合同中英文对照

建设工程施工合同发包方（甲方）xxxxParty A: xxxx承包方（乙方）xxxxParty B: xxxx本合同由如上列明的甲、乙双方按照《中华人民共和国合同法》、《建筑安装工程承包合同条例》以及国家相关法律法规的规定，结合本合同具体情况，于xx年x月x日在xx签订。

This contract is signed by the two Parties in xxxx on xxxx according to the “Contract Law of the People’s Republic of China”, the “Regulation on Building and Installation Contracting Contract”, and other relevant national laws and regulations, as well as the specific nature of this project第一条总则Article 1 General Principles1.1合同文件Contract Documents本合同包含合同、展示、施工图纸、作法说明、招投标文件以及合同所指的其他文件，它们均被视为合同的一部分。

合同文件应该能够相互解释，互为说明。

组成本合同的文件及优先解释的顺序如下：本合同、中标通知书、投标书及其附件、标准、规范及有关技术文件、图纸、工程量清单及工程报价单或预算书。

合同履行中，发包人承包人有关工程的洽商、变更等书面下一或文件视为本合同的组成部分。

This contract includes the contract itself, exhibits, construction drawings, explanations ofwork procedures, tender documents, as well as other documents specified by the contract. The contract documents should be mutually explainable and mutually descriptive. The documents that constituted the contract and the priority hierarchy of explanations of the documents are as follows: this contract; the official letter of winning the tender; Letter of bidding and its annex, standards, guidelines, and relevant technical documents, drawings, Bill of Quantity (BOQ), quotation of prices, and project budget. During the implementation of the contract, any written agreements or documents between two parties such as change-orders are also regarded will be deemed as part of this contract.1.1.1项目概况Project Introduction1.1.2工程名称：xxxxName of Project: xxxx1.1.3工程地点：xxxxLocation of Project: xxxx1.1.3.1工程范围：除了本合同其他条款另有说明外，乙方应提供为履行合同所需的所有服务，用品以及其他保障工程进行所需的必要花费以完成下列工作：Scope of the project: unless otherwise explained by other articles in this contract, Party B shall provide all services, utensils, and other necessary cost for the implementation of this contract; the scope of project includes, but not limited to:※室内装饰工程，详见附件一和附件二Inner decoration, see appendix 1 & 2※室外装饰工程（门窗、屋面、台阶等），详见附件一和附件二Façade(including doors, windows, roof and stairs) see appendix 1 & 2※电器工程，详见附件一和附件二Electronic Engineering, see appendix 1 & 2※空调工程，详见附件一和附件二Air Conditioning System, see appendix 1 & 2※给排水及采暖工程，详见附件一和附件二Water Supply, Sewage and Heating System, see appendix 1 & 2※消防工程Fire Control System, see appendix 1 & 2※其他图纸上所列项目（任何对原定设计的变更应提供新的图纸并有甲方的签字确认）以上所有的工程项目以下统称为“工程”。

建筑施工合同中英文对照

主合同文本甲方：乙方：签订时间：年月日签订地点：使用说明：1、本合同适用于与业务相关的所有签约事宜；2、本合同书中空白部分由当事人根据实际情况进行填写，当事人使用本合同书时约定无需填写的条款，应在该条款处注明“无”等字样；3、未尽事项，可由当事人附页另行约定，并可作为本合同的组成部分。

This Term Sheet ("TS") is entered into on [DD MMM YYYY] between Party A and Party B (as respectively defined below) and sets out the key terms relating to the Proposed Transaction (as defined below). The key terms set out herein shall form the basis of the definitive agreements("Definitive Agreements') to be negotiated and entered into between the Parties in relation to the Proposed Transaction此协议（以下称“本协议“）于【】年【】月【】日，由甲方与乙方签署 (”甲方”与“乙方”的定义在以下的协议内容明细)，明确相关单位就本协议的具体投资条款清单。

