国际承包工程合同中英完整版

合集下载

国际承包工程合同中英版

国际承包工程合同中英版在全球化的经济背景下，国际承包工程日益增多，涉及的合同也更加复杂。

一个明确、全面的合同能够为双方提供法律保障，避免不必要的纠纷。

以下是一份国际承包工程合同中英版范本，供大家参考。

甲方（业主）：________________乙方（承包商）：________________鉴于甲方拟建设________________项目（以下简称“项目”），并希望乙方承担该项目的建设工作；乙方愿意接受甲方的委托，承担该项目的建设工作。

现根据《中华人民共和国民法典》及相关法律法规的规定，甲乙双方在平等、自愿、公平、诚实信用的基础上，经友好协商，就乙方承担项目建设工作事宜达成如下协议：1. 项目描述：本项目位于________________，主要包括_______________等。

2. 工作范围：乙方应按照甲方提供的图纸和技术要求，完成项目的建设工作。

3. 合同价款：本项目的总价款为人民币______元整（大写：人民币______元整）。

4. 支付方式：甲方应按以下方式向乙方支付合同价款：________________。

5. 工期：乙方应于____年__月__日开始施工，并于____年__月__日竣工。

6. 质量保证：乙方应保证工程质量符合国家和行业的相关标准，并对所完成的工程提供__年的质量保证期。

7. 违约责任：如一方违反本合同的任何条款，应向另一方支付违约金，并赔偿由此给对方造成的损失。

8. 争议解决：如双方在本合同执行过程中发生争议，应首先通过友好协商解决；协商不成的，任何一方均有权将争议提交至____仲裁委员会进行仲裁。

9. 其他：本合同自双方签字盖章之日起生效，有效期至项目竣工验收合格之日止。

本合同一式两份，甲乙双方各执一份。

本合同未尽事宜，可由双方另行签订补充协议。

补充协议与本合同具有同等法律效力。

甲方（业主）：________________（盖章）乙方（承包商）：________________（盖章）日期：____年__月__日。

国际承包工程合同中英版

国际承包工程合同合同编号：__________本合同由以下双方于______年______月______日签订。

甲方：（以下简称“业主”）地址：____________________________代表：____________________________乙方：（以下简称“承包商”）地址：____________________________代表：____________________________鉴于甲方为某项工程（以下简称“工程”）的业主，并愿意委托乙方承担该工程的施工任务；鉴于乙方愿意承担该工程的施工任务，并保证按照约定的标准和质量完成工程；双方本着平等、自愿、公平、诚信的原则，经协商一致，达成如下协议：第一条工程概况1.1 工程名称：____________________1.2 工程地点：____________________1.3 工程规模：____________________1.4 工程内容：____________________第二条合同价格2.1 乙方向甲方提交的工程报价为人民币（大写）：____元整（小写）：_____元。

2.2 乙方应按照本合同约定的工程内容和质量标准，完成工程。

2.3 甲方应按照本合同约定的付款方式和付款时间，向乙方支付合同价款。

第三条工程质量3.1 乙方应按照约定的标准和质量要求完成工程。

3.2 工程质量的评定标准应按照_________________执行。

3.3 乙方应承担工程质量问题的修复和返工费用。

第四条工程进度4.1 乙方应按照本合同约定的工程内容和施工方案，保证工程按时完成。

4.2 工程进度计划的制定和调整应经过甲方同意。

4.3 乙方应承担因工程进度延误而产生的违约金。

第五条付款方式5.1 甲方应按照乙方完成的工程量和质量，向乙方支付合同价款。

5.2 甲方支付合同价款的方式为：____期支付____%。

5.3 乙方应按照甲方的要求，提供相关发票和财务报表。

国际工程合同范本英文

国际工程合同范本英文International Engineering ContractThis International Engineering Contract (the "Contract") is made and entered into as of [date] (the "Effective Date") and between:Party A:Name: [Party A's Name]Address: [Party A's Address]Contact Person: [Contact Person's Name]Telephone Number: [Telephone Number]Fax Number: [Fax Number]E Address: [E Address]Party B:Name: [Party B's Name]Address: [Party B's Address]Contact Person: [Contact Person's Name]Telephone Number: [Telephone Number]Fax Number: [Fax Number]E Address: [E Address]WHEREAS Party A desires to have certn engineering works performed and Party B has the necessary expertise and capabilities to undertake such works;NOW, THEREFORE, in consideration of the mutual covenants and agreements contned herein, the parties hereto agree as follows:1. Project DescriptionThe project (the "Project") consists of [describe the scope and nature of the engineering works].2. Project ScheduleParty B shall mence the Project on or before [mencement date] and plete the Project [pletion date], subject to any extensions as provided herein.3. Project Price and Payment TermsThe total price for the Project is [amount] (the "Project Price"). Party A shall make payments to Party B in accordance with the following schedule: [detl the payment terms and milestones]4. Quality and StandardsThe engineering works shall be performed in accordance with the applicable industry standards and specifications and to the satisfaction of Party A.5. Changes and AmendmentsAny changes or amendments to the scope of the Project, the Project Schedule, or the Project Price shall be made in writing and signed both parties.6. Warranties and GuaranteesParty B warrants that the engineering works will be free from defects in materials and workmanship for a period of [warranty period] from the date of pletion.7. Force MajeureNeither party shall be liable for any flure or delay in performing its obligations under this Contract to the extent such flure or delay is caused an event of force majeure.8. Dispute ResolutionAny disputes arising out of or in connection with this Contract shall be resolved through friendly negotiation. If negotiation fls, the dispute shall be submitted to arbitration in accordance with the rules of [arbitration institution].9. ConfidentialityBoth parties agree to keep confidential all information related to the Project and this Contract.10. Governing Law and JurisdictionThis Contract shall be governed and construed in accordance with the laws of [jurisdiction]. Any legal action arising out of or in connection with this Contract shall be brought in the courts of [jurisdiction].IN WITNESS WHEREOF, the parties hereto have executed this Contract as of the date first above written.Party A: [Signature and Seal]Party B: [Signature and Seal]Please note that the above is just a sample and should not be used without proper legal review and customization based on your specific circumstances.。

