技术合同英文标准范本
英文技术开发合同6篇
英文技术开发合同6篇篇1Technical Development AgreementThis Technical Development Agreement (the "Agreement") is entered into as of [Date], by and between [Company Name], having its principal place of business at [Address] (the "Company"), and [Developer Name], having its principal place of business at [Address] (the "Developer").BackgroundThe Company is engaged in the business of [Brief description of Company's business], and the Developer possesses certain technical expertise in [Brief description of Developer's technical expertise].The Company wishes to engage the Developer to provide technical development services as described herein, and the Developer wishes to provide such services under the terms and conditions set forth in this Agreement.Agreement1. Scope of Services. The Developer shall provide technical development services to the Company as requested by the Company from time to time. The services to be provided by the Developer may include, but are not limited to, [Description of services to be provided].2. Compensation. The Company shall compensate the Developer for the services provided under this Agreement at the rate of [Rate] per hour. The Developer shall submit invoices to the Company on a [Weekly/Monthly] basis for payment.3. Term. This Agreement shall commence on the date first written above and shall continue until terminated by either party upon [Number] days' written notice.4. Confidentiality. The Developer agrees to keep all information and materials provided by the Company confidential and not to disclose such information to any third party without the Company's prior written consent.5. Intellectual Property. Any intellectual property created by the Developer in connection with the services provided under this Agreement shall belong to the Company, and the Developer hereby assigns all rights, title, and interest in and to such intellectual property to the Company.6. Termination. Either party may terminate this Agreement at any time for any reason upon [Number] days' written notice. Upon termination, the Developer shall cease providing services to the Company, and the Company shall compensate the Developer for services rendered up to the date of termination.7. Governing Law. This Agreement shall be governed by and construed in accordance with the laws of the State of [State].In Witness Whereof, the parties hereto have executed this Agreement as of the date first written above.[Company Name]By: ___________________________ Name: Title:[Developer Name]By: ___________________________ Name: Title:This Agreement constitutes the entire agreement between the parties with respect to the subject matter hereof and supersedes all prior agreements and understandings, whether written or oral, relating to such subject matter. This Agreement may be amended only by a written instrument signed by both parties.IN WITNESS WHEREOF, the parties have executed this Agreement as of the date first written above.[Company Name]By: __________________________ Name: Title:[Developer Name]By: __________________________ Name: Title:篇2Technical Development AgreementThis Technical Development Agreement (the "Agreement") is entered into as of [Date] by and between [Company Name], a [Company Type] organized and existing under the laws of [Jurisdiction], with its principal office located at [Company Address] (hereinafter referred to as "Company") and [Developer Name], an individual residing at [Developer Address] (hereinafter referred to as "Developer").WHEREAS, Company desires to engage Developer for the development of certain technical products and services as further described in Exhibit A attached hereto (the "Project"); andWHEREAS, Developer has the necessary expertise and resources to undertake the development of the Project in accordance with Company's specifications;Now, therefore, in consideration of the premises and mutual covenants contained herein, the parties hereto agree as follows:1. Services. Developer shall perform the development services for the Project as described in Exhibit A in a professional and timely manner, using commercially reasonable efforts to meet the milestones and deadlines set forth therein.2. Compensation. In consideration for the services provided by Developer under this Agreement, Company shall pay Developer a total fee of [Total Fee]. Payment shall be made in installments as set forth in Exhibit B attached hereto.3. Ownership. All intellectual property rights, including but not limited to copyrights, patents, trademarks, and trade secrets, developed by Developer in the course of performing the services under this Agreement shall belong exclusively to Company. Developer hereby assigns to Company all rights, titles, and interests in and to such intellectual property rights.4. Confidentiality. Developer shall keep confidential all information related to the Project and shall not disclose suchinformation to any third parties without the prior written consent of Company. This confidentiality obligation shall survive the termination of this Agreement.5. Term and Termination. This Agreement shall commence on the effective date set forth above and shall continue until the completion of the Project unless terminated earlier by either party upon thirty (30) days' written notice. In the event of termination, Company shall pay Developer for the services performed up to the date of termination.6. Governing Law. This Agreement shall be governed by and construed in accordance with the laws of [Jurisdiction]. Any disputes arising out of or related to this Agreement shall be resolved through arbitration in [Arbitration Location] in accordance with the rules of the American Arbitration Association.7. Entire Agreement. This Agreement constitutes the entire agreement between the parties with respect to the subject matter hereof and supersedes all prior agreements, understandings, and negotiations, whether oral or written.IN WITNESS WHEREOF, the parties hereto have executed this Agreement as of the date first above written.[Company Name] [Developer Name]_________________________ _________________________Company Signature Developer SignatureExhibit A - Project DescriptionExhibit B - Payment ScheduleThis is a sample Technical Development Agreement for reference purposes only. It is recommended that you consult with legal professionals to draft a customized agreement that meets your specific needs and requirements.篇3Technology Development ContractThis Technology Development Contract (the "Contract") is made and entered into as of [Insert Date], (the "Effective Date") by and between [Company Name], a corporation organized and existing under the laws of the [state/country], with its principal place of business located at [Company Address] (the "Developer"), and [Company Name], a corporation organized and existing under the laws of the [state/country], with its principal place of business located at [Company Address] (the "Client").1. Scope of WorkThe Developer agrees to provide technical development services to the Client in accordance with the specifications set forth in the Statement of Work (the "SOW") attached hereto as Exhibit A. The SOW shall include a description of the services to be provided, the timeline for completion, and the compensation to be paid.2. PaymentIn consideration for the services provided by the Developer under this Contract, the Client agrees to pay the Developer a fee of [Insert Amount] (the "Fee"). Payment shall be made in [Insert Payment Terms], with [Insert Percentage] due upon signing of the Contract, [Insert Percentage] due upon delivery of the completed work, and the balance due upon final acceptance by the Client.3. Ownership of Work ProductAll work products created by the Developer under this Contract, including but not limited to software code, designs, and documentation, shall be the exclusive property of the Client. The Developer agrees to assign all rights, title, and interest in andto the work product to the Client upon completion of the services.4. ConfidentialityThe Developer agrees to keep confidential all information provided by the Client in connection with the services, including but not limited to proprietary information, trade secrets, and intellectual property. The Developer shall not disclose such information to any third party without the Client's prior written consent.5. Term and TerminationThis Contract shall commence on the Effective Date and shall continue until the services described in the SOW are completed. Either party may terminate this Contract upon written notice to the other party if the other party materially breaches any provision of the Contract and fails to cure such breach within [Insert Cure Period] days of receiving written notice.6. Independent ContractorThe Developer is an independent contractor and not an employee of the Client. The Developer shall have sole control over the manner and means by which the services are performed,provided that the work is completed in accordance with the specifications set forth in the SOW.7. Governing LawThis Contract shall be governed by and construed in accordance with the laws of the [state/country] without regard to conflicts of law principles. Any disputes arising out of or relating to this Contract shall be resolved by binding arbitration in accordance with the rules of the American Arbitration Association.IN WITNESS WHEREOF, the parties hereto have executed this Contract as of the Effective Date.[Signature Page Follows]IN WITNESS WHEREOF, the parties hereto have executed this Contract as of the Effective Date.Developer: [Developer Name]Client: [Client Name]By: _________________ By: __________________Name: Name:Title: Title:Date: Date:篇4Technical Development ContractThis Technical Development Contract (the "Contract") is entered into on this __________ day of __________, 20__, by and between _______________________ (the "Client") and_______________________ (the "Developer").1. Scope of WorkThe Developer agrees to provide technical development services to the Client for the project described as_______________________ (the "Project"). The scope of work includes but is not limited to:- Designing and developing software or applications according to Client's specifications.- Testing and debugging the software to ensure proper functionality.- Providing ongoing technical support and maintenance for the software post-launch.- Meeting all deadlines and milestones as outlined in the project plan.2. PaymentThe Client agrees to pay the Developer a total fee of$__________ for the completion of the Project. Payment will be made in installments as follows:- 25% upon signing of the Contract.- 25% upon completion of the design phase.- 25% upon completion of the development phase.- 25% upon final delivery and acceptance of the Project.Payment can be made via check, wire transfer, or credit card, as agreed upon by both parties.3. Intellectual Property RightsAll intellectual property rights, including but not limited to copyrights, patents, and trademarks, related to the software developed under this Contract shall belong to the Client. The Developer agrees to transfer all such rights to the Client upon completion of the Project.4. ConfidentialityBoth parties agree to keep all information exchanged during the course of the Project confidential. This includes but is notlimited to source code, design documents, and any other proprietary information related to the software.5. TerminationEither party may terminate this Contract with written notice if the other party breaches any of the terms outlined herein. In the event of termination, the Developer shall be entitled to payment for services rendered up to the date of termination.6. Governing LawThis Contract shall be governed by the laws of the state of __________. Any disputes arising under this Contract shall be resolved through arbitration in accordance with the rules of the American Arbitration Association.In witness whereof, the parties have executed this Contract as of the date first written above.___________________________Client Name___________________________Developer NameThis document constitutes the entire agreement between the Client and the Developer and supersedes any prior agreements or understandings, whether written or oral.