本协议的条款将作为日后双方协商以及签署的投资合同（以下称“合同“）的基础。

建设工程施工合同发包方（甲方）xxxxParty A: xxxx承包方（乙方）xxxxParty B: xxxx本合同由如上列明的甲、乙双方按照《中华人民共和国合同法》、《建筑安装工程承包合同条例》以及国家相关法律法规的规定，结合本合同具体情况，于xx年x月x日在xx签订。

建筑施工合同中英文对照版本

建筑施工合同中英文对照版本甲方：Party A乙方：Party B根据《中华人民共和国合同法》及相关法律法规的规定，甲乙双方在平等、自愿、公平、诚信的原则基础上，就甲方委托乙方进行建筑施工事宜，经友好协商，达成以下协议：Article 1: General Provisions1.1 This Contract shall be effective from the date of signing by both Parties and shall expire upon the completion of the Construction Project.1.2除非本合同另有规定，本合同未尽事宜，可由双方另行协商达成补充协议，补充协议与本合同具有同等法律效力。

1.3除非本合同另有规定，本合同一式两份，甲乙双方各执一份，两份合同具有同等法律效力。

Article 2: Construction Scope and Objectives2.1 Party A entrusts Party B with the Construction Project (hereinafter referred to as the "Project") located at ____________ (hereinafter referred to as the "Construction Site").2.2 The Construction Scope of the Project shall include, but not limited to, the following:(1)____________;(2)____________;(3)____________;2.3 The objectives of the Project are to complete the construction within the agreed timeand budget, and to achieve the required quality standards.Article 3: Construction Period3.1 The Construction Period of the Project shall be ____________ days from the date of signing this Contract.3.2 Party B shall notify Party A in writing if it expects to extend the Construction Period. The extension shall not be unreasonably denied by Party A. The extension period shall be agreed upon by both Parties.Article 4: Construction Cost4.1 The total Construction Cost of the Project shall be ____________ RMB (Renminbi), including taxes and other related fees.4.2 The payment schedule shall be as follows:(1)____________ RMB upon signing this Contract;(2)____________ RMB upon the completion ofthe____________ phase of the Project;(3)____________ RMB upon the finalcompletion of the Project.4.3 Party A shall pay Party B theConstruction Cost within 30 days after receiving the relevant invoices and supporting documents.Article 5: Quality and Standards5.1 The construction work shall comply with the relevant laws, regulations, codes, standards, and specifications required by the Construction Project.5.2 Party B shall be responsible for the quality of the construction work. Party B shall repair or replace any defective work within areasonable time after the completion of the Project at its own expense.Article 6: Safety and EnvironmentalProtection6.1 Party B shall ensure the safety of the construction site, and shall take necessary measures to protect the environment and prevent pollution.6.2 Party B shall be responsible for anyinjury or damage caused by its employees or agents during the performance of this Contract.Article 7: Force Majeure7.1 Neither Party shall be liable for the failure or delay in the performance of its obligations under this Contract due to force majeure events such as acts of God, war, strikes, riots, etc.7.2 The Party affected by the force majeure shall notify the other Party in writing as soon as possible, and shall take necessary measures to minimize the losses.Article 8: Dispute Resolution8.1 Any disputes arising out of or in connection with this Contract shall be firstly resolved through friendly negotiation.8.2 If the negotiation fails, the disputes shall be submitted to the____________ people's court with jurisdiction over the place of performance of this Contract.Article 9: Miscellaneous9.1 This Contract may not be assigned by either Party without the prior written consent of the other Party.9.2 This Contract shall be governed by and construed in accordance with the laws of the People's Republic of China.9.3 In case any clause of this Contract is found to be invalid or unenforceable, the validity and enforceability of the remaining clauses shall not be affected.9.4 The headings in this Contract are for convenience only and shall not be used to interpret the contents of the clauses.Article 10: SignatureThe Parties have executed this Contract as of the date first above written.Party A: ________________Representative: ________________Date: ________________Party B: ________________ Representative: ________________ Date: ________________。