承包工程合同中英文

Contract for Contracted EngineeringThis Contract for Contracted Engineering (the "Contract") is made and entered into as of [Insert Date], by and between [Insert Contractor Name] ("Contractor"), a [insert contractor's legal entity type] organized and existing under the laws of [insert contractor's country of incorporation], with a principal place of business located at [insert contractor's address], and [Insert Client Name] ("Client"), a [insert client's legal entity type] organized and existing under the laws of [insert client's country of incorporation], with a principal place of business located at [insert client's address].1. Scope of Work1.1 The Contractor agrees to perform the following services (the "Services") for the Client: [Insert detailed description of services to be performed].1.2 The Services shall be performed in accordance with thespecifications and requirements set forth in the attached Exhibit A (the "Specifications"). The Contractor shall perform the Services with due diligence, care, and skill, in conformity with all applicable laws, regulations, and industry standards.2. Term and Termination2.1 The term of this Contract shall commence on the Effective Date and shall continue for [Insert Duration] (the "Term"). The Term may be extended by mutual written agreement of the parties.2.2 either party may terminate this Contract at any time for any reason or for no reason upon written notice to the other party.3. Payment3.1 The Client agrees to pay the Contractor the total consideration for the Services as set forth in the attached Exhibit B (the "Fee"). The Fee shall be paid in accordance with the payment schedule set forth inExhibit B.3.2 The Client shall be entitled to offset any amounts owed to the Contractor under this Contract against any amounts owed by the Client to the Contractor.4. Warranties and Representations4.1 The Contractor represents and warrants that it has the legal authority to enter into this Contract and to perform the Services.4.2 The Contractor represents and warrants that it will perform the Services in compliance with all applicable laws, regulations, and industry standards.4.3 The Client represents and warrants that it has the legal authority to enter into this Contract and to request the Services.5. Indemnification5.1 The Contractor shall indemnify and hold harmless the Client from any and all claims, damages, liabilities, losses, and expenses (including attorney's fees and costs) arising out of or in connection with the performance of the Services, except to the extent such claims, damages, liabilities, losses, and expenses are caused by the sole negligence or willful misconduct of the Client.5.2 The Client shall indemnify and hold harmless the Contractor from any and all claims, damages, liabilities, losses, and expenses (including attorney's fees and costs) arising out of or in connection with the performance of the Services, except to the extent such claims, damages, liabilities, losses, and expenses are caused by the sole negligence or willful misconduct of the Contractor.6. Confidentiality6.1 The Contractor and Client shall maintain in confidence and not disclose to any third party any Confidential Information (as defined below) obtained from the other party in connection with this Contract, except to the extent such Confidential Information is required to be disclosed by a court of competent jurisdiction or by operation of law.6.2 For purposes of this Contract, "Confidential Information" means any and all information, data, and materials disclosed by a party to the other party, whether orally, in writing, or in any other form, that is marked or identified as confidential or that a reasonable person would understand to be confidential.7. Miscellaneous7.1 This Contract constitutes the entire agreement between the parties with respect to the subject matter hereof and supersedes all prior agreements, understandings, negotiations, and discussions, whether oral or written, of the parties.7.2 This Contract may be amended or modified only by a written instrument executed by both parties.7.3 If any term, provision, covenant, or condition of this Contract is held by a court of competent jurisdiction to be invalid, void, or unenforceable, the remainder of the provisions shall remain in full force and effect and shall in no way be affected, impaired, or invalidated.7.4 This Contract shall be governed by and construed in accordance with the laws of [Insert Governing Jurisdiction].7.5 All disputes arising out of or in connection with this Contract shall be resolved by arbitration in accordance with the rules of the [Insert。