篇5Technical Development AgreementThis Technical Development Agreement (“Agreement”) is entered into on this [insert date] by and between [Company Name], having its principal place of business at [insert address] (“Developer”) and [Client Name], having its principal place of business at [insert address] (“Client”).WHEREAS, Client desires to engage Developer to provide technical development services for the purpose of [insert description of project]; andWHEREAS, Developer is willing to perform such services for Client on the terms and conditions set forth herein.NOW, THEREFORE, in consideration of the mutual covenants and agreements contained herein, the parties agree as follows:1. Services. Developer shall provide technical development services for Client in accordance with the specifications outlined in Exhibit A attached hereto.2. Compensation. Client shall pay Developer a fee of [insert amount] for the services to be provided under this Agreement. Payment shall be made in [insert payment terms], as outlined in Exhibit B attached hereto.3. Term. This Agreement shall commence on [insert start date] and shall continue until the completion of the project or termination by either party.4. Confidentiality. Developer acknowledges that in the course of performing services for Client, Developer may have access to confidential information belonging to Client. Developer agrees to keep such information confidential and shall not disclose it to any third party without the prior written consent of Client.5. Ownership of Work Product. All work product created by Developer in connection with the services provided under this Agreement shall be the exclusive property of Client. Developer agrees to assign all rights, title, and interest in such work product to Client.6. Warranties. Developer warrants that the services provided under this Agreement shall be performed in a professional and workmanlike manner and shall conform to the specifications outlined in Exhibit A. Developer further warrants that it has theright to enter into this Agreement and that the services provided do not infringe upon the intellectual property rights of any third party.7. Indemnification. Developer shall indemnify and hold harmless Client from any claims, damages, losses, or expenses arising out of Developer's breach of this Agreement or negligence in the performance of its services.8. Termination. Either party may terminate this Agreement upon written notice if the other party materially breaches any provision of this Agreement and fails to cure such breach within [insert number] days of receiving written notice.9. General Provisions. This Agreement constitutes the entire understanding between the parties with respect to the subject matter hereof and supersedes all prior agreements and understandings, whether written or oral. This Agreement may not be amended except by written agreement signed by both parties.IN WITNESS WHEREOF, the parties have executed this Agreement as of the date first set forth above.[Developer Name][Client Name]Exhibit A: Project SpecificationsExhibit B: Payment Terms_______________________________[Signature] [Date]篇6Technical Development AgreementThis Technical Development Agreement ("Agreement") is entered into by and between [Company Name], a company organized and existing under the laws of [Country], having its principal place of business at [Address] ("Company"), and [Developer Name], an individual residing at [Address] ("Developer").1. Scope of ServicesDeveloper agrees to provide technical development services to Company. The services to be provided by Developer shall include but not be limited to designing, coding, testing, and implementing software solutions in accordance with Company's specifications. Developer shall perform the services in a timely and professional manner and in accordance with best industry practices.2. PaymentCompany agrees to pay Developer for the services rendered in accordance with the fee schedule attached as Schedule A to this Agreement. Payment shall be made [payment terms]. Developer shall invoice Company for the services rendered on a [payment frequency] basis.3. Ownership of Intellectual PropertyAny intellectual property developed by Developer in the course of providing the services under this Agreement shall be the exclusive property of Company. Developer hereby assigns to Company all right, title, and interest in and to any intellectual property developed herein.4. ConfidentialityDeveloper acknowledges that in the course of providing the services under this Agreement, Developer may have access to confidential information of Company, including but not limited to Company's proprietary software, technical data, and business strategies. Developer agrees to keep all confidential information confidential and not to disclose it to any third party without Company's prior written consent.5. Term and TerminationThis Agreement shall commence on [Commencement Date] and continue until [Termination Date], unless earlier terminated as provided herein. Either party may terminate this Agreement upon [notice period] written notice to the other party. Upon termination of this Agreement, Developer shall deliver to Company all materials and property belonging to Company and cease using Company's confidential information.6. IndemnificationDeveloper agrees to indemnify and hold harmless Company against all claims, damages, and liabilities arising out of Developer's breach of this Agreement or negligence in providing the services hereunder.7. Governing LawThis Agreement shall be governed by and construed in accordance with the laws of [Country]. Any dispute arising out of or in connection with this Agreement shall be resolved by arbitration in [City], [Country], in accordance with the rules of the [Arbitration Institution].IN WITNESS WHEREOF, the parties hereto have executed this Agreement as of the date first above written.[Company Name]By:Name:Title: [Developer Name] By:Name:。
英文技术服务合同6篇
英文技术服务合同6篇篇1Technical Service ContractThis Technical Service Contract is entered into by and between [Company Name], located at [Company Address] (hereinafter referred to as "Client") and [Service Provider Name], located at [Service Provider Address] (hereinafter referred to as "Service Provider") on [Contract Start Date].1. Scope of ServicesService Provider agrees to provide technical services to Client as detailed below:- Description of Services: [Detailed description of the technical services to be provided]- Service Hours: [Days and times when services will be provided]- Service Location: [Where services will be provided]2. Service FeesClient agrees to pay Service Provider the following fees for the technical services:- Hourly Rate: [Hourly rate for services provided]- Additional Fees: [Any additional fees for materials or equipment required]- Payment Terms: [Payment terms, such as monthly orbi-weekly payments]3. Term of ContractThis contract shall begin on [Contract Start Date] and shall continue for a period of [Contract Duration]. Either party may terminate this contract with [Notice Period] days’ notice in writing.4. ConfidentialityBoth parties agree to keep all information exchanged during the provision of technical services confidential. This includes any proprietary information or trade secrets.5. Ownership of WorkAll work performed by Service Provider under this contract shall become the property of Client. Service Provider agrees not to claim any ownership rights over any work performed.6. WarrantiesService Provider warrants that all work performed will be of professional quality and will meet the specifications outlined in this contract. Service Provider also warrants that they have the necessary experience and qualifications to perform the technical services.7. IndemnificationService Provider agrees to indemnify and hold harmless Client from any claims, damages, or liabilities arising from the provision of technical services under this contract.8. Governing LawThis contract shall be governed by the laws of[State/Country]. Any disputes arising from this contract shall be resolved through arbitration.In witness whereof, the parties hereto have executed this contract as of the date first above written.[Signature of Client] [Signature of Service Provider][Printed Name of Client] [Printed Name of Service Provider]Date: [Contract Start Date]This Technical Service Contract sets forth the entire agreement between the parties and supersedes any prior agreements or understandings, whether written or oral. This contract may only be modified in writing and signed by both parties.篇2Technical Service ContractThis Agreement is entered into on the ______ day of __________, 20__, by and between _________________________ ("Client") and________________________ ("Service Provider").1. Scope of ServicesService Provider agrees to provide technical services to Client in accordance with the terms and conditions of this Agreement. The services may include but are not limited to: software installation, hardware troubleshooting, network configuration, and other technical support as requested by the Client.2. Fees and PaymentClient agrees to pay Service Provider a fixed fee of $____ for each month of service. Payment is due on the first day of eachmonth and will be considered past due if not received within 30 days of the due date. Service Provider reserves the right to suspend services if payment is not received in a timely manner.3. Term and TerminationThis Agreement shall commence on the effective date and shall remain in effect for a period of one year. Either party may terminate this Agreement with 30 days written notice. Upon termination, all outstanding fees must be paid in full.4. ConfidentialityBoth parties agree to keep all information shared during the course of this Agreement confidential. This includes but is not limited to client data, technical processes, and business strategies.5. Ownership of WorkAny work created by Service Provider during the course of this Agreement shall be considered the property of the Client. Service Provider agrees not to disclose, sell, or use this work for any purpose other than providing services to the Client.6. WarrantyService Provider warrants that all services provided under this Agreement will be performed in a professional and workmanlike manner. If any services are found to be unsatisfactory, Service Provider agrees to make reasonable efforts to correct the issue.7. Limitation of LiabilityIn no event shall either party be liable for any indirect, incidental, special, or consequential damages arising from the performance of this Agreement. This limitation of liability shall apply to all claims, regardless of the nature of the claim or the form of action.8. Governing LawThis Agreement shall be governed by and construed in accordance with the laws of the State of ______________. Any disputes arising from this Agreement will be resolved through arbitration in the State of _____________.9. Entire AgreementThis Agreement constitutes the entire understanding between the parties and supersedes all prior agreements, whether written or oral, concerning the subject matter herein.IN WITNESS WHEREOF, the Parties hereto have executed this Agreement as of the date first above written.______________________________________________________ClientService Provider篇3Technical Service AgreementThis Technical Service Agreement (the "Agreement") is made and entered into as of [date] by and between [Company Name], a company organized and existing under the laws of [jurisdiction], with its principal place of business at [address] (the "Client"), and [Service Provider], a company organized and existing under the laws of [jurisdiction], with its principal place of business at [address] (the "Service Provider").1. Services. The Client hereby engages the Service Provider to perform the following services (the "Services"):- [list of services to be provided]- [list any specific deliverables or milestones]- [any other specific terms relating to the Services]2. Term. The term of this Agreement shall commence on [start date] and shall continue until [end date], unless earlier terminated by either party in accordance with the terms of this Agreement.3. Compensation. In consideration for the Services to be provided by the Service Provider, the Client shall pay the Service Provider the sum of [amount] per [payment period] for the term of this Agreement. Payment shall be made [describe payment terms] and shall be due [describe due date].4. Confidentiality. Both parties agree to keep confidential all information provided by the other party in connection with this Agreement, and to not disclose such information to any third party without the prior written consent of the disclosing party.5. Termination. Either party may terminate this Agreement upon written notice to the other party if the other party materially breaches any provision of this Agreement and fails to cure such breach within [number] days of receiving notice of such breach.6. Governing Law. This Agreement shall be governed by and construed in accordance with the laws of [jurisdiction].IN WITNESS WHEREOF, the parties have executed this Agreement as of the date first above written.[Client Name]By: __________________________Title: _________________________[Service Provider Name]By: __________________________Title: _________________________篇4Technical Service ContractThis Technical Service Contract (the “Contract”) is made and entered into on [date], between [Company Name], with a princip al place of business at [address] (the “Client”), and [Service Provider Name], with a principal place of business at [address] (the “Service Provider”).1. ServicesThe Service Provider agrees to provide technical services to the Client. These services may include but are not limited to:- IT support- Software development- Hardware maintenance- Network administration- Security services- Data backup and recovery2. DeliverablesThe Service Provider will deliver the following to the Client:- Regular updates on the progress of the services- Reports on any issues or concerns- Documentation of all work performed- Recommendations for improvements or upgrades3. TermThis Contract will begin on [start date] and will continue for a period of [duration]. After the initial term, the Contract may be renewed by mutual agreement of both parties.4. PaymentThe Client agrees to pay the Service Provider [amount] for the services rendered. Payment will be made in [frequency]installments, with the first payment due on [date]. The final payment will be made upon completion of the services.5. ConfidentialityBoth parties agree to maintain the confidentiality of any proprietary or sensitive information shared during the course of this Contract. This includes but is not limited to technical details, business strategies, and financial information.6. IndemnificationThe Service Provider warrants that all services provided under this Contract will be performed in a professional and timely manner. The Client agrees to indemnify and hold harmless the Service Provider from any claims or damages arising from the performance of the services.7. TerminationEither party may terminate this Contract by providing written notice to the other party. Upon termination, the Client will pay for all services rendered up to the date of termination.8. Governing LawThis Contract shall be governed by and construed in accordance with the laws of [Jurisdiction]. Any disputes arisingunder this Contract shall be resolved through arbitration in [City], [Jurisdiction].In witness whereof, the parties have executed this Contract as of the date first above written.