施工合同中英文模板-construction-contract

Construction Contract工程合同PO No.: XXXXXXXBuyer:. Date of signature:甲方:签约日期：Seller:乙方:This Purchase Order is made by and between the Buyer and the Seller: Whereby the Buyer agrees to buy and the Seller agrees to sell the under mentioned commodity according to the terms and conditions stipulated below:甲乙双方经友好协商，一致就供应下列产品，达成如下条款：1. Scope of Supply and Price工作范围及价格明细2. Technical Requirement, Quality Requirement, Standard & Warranty Period:Seller shall carried out the construction in strict accordance with the National Standard and the requirements stipulated in the Technical Agreement No. ________which both party signed (see attached documents). The warranty period shall be 1 year after placement of Goods in service.技术要求、质量要求、技术标准和质保期限: 按国家标准和双方签定的技术协议（编号：______见附件）施工，质保期为投产后1年。

3. Job Sites:施工地点：4. Construction Equipment, Tools & Field Personnel Management:施工设备工具及现场人员管理：(1) All the construction equipment and tools shall be provided by Seller.所有施工用设备及工具由乙方自带。

建设工程施工合同中英文对照版

建设工程施工合同中英文对照版建设工程施工合同Construction Contract for Building Projects 甲方：________（中文名称）Party A：________ (Chinese Name)乙方：________（中文名称）Party B：________ (Chinese Name)第一章项目概况1.1 项目名称：________（中文名称）Project Name：________ (Chinese Name)1.2 项目地质：________（中文地质）Project Address：________ (Chinese Address) 1.3 项目内容：________Project Scope：________1.4 项目规模：________Project Scale：________1.5 工程进度：________Project Schedule：________第二章合同签订2.1 合同签署日期：________ Contract Signing Date：________ 2.2 合同有效期：________ Contract Duration：________2.3 合同价款：________Contract Price：________2.4 付款方式：________Payment Terms：________第三章工程设计及施工图纸3.1 设计文件：________Design Documents：________3.2 施工图纸：________ Construction Drawings：________ 3.3 变更设计：________Design Changes：________第四章工程质量4.1 施工质量标准：________Construction Quality Standards：________ 4.2 质量检验与验收：________Quality Inspection and Acceptance：________ 4.3 保修期限：________Warranty Period：________第五章施工进度5.1 工期计划：________Construction Schedule：________5.2 施工延期：________Construction Delays：________5.3 里程碑节点：________Milestone Points：________第六章安全与环境保护6.1 安全管理：________Safety Management：________6.2 环境保护：________Environmental Protection：________第七章分包与进场7.1 分包合同：________Subcontracting Contracts：________7.2 分包管理：________Subcontracting Management：________7.3 进场准备：________Site Mobilization：________第八章合同变更8.1 变更范围：________Scope of Changes：________8.2 变更手续：________Change Procedures：________8.3 变更后价款及工期调整：________ Adjustment of Price and Schedule：________第九章履行保证9.1 甲方履行保证：________Party A's Performance Guarantee：________9.2 乙方履行保证：________Party B's Performance Guarantee：________第十章违约责任10.1 甲方违约责任：________Party A's Breach of Contract Liability：________ 10.2 乙方违约责任：________Party B's Breach of Contract Liability：________十第一章争议解决11.1 合同争议解决方式：________Contract Dispute Resolution Mechanism：________ 11.2 适用法律：________Applicable Laws：________11.3 仲裁地点：________Arbitration Venue：________附件：________附件一：________设计文件附件二：________施工图纸附件三：________分包合同法律名词及注释：________1.甲方：________建筑工程的委托方，负责支付合同价款和提供项目要求。