工程承包合同中英文

工程承包合同中英文工程承包合同是发包方（甲方）与承包方（乙方）之间就某一建设工程项目的实施所签订的法律文件。

该合同详细规定了工程的范围、质量要求、施工周期、价格条款以及双方的权利与义务等关键信息。

以下是一份简化的工程承包合同中英文范本的核心内容：---工程承包合同Construction Contract甲方（发包方）：__________arty A (Emloyer): __________乙方（承包方）：__________arty (Contractor): __________鉴于甲乙双方就[工程名称]项目达成一致，特此签订本合同。

Whereas arty A and arty have agreed to the [roject Name] roject, this contract is herey signed.第一条工程范围Article 1 Scoe of Work本工程包括但不限于以下内容：__________The work shall include, ut not e limited to: __________第二条工程质量Article 2 Quality of Work乙方须确保工程质量满足甲方要求及相关国家标准。

arty shall ensure that the quality of work meets arty A's requirements and relevant national standards.第三条施工周期Article 3 Construction eriod工程预计开工日期为____年____月____日，竣工日期为____年____月____日。

The exected commencement date of the roject is ____ Year ____ Month ____ Day, and the comletion date is ____ Year ____ Month ____ Day.第四条合同价款Article 4 Contract rice合同总价为人民币____元或其等值美元。

工程承包类合同中英

工程承包类合同中英---工程承包合同（Construction Contract）甲方（arty A）：_____________乙方（arty ）：_____________鉴于甲方拟委托乙方进行以下所述工程项目的施工，现双方遵循平等、自愿、公平和诚信的原则，根据相关法律法规的规定，经友好协商一致，订立本合同如下：第一条工程概述（roject Overview）1.1 工程名称：______________________1.2 工程地点：______________________1.3 工程内容：______________________1.4 工程规模：______________________1.5 工程质量要求：____________________第二条合同价格与支付方式（Contract rice and ayment Method）2.1 合同总价为人民币____________元或美元____________USD。

2.2 支付方式：________________________________________2.3 支付时间：________________________________________第三条工期与竣工（Construction eriod and Comletion）3.1 开工日期：____年____月____日3.2 竣工日期：____年____月____日3.3 如遇不可抗力因素导致工期延误，应及时通知对方并商定处理办法。

第四条质量要求与验收（Quality Requirements and Accetance）4.1 乙方必须按照国家及行业标准和规范执行，保证工程质量达到约定的标准。

4.2 工程完成后，由甲方组织验收，验收合格后视为工程交付完成。

第五条违约责任（Liaility for reach of Contract）5.1 双方应严格履行合同义务，任何一方违约均应承担相应的违约责任。

国际承包工程合同(中英完整版)

Contract for Works of Civil Engineering Construction土木工程施工合同This CONTRACT is made on the _th of_(month), _(year) by and between_(hereinafter called “Party A”) of the one part, and _(hereinafter called “Party B”) of the other part._公司（以下简称“雇主”）与_公司（以下简称“承包商”）于_年_月_日特签订本合同。

WHEREAS 鉴于。

…NOW THEREFORE THIS CONTRACT WITNESSETH that it is hereby agreed by and between the parties hereto as follows:双方达成协议如下：civil engineering 土木工程Chapter 1 Definitions and InterpretationArticle 1 DefinitionsIn the Contract (as hereinafter defined) the following words and expressions shall have the meanings hereby assigned to them, except where the context other requires:第一条定义本合同（按下文所定义的）中的下列词和用语，除文中另有要求者外，应具有本条所赋予的含义：1.1“employer” means the person named as such in this contract and the legalsuccessors in title to such person, but not (except with the consent of the Contractor) any assignee of such person.1.1“雇主”是指本合同所指明的当事人以及取得当事人资格的合法继承人，但除非承包商同意，不包括此当事人的任何受让人，本合同中的雇主为_(填入名称)。

国际工程项目施工分包合同中英文

国际工程项目施工分包合同（中英文）CONTRACT OF SUBPROJECT EXECUTION 本合同系中译英翻译：张云军Translated from Chinese to English by Mr. Chang Yunejune.签署日期：Date of Signature :总包商：General Contractor分包商：Subcontractor电气机械承包公司（以下简称总包商），和工程施工公司（以下简称分包商），于＿＿订立本分包合同。

鉴于总包商已同利比亚国大型电气项目管理局（以下简称业主），就电气机械承包工程项目的设计，运输和施工签订了合同；鉴于分包商愿按该合同实施土建和安装工程而报了价；鉴于总包商已接受分包商的报价，并依据分包商所附的报价表，现双方达成协议如下：This contract is made and entered into on , between Electrical Machine Contracting Company (hereinafter referred to as general contractor) and Engineering Company (hereinafter referred to as subcontractor). WHEREAS general contractor has concluded contract, with Libyan National Authority of Large Electrical Project (hereinafter referred to as employer ), of the design, transportation and execution of the contracted project of electrical machine installation;WHEREAS subcontractor is willing to execute the project of civil engineering and installation and made quotation thereon;WHEREAS general contractor has accepted subcontractor’s quotation;NOW THEREFORE parties hereto, as per subcontractor’s quotation, hereby covenant and agree as follows:（一）下列文件应是本分包协议的组成部分：Following documents is the integral parts of this subcontracting contract.１．电气、机械及技术操作的合同通用条款（1980年第一版）；General Provisions on Electrical / Machine and Technical Operation ( First version 1980);２．合同的特殊条款；Particular Provisions of Contract;３．电气机械工程项目的技术规范；Technical Norms of Project of Electrical / Machine;４．工作范围和技术要求；Contents and Technical Requirements for Project;５．土建和安装工程分包合同的报价表。