[Client Name] [Service Provider Name]By:_____________________________ By:____________________________Title:___________________________ Title:________________________This Technical Service Contract represents the entire agreement between the parties and supersedes any previous agreements or understandings. This Contract may only be modified in writing signed by both parties.篇5Technical Service ContractThis Technical Service Contract (hereinafter referred to as "the Contract") is entered into on [date] by and between [Company Name], with its principal place of business at [address] (hereinafter referred to as the "Client") and [Service Provider Name], with its principal place of business at [address] (hereinafter referred to as the "Service Provider").1. Scope of ServicesThe Service Provider agrees to provide technical services to the Client in accordance with the terms and conditions of this Contract. The scope of services shall include, but not be limited to:- [List of specific services to be provided]- [List of any additional services to be provided]2. Term of ContractThe Contract shall be effective as of the date of signing and shall continue for a period of [term]. The Contract may be renewed or terminated by either party upon written notice.3. Service FeesThe Client agrees to pay the Service Provider a fee of [amount] for the services provided under this Contract. Payment shall be made in [currency] and shall be due [payment terms].4. ConfidentialityBoth parties agree to keep confidential any information shared during the course of providing services under this Contract. This includes any proprietary or sensitive information disclosed by either party.5. Intellectual Property RightsAll intellectual property rights associated with the services provided under this Contract shall remain with the Service Provider. The Client agrees not to reproduce, modify, or distribute any intellectual property without the prior written consent of the Service Provider.6. Limitation of LiabilityIn no event shall either party be liable for any indirect, special, or consequential damages arising out of or in connection with this Contract.7. Governing LawThis Contract shall be governed by and construed in accordance with the laws of [jurisdiction]. Any disputes arising under this Contract shall be resolved through arbitration in accordance with the rules of [arbitration provider].IN WITNESS WHEREOF, the parties hereto have executed this Contract as of the date first above written.[Client Signature] [Service Provider Signature]篇6Technical Services AgreementThis Technical Services Agreement ("Agreement") is entered into as of [Date], by and between [Company Name], a company organized and existing under the laws of [State/Country], with its principal place of business located at [Address] ("Client"), and [Service Provider Name], a company organized and existing under the laws of [State/Country], with its principal place of business located at [Address] ("Service Provider").1. ServicesService Provider agrees to provide technical services to Client in accordance with the terms and conditions of this Agreement. The technical services to be provided may include, but are not limited to, software development, system integration, network design, and technical support.2. Scope of WorkService Provider shall perform the following services:a) Develop software applications as per Client's specifications and requirements.b) Integrate systems to facilitate seamless communication between different platforms.c) Design and implement network infrastructure for efficient data transfer.d) Provide technical support to resolve any issues or concerns that may arise during the term of this Agreement.3. Fees and PaymentClient shall pay Service Provider a fixed fee for the technical services rendered in accordance with the scope of work. Payment shall be made in [currency] within [Number] days of receipt of an invoice from Service Provider.4. Term and TerminationThis Agreement shall commence on the effective date and shall continue until the services are completed unless terminated by either party with [Number] days written notice. In the event of termination, Client shall pay Service Provider for any services rendered up to the date of termination.5. ConfidentialityService Provider shall keep all information provided by Client confidential and shall not disclose it to any third party without the prior written consent of Client. This obligation shall survive the termination of this Agreement.6. Intellectual PropertyAny intellectual property developed or created by Service Provider during the course of providing the services shall belong to Client. Service Provider agrees to transfer all rights to Client upon completion of the services.7. IndemnificationService Provider shall indemnify and hold harmless Client from any claims, damages, or liabilities arising out of the performance of the services under this Agreement.8. Governing LawThis Agreement shall be governed by and construed in accordance with the laws of [State/Country].9. Entire AgreementThis Agreement constitutes the entire agreement between the parties and supersedes any prior agreements or understandings, whether written or oral.IN WITNESS WHEREOF, the parties have executed this Agreement as of the effective date.[Client Name] [Service Provider Name]By: By:Title: Title: Date: Date:。
英文技术服务合同5篇
英文技术服务合同5篇篇1Technical Service ContractThis Technical Service Contract ("Contract") is entered into on [date] by and between [Company Name], with a principal place of business at [address] ("Client"), and [Service Provider], with a principal place of business at [address] ("Service Provider").1. Scope of Services: Service Provider agrees to provide technical services to Client in accordance with the terms and conditions of this Contract. The services to be provided shall include but not be limited to [list of services].2. Duration of Contract: This Contract shall commence on [start date] and shall continue for a period of [duration] unless terminated earlier in accordance with the terms of this Contract.3. Fees: In consideration for the services provided under this Contract, Client shall pay Service Provider a fee of [fee amount] on a [monthly/quarterly/annual] basis. Payment shall be made within [number] days of receipt of an invoice from Service Provider.4. Confidentiality: Service Provider agrees to maintain the confidentiality of all information provided by Client in the course of providing the services under this Contract. Service Provider shall not disclose such information to any third party without the prior written consent of Client.5. Termination: Either party may terminate this Contract upon [number] days' written notice to the other party. In the event of termination, Service Provider shall be entitled to compensation for services rendered up to the date of termination.6. Governing Law: This Contract shall be governed by and construed in accordance with the laws of the State of [State].In witness whereof, the parties hereto have caused this Contract to be executed by their duly authorized representatives as of the date first above written.[Client Signature] [Service Provider Signature][Print Name] [Print Name][Title] [Title][Date] [Date]This Technical Service Contract constitutes the entire agreement between the parties with respect to the subject matter hereof and supersedes all prior agreements, understandings, negotiations, and discussions, whether oral or written.篇2Technical Service ContractThis Contract is made and entered into on this ___ day of___________, 2019, by and between:(1) [Company Name], a company having its place of business at [Company Address] (hereinafter referred to as the "Company")AND(2) [Service Provider Name], a company having its place of business at [Service Provider Address] (hereinafter referred to as the "Service Provider").WHEREAS, the Company desires to engage the Service Provider to provide technical services as described herein, and the Service Provider is willing to provide such services in exchange for the agreed upon compensation.NOW, THEREFORE, in consideration of the premises and mutual covenants contained herein, the parties hereto agree as follows:1. Scope of Services: The Service Provider agrees to provide technical services as described in Exhibit A attached hereto.2. Term: The term of this Contract shall commence on the effective date and shall continue for a period of _______ months, unless terminated earlier in accordance with the provisions of this Contract.3. Compensation: The Company shall pay the Service Provider the sum of $_________ as compensation for the services rendered under this Contract. Payment shall be made in accordance with the payment schedule set forth in Exhibit B.4. Confidentiality: The Service Provider shall maintain the confidentiality of all information received from the Company and shall not disclose such information to any third party without the Company's prior written consent.5. Indemnification: The Service Provider shall indemnify and hold harmless the Company from and against any and all claims, damages, losses, liabilities, and expenses arising out of or inconnection with the Service Provider's performance of the services under this Contract.6. Termination: This Contract may be terminated by either party upon _______ days' written notice to the other party.IN WITNESS WHEREOF, the parties hereto have executed this Contract as of the date first above written.[Company Name]By: _______________________ [Signature]Title: _____________________ [Print Name][Service Provider Name]By: _______________________ [Signature]Title: _____________________ [Print Name]Exhibit A: Description of ServicesExhibit B: Payment Schedule篇3Technical Service ContractThis Technical Service Contract ("Contract") is entered into as of [date], by and between [Client Company], whose principalplace of business is located at [address], hereinafter referred to as "Client", and [Service Provider Company], whose principal place of business is located at [address], hereinafter referred to as "Service Provider".1. Scope of Services:Service Provider agrees to provide technical services to Client during the term of this Contract. The scope of services shall include but not be limited to: [list of specific services to be provided].2. Term:This Contract shall commence on [start date] and shall continue for a period of [number] months, unless terminated earlier in accordance with the provisions of this Contract.3. Compensation:Client agrees to pay Service Provider a fee of [amount] for the services provided under this Contract. Payment shall be made in [currency] within [number] days of receipt of an invoice from Service Provider.4. Representations and Warranties:Service Provider represents and warrants that it has the necessary expertise and resources to perform the services under this Contract in a professional manner. Client represents and warrants that it has the authority to enter into this Contract on behalf of the organization.5. Confidentiality:Both parties agree to maintain the confidentiality of any proprietary or confidential information disclosed during the performance of this Contract. This obligation of confidentiality shall survive the termination of this Contract.6. Termination:Either party may terminate this Contract by providing thirty (30) days written notice to the other party. In the event of termination, Client shall pay Service Provider for any services rendered up to the date of termination.7. Governing Law:This Contract shall be governed by and construed in accordance with the laws of [state/country]. Any disputes arising under this Contract shall be resolved through arbitration in [city], conducted in accordance with the rules of the American Arbitration Association.In witness whereof, the parties hereto have executed this Contract as of the date first written above.[Client Company]By: __________________________Title: __________________________[Service Provider Company]By: __________________________Title: __________________________This contract sets forth the entire agreement between the parties with respect to the subject matter hereof and supersedes all prior agreements and understandings, whether written or oral. This Contract may be modified only by a written agreement signed by both parties.