建设工程施工合同中英文对照版

建设工程施工合同中英文对照版1.总则1.1 背景本合同是由甲方（委托方）和乙方（承包方）之间就特定建设工程的施工相关事宜达成的法律协议。

1.2 定义在本合同中，以下术语的定义分别如下：●“甲方”指委托方。

●“乙方”指承包方。

●“建设工程”指在本合同中具体描述的工程项目。

●…2.合同的设立2.1 合同的效力本合同自双方当事人双方签署后生效，并对双方具有法律约束力。

2.2 合同的变更双方当事人可以通过书面协议对本合同进行变更。

变更协议应明确记录变更的具体内容、生效日期等相关信息。

3.工程范围3.1 工程描述本合同的工程范围涵盖但不限于以下内容：●工程名称、地点、规模等基本信息。

●工程实施的时间和期限。

●工程的任务和目标。

●…3.2 工程图纸和设计文件乙方应在工程施工之前，获得甲方提供的工程图纸和设计文件，并确认其具备实施工程的必要条件。

4.工程进度4.1 工期甲方和乙方应在合同中明确约定工程的开始和结束日期，并在履行合同过程中确保工程按时完成。

4.2 进度计划在工期约定的前提下，乙方应根据工程的具体情况制定详细的工程进度计划，并在实施过程中及时进行更新和调整。

5.质量控制5.1 质量标准甲方应在合同中明确规定工程的质量标准，并要求乙方按照相关法规和行业标准进行施工。

5.2 质量保证乙方应确保施工过程中的所有工作符合甲方要求，并对施工结果承担相应的质量责任。

6.工程支付6.1 付款方式双方应在合同中明确约定工程支付的方式和时间。

甲方应按照约定的比例或时间节点支付工程款项。

6.2 工程结算工程的结算方式和程序应在合同中详细阐明。

乙方应向甲方提供相关的工程进度报告和结算申请。

7.违约责任7.1 甲方违约如果甲方未按照合同约定的方式支付工程款项或未提供必要的配合和支持，甲方应承担相应的违约责任。

7.2 乙方违约如果乙方未按照合同约定的方式完成工程，并导致严重延误或质量问题，乙方应承担相应的违约责任。

8.法律适用和争议解决8.1 法律适用本合同受相关法律法规的约束，并在合同中明确适用的法律法规。

中英文对照工程施工合同

中英文对照工程施工合同Contract No.: [合同编号] Date: [日期] arty A: [甲方名称] arty : [乙方名称]---Contract No.: [合同编号] Date: [日期] arty A: [甲方名称] arty : [乙方名称]---Article 1: roject Information1.1 roject Name: [项目名称]1.2 roject Location: [项目地点]1.3 Scoe of Work: [工作范围描述]---Article 2: Oligations and Rights of arty A2.1 rovide necessary construction conditions and ensure unimeded access to the site.2.2 ay construction fees in accordance with the contract terms and conditions.---Article 3: Oligations and Rights of arty3.1 Comlete the construction work within the agreed timeframe, ensuring quality standards are met.3.2 Sumit rogress reorts on schedule and resond to any issues romtly.---Article 4: Construction eriod4.1 Start Date: [开始日期]4.2 Comletion Date: [完成日期]4.3 Should there e any delay, arty must rovide written notice and reasons to arty A.---Article 5: Quality Requirements5.1 The construction must meet national standards and industry norms.5.2 Uon comletion, oth arties shall conduct a joint insection; any discreancies should e resolved through negotiation.---Article 6: Safety roduction6.1 arty is resonsile for safety management and must comly with all relevant safety regulations.6.2 In case of an accident, immediate measures must e taken, and arty A should e informed without delay.---Article 7: rice and ayment Method7.1 Total contract rice: [合同总价]7.2 ayment schedule: [付款计划描述]---Article 8: Changes and Rescission of the Contract8.1 Any changes or amendments to the contract must e in writing and agreed uon y oth arties.8.2 Either arty may rescind the contract under certain conditions as stiulated y law.---Article 9: Settlement of Disutes9.1 Disutes arising from the contract shall e settled through friendly consultation.9.2 If consultation fails, either arty may sumit the disute to aritration or ursue legal action in court.---Article 10: Force Majeure10.1 Force majeure includes natural disasters and other unforeseeale events that revent erformance of the contract.10.2 The affected arty must immediately inform the other arty and rovide suorting evidence. ---Article 11: Miscellaneous11.1 Confidentiality clauses, intellectual roerty rights, etc., shall e detailed searately.11.2 This contract is executed in two counterarts, each held y one arty, and ecomes effective uon signing.---Article 12: Signatures and Seals[甲方签名盖章处] [乙方签名盖章处]Authorized Reresentative: [授权代表人姓名] Authorized Reresentative: [授权代表人姓名] Seal: [公司印章] Seal: [公司印章]Date: [日期] Date: [日期]。