国际土木工程建筑承包合同(中英文对照)

国际土木工程建筑承包合同（中英文对照）International Civil Engineering and Construction Contract（中英文对照）1.背景为了实现国际土木工程建筑承包合同的良好执行和管理，特制订本合同。

本合同适用于各种大规模土木建筑工程。

2.定义2.1甲方：指业主或甲方委派的其他代表机构。

2.2乙方：指承包商或乙方委派的其他代表机构。

2.3工程：指甲方委托乙方进行的土木建筑工程。

2.4设计文件：指甲方提供的工程设计、施工图以及其他的相关文件。

2.5标的物：指工程中的物质、设备、设施、建筑物等。

3.委托3.1乙方按照甲方的要求，承担工程的设计、施工、材料采购、设备租赁、运输、安装、调试、试运行等任务。

若有必要，乙方可以委托第三方承担部分或全部任务，但乙方应对承包前的审查及所委托的第三方行为承担全部责任。

3.2乙方不会依据本合同修改甲方提供的设计文件，也不能擅自更改，除非经甲方书面批准。

4.工期4.1合同项下的工程计划将在合同签订后得到制定并以书面形式送交甲方。

乙方在计划实施期间应在任何时间内保证工程按期完工。

4.2若乙方不能按期完工，乙方应向甲方提前一段时间进行书面通知。

此时，甲方可以选择终止本合同。

5.工程造价5.1工程造价包括所有改善、调整和整理前的全部费用。

5.2付款的准确性和即时性至关重要。

甲方按合同规定时间向乙方支付费用。

5.3工程验收结束后，任何由乙方未支付的费用将在合同下注明的时间上按日计算利息，并应由乙方支付。

6.质保和维护6.1合同项下的工程施工完成后，乙方应向甲方交付完整的用户手册和保修计划。

乙方必须对工程进行质保和维护，时间为乙方向甲方提交用户手册之日起至质保期满为止。

6.2甲方有权检查、审核、测试或验收乙方所提供的材料、设备、产品或者服务。

乙方必须尽到其义务，协助甲方进行上述活动。

7.变更7.1若工程发生了变化或必要的修正，甲、乙双方应在书面形式下进行调整，并应就在装置或提供方面所做的任何变化进行重新评估，并以书面形式确认。

国际土木工程建筑承包合同（中英文对照）_合同范本

国际土木工程建筑承包合同（中英文对照）part工general conditions第一章总则definitions and interpretation定义和释义1.（1）in the contract，as hereinafter defined，the following words and expressions shall have the meanings hereby assigned to them，except where the context otherwise requires：1.1在本中，除按上下文另具意义者外，下列词语应解释如下：（a）'employer' means the party named in part ii who will employ the contractor and the legal successors in title to the employer，but not，except with the consent of the contractor，any assignee of the employer.“业主”指第二章中所指定的雇用承包人的一方或其权利继承人，但不包括业主的受让人，经承包人同意者除外。

（b）“contractor”means the person or persons，firm or company whose tender has been accepted by the employerand includes the contractor’s personal r epresentatives，successors and permitted assigns.“承包人”指标书已被业主接受的某个或某些人、商行或公司，包括其个人代表，继承人和业经认可的受让人。

（c）“engineer”means the engineer designated as such in part ii，or other engineer appointed from time to time by the employer and notified in writing to the contractor to act as engineer for the purposes of the contract in place of the engineer、designated.“工程师”指第二章中所指定的工程师，或由业主随时任命且书面通知承包人以代替指定工程师履行合同职责的其他工程师。

国际土木工程建筑承包合同(中英文对照)

国际土木工程建筑承包合同（中英文对照）PART工GENERAL CONDITIONS第一章总则DEFINITIONS AND INTERPRETATION定义和释义1．（1）In the Contract，as hereinafter defined，the following words and expressions shall have the meanings hereby assigned to them，except where the context otherwise requires：1．1在本合同中，除按上下文另具意义者外，下列词语应解释如下：（a）'Employer' means the party named in Part II who will employ the Contractor and the legal successors in title to the Employer，but not，except with the consent of the Contractor，any assignee of the Employer．“业主”指第二章中所指定的雇用承包人的一方或其权利继承人，但不包括业主的受让人，经承包人同意者除外。

（b）“Contractor”means the person or persons，firm or company whose tender has been accepted by the Employerand includes the Contractor’s personal representatives，successors and permitted assigns．“承包人”指标书已被业主接受的某个或某些人、商行或公司，包括其个人代表，继承人和业经认可的受让人。