篇4Technical Service ContractThis Technical Service Contract (the "Contract") is entered into on [Date] by and between [Company Name] ("Client") and [Service Provider] ("Provider").1. Scope of ServicesProvider agrees to provide technical services to Client, including but not limited to software development, server maintenance, network administration, troubleshooting, and technical support.2. Service PeriodThe service period shall commence on the Effective Date and shall continue for a period of [Duration]. The parties may extend the service period by mutual agreement in writing.3. Service FeesClient shall pay Provider a fee of [Fee] for the services provided under this Contract. Payment shall be made [Payment Terms]. In the event of any additional services requested by Client, Provider shall provide a written estimate of costs prior to commencing work.4. ResponsibilitiesProvider shall use reasonable efforts to ensure that all services are performed in a professional and timely manner. Client shall provide all necessary access, information, and cooperation required for Provider to perform the services.5. ConfidentialityBoth parties agree to keep all confidential information shared during the term of this Contract confidential and not to disclose it to any third party without prior written consent.6. TerminationEither party may terminate this Contract by providing [Notice Period] written notice to the other party. In the event of termination, Provider shall be paid for all services provided up to the date of termination.7. IndemnificationProvider agrees to indemnify and hold harmless Client from any claims, damages, losses, or liabilities arising from Provider's negligence or breach of this Contract.8. Governing LawThis Contract shall be governed by and construed in accordance with the laws of [State/Country].9. Entire AgreementThis Contract constitutes the entire agreement between the parties with respect to the subject matter herein and supersedes all prior agreements, written or oral.In Witness whereof, the parties have executed this Contract as of the Effective Date.[Signature of Client][Printed Name of Client][Signature of Provider][Printed Name of Provider]篇5Technical Service AgreementThis Agreement is entered into between [Company Name], a company incorporated under the laws of [Country], with its principal place of business at [Address] (hereinafter referred to as the "Company") and [Service Provider Name], a company incorporated under the laws of [Country], with its principal place of business at [Address] (hereinafter referred to as the "Service Provider"), collectively referred to as the "Parties" and individually as a "Party."1. Services1.1 The Service Provider agrees to provide technical services to the Company as outlined in Exhibit A attached hereto.1.2 The Company agrees to provide all necessary information, access, and support to enable the Service Provider to perform the services outlined in Exhibit A.2. Term2.1 This Agreement shall commence on [Start Date] and shall continue in full force and effect until terminated by either Party in accordance with the termination provisions set forth in Section 7.3. Compensation3.1 In consideration for the services provided by the Service Provider under this Agreement, the Company shall pay the Service Provider a fee of [Amount] per month. Payment shall be made on a monthly basis, on the first day of each month, via wire transfer.4. Confidentiality4.1 The Parties acknowledge and agree that during the performance of this Agreement, each Party may have access to confidential information of the other Party. The Parties agree to keep all such confidential information confidential and not to disclose it to any third party without the prior written consent of the other Party.5. Intellectual Property5.1 The Parties agree that all intellectual property developed or created by the Service Provider in the course of providing the services under this Agreement shall be the sole and exclusive property of the Company. The Service Provider agrees to assign all rights, title, and interest in such intellectual property to the Company.6. Indemnification6.1 The Service Provider agrees to indemnify, defend, and hold harmless the Company from and against any and all claims, damages, losses, liabilities, and expenses arising out of or related to the services provided by the Service Provider under this Agreement.7. Termination7.1 Either Party may terminate this Agreement by giving [Number] days' written notice to the other Party.7.2 In the event of termination, the Service Provider shall be entitled to receive payment for all services rendered up to the date of termination.8. Governing Law8.1 This Agreement shall be governed by and construed in accordance with the laws of [Country]. Any disputes arising out of or related to this Agreement shall be settled through arbitration in [City], [Country].IN WITNESS WHEREOF, the Parties have executed this Agreement as of the Effective Date.[Company Name]By: ______________________Name: ______________________Title: ______________________[Service Provider Name]By: ______________________Name: ______________________Title: ______________________Exhibit A: Description of Services。
英文技术服务合同范本4篇
英文技术服务合同范本4篇Model contract for technical services in English甲方：乙方：签订日期：年月日英文技术服务合同范本4篇小泰温馨提示：合同是民事主体之间设立、变更、终止民事法律关系的协议。
依法成立的合同，受法律保护。
本文档根据服务合同内容要求和特点展开说明，具有实践指导意义，便于学习和使用，本文下载后内容可随意修改调整及打印。
本文简要目录如下：【下载该文档后使用Word打开，按住键盘Ctrl键且鼠标单击目录内容即可跳转到对应篇章】1、篇章1：英文技术服务合同范本2、篇章2：翻译服务合同英文模板文档3、篇章3：翻译服务合同英文模板文档4、篇章4：翻译服务合同英文模板文档篇章1:英文技术服务合同范本Contract No.:________________________.Date of Signature:____________________.Place of Signature:____________________.This Contract is made and entered into through friendly negotiation by and betweenChina____________________ （hereinafter referred to as “Client”）, as one party, and____________________ （hereinafter referred to as“Consultant”）,as the other party, concerning the technical consultancy service of__________, under the following terms and conditions:Article 1 Contents of Technical Consultancy Service1.1 Whereas Client desires to obtain thetechnical consultancy service of from Consultant and Consultant has agreed to perform such services.1.2 The Scope of Technical Services is defined in Appendix 1.1.3 The Time Schedule for the Services is shownin Appendix 2.1.4 The Manning Schedule is described in Appendix 3.1.5 Consultant shall complete the Serviceswithin__________months from the Effective Date of this Contract and furnish the final technical servicereport, including drawings, designing documents, all kinds of standards and photos, within____months. Consultant shall keep aware, free of charge, Client of the latest development of similar projects and any progress made in order to improve the designing of the project.Article 2 Both Parties' Responsibility and Liability2.1 Client shall furnish to Consultant the pertinent data, technical service reports, maps and information available to him and shall give to Consultant the reasonable assistance necessary for carrying out of his duties. Particularly Client shall nominate a general representative who shall be available at reasonable time.2.2 Client shall assist Consultant with the responsible authorities for obtaining visas, work permits and other documents required by Consultant to enter the country and to have access to the Site of the Project. The above expenses shall be borne by Consultant.2.3 Consultant shall furnish a sufficient number of competent personnel to perform its obligation hereunder, in addition to those personnel specifically listed in Appendix3.All personnel employed by Consultant in carrying out the work shall be exclusively Consultant's responsibility, and Consultant shall hold Client harmless from any claims of any kind by Consultant's personnel arising out of any acts by Consultant or its personnel in connection with the work performed hereunder.2.4 Consultant shall provide Client all the technical technical service reports and relevant documentation within the Scope of Technical Services and within the Time Schedule of the Time Schedule for the Services.2.5 Consultant shall assist Client＇S personnelin his country in obtaining visas and in arranging lodgings. Hotel and boarding expenses shall be borne by Client. Consultant shall supply to Client＇Spersonnel office space and necessary facilities as well as transportation.2.6 Consultant shall be responsible for and shall indemnify Client and his employee in respect of injury to person or damage to property occurring in connection with the services, to the extent that such damage or injury directly results from negligence of Consultant's personnel while engaged in activities under this shall be liable only to the work under this Contract.2.7 Any and all liability of Consultant with respect to this Contract shall be limited to the Total Contract Price received by Consultant for his profession services and shall terminate uponexpiration of the warranty period set forth in Article 7.3.Article 3 Price and Payment3.1 The total contract price is__________（say__________________only） in________（currency）. Thebreakdown prices of the above mentioned total contract price are as follows:Contract Price for Item 1: ______（say____________only） in________ （currency）; Contract Price for Item 2: ______（say ____________only）in________ （currency）; Contract Price for Item 3:______（say ____________only） in________ （currency）; Contract Price for Item 4: ______（say____________only） in________ （currency）.3.2 The total contract price will include all the service and technology provided by Consultant. Thetotal contract price shall be firm and fixed and shall not fluctuate with any inflation. The total contract price shall include all charges and expenses incurred by Consultant in performing his obligations both inhis own country and in the People's Republic of China and includes the expenses incurred in sending the Technical Documentation to Client's office by allkinds of forms.In the event of Force Majeure as defined in the Contract, the total contract price shall be readjusted through friendly negotiations between the parties. If Client requires services not contemplated in the Scope of Services the parties shall friendly discuss an amendment to thetotal contract price. Any such amendment shall be in writing countersigned by both parties. This document shall then form integral part of the Contract.3.3 All payments to be made by Client to Consultant under the present Contract shall be made by telegraphic transfer. In case of any payment by Client, the payment shall be effected through__________inChina to _________ for the account of Consultant.In consideration for the services provided by Consultant hereunder, Client shall effect the payment to Consultant in accordance with the following manner and percentage:3.3.1 _______ percent （________ %） of the total contract price, i.e._____________ （Say: ________ only）, shall be paid by Client to Consultant within ________ （____） days after the client has received the following documents provided by Consultant and found them in order.A. One（1） original and two（2） duplicate copies of Consultant's government approval, or a written statement of the competent authorities or relevant agency of Consultant's country certifying that such document is not required;B. One（1） original and one（1） duplicate copy of Irrevocable Letter of Guarantee for advance payment issued by Consultant's Bank in favor of Client covering_______（Say:________ only）, specimen of which is as per Appendix 4;C. Five （5） copies of profoma invoice covering the total contract price;D. Five （5） copies of manually signedcommercial invoice indicating the amount to be paid;E. Two （2） copies of sight draft.The said shall be delivered by Consultant notlater than ____days after the effective date of the________present Contract.3.3.2 ________percent （____%） of the Contract price for Item 1, i.e._________ （Say: __________ only）shall be paid by Client to Consultant within _____（__） days after Consultant has received thefollowing documents provided by Consultant and found them in order.A. Ten （10） copies of technical service report on Item 1;B. Five （5） copies of manually signedcommercial invoice indicating the amount to be paid;C. Two （2） copies of sight draft.3.3.3 ________ percent （____%） of the Contract price for Item 2, i.e. ___________ （Say: ____________ only） shall be paid by Client to Consultant within________ （___） days after Licensee has received the following documents provided by Consultant and found themin order.A. Ten （10） copies of technical service report on Item 1;B. Five （5） copies of manually signedcommercial invoice indicating the amount to be paid;C. Two （2） copies of sight draft.3.3.4 ________percent （____%） of the Contract price for Item 3, i.e._________ （Say: __________ only）shall be paid by Client to Consultant within _____（__） days after Consultant has received thefollowing documents provided by Consultant and found them in order.A. Ten （10） copies of technical service report on Item 1;B. Five （5） copies of manually signedcommercial invoice indicating the amount to be paid;C. Two （2） copies of sight draft.3.3.5 ________percent （____%） of the Contract price for Item 4, i.e._________ （Say: __________ only）shall be paid by Client to Consultant within _____（__） days after Consultant has received thefollowing documents provided by Consultant and found them in order.A. Ten （10） copies of technical service report on Item 1;B. Five （5） copies of manually