(完整word版)中英文版施工合同示范文本

Construction Contract工程合同PO No.: XXXXXXXBuyer:. Date of signature:甲方:签约日期：Seller:乙方:This Purchase Order is made by and between the Buyer and the Seller: Whereby the Buyer agrees to buy and the Seller agrees to sell the under mentioned commodity according to the terms and conditions stipulated below:甲乙双方经友好协商，一致就供应下列产品，达成如下条款：1. Scope of Supply and Price工作范围及价格明细2. Technical Requirement, Quality Requirement, Standard & Warranty Period:Seller shall carried out the construction in strict accordance with the National Standard and the requirements stipulated in the Technical Agreement No. ________which both party signed (see attached documents). The warranty period shall be 1 year after placement of Goods in service.技术要求、质量要求、技术标准和质保期限: 按国家标准和双方签定的技术协议（编号：______见附件）施工，质保期为投产后1年。

3. Job Sites:施工地点：4. Construction Equipment, Tools & Field Personnel Management:施工设备工具及现场人员管理：(1) All the construction equipment and tools shall be provided by Seller.所有施工用设备及工具由乙方自带。

中英文对照-工程施工合同范本(DOC8页)

工程施工合同合同编号( . )：签订日期( )：发包方（简称甲方）:承包方（简称乙方）：:根据《中华人民共和国合同法》以及其他有关法律法规规定的原则，结合本工程的具体情况，甲、乙双方在平等、自愿、协商一致的基础上达成如下协议，共同遵守。

“ ”,, .1.工程概况1.1工程名称：:1.2工程地点：:1.3工程范围：. 新研发中心和新厂房的网络综合布线系统的施工；. 数据中心的建设，主要包含：数据中心的装饰工程、电气系统、空调系统、机房闭路监控系统、机房门禁系统、消防系统改造、机柜系统等。

:. ;. Data Center, : , , , , , .1.4开工条件：合同生效后，甲方预付款到位和现场具备开工条件。

: , .1.5工程造价：合同工程总造价为￥元（），人民币大写：( ).详细合同价格表见附件报价清单。

.在详细设计和施工过程中，若工程量发生变化，按合同单价相应调整工程造价；若材质发生变化，按双方商定的补充协议调整工程造价。

, , ; , .2.付款方式2.1由乙方向甲方提供指定帐户、甲方以支票方式或银行转账方式向乙方结算合同款；, .2.2本合同生效后，甲方付给乙方合同总价的作为工程预付款，即￥元；, ;2.3数据中心及网络布线系统工程完工并且双方签订工程验收报告后天以内，甲方付给乙方合同总价的，即￥元；, .2.4工程竣工后个月内，甲方支付给乙方剩余的合同款，即￥元；, .3.双方职责3.1甲方职责：:. 及时以书面形式通知乙方本工程具备开工条件的时间;;. 协助乙方办理进驻施工现场所需人员证件、批件等有关手续；, ;. 为乙方提供现场工程办公室和足够的现场仓库；;. 积极协助乙方施工，协调施工时与各部门的配合，并负责提供工程所需的现场平面图及建筑结构图。

, , .. 及时按合同规定之付款进度向乙方支付工程款项。

3.2乙方职责：:. 乙方在工程开始前应组织有关人员研究和熟悉图纸，参与设计交底，安排施工总进度计划并提交给甲方；, , ;. 向甲方或项目监理提供所购各种产品、设备的技术资料，接受进场检验；, , , ;. 遵守甲方或监理方对施工现场的有关规定；;. 按时完成乙方所承担的施工任务，保证工程施工质量。

建筑施工合同中英文对照版本

xxx施工合同Construction Contract of xxxx发包方（甲方）xxxxParty A: xxxx承包方（乙方）xxxxParty B: xxxx本合同由如上列明的甲、乙双方按照《中华人民共和国合同法》、《建筑安装工程承包合同条例》以及国家相关法律法规的规定，结合本合同具体情况，于xx年x月x日在xx签订。

tract Law of the This contract is signed by the two Parties in xxxx on xxxx according to the “ConPeople’s Republic of China”, the “Regulation on Building and Installation Contracting Contract and other relevant national laws and regulations, as well as the specific nature of this project第一条总则Article 1 General Principles1.1合同文件Contract Documents本合同包含合同、展示、施工图纸、作法说明、招投标文件以及合同所指的其他文件，它们均被视为合同的一部分。