（c）“Engineer”means the Engineer designated as such in Part II，or other Engineer appointed from time to time by the Employer and notified in writing to the Contractor to act as Engineer for the purposes of the Contract in place of theEngineer、designated．“工程师”指第二章中所指定的工程师，或由业主随时任命且书面通知承包人以代替指定工程师履行合同职责的其他工程师。

工程承包合同中英文

工程承包合同中英文甲方（发包方）：[甲方名称]乙方（承包方）：[乙方名称]第一条工程概况1.1 工程名称：[工程名称]1.2 工程地点：[工程地点]1.3 工程内容：[工程内容]1.4 工程期限：自[开始日期]至[结束日期]Article 1 Project Overview1.1 Project Name: [Name of the Project]1.2 Project Location: [Location of the Project]1.3 Project Content: [Content of the Project]1.4 Project Duration: From [Start Date] to [End Date]第二条工程价款2.1 工程总价款为[金额]，包括但不限于材料费、人工费、管理费等。

2.2 工程价款的支付方式为：[支付方式描述]。

Article 2 Project Price2.1 The total project price is [Amount], including but not limited to material costs, labor costs, management fees, etc.2.2 The payment method for the project price is: [Descriptionof Payment Method].第三条工程质量3.1 乙方应按照国家及行业标准进行施工，确保工程质量。

3.2 工程验收标准按照[验收标准]执行。

Article 3 Project Quality3.1 The Contractor shall carry out construction in accordance with national and industry standards to ensure project quality.3.2 The project acceptance standards shall be implemented according to [Acceptance Standards].第四条双方责任4.1 甲方负责提供工程所需的场地、水电等条件。

国际工程合同英汉对照阅读

国际工程合同英汉对照阅读篇一：xxx工程合同中英文版xxx engineering contractxxx工程合同Contract No.: 合同编号：Party A: xxxCompany Limited甲方：xxx有限公司 Party B:xxx Company Limited乙方：xxx有限公司This contract is made and entered into on the day of , XX by the following Parties in . 本合同于XX年月日由以下当事方在签署。

Party A: xxx Company Limited,甲方：xxx有限公司，xxx经营的公司，住所地为xxx，（下称“甲方”），法定代表人：xxx Party B: xxx Company Limited,乙方：xxx有限公司，一家xxx经营的公司，注册地址是：xxx，（下称“乙方”），法定代表人：xxx Party A and Party B are called by a joint name of Both Parties under this contract, each of which is called as A Party.甲方和乙方在本合同项下统称为“双方”，单独称为“一方”。

1. 1.In accordance with the items stipulated in this Contract, Party B shall conduct the project as per the Projectstandard and quality standard stipulated by Ministry of Engineering of the Union of xx. 依据本合同所限定的条款，乙方应以xx工程部规定的建筑标准和质量要求执行本工程。

2. 2.Work period for the Road Construction Project: the work shall be completed within 2 month upon signing the Contract. The condition of handover is that the Project Inspection & Acceptance Team constituted by Party A, shall issue the Inspection & Acceptance Sheet after onsite inspection.本次工程时间周期：合同签订后14个工作日内完成，并以甲方组成的竣工验收小组现场检验并出具验收单为竣工交接条件。