signedcommercial invoice indicating the amount to be paid;C. Two （2） copies of sight draft.3.3.6 ________percent （____%） of the Total Contract price , i.e._________ （Say: __________ only）shall be paid by Client to Consultant within _____（__） days after Consultant has received thefollowing documents provided by Consultant and found them in order.A. Five （5） copies of manually signed commercial invoice indicating the amount to be paid;B. Two （2） copies of sight draft.3.4 In case Consultant is liable for paying to Client the penalty under the Contract, Client shall have the right to deduct it from any said payment.3.5 The banking charges of both parties incurred in China for the execution of the Contract shall be borne by Client and those incurred outside China shall be borne by Consultant.Article 4 Delivery Schedule4.1 The deadline for the arrival of the Technical service reports CIF _____ are:A. Technical service report on Item 1 :_________months after effectiveness of the Contract;B. Technical service report on Item 2 :_________months after effectiveness of the Contract;C. Technical service report on Item 3 :_________months after effectiveness of the Contract;D. Technical service report on Item 4 :________months after effectiveness of the Contract.4.2 Consultant will inform Client by Fax when the Technical service reports are airmailed to Client indicating the date and number of airway bill. Client will inform Consultant when the Technical service reports have been received.4.3 Should any document be missing or damaged during the transport Consultant shall be notified accordingly and within two （2） weeks the missing or damaged document shall be replaced by Consultant free of charge.Article 5 Confidentiality5.1 All data assembled, developed, compiled, reproduced, studied, and prepared in connection withthe work done hereunder and furnished to Consultant by Client shall be considered confidential and shall not be divulged to any person, firm or corporation other than Client or its designated representatives. This Clause shall remain binding on Consultant notwithstanding the termination of the Contract for any reason.5.2 Within the validity period of Contract, Both parties shall take proper measures to keep the materials or information strictly confidential. The other party shall not disclose or divulge to any third party without prior written consent of one party.5.3 Either party shall be obliged to keep confidential any secret information of the other party which either party and its personnel may obtain or be accessible to in the course of the performance of Contract. Either party shall not make use of or disclose such secret information obtained from the other party without prior written permission issued by the other party.Article 6 Taxes and Duties6.1 All taxes and duties in connection with and in the execution of Contract levied by the Chinese government on Client in accordance with the tax laws of PRC shall be borne by Client.6.2 All taxes and duties levied by the Chinese government on Consultant, in connection with and in the execution of Contract, according to Chinese tax laws and the agreement between the government of PRC and the government of Consultant's country for the reciprocal avoidance of double taxation and the prevention of fiscal evasion with respect to taxes on income shall be borne by Consultant.Client is legally obliged to withhold, as a withholding agent, the amount of taxes pro rata each taxable payment under Contract and pay them to the relevant Chinese tax authorities. After receiving the tax receipts issued by the relevant Chinese tax authorities for the aforesaid withholding taxes,Client shall forward them to Consultant without undue delay.6.3 All taxes and duties arising outside PRC in connection with and in the execution of Contract shall be borne by Consultant.Article 7 Warranty7.1 Consultant warrants that he has the experience and capability to efficiently and expeditiously perform the services in a satisfactory manner and that the services performed by him under this Contract shall be performed by competent personnel in accordance with accepted standards.7.2 In the event of a failure of Consultant to provide to Client satisfactory services within the scope of work described in Appendix at any time for any reason within the control of the Consultant,Client may notify Consultant of such dissatisfaction. Consultant shall be afforded a period of days to correct or remedy the matter. Should Consultant withinthe time afforded by Client fail to correct or remedy the matter to the satisfaction of Client, all charges shall cease forthwith until such time as Consultant is able to provide satisfactory services in accordance with the Scope of work described in Appendix.7.3 Consultant guarantees to Client that he shall, after receipt of notice from Client, promptly correct at no cost any errors in the services arising out of the negligent performance thereof.Article 8 Ownership of Technical Service Reports8.1 Final version of the technical service report submitted to Client and all relevant data such as maps, plans and supporting material compiled in performing the Scope of Services, shall be the property of Client. Such materials shall be sorted and indexed by Consultant prior to transmission to Client.8.2 Consultant shall be permitted to retaincopies thereof, provided however that such materials, including the material furnished by Client as statedin Article 5 of this Contract, shall not be used by Consultant for purposes not related with this Project without the prior written approval of Client.Article 9 Assignment9.1 Neither Client nor Consultant shall assign or sublet their rights or obligations hereunder without the prior written consent of the other party.Article 10 Termination10.1 If, due to the responsibility of Consultant, the technical service reports have not been delivered at dates according to the delivery schedules as stipulated in Article 4 of the Contract, Consultant shall be obliged to pay to Client penalty for such delay in delivery at the following rates:A. ______ percent （____%） of the total contract price per week for the first four weeks;B. _____ percent （____%） of the total contract price per week from the fifth week to the eighth week;C. ______ percent （____%） of the total contract price per week from the ninth week of delay.Odd days less than one（1） week shall be counted as one（1） week for calculating the liquidated damage.10.2 The total liquidated damage for latedelivery shall not exceed ______ percent （____%） of the total contract price. Payment of the liquidated damage for late delivery shall not releaseConsultant from its obligation to deliver technical service reports.10.3 Client may, without prejudice to any other remedy for Consultant's following breach of Contract, terminate Contract in whole or in part by a written notice of default send to Consultant, if ConsultantA. Fails to deliver any or all of technical service reports within______（____） days after the scheduled delivery date as specified in Article 1; orB. Fails to make the technical service reports meet the minimum level of Acceptance Standards as specified in Appendix 1.Consultant shall refund to Client all the payments effected by Client to Consultant plus an interest at the rate of______ percent （____%） per annum in case of such a termination.10.4 Either party may, without prejudice to any other remedy, terminate Contract in whole or in partby a written notice send to the other party, if the other party.A. fails to perform its confidentialityobligation under Contract; orB. fails to perform any other obligations under Contract except minor parts thereof, and does not remedy for its failure within a period of______ （____）days upon receipt of the written notice or a period agreed upon between the parties; orC. becomes bankrupt or insolvent; orD.Affected by any event of Force Majeure for more than ______ days.Article 11 Force Majeure11.1 Should either party be prevented from performing any of its obligations under Contract dueto event of Force Majeure, such as war, serious fire, typhoon, earthquake, flood and any other events which could not be expected, avoided and overcome, the affected party shall notify the other party of its occurrence by fax and send by registered airmail a certificate issued by the competent authorities or agency within fourteen （14） days following its occurrence.11.2 The affected party shall not be liable for any delay or failure in performing any or all of its obligations due to the event of Force Majeure. However, the affected party shall inform the other party by fax the termination or elimination of the event of Force Majeure without delay.11.3 Both parties shall proceed with their obligations immediately after the cease of the event of Force Majeure or removal of the effects. Thevalidity period of Contract and/or the scheduled period for relative execution of Contract shall be extended correspondingly.Article 12 Arbitration12.1 Any dispute arising from or in connection with this Contract shall be submitted to China International Economic and Trade Arbitration Commission，Shenzhen Commission for arbitration in accordance with the Commission's arbitration rules in effect at the time of applying for arbitration. The arbitral award is final and binding upon both parties and the applicable law is the material law of P.R.C.12.2 Notwithstanding any reference to arbitration, both Parties shall continue to perform their respective obligations under the Contract unless otherwise agreed.Article 13 Language and Standards13.1 Correspondance except this Contract between Client and Consultant, data and documents madeavailable by Client to Consultant and the technical service reports and drawings prepared by Consultant shall be in the English language.13.2 Measures shall be written in the metric system.Article 14 Governing Law14.1 The construction, validity and performanceof this Contract shall be governed by the laws of the People's Republic of China.Chapter 15 Effectiveness of the Contract and Miscellaneous15.1 Both parties shall make effort to obtain the approval from the respective authorities, if necessary, within thirty （30） days after Contract is signed by the authorized representatives of the two parties. Either Party shall notify in writing the other partyof the approval date. The later date of approval shall be taken as the Date of Effectiveness of Contract.15.2 Contract shall be valid and remain in force for_______（____） years from the Date of Effectiveness.15.3 The outstanding credit and debt between the parties under Contract shall not be affected upon the termination or expiration of Contract.15.4 Appendices hereof shall be integral parts of Contract and have the same legal force as the text of Contract itself. The text of Contract shall prevail in case of any discrepancies between the text of Contract and Appendices.15.5 All amendments, supplements, subtractions,or alterations to Contract shall be made in writ篇章2:翻译服务合同英文模板文档【按住Ctrl键点此返回目录】Technical Cooperation Agreement甲方：XX油脂化学有限公司Party A: XX Grease Chemical Co. , Ltd.Address: XXHigh-tech Industrial ParkLegal Representative: XXX本协议合作双方就组建技术研发团队事项，经过平等协商，在真实、充分地表达各自意愿互惠互利的基础上，根据《中华人民共和国合同法》的规定，达成如下协议，并由合作各方共同恪守。
英文版技术合同模板
英文版技术合同模板Technology Contract Template。
This Technology Contract ("Contract") is entered into as of [Date] by and between [Company Name], a [State] corporation with its principal place of business at [Address] ("Company"), and [Vendor Name], a [State] corporation with its principal place of business at [Address] ("Vendor").1. Scope of Work。
Vendor agrees to provide the following services to Company:a. Development and implementation of a new software system to manage Company's inventory and supply chain operations.b. Training and support for Company's employees on the use of the new software system.c. Maintenance and updates for the software system for a period of [Time Period] after the initial implementation.2. Payment。
Company agrees to pay Vendor a total of [Total Amount] for the services outlined in Section 1. Payment will be made in [Number of Installments] installments as follows:a. [Amount] upon signing of this Contract.b. [Amount] upon completion of the software development phase.c. [Amount] upon completion of the training and support phase.d. [Amount] upon completion of the maintenance and updates phase.3. Timeline。
英文技术开发合同5篇
英文技术开发合同5篇篇1Contract for Technical Development甲方（客户）：__________________乙方（开发方）：__________________签订日期：____________________一、合同背景及目的本合同由甲方和乙方共同签署，目的在于明确双方在技术开领域的合作关系及具体事务处理细节。
甲方委托乙方进行特定的技术开发工作，乙方同意接受委托并按照本合同的要求完成相关任务。
二、开发内容与技术要求1. 开发内容：具体描述开发的系统名称、功能及目标。
（例如：开发一套智能物流管理系统，实现货物追踪、数据分析及优化物流路径等功能。
）2. 技术要求：明确开发的软件应满足的技术标准和规范，包括但不限于系统稳定性、兼容性、安全性等方面的要求。
三、开发周期与进度安排1. 开发周期：自合同签订之日起至完成所有开发任务并交付验收的总时长。
2. 进度安排：详细列明开发各阶段的时间节点及主要任务，包括需求分析、设计、编码、测试等阶段的具体时间安排。
四、知识产权与保密条款1. 知识产权归属：明确开发成果的知识产权归属，是归属于甲方还是双方共同拥有。
如归属甲方，则乙方不得擅自将相关技术用于其他用途或转让给第三方。
2. 保密条款：双方应对在合作过程中获知的对方商业秘密和技术秘密承担保密义务，未经对方书面同意，不得向任何第三方泄露。
五、费用与支付方式1. 开发费用：详细列明本次技术开发的费用总额及构成，包括各个阶段的工作费用。
费用的确定应遵循公平合理原则。
2. 支付方式：约定支付的时间节点（如预付款、进度款、尾款等）及支付条件。
同时明确如发生变更时双方应如何调整费用。
六、验收与交付1. 验收标准：根据开发内容和技术要求制定详细的验收标准。
2. 交付物：明确开发完成后应交付的文档、软件等物品及其格式和存储方式。
七、风险承担与违约责任1. 风险承担：明确在开发过程中可能遇到的风险及责任承担方式，包括但不限于技术风险、市场风险及不可抗力等因素。
技术开发的英文合同5篇