合同文件应该能够相互解释，互为说明。

组成本合同的文件及优先解释的顺序如下：本合同、中标通知书、投标书及其附件、标准、规范及有关技术文件、图纸、工程量清单及工程报价单或预算书。

合同履行中，发包人承包人有关工程的洽商、变更等书面下一或文件视为本合同的组成部分。

This contract includes the contract itself, exhibits, construction drawings, explanations ofwork procedures, tender documents, as well as other documents specified by the contract. The contract documents should be mutually explainable and mutually descriptive. The documents that constituted the contract and the priority hierarchy of explanations of the documents are as follows: this contract; the official letter of winning the tender; Letter of bidding and its annex, standards, guidelines, and relevant technical documents, drawings, Billof Quantity (BOQ), quotation of prices, and project budget. During the implementation of thecontract, any written agreements or documents between two parties such as change-ordersare also regarded will be deemed as part of this contract.1.1.1项目概况Project Introduction1.1.2工程名称：xxxxName of Project: xxxx1.1.3工程地点：xxxxLocation of Project: xxxx1.1.3.1工程范围：除了本合同其他条款另有说明外，乙方应提供为履行合同所需的所有服务，用品以及其他保障工程进行所需的必要花费以完成下列工作：Scope of the project: unless otherwise explained by other articles in this contract, Party Bshall provide all services, utensils, and other necessary cost for the implementation of this contract; the scope of project includes, but not limited to:※室内装饰工程，详见附件一和附件二Inner decoration, see appendix 1 & 2※室外装饰工程（门窗、屋面、台阶等），详见附件一和附件二Fa?ade(including doors, windows, roof and stairs) see appendix 1 & 2※电器工程，详见附件一和附件二Electronic Engineering, see appendix 1 & 2※空调工程，详见附件一和附件二Air Conditioning System, see appendix 1 & 2※给排水及采暖工程，详见附件一和附件二Water Supply, Sewage and Heating System, see appendix 1 & 2※消防工程Fire Control System, see appendix 1 & 2※其他图纸上所列项目（任何对原定设计的变更应提供新的图纸并有甲方的签字确认）以上所有的工程项目以下统称为“工程”。

建筑施工合同中英文对照.doc

建设工程施工合同发包方（甲方）xxxxParty A: xxxx承包方（乙方）xxxxParty B: xxxx本合同由如上列明的甲、乙双方按照《中华人民共和国合同法》、《建筑安装工程承包合同条例》以及国家相关法律法规的规定，结合本合同具体情况，于xx年x月x日在xx签订。

This contract is signed by the two Parties in xxxx on xxxx according to the “Contract Law of the People’s Republic of China”, the “Regulation on Building and Installation Contracting Contract”, and other relevant national laws and regulations, as well as the specific nature of this project第一条总则Article 1 General Principles1.1合同文件Contract Documents本合同包含合同、展示、施工图纸、作法说明、招投标文件以及合同所指的其他文件，它们均被视为合同的一部分。