（完整）FIDIC国际合同条款中英文对照.doc

（完整）FIDIC国际合同条款中英文对照.docCONTENTS目录1General Provisions一般规定 (5)1.1Definitions定义 (5)1.2Interpretation解释 (10)1.3Communications通信交流 (11)1.4Law and Language法律和语言 (12)1.5Priority of Document文件优先次序 (12)1.6Contract Agreement合同协议书 (12)1.7Assignment权益转让 (13)1.8Care and Supply of Document文件的照管和提供 (13)1.9Confidentiality保密性 (14)1.10Employer’s Use of Contractor’s Documents雇主使用承包商文件 (14)1.11Contractor’s Use of Employer’s Documents承包商使用雇主文件 (15)1.12Confidential Details保密事项 (15)1.13Compliance with Laws遵守法律 (15)1.14Joint and Several Liability共同的和各自的责任 (16)2The Employer雇主 (16)2.1Right of Access to the Site现场进入权 (16)2.2Permits, Licences or Approves许可、执照或批准 (17)2.3Employer’s personnel雇主人员 (18)2.4Employer’s Financial Arrangements雇主的资金安排 (18)2.5Employer’s Claims雇主的索赔 (18)3The Employer’s Administration雇主的管理 (19)3.1The Employer’s Representative雇主代表 (19)3.2The Employer’s personnel其他雇主人员 (20)3.3Delegated Persons受托人员 (20)3.4Instructions指示 (21)3.5Determinations确定 (21)4The Contractor承包商 (21)4.1The Contractor’s General Obligations承包商的一般义务(22)4.2Performance security履约担保 (22)4.3Contractor’s Representative承包商代表 (23)4.4Subcontractors分包商 (24)4.5Nominated Subcontractors指定的分包商 (25)4.6Co-operation合作 (25)4.7Setting out放线 (26)4.8Safety procedures安全程序 (26)4.9Quality Assurance质量保证 (27)4.10Site Data现场数据 (27)4.11Sufficiency of the Contract Price合同价格 (28)4.12Unforeseeable Difficulties不可预见的困难 (28)4.13Rights of way and Facilities道路通行权于设施 (28)4.14Avoidance of Interference避免干扰 (29)4.15Access Route进场通路 (29)4.16Transport of Goods货物运输 (30)4.17Contractor’s Equipment承包商设备 (30)4.18Protection of the Environment环境保护 (30)4.19Electricity, Water and Gas电、水和燃气 (31)4.20Employer’s Equipment and Free-Issue Material雇主设备和免费供应的材料 (31)4.21Progress Reports进度报告 (32)4.22Security of the Site现场保安 (33)4.23Contractor’s Operations on Site承包商的现场作业 (34)4.24Fossils化石 (34)5Design设计 (35)5.1General Design Obligations设计义务一般要求 (35)5.2Contractor’s Documents承包商文件 (36)5.3Contractor’s Undertaking承包商的承诺 (37)5.4Technical Standards and Regulations技术标准和法规 (37)5.5Training培训 (38)5.6As-Built Documents竣工文件 (38)5.7Operation and Maintenance Manuals操作和维修手册 (39)5.8Design Error设计错误 (39)6Staff and Labour员工 (39)6.1Engagement of Staff and Labour员工的雇用 (40)6.2Rates of Wages and Conditions of Labour工资标准和劳动条件 (40)6.3Persons in the Service of Employer为雇主服务的人员 (40)6.4Labour Laws劳动法 (40)6.5Working Hours工作时间 (41)6.6Facilities for Staff and Labour为员工提供设施 (41)6.7Health and Safety健康和安全 (41)6.8Contractor’s Superintendence承包商的监督 (42)6.9Contractor’s Personnel承包商人员 (42)6.10Records of contractor’s Personnel and Equipment承包商人员和设备的记录 (43)6.11Disorderly Conduct无序行为 (43)7Plant, Materials and Workmanship生产设备、材料和工艺 (43)7.1Manner of Execution实施方法 (43)7.2Samples样品 (44)7.3Inspection检验 (44)7.4Testing试验 (45)7.5Rejection拒收 (46)7.6Remedial Work修补工作 (46)7.7Ownership of Plant and Materials生产设备和材料的所有权(47)7.8Royalties土地(矿区)使用费 (47)8Commencement,Delays and Suspension开工、延误和暂停(48)8.1Commencement of Works工程的开工 (48)8.2Time for Completion竣工时间 (48)8.3Programme进度计划 (49)8.4Extension of Time for Completion竣工时间延长 (50)8.5Delays Caused by Authorities当局造成的延误 (50)8.6Rate of Progress工程进度 (51)8.7Delay Damages误期损害赔偿费 (51)8.8Suspension of Work暂时停工 (52)8.9Consequences of Suspension暂停的后果 (52)8.10Payment for Plant and Materials in Event of Suspension 暂停时对生产设备和材料的付款 (53)8.11Prolonged Suspension托长的暂停 (53)8.12Resumption of Work复工 (53)9Tests on Completion竣工试验 (54)9.1Contractor’s Obligations承包商的义务 (54)9.2Delayed Tests延误的试验 (55)9.3Retesting重新试验 (55)9.4Failure to Pass Tests on Completion未能通过竣工试验 (56)10Employer’s Taking Over雇主的接收 (56)10.1Taking Over of the Works and Sections工程和分项工程的接收 (56)10.2Taking Over of Parts of the Works部分工程的接收 (57)10.3Interference with Tests on Completion对竣工试验的干扰(57)11Defects Liability缺陷责任 (58)11.1Completion of Outstanding Work and Remedying Defects完成扫尾工作和修补缺陷 (58)11.2Cost of Remedying Defects修补缺陷的费用 (59)11.3Extension of Defects Notification Period缺陷通知期的延长 (59)11.4Failure to Remedy Defects未能修补的缺陷 (60)11.5Removal of Defective Work移出有缺陷的工程 (60)11.6Further Tests进一步试验 (61)11.7Right of Access进入权 (61)11.8Contractor to Search承包商调查 (61)11.9Performance Certificate履约证书 (62)11.10Unfulfilled Obligations未履行的义务 (62)11.11Clearance of Site现场清理 (62)12Tests after Completion竣工后试验 (63)12.1Procedure for Tests after Completion竣工后试验的程序(63)12.2Delayed Tests延误的试验 (64)12.3Retesting重新试验 (64)12.4Failure to Pass Tests after Completion未能通过的竣工后试验 (65)13Variations and Adjustments变更和调整 (66)13.1Right to Vary变更权 (66)13.2Value Engineering价值工程 (66)13.3Variation Procedure变更程序 (66)13.4Payment in