技术开发的英文合同5篇篇1TECHNOLOGY DEVELOPMENT CONTRACTContract No.: [Insert Contract Number]Date: [Insert Date]1. Scope of Work:The Developer agrees to undertake the development of [describe the technology to be developed in detail] (hereinafter referred to as the "Technology") for the Principal. The Technology shall be developed in accordance with the specifications and requirements provided by the Principal.2. Development Period:The period of development shall commence on [Start Date] and continue until [End Date], unless extended by mutual agreement in writing.3. Project Milestones:The Developer shall achieve the following milestones within the specified timeframes:* Milestone 1: [Describe milestone 1 with timeline]* Milestone 2: [Describe milestone 2 with timeline]* ... (as per the requirements of the project)4. Intellectual Property Rights:All intellectual property rights arising out of or in connection with the Technology shall be owned by the Principal. The Developer shall assign all such rights to the Principal upon completion of the project.5. Payments:The Principal shall pay the Developer the following fees for the development work:* Development Fee: [Amount]* Milestone Payments: [Describe milestone payments with amounts and conditions]* Any other fees or expenses: [Specify other fees/expenses, if any, with amounts]All payments shall be made within [specified timeframes] from the date of invoice.6. Confidentiality:Both parties shall maintain confidentiality of all information disclosed to each other during the course of this Contract. Neither party shall disclose any confidential information to third parties without the prior written consent of the other party.7. Warranty and Liability:The Developer shall ensure that the Technology developed is free from defects in material and workmanship for a period of [Warranty Period]. The Developer shall indemnify and hold harmless the Principal from any claims, losses, or damages arising out of any defects in the Technology.8. Termination:9. Force Majeure:Neither party shall be liable for any failure to perform its obligations due to events beyond its reasonable control, such as acts of war, riots, natural disasters, etc. The affected party shall notify the other party of such events and provide evidence to support its claim.10. General Terms:* This Contract constitutes the entire agreement between the parties and no modifications shall be made except by a written agreement signed by both parties.* The laws of [Country/State] shall apply to this Contract.* Any disputes arising out of or in connection with this Contract shall be settled through friendly negotiations. If no settlement is reached, the dispute shall be referred to [specify dispute resolution mechanism, e.g., arbitration].* This Contract shall be governed by and construed in accordance with the laws of [Country/State].* This Contract may be executed in [number of counterparts] counterparts, each of which shall be deemed an original and all of which shall constitute one and the same instrument.In witness whereof, the parties have executed this Contract on the dates indicated below.Developer:Principal:(Authorized Representative) (Authorized Representative)Date: Date:Place: Place:------------------------------------------------------------------------ 签名与印章应分别在上述打印日期下方占据指定空间位置的位置上对齐插入以加强正式感与合法性表达。
技术合同范本英文
技术合同范本英文TECHNOLOGY AGREEMENTThis Technology Agreement (the "Agreement") is made and entered into as of the __________ day of __________, 20__, by and between __________ (the "Licensor"), a __________ with a registered address at __________, and __________ (the "Licensee"), a __________ with a registered address at__________.1. Purpose of the AgreementThe Licensor desires to grant to the Licensee a non-exclusive, non-transferable license to use certain proprietary technology, and the Licensee desires to obtain such licensefor the purposes of __________.2. DefinitionsFor the purposes of this Agreement, the following terms shall have the meanings set forth below:- "Confidential Information" means any information disclosedby one party to the other which is marked as confidential or which should be reasonably understood to be confidentialgiven the nature of the information and the circumstances of disclosure.- "Intellectual Property Rights" means all patents, copyrights, trademarks, trade secrets, and other proprietary rights, including applications and registrations for any ofthe foregoing.- "Licensed Technology" means the specific technology, including but not limited to patents, know-how, and processes, owned by the Licensor and licensed to the Licensee under this Agreement.3. Grant of LicenseThe Licensor hereby grants to the Licensee a non-exclusive, non-transferable, revocable license to use the Licensed Technology solely for the purpose of __________. The Licensee shall not have the right to sublicense the LicensedTechnology without the prior written consent of the Licensor.4. TermThis Agreement shall commence on the Effective Date and shall continue for a period of __________ (the "Term"), unlessearlier terminated in accordance with the provisions of this Agreement.5. ConsiderationIn consideration for the rights granted under this Agreement, the Licensee shall pay to the Licensor a royalty fee of__________ percent (__________%) of the net sales of products incorporating the Licensed Technology.6. ConfidentialityThe Licensee agrees to keep confidential all Confidential Information received from the Licensor and to use such information solely for the purposes of this Agreement. The obligations of confidentiality shall survive the terminationor expiration of this Agreement.7. OwnershipThe Licensor retains all right, title, and interest in and to the Licensed Technology, including all Intellectual Property Rights associated therewith. The Licensee acknowledges the Licensor's ownership and agrees not to take any action that would impair the Licensor's rights.8. Warranty and RepresentationsThe Licensor represents and warrants that it has the right to grant the license to the Licensee and that the Licensed Technology does not infringe upon any third-partyIntellectual Property Rights.9. IndemnificationThe Licensor shall indemnify and hold harmless the Licensee from any and all claims, damages, and expenses arising from any third-party claim that the Licensed Technology infringes upon any third-party Intellectual Property Rights.10. TerminationEither party may terminate this Agreement upon __________days' written notice if the other party breaches any material term or condition of this Agreement and fails to cure such breach within __________ days after receipt of written notice.11. Effect of TerminationUpon termination of this Agreement, all rights granted to the Licensee hereunder shall cease, and the Licensee shallpromptly return or destroy all materials containing the Licensed Technology.12. Governing Law and JurisdictionThis Agreement shall be governed by and construed in accordance with the laws of the __________ without giving effect to any choice of law or conflict of law provisions. Any disputes arising out of or in connection with this Agreement shall be resolved by the courts of __________.13. Entire AgreementThis Agreement constitutes the entire agreement between the parties with respect to the subject matter hereof and supersedes all prior agreements and understandings, whether written or oral.14. AmendmentsThis Agreement may be amended only in writing signed by both parties.15. NoticesAll notices, requests, demands, and other communications required or permitted hereunder shall be in writing and shall be deemed given when delivered personally or by overnight courier service, or three days after being sent by certified mail, postage prepaid, return receipt requested, to the respective addresses set forth above or to such other address as either party may designate in writing.IN WITNESS WHEREOF, the parties have executed this Agreement as of the date first above written.__________ [Licensor] __________ [Licensee]By: __________ By: __________ Name: __________ Name: __________ Title: __________ Title: __________。
英文技术开发合同7篇
英文技术开发合同7篇篇1Development Contract for Technology in English甲方（委托方）：____________________（Name of Client）地址：____________________（Address）联系方式：____________________（Contact Information）乙方（开发方）：____________________（Name of Developer）地址：____________________（Address）联系方式：____________________（Contact Information）鉴于甲方需要对特定技术进行开发，而乙方具备相关技术开发的实力和经验，双方在平等、自愿、公平的基础上，经过友好协商，达成以下技术开发合同协议：一、合同目的和背景本合同旨在明确甲、乙双方在技术开发项目中的权利与义务，确保双方合作顺利进行，共同实现技术开发的成功。
二、开发内容和目标（详细说明开发项目的名称、内容、目标、预期成果等）三、开发时间和进度安排（明确开发项目的起始日期、预计完成日期、各个阶段的时间节点和主要任务等）四、知识产权归属1. 乙方在本合同期间所完成的技术成果及其知识产权归甲方所有。
2. 未经甲方书面同意，乙方不得将本合同约定的技术成果转让给第三方。
3. 双方共同保守本合同约定的技术秘密和商业秘密。
五、费用支付和结算方式1. 甲方应按照约定的时间和金额支付乙方的开发费用。
2. 开发费用包括研发费用、材料费、差旅费等，具体金额和支付方式由双方另行约定。
3. 若因甲方原因导致开发进度延误，甲方应相应调整支付时间。
六、质量保证和技术支持1. 乙方应保证开发的技术成果符合约定的质量要求。
2. 甲方在开发过程中遇到技术问题，乙方应提供必要的技术支持。
3. 乙方应确保所提供的技术成果不侵犯第三方的知识产权。
技术支援英文合同3篇
技术支援英文合同3篇篇1合同编号：[具体编号]甲方（客户）：[甲方公司名称]地址：[甲方公司地址]乙方（服务提供商）：[乙方公司名称]地址：[乙方公司地址]根据《中华人民共和国合同法》及相关法律法规的规定，甲乙双方在平等、自愿、公平、诚实信用的基础上，就甲方所需的技术支援服务达成以下协议：一、服务内容乙方将为甲方提供技术支援服务，具体内容如下：1. 技术咨询：就甲方提出的技术问题提供解答和建议。
2. 技术培训：为甲方人员提供相关技术培训。
3. 故障排除：协助甲方解决技术故障，确保设备正常运行。
4. 系统升级：根据甲方需求，协助完成相关系统的升级工作。
5. 其他技术支援服务：[其他服务内容]二、服务期限本合同的服务期限自XXXX年XX月XX日起至XXXX年XX月XX 日止。
三、服务费用及支付方式1. 服务费用：人民币[金额]元。
2. 支付方式：[支付方式描述]。
3. 付款期限：[付款期限描述]。
四、双方责任与义务1. 甲方应确保所需服务的设备、环境等条件满足要求，配合乙方完成服务任务。
2. 乙方应按照合同约定的内容和期限提供服务，确保服务质量。
3. 乙方在提供服务过程中，应保护甲方的商业秘密和技术秘密，不得泄露或非法使用。
4. 双方应共同遵守国家法律法规，维护数据安全。
五、保密条款1. 双方同意对在执行本合同过程中了解到的对方商业秘密和技术秘密予以保密。
2. 未经对方许可，任何一方不得向第三方泄露、披露或公开涉及对方商业秘密和技术秘密的信息。
3. 保密期限为本合同生效之日起至合同终止后两年。
六、违约责任1. 若因乙方原因未按合同约定提供服务，乙方应承担违约责任，并赔偿甲方因此造成的损失。
2. 若甲方未按合同约定支付服务费用，甲方应承担违约责任。
3. 若因不可抗力导致合同无法履行，双方应及时沟通，协商解决。
七、争议解决因执行本合同所引起的任何争议，双方应通过友好协商解决；协商不成的，任何一方均有权向有管辖权的人民法院提起诉讼。
英文技术合同模板
英文技术合同模板This Technology Contract (“Contract”) is made and entered into as of [Date], by and between [Company Name], a company organized and existing under the laws of[State/Country], having its principal place of business at [Address], hereinafter referred to as “Company”, and [Vendor Name], a company organized and existing under the laws of [State/Country], having its principal place of business at [Address], hereinafter referred to as “Vendor”.1. Scope of WorkVendor agrees to provide technology services and support to Company as detailed in the Scope of Work attached hereto as Exhibit A. Vendor shall provide all services in a timely and professional manner in accordance with best industry practices.2. PaymentCompany agrees to pay Vendor the fees as outlined in Exhibit A for the technology services provided. Payment shall be made [payment terms]. In the event that payment is not made on time, Company shall be liable for any late fees or interest charges as set forth in this Contract. All fees are non-refundable.3. Term and TerminationThis Contract shall commence on the Effective Date and shall continue for a period of [Term] months/years, unless earlier terminated by either party upon [Notice Period] prior written notice. Upon termination, Vendor shall cease providing services and Company shall pay any outstanding fees.4. ConfidentialityVendor agrees to maintain the confidentiality of all Company information and shall not disclose any confidential information to any third party without Company’s prior written consent. Vendor shall take all necessary measures to protect and secure Company’s confidential information.5. Intellectual PropertyAll intellectual property, including but not limited to software, code, and designs developed by Vendor in connection with the services provided under this Contract shall be the exclusive property of Company. Vendor agrees to assign, transfer, and convey all rights, title, and interest in and to such intellectual property to Company.6. IndemnificationVendor agrees to indemnify, defend, and hold harmless Company from and against any and all claims, damages, losses, liabilities, and expenses arising out of or related to Vendor’s performance under this Contract.7. Limitation of LiabilityIn no event shall either party be liable to the other party for any indirect, incidental, consequential, special, or punitive damages arising out of or related to this Contract, even if such party has been advised of the possibility of such damages.8. Governing LawThis Contract shall be governed by and construed in accordance with the laws of[State/Country]. Any disputes arising out of or relating to this Contract shall be subject to the exclusive jurisdiction of the courts of [State/Country].9. Entire AgreementThis Contract constitutes the entire agreement between the parties with respect to the subject matter hereof and supersedes all prior and contemporaneous agreements and understandings, whether written or oral, relating to such subject matter.IN WITNESS WHEREOF, the parties hereto have executed this Contract as of the Effective Date.[Company Name] [Vendor Name]By: [Authorized Signatory] By: [Authorized Signatory]Title: [Title] Title: [Title]Date: [Date] Date: [Date]。
技术服务合同,英文版
技术服务合同,英文版篇一：技术服务合同中英对照2技术开发合同项目名称：基于脂质分子的思普定30纳米颗粒制剂projectname：Lipid-basednanoparticleformulationofSiP30签订时间：20XX-12-25Signingtime：25/12/20XX签订地点：苏州晶奇生物纳米技术有限公司有限公司Signinglocation：JingQibio-nanotechnology.,LTd委托方（甲方）：苏州晶奇生物纳米技术有限公司有限公司consignor：JingQibio-nanotechnology.,LTd电话：+86051286860521Tel：+86051286860521通讯地址：苏州星湖街218号生物纳米园a2-327adress：Room327,Blda2，no.218XinghuRoad，BioBaY,Suzhou，PRc 传真：+86-0512-********Fax:+86-0512-********受托方（乙方）：美国引药明创药业科技有限公司consignee:innovformTherapeutics，LLc通讯地址：116Researchdrive,Bethlehem,Pa18015USaadress：116Researchdrive,Bethlehem,Pa18015USa.电话：_001-609-558-7055_____Tel:本合同甲方委托乙方就__基于脂质分子的思普定30纳米颗粒制剂项目进行专项技术服务，并支付相应的技术服务报酬。