合同文件应该能够相互解释，互为说明。

组成本合同的文件及优先解释的顺序如下：本合同、中标通知书、投标书及其附件、标准、规范及有关技术文件、图纸、工程量清单及工程报价单或预算书。

合同履行中，发包人承包人有关工程的洽商、变更等书面下一或文件视为本合同的组成部分。

This contract includes the contract itself, exhibits, construction drawings, explanations of work procedures, tender documents, as well as other documents specified by the contract. The contract documents should be mutually explainable and mutually descriptive. The documents that constituted the contract and the priority hierarchy of explanations of the documents are as follows: this contract; the official letter of winning the tender; Letter of bidding and its annex, standards, guidelines, and relevant technical documents, drawings, Bill of Quantity (BOQ), quotation of prices, and project budget. During the implementation of the contract, any written agreements or documents between two parties such as change-orders are also regarded will be deemed as part of this contract.1.1.1项目概况Project Introduction1.1.2工程名称：xxxxName of Project: xxxx1.1.3工程地点：xxxxLocation of Project: xxxx1.1.3.1工程范围：除了本合同其他条款另有说明外，乙方应提供为履行合同所需的所有服务，用品以及其他保障工程进行所需的必要花费以完成下列工作：Scope of the project: unless otherwise explained by other articles in this contract, Party B shall provide all services, utensils, and other necessary cost for the implementation of this contract; the scope of project includes, but not limited to:※室内装饰工程，详见附件一和附件二Inner decoration, see appendix 1 & 2※室外装饰工程（门窗、屋面、台阶等），详见附件一和附件二Façade(including doors, windows, roof and stairs) see appendix 1 & 2※电器工程，详见附件一和附件二Electronic Engineering, see appendix 1 & 2※空调工程，详见附件一和附件二Air Conditioning System, see appendix 1 & 2※给排水及采暖工程，详见附件一和附件二Water Supply, Sewage and Heating System, see appendix 1 & 2※消防工程Fire Control System, see appendix 1 & 2※其他图纸上所列项目（任何对原定设计的变更应提供新的图纸并有甲方的签字确认）以上所有的工程项目以下统称为“工程”。

建筑施工合同中英文对照版本

xxxx施工合同Construction Contract of xxxx发包方（甲方）xxxxParty A: xxxx承包方（乙方）xxxxParty B: xxxx本合同由如上列明的甲、乙双方按照《中华人民共和国合同法》、《建筑安装工程承包合同条例》以及国家相关法律法规的规定，结合本合同具体情况，于xx年x月x日在xx签订。

This contract is signed by the two Parties in xxxx on xxxx according to the “Contr act Law of the People’s Republic of China”, the “Regulation on Building and Installation Contracting Contract”, and other relevant national laws and regulations, as well as the specific nature of this project第一条总则Article 1 General Principles合同文件Contract Documents本合同包含合同、展示、施工图纸、作法说明、招投标文件以及合同所指的其他文件，它们均被视为合同的一部分。

合同文件应该能够相互解释，互为说明。

组成本合同的文件及优先解释的顺序如下：本合同、中标通知书、投标书及其附件、标准、规范及有关技术文件、图纸、工程量清单及工程报价单或预算书。

合同履行中，发包人承包人有关工程的洽商、变更等书面下一或文件视为本合同的组成部分。

This contract includes the contract itself, exhibits, construction drawings, explanations of work procedures, tender documents, as well as other documents specified by the contract. The contract documents should be mutually explainable and mutually descriptive. The documents that constituted the contract and the priority hierarchy of explanations of the documents are as follows: this contract; the official letter of winning the tender; Letter of bidding and its annex, standards, guidelines, and relevant technical documents, drawings, Bill of Quantity (BOQ), quotation of prices, and project budget. During the implementation of the contract, any written agreements or documents between two parties such as change-orders are also regarded will be deemed as part of this contract.1.1.1项目概况Project Introduction1.1.2工程名称：xxxxName of Project: xxxx1.1.3工程地点：xxxxLocation of Project: xxxx1.1.3.1工程范围：除了本合同其他条款另有说明外，乙方应提供为履行合同所需的所有服务，用品以及其他保障工程进行所需的必要花费以完成下列工作：Scope of the project: unless otherwise explained by other articles in this contract, Party B shall provide all services, utensils, and other necessary cost for the implementation of this contract; the scope of project includes, but not limited to:※室内装饰工程，详见附件一和附件二Inner decoration, see appendix 1 & 2※室外装饰工程（门窗、屋面、台阶等），详见附件一和附件二Fa?ade(including doors, windows, roof and stairs) see appendix 1 & 2※电器工程，详见附件一和附件二Electronic Engineering, see appendix 1 & 2※空调工程，详见附件一和附件二Air Conditioning System, see appendix 1 & 2※给排水及采暖工程，详见附件一和附件二Water Supply, Sewage and Heating System, see appendix 1 & 2※消防工程Fire Control System, see appendix 1 & 2※其他图纸上所列项目（任何对原定设计的变更应提供新的图纸并有甲方的签字确认）以上所有的工程项目以下统称为“工程”。