Applicable Currencies以适用货币支付 (67)13.5Provisional Sums暂列金额 (67)13.6Daywork计日工作 (68)13.7Adjustments for Changes in Legislation因法律改变的调整(69)13.8Adjustments for Changes in Cost因成本改变的调整 (70)14Contract price and Payment合同价格和支付 (70)14.1The Contract Price合同价格 (70)14.2Advance payment预付款 (70)14.3Application for Interim Payments期中付款的申请 (72)14.4Schedule of Payments付款价格表 (73)14.5Plant and Materials intended for the Works拟用于工程的生产设备和材料 (73)14.6Interim Payments期中付款 (74)14.7Timing of Payments付款的时间安排 (74)14.8Delayed Payment延误的付款 (75)14.9Payment of Retention Money保留金支付 (75)14.10Statement at Completion施工报表 (76)14.11Application for Final Payment最终付款的申请 (76)14.12Discharge结清证明 (77)14.13Final Payment最终付款 (77)14.14Cessation of Employer’s Liability雇主责任的中止 (78)14.15Currencies of Payment支付的货币 (78)15Termination by Employer由雇主终止 (79)15.1Notice to Correct通知改正 (79)15.2Termination by Employer由雇主终止 (79)15.3Valuation at Date of Termination终止日期时的估价 (81)15.4Payment after Termination终止后的付款 (81)15.5Employer’s Entitlement to Termination雇主终止的权利(82)16Suspension and termination by Contractor承包商暂停和终止 (82)16.1Contractor’s Entitlement to Suspend Work承包商暂停工作的权利 (82)16.2Termination by Contractor由承包商终止 (83)16.3Cessation of Work and Removal of Contractor’sEquipment停止工作和承包商设备的撤离 (84)16.4Payment on Termination终止时的付款 (84)17Risk and Responsibility风险和职责 (85)17.1Indemnities保障 (85)17.2Contractor’s Care of the Works承包商对工程的照管 (86)17.3Employer’s Risks雇主的风险 (87)17.4Consequence of Employer’s Risks雇主风险的后果 (87)17.5Intellectual and Industrial Property Rights知识产权和工业产权 (88)17.6Limitation of Liability责任限度 (89)18Insurance保险 (89)18.1General Requirements for Insurances有关保险的一般要求(89)18.2Insurance for Works and Contractor’s Equipment工程和承包商设备的保险 (91)18.3Insurance against Injury to Persons and Damage to Property人身伤害和财产损害险 (93)18.4Insurance for Contractor’s Personnel承包商人员的保险(94)19Force Majeure不可抗力 (94)19.1Definition of Force Majeure不可抗力的定义 (95)19.2Notice of Force Majeure不可抗力的通知 (96)19.3Duty to Minimise Delay将延误减至最小的义务 (96)19.4Consequences of Force Majeure不可抗力的后果 (96)19.5Force Majeure Affecting Subcontractor不可抗力影响分包商 (97)19.6Optional Termination, Payment and Release自主选择终止、支付和解除 (97)19.7Release from Performance under the Law根据法律解除履约 (98)20Claims, Disputes and Arbitration索赔、争端和仲裁 (98)20.1Contractor’s Claims承包商的索赔 (99)20.2Appointment of the Dispute Adjudication Board争端裁决委员会的任命 (100)20.3Failure to Agreement Dispute Adjudication Board对争端裁决委员会未能取得一致时 (102)20.4Obtaining Dispute Adjudication Board’s Decision取得争端裁决委员会的决定 (102)20.5Amicable Settlement友好解决 (103)20.6Arbitration仲裁 (104)20.7Failure to Comply with Dispute Adjudication Board’s Decision未能遵守争端裁决委员会的决定 (105)20.8Expiry of Dispute Adjudication Board’s Appointment争端裁决委员会任命期满 (105)1General Provisions一般规定1.1Definitions定义In the Conditions of Contract (“these Conditions”), which include Particular Conditions and these General Conditions, the following words and expressions shall have the meaning stated. Words indicating persons or parties includecorporation and other legal entities, except where the context requires otherwise.在合同条件（“本条件”），包括专用条件和通用条件中，下列词语和措辞应具有以下所述的含义.除上下文另有要求外，文中人员或当事各方等词语包括公司和其他合法实体.1.1.1The Contract合同1.1.1.1“Contract” means the Contract Agreement, theseConditions, the Employer’s Requirement, the Tender, and further document (if any) which are listed in the Contract Agreement.“合同”系指合同协议书、本条件、雇主要求、投标书和合同协议书列出的其他文件（如果有）.1.1.1.2“Contract Agreement” means the contract agreement referred to in Sub-Clause 1.6 [Contract Agreement], including any annexed memoranda.“合同协议书”系指第1.6款[合同协议书]中所述的合同协议书及所附各项备忘录.1.1.1.3“Employer’s requirements” means the document entitled employer’s requirements, as inclu ded in the Contract, and any additions and modifications to such document in accordance with the Contract. Such document specifies the purpose, scope, and/or design and/or other technical criteria, for the Works.“雇主要求”系指合同中包括的，题为雇主要求的文件，其中列明工程的目标、范围、和（或）设计和（或）其他技术标准，以及按合同对此项文件所作的任何补充和修改.1.1.1.4“Tender” means the Contractor’s signed offer for the Works and all other documents which the Contractor submitted therewith (other than these Conditions and Employer’s Requiremen ts, if so submitted), as included in the Contract.“投标书”系指包含在合同中的由承包商提交的为完成工程签署的报价，以及随同提交的所有其他文件（本条件和雇主要求除外，如同时提交）.1.1.1.5“Performance Guarantees” and “Schedule of payments” mean the documents so named (if any), as included in the Contract.“履约保证”和“付款计划表”系指合同中包括的具有上述名称的文件（如果有）.1.1.2Parties and Persons各方和人员1.1.2.1“Party” means the Employer or the Contractor, as the context requires.“当事方（或一方）”根据上下文需要，或指雇主，或指承包商。