双方经过平等协商，在真实、充分地表达各自意愿的基础上，根据《中华人民共和国合同法》的规定，达成如下协议，并由双方共同恪守。
JingQibio-nanotechnology.,LTdentrustsRutgersUniversitytodoexperiment ofLipid-basednanoparticleformulationofSiP30andpayTechnicalservicerem uneration.Twopartsagreeasfollowsaccordingtotheprovisionsofthecontractl awofthePeople'sRepublicofchina,onthe basisoffullyexpresstheirwill.第一条甲方委托乙方进行技术服务的内容如下Thecontentofthetechnicalservice：技术服务的内容：基于脂质分子的思普定30纳米颗粒制剂实验content:experimentofLipid-basednanoparticleformulationofSiP30第二条乙方应按下列要求完成技术服务工作completetechnicalservicesasrequired1．技术服务地点：美国引药明创药业科技有限公司Locationoftechnicalservice：innovformTherapeutics，LLc2．技术服务期限：8个月Technicalserviceperiod：8months第三条为保证乙方有效进行技术服务工作，甲方应当向乙方提供下列工作条件和协作事项JinGQishouldoffersomeworkingconditionstoassureRUcouldcompletethejobperfectly1．提供技术资料；Providetechnicalinformation2．提供工作条件；Provideworkcondition 第四条甲方向乙方支付技术服务报酬及支付方式为ThewaythatJingQibio-nanotechnology.,LTdpayfortechnicalservicestoRU 1．技术术服务费由甲方（一次或分期）支付乙方。
英文技术服务合同样本5篇
英文技术服务合同样本5篇篇1TECHNOLOGY SERVICE CONTRACTThis Technology Service Contract is made on [Date], between [Company A], with its principal place of business located at [Address], hereinafter referred to as "Service Provider" and [Company B], with its principal place of business located at [Address], hereinafter referred to as "Client," in accordance with the laws of the [Country/State].1. Scope of ServicesService Provider agrees to provide the following technical services to Client:* Detailed list of services (including but not limited to technology consulting, software development, system integration, technical support, etc.)* Description of tasks, milestones, deliverables, and project management related to each service item.2. Contract TermThe term of this Contract shall begin on the date of signing and shall continue until the services are fully performed or until the Contract is terminated in accordance with its terms.3. Fees and Payment* The total fees for the services to be provided by Service Provider shall be [Amount]. The fees shall be paid in full according to the payment schedule agreed upon by both parties.* Any additional services not listed in the Scope of Services section shall be agreed upon separately and shall be subject to additional fees.* All fees are exclusive of taxes, which Client shall be responsible for paying.4. ConfidentialityBoth parties shall maintain confidentiality regarding any information or data disclosed during the performance of this Contract. This includes any business secrets, proprietary information, technical know-how, and other confidential matters.5. Intellectual Property Rights* Service Provider shall retain ownership of all intellectual property rights related to the services provided unless otherwise agreed in writing.* Client shall have non-exclusive, non-transferable rights to use any deliverables resulting from the services provided under this Contract.* Any joint intellectual property developed during the term of this Contract shall be owned equally by both parties.6. Warranty and LiabilityService Provider shall ensure that the services provided are performed in a professional and workmanlike manner and are free from defects. If any defects are found, Service Provider shall promptly rectify them at no additional cost to Client. Service Provider shall not be liable for any indirect, consequential, or exemplary damages arising from the performance or breach of this Contract.7. TerminationThis Contract may be terminated by either party in the case of default by the other party, if the default is not rectified within a reasonable period of time. Termination shall be subject towritten notice and compliance with all applicable laws and procedures.8. Force MajeureNeither party shall be liable for any delay or failure in performance due to unforeseen circumstances or acts of God, such as natural disasters, wars, riots, or other events beyond their reasonable control.9. Miscellaneous* This Contract constitutes the entire agreement between the parties and supersedes all prior agreements or understandings, whether oral or written, regarding the subject matter hereof.* Any amendments or modifications to this Contract must be made in writing and signed by both parties.* Any disputes arising out of or in connection with this Contract shall be settled through friendly negotiations. If no settlement can be reached, either party may submit the dispute to [Dispute Resolution Mechanism/Court] for resolution.* This Contract shall be governed by the laws of [Country/State].* The headings in this Contract are for reference purposes only and shall not affect the interpretation or construction of any provisions herein.* The words "include," "includes," and "including" shall be deemed to be followed by the phrase "without limitation."In witness whereof, the parties have executed this Technology Service Contract:Service Provider:__________ (Signature)Title/NameDateClient:__________ (Signature)Title/Name篇2甲方（客户）：__________地址：__________联系方式：__________乙方（服务提供商）：__________地址：__________联系方式：__________鉴于甲方需要乙方提供特定的技术服务，双方经过友好协商，达成如下协议：一、服务内容（Scope of Services）1. 乙方将为甲方提供______技术服务。
技术开发合同英文 示范文本
技术开发合同英文示范文本I. Parties Involved.Party A (The Entrusting Party):Full name: [Company/Individual Name of Party A]Address: [Address of Party A]Contact person: [Name of Contact Person]Phone number: [Phone Number]Email: [Email Address]Party B (The Contractor):Full name: [Company/Individual Name of Party B]Address: [Address of Party B]Contact person: [Name of Contact Person]Phone number: [Phone Number]Email: [Email Address]II. Background and Purpose.Party A has some specific technological needs in [describe the general area, like "mobile app development" or "new manufacturing process improvement"]. Party B is an expert in relevant technology fields and has the ability to carry out the development work. So, the two parties reach this contract to jointly promote the development of this technology.III. Technical Development Content.1. Project Name.The name of this technology development project is: [Project Name]2. Specific Technical Requirements.Party A hopes that Party B can develop a system/technology/product with the following functions:[Function 1, describe it in detail, e.g., "A user friendly interfacethat allows users to easily input their personal information."][Function 2][Function 3]...The technology should meet the following performance standards:[Performance Standard 1, such as "The response time should be within 2 seconds."][Performance Standard 2][Performance Standard 3]...3. Development Plan and Milestones.Party B will follow the following development plan:In the first [number] weeks/months, complete the basic framework design. This includes [describe what is included in the basic framework].By the end of [specific time period], finish the key function development. For example, [mention the key functions to be completed].In the final [number] weeks/months, conduct comprehensive testing and debugging to ensure that all functions work properly and meet the performance standards.Party A has the right to check the progress at each milestone. If Party B fails to meet the milestone requirements on time, Party B should take immediate remedial measures and inform Party A in advance.IV. Intellectual Property Rights.1. Ownership of Intellectual Property.All intellectual property rights related to the developed technology, including but not limited to patents, copyrights, and trade secrets, shall belong to Party A. Party B agrees to transfer all relevant rights to PartyA upon completion of the project.However, Party B can use the relevant technology for internal research and improvement purposes, but not for any commercial use without thewritten permission of Party A.2. Confidentiality.Both parties shall keep the technical information, business secrets,and any other confidential information related to this project confidential.The confidentiality period is [number] years from the date of signing this contract.V. Consideration and Payment Terms.1. Total Consideration.Party A shall pay Party B a total of [amount in currency] for this technology development project.2. Payment Schedule.An initial payment of [amount] shall be made within [number] days after signing this contract. This payment is to cover Party B's initial research and preparation costs.After Party B completes the key milestone [describe the milestone], Party A shall pay [amount].The final payment of [amount] will be made upon successful completion of the project and acceptance by Party A.VI. Project Acceptance.1. Acceptance Criteria.Party A will accept the project based on the technical requirements and performance standards specified in this contract.Party B shall submit all relevant technical documents, including design documents, test reports, and user manuals, to Party A for review.2. Acceptance Procedure.Party B shall notify Party A in writing when the project is ready for acceptance.Party A shall organize relevant personnel to conduct acceptance tests within [number] days after receiving the notice.If the project fails to pass the acceptance test, Party B shall make necessary modifications and re submit for acceptance within [number] days.VII. Liability for Breach of Contract.1. By Party A.If Party A fails to make payments on time according to the payment schedule, Party A shall pay a late fee of [percentage] of the overdue amount per day.If Party A unilaterally terminates the contract without justifiable reasons, Party A shall compensate Party B for all losses already incurred and the expected profit of the unfinished part of the project.2. By Party B.If Party B fails to complete the project on time or fails to meet the technical requirements and performance standards, Party B shall refund all payments already received from Party A and compensate Party A for any losses caused thereby.If Party B discloses confidential information of Party A, Party B shall bear all legal liabilities and compensate Party A for all losses.VIII. Governing Law and Dispute Resolution.1. Governing Law.This contract shall be governed by the laws of [specific jurisdiction, like "the laws of the State of California" or "the laws of the People's Republic of China"].2. Dispute Resolution.In case of any disputes arising from this contract, the two parties shall first try to resolve them through friendly negotiation.If the negotiation fails, either party can submit the dispute to [specific arbitration body or court] for arbitration or litigation.IX. Miscellaneous.1. Amendments and Supplements.Any amendments or supplements to this contract shall be made in writing and signed by both parties.2. Entire Agreement.This contract constitutes the entire agreement between the two parties with respect to the subject matter hereof and supersedes all prior oral or written agreements and understandings relating to the same.3. Severability.If any provision of this contract is held to be invalid or unenforceable, the validity and enforceability of the remaining provisions shall not in any way be affected.This contract is made in duplicate, with each party holding one copy. The contract shall come into force as of the date of signing by both parties.Party A (Signature): [Authorized Signature of Party A]Date: [Date of Signing]Party B (Signature): [Authorized Signature of Party B]Date: [Date of Signing]。
技术开发合同英文版示范文本