建筑施工合同中英文对照版本

xxxx施工合同Construction Contract of xxxx发包方（甲方）xxxxParty A: xxxx承包方（乙方）xxxxParty B: xxxx本合同由如上列明的甲、乙双方按照《中华人民共和国合同法》、《建筑安装工程承包合同条例》以及国家相关法律法规的规定，结合本合同具体情况，于xx年x月x 日在xx签订。

This contract is signed by the two Parties in xxxx on xxxx according to the “Contract Law of the People’s Republic of China”, the “Regulation on Building and Installation Contracting Contract”, and other relevant national laws and regulations, as well as the specific nature of this project第一条总则Article 1 General Principles1.1合同文件Contract Documents本合同包含合同、展示、施工图纸、作法说明、招投标文件以及合同所指的其他文件，它们均被视为合同的一部分。

合同文件应该能够相互解释，互为说明。

组成本合同的文件及优先解释的顺序如下：本合同、中标通知书、投标书及其附件、标准、规范及有关技术文件、图纸、工程量清单及工程报价单或预算书。

合同履行中，发包人承包人有关工程的洽商、变更等书面下一或文件视为本合同的组成部分。

This contract includes the contract itself, exhibits, construction drawings, explanations of work procedures, tender documents, as well as other documents specified by the contract. The contract documents should be mutually explainable and mutually descriptive. The documents that constituted the contract and the priority hierarchy of explanations of the documents are as follows: this contract; the official letter of winning the tender; Letter of bidding and its annex, standards, guidelines, and relevant technical documents, drawings, Bill of Quantity (BOQ), quotation of prices, and project budget. During the implementation of the contract, any written agreements or documents between two parties such as change-orders are also regarded will be deemed as part of this contract.1.1.1项目概况Project Introduction1.1.2工程名称：xxxxName of Project: xxxx1.1.3工程地点：xxxxLocation of Project: xxxx1.1.3.1工程范围：除了本合同其他条款另有说明外，乙方应提供为履行合同所需的所有服务，用品以及其他保障工程进行所需的必要花费以完成下列工作：Scope of the project: unless otherwise explained by other articles in thiscontract, Party B shall provide all services, utensils, and other necessary cost for the implementation of this contract; the scope of project includes, but not limited to:※室内装饰工程，详见附件一和附件二Inner decoration, see appendix 1 & 2※室外装饰工程（门窗、屋面、台阶等），详见附件一和附件二Fa?ade(including doors, windows, roof and stairs) see appendix 1 & 2※电器工程，详见附件一和附件二Electronic Engineering, see appendix 1 & 2※空调工程，详见附件一和附件二Air Conditioning System, see appendix 1 & 2※给排水及采暖工程，详见附件一和附件二Water Supply, Sewage and Heating System, see appendix 1 & 2※消防工程Fire Control System, see appendix 1 & 2※其他图纸上所列项目（任何对原定设计的变更应提供新的图纸并有甲方的签字确认）以上所有的工程项目以下统称为“工程”。

中英文对照工程施工合同模板协议模板.doc

建筑施工合同中英文对照版本

建设工程施工合同中英文对照版

施工合同中英文模板

施工合同中英文模板

中英文对照-工程施工合同范本-精选.docx

最新建设工程施工合同中英文翻译件范本

工程合同中英双语

中英文版施工合同：建筑施工合同中英文对照

建筑施工合同中英文对照

建筑施工合同中英文对照版本

施工合同中英文模板-construction-contract

建设工程施工合同中英文对照版

建设工程施工合同中英文对照版

中英文对照工程施工合同

(完整word版)中英文版施工合同示范文本

中英文对照-工程施工合同范本(DOC8页)

建筑施工合同中英文对照版本

建筑施工合同中英文对照.doc

建筑施工合同中英文对照版本

建筑施工合同中英文对照版本