fidic工程合同模板中英

fidic工程合同模板中英这是小编精心编写的合同文档，其中清晰明确的阐述了合同的各项重要内容与条款，请基于您自己的需求，在此基础上再修改以得到最终合同版本，谢谢！标题：fidic工程合同模板（中英）一、前言本合同模板是根据国际咨询工程师联合会（FIDIC）的相关规定，结合我国实际情况，为工程建设项目量身定制的中英双语合同。

本合同旨在明确双方的权利、义务和责任，确保工程项目的顺利进行。

二、合同主体1. 承包商：（全称，以下简称“乙方”）2. 业主：（全称，以下简称“甲方”）三、合同条款1. 工程范围（1）乙方按照甲方提供的工程图纸、技术规范和施工要求，承担以下工程：1）土建工程；2）安装工程；3）调试工程；4）其他配套工程。

（2）乙方应按照合同约定的时间、质量、安全等要求，完成上述工程。

2. 合同价格（1）合同价格采用固定总价方式，包括但不限于设计、施工、材料、设备、劳务、管理、税费、利润等一切费用。

（2）合同价格的具体金额为：（大写：人民币元整；小写：￥元）。

3. 工期（1）合同工期为（年/月/日）至（年/月/日），共计（天）。

（2）乙方应按照合同约定的工期完成工程，如因乙方原因造成工期延误，乙方应承担相应的违约责任。

4. 付款方式（1）合同签订后，甲方支付乙方合同总价款的（%）作为预付款。

（2）工程进度达到（%）时，甲方支付乙方合同总价款的（%）。

（3）工程竣工验收合格后，甲方支付乙方合同总价款的（%）。

（4）工程保修期满，甲方支付乙方合同总价款的（%）。

（5）剩余（%）的款项，按照双方约定的质量保证金返还方式进行支付。

5. 违约责任（1）如乙方未按照合同约定完成工程，应承担违约责任，向甲方支付违约金，违约金计算方式为：（）。

（2）如甲方未按照合同约定支付款项，应承担违约责任，向乙方支付违约金，违约金计算方式为：（）。

6. 争议解决（1）双方在履行合同过程中发生的争议，应首先通过友好协商解决。

国际工程合同中英

国际工程合同中英---合同标题：International Engineering roject Contract合同编号：[合同编号]甲方（业主）名称：[甲方全称]地址：[甲方地址]乙方（承包商）名称：[乙方全称]地址：[乙方地址]签约日期：[签约日期]工程地点：[工程地点]I. 引言本合同由甲方（以下简称“业主”）与乙方（以下简称“承包商”）根据平等互利的原则订立，目的在于规定双方关于[具体工程名称]的建设和管理的权利、义务及责任。

II. 工程描述本合同所涉及的工程内容、规模、技术要求、工期等详细信息如下：1. 工程内容： [详细描述工程的性质、规模、位置等]2. 技术要求： [列出工程的技术标准和规范]3. 工期： [明确工程的开始和完成日期]4. 质量控制： [规定工程质量的标准和验收程序]III. 价格条款1. 合同总价： [合同金额]2. 支付方式： [详细描述支付条件、时间和方式]3. 价格调整： [如有必要，说明价格调整的条件和程序]IV. 施工期限1. 开工日期： [具体日期]2. 竣工日期： [具体日期]3. 延期条款： [规定延期的责任、通知和赔偿等]V. 质量保证1. 保证期限： [明确质量保证的时间范围]2. 维护责任： [详细说明维护的责任方和维护措施]VI. 违约责任1. 违约定义： [明确什么情况下构成违约]2. 责任承担： [违约方应承担的责任和后果]VII. 争议解决1. 适用法律： [指定适用的法律和仲裁规则]2. 解决方式： [优先采用协商，其次是仲裁或诉讼]VIII. 其他条款1. 保密协议： [对商业秘密和技术信息的保护]2. 变更和补充： [合同变更和补充的程序]3. 终止条件： [合同提前终止的条件和处理方式]IX. 签字页本合同一式两份，甲乙双方各执一份，自双方代表签字盖章之日起生效。

甲方代表：_________________ (签字) 日期：____年____月____日乙方代表：_________________ (签字) 日期：____年____月____日---。