技术开发合同英语示范文本1Technology development contracts play a crucial role in modern business, especially in the fields of software and hardware. A well-structured technology development contract clearly defines the rights and obligations of both parties, minimizing potential disputes and ensuring the smooth progress of the project.Let's take a software technology development contract as an example. Intellectual property rights are a key element. It should be clearly stipulated who owns the rights to the software developed, whether it's the developer or the client. For instance, if the client commissions a software for internal use only, the contract might state that the client has exclusive rights to use the software within their organization, but the developer retains the right to reuse certain components for other projects.In the case of hardware technology development, detailed specifications for product performance indicators are of great significance. The contract might specify parameters such as processing speed, power consumption, and durability. For example, in the development of a new type of mobile phone chip, the contract could require that the chip must achieve a certain benchmark in processing speed and energy efficiency to meet market expectations.Another important aspect is the timeline for the project. The contract should clearly outline the milestones and deadlines for each stage of the development process. This helps to ensure that the project stays on track and is delivered on time.In conclusion, a comprehensive and precise technology development contract is essential for the success of any technology-related project. It not only protects the interests of both parties but also lays a solid foundation for efficient collaboration and the achievement of common goals.2Technology development contracts play a crucial role in modern business and research scenarios. They serve as legal bindings that safeguard the interests of all parties involved. Let's take an example of a company collaborating with a scientific research institution to develop a new technology. In such a contract, the rights and obligations of both sides are clearly stipulated. The company might commit to providing financial resources and marketing support, while the research institution is responsible for conducting the technical research and development work. The contract would detail the timeline for each stage of the project, the ownership of intellectual property rights, and the mechanisms for resolving disputes.Another instance could be a startup team signing a technology development contract with an investor. This contract would clearly definethe investment amount and the usage of funds. The startup team might be obligated to achieve certain milestones within a specified time frame. At the same time, the investor would have the right to monitor the progress and have a say in major decisions. The contract would also address issues such as the exit strategy for the investor and the consequences of non-compliance by either party.In conclusion, technology development contracts are not just pieces of paper; they are powerful tools that ensure fairness, clarity, and protection. They provide a solid foundation for successful collaborations and innovations, allowing both parties to focus on achieving their common goals with confidence and security.3Technology development contracts play a crucial role in modern business transactions. However, they often come with hidden traps that one must be aware of. One common pitfall is the ambiguity in the technical standards stipulated in the contract. For instance, if the contract merely states that the developed technology should be "advanced" without clearly defining what constitutes "advanced", it can lead to significant disputes later on. The parties might have different understandings of this term, resulting in delays, extra costs, and even legal battles.Another potential risk lies in unreasonable confidentiality clauses. Say a contract demands an overly broad and long-term confidentialityobligation, which could severely restrict the developer's ability to collaborate with others or use similar technologies in future projects. This might prevent the developer from making legitimate advancements and limit their business opportunities.To prevent such issues, it is essential to have a detailed and precise contract. All technical standards should be clearly defined using measurable and objective criteria. When it comes to confidentiality, the scope and duration should be reasonable and balanced, taking into account the nature of the technology and the industry norms.In conclusion, a well-drafted technology development contract that anticipates and mitigates these potential traps is crucial for the success of the project and the protection of the interests of all parties involved.4Technology development contracts play a crucial role in driving innovation and progress in various industries. Different types of these contracts exhibit distinct characteristics and disparities.Take the contrast between internet technology development contracts and those in traditional manufacturing. In terms of delivery standards, for internet technology, the focus might be on seamless user experience, high performance, and scalability. The software or applications need to be compatible with a wide range of devices and operating systems. On the contrary, in traditional manufacturing, the delivery standard often lies inthe physical product meeting precise specifications, quality benchmarks, and functional requirements. Regarding the acceptance methods, for internet technology, it usually involves extensive testing of the software's functionality, security, and performance through automated tools and user feedback. However, in traditional manufacturing, physical inspections, quality checks, and performance evaluations of the manufactured products are common.Another example is the comparison between multinational and domestic technology development contracts. When it comes to legal application, multinational contracts have to navigate through the complex web of different legal systems and international laws. Cultural differences also pose significant considerations. Language barriers, diverse business practices, and different expectations regarding project timelines and communication styles can all impact the success of the contract. In domestic contracts, the legal framework is relatively uniform, and cultural understanding is typically more straightforward.In conclusion, understanding the unique features and differences of various types of technology development contracts is essential for achieving successful technological advancements and business collaborations in today's globalized and diverse marketplace.5Technology development contracts play a crucial role in both the legaland business domains. They serve as the foundation for successful collaborations and innovations in the technological landscape.Consider a case where a well-structured and comprehensive technology development contract was in place. A leading tech company joined forces with a research institution to develop a revolutionary software. The contract clearly defined the rights and obligations of each party, including the scope of the project, timelines, intellectual property rights, and financial arrangements. As a result, the project progressed smoothly, and the new software not only met but exceeded expectations. It led to a significant increase in market share for the company and established it as an industry leader.On the contrary, imagine a situation where a technology development contract had loopholes and ambiguous terms. A startup entered into a partnership with a larger firm to create a cutting-edge hardware device. However, due to the lack of clear provisions regarding the sharing of profits and the ownership of patents, disputes arose during the development process. This led to delays, increased costs, and ultimately, the failure of the project. The startup suffered substantial financial losses and lost valuable time and opportunities.In conclusion, a well-drafted technology development contract is not just a piece of paper; it is the blueprint for success. It ensures that all parties involved have a clear understanding of their roles and responsibilities,mitigates risks, and protects the interests of both sides. Only through careful consideration and precise drafting can these contracts drive technological advancements and business growth.。
技术服务合同版中英文(实用17篇)
技术服务合同版中英文（实用17篇）（经典版）编制人：__________________审核人：__________________审批人：__________________编制单位：__________________编制时间：____年____月____日序言下载提示：该文档是本店铺精心编制而成的，希望大家下载后，能够帮助大家解决实际问题。
文档下载后可定制修改，请根据实际需要进行调整和使用，谢谢!并且，本店铺为大家提供各种类型的经典范文，如职场文书、公文写作、党团资料、总结报告、演讲致辞、合同协议、条据书信、心得体会、教学资料、其他范文等等，想了解不同范文格式和写法，敬请关注!Download tips: This document is carefully compiled by this editor. I hope that after you download it, it can help you solve practical problems. The document can be customized and modified after downloading, please adjust and use it according to actual needs, thank you!Moreover, this store provides various types of classic sample essays for everyone, such as workplace documents, official document writing, party and youth information, summary reports, speeches, contract agreements, documentary letters, experiences, teaching materials, other sample essays, etc. If you want to learn about different sample formats and writing methods, please pay attention!技术服务合同版中英文（实用17篇）技术合同是保障技术交流和合作的重要依据，具有明确的权利和义务。
技术服务合同范本英文
技术服务合同范本英文当然，以下是一个简单的技术服务合同范本的英文示例：TECHNICAL SERVICE AGREEMENTThis Technical Service Agreement (the "Agreement") is entered into as of [Date], by and between [Client Name], a company incorporated under the laws of [Client Jurisdiction], withits principal place of business at [Client Address] (hereinafter referred to as "Client"), and [Service Provider Name], a company incorporated under the laws of [Service Provider Jurisdiction], with its principal place of business at [Service Provider Address] (hereinafter referred to as "Service Provider").1. Purpose of the AgreementThe purpose of this Agreement is to set forth the terms and conditions under which the Service Provider shall provide certain technical services to the Client.2. Scope of Services2.1 The Service Provider agrees to provide the following technical services: [List of Services].2.2 The scope of the services shall be as detailed in theattached Exhibit A.3. Term of AgreementThis Agreement shall commence on [Start Date] and continueuntil terminated by either party upon [Notice Period].4. Payment Terms4.1 The Client shall pay the Service Provider for theservices rendered as per the attached Exhibit B.4.2 All payments shall be made within [Payment Period] days from the date of invoice.5. Warranties and Representations5.1 The Service Provider warrants that it has the necessary expertise and qualifications to provide the services.5.2 The Client represents that it has the right to enter into this Agreement and to perform its obligations hereunder.6. ConfidentialityBoth parties agree to keep confidential any information disclosed by one party to the other during the term of this Agreement.7. TerminationEither party may terminate this Agreement upon [Notice Period] days written notice to the other party.8. Governing LawThis Agreement shall be governed by and construed in accordance with the laws of [Governing Jurisdiction].9. Entire AgreementThis Agreement constitutes the entire agreement between the parties concerning the subject matter hereof and supersedes all prior agreements and understandings, both written and oral.IN WITNESS WHEREOF, the parties have executed this Agreement as of the date first above written.[Client Name] [Service Provider Name]By:\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\ _\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_ \_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\ _\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_ \_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\ _\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_ \_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_[Authorized Signature][Title][Date]By:\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\ _\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_ \_。
技术合同英文范本3篇.doc
技术合同英文范本3篇有技术，不怕没有工作!英文技术合同对推进我国对外贸易事业的发展具有重要意义，在现代发展中使用越来越多。
技术合同英文范文篇一甲方：party a：乙方：party b：合同编号：contract no日期：date：签约地点：signed at：特约定：甲方基于下文所列各种因素，特与乙方达成了协议并一致同意：由甲方在订约日期之翌日起_____天之内为乙方建造并完成_____(涉约建筑)。
涉约建筑之规模及所需的钢筋、水泥、砖块、石子和其它建筑材料之数量，均在作为合同附件的设计图和施工细则中予以说明。
witnesses that the party a for considerations hereinafter named, contracts and agrees with the party b that party a will, within_____ days, next following the date hereof, build and finish a libarary building for party b. ( the building hereinafter is referred to as the said building.) the said building is of the following dimensions, with reinforced concrete, brick, stones and other materials, as are described in plans and specifications gereto annexed.基于上述情况，乙方及其法定代表郑重承诺向甲方支付人民币_____元整。
支付方法商定如下：in consideration of the foregoing, party b shall, for itself and its legal representatives, promise to pay party a the sum of one million rmb yuan in manner as follows, to wit：在上述工程开工之日，支付人民币_____元整在_____年_____月_____日，支付人民币_____元整甲方：party a：乙方：party b：合同编号：contract no日期：date：签约地点：signed at：技术合同英文范文篇二合同contract日期：合同号码：date: contract no.:买方：(the ;buyers) 卖方：(the sellers)兹经买卖双方同意按照以下条款由买方购进，卖方售出以下商品：this contract is made by and between the buyers and the sellers; whereby the buyers agree to buy and the sellers agree to sell the under-mentioned goods subject to the terms and conditions asstipulated hereinafter: (1) 商品名称: name of commodity：(2) 数量：quantity:(3) 单价：unit price:(4) 总值：total value:(5) 包装：packing:(6) 生产国别：country of origin : (7) 支付条款：terms of payment: (8) 保险：insurance:(9) 装运期限：time of shipment: (10) 起运港：port of lading: (11) 目的港：port of destination:(12)索赔：在货到目的口岸45天内如发现货物品质，规格和数量与合同不附，除属保险公司或船方责任外，买方有权凭中国商检出具的检验证书或有关文件向卖方索赔换货或赔款。
- 1、下载文档前请自行甄别文档内容的完整性，平台不提供额外的编辑、内容补充、找答案等附加服务。
- 2、"仅部分预览"的文档,不可在线预览部分如存在完整性等问题,可反馈申请退款(可完整预览的文档不适用该条件!)。
- 3、如文档侵犯您的权益，请联系客服反馈,我们会尽快为您处理(人工客服工作时间：9:00-18:30)。
协议编号：LX-FS-A36339 技术合同英文标准范本
After Negotiation On A Certain Issue, An Agreement Is Reached And A Clause With Economic Relationship Is Concluded, So As To Protect Their Respective Legitimate Rights And Interests.
编写：_________________________
审批：_________________________
时间：________年_____月_____日
A4打印/ 新修订/ 完整/ 内容可编辑
技术合同英文标准范本
使用说明：本协议资料适用于经过谈判或共同协商的某个问题，在取得一致意见后并订立的具有经济或其它关系的契约条款，最终实现保障各自的合法权益的结果。
资料内容可按真实状况进行条款调整，套用时请仔细阅读。
合同contract
日期：合同号码：
date: contract no.:
买方：(the ;buyers) 卖方：(the sellers)
兹经买卖双方同意按照以下条款由买方购进，卖方售出以下商品：
this contract is made by and between the buyers and the sellers; whereby the buyers agree to buy and the sellers agree to sell the under-mentioned goods subject to the terms and conditions as stipulated hereinafter:
(1) 商品名称:
name of commodity：(2) 数量：quantity:
(3) 单价：
unit price:
(4) 总值：
total value:
(5) 包装：packing:
(6) 生产国别：country of origin : (7) 支付条款：
terms of payment: (8) 保险：
insurance:
(9) 装运期限：
time of shipment:
(10) 起运港：
port of lading:
(11) 目的港：
port of destination:
(12)索赔：在货到目的口岸45天内如发现货物品质，规格和数量与合同不附，除属保险公司或船方责任外，买方有权凭中国商检出具的检验证书或有关文件向卖方索赔换货或赔款。
claims:
within 45 days after the arrival of the goods at the destination, should the quality, specifications or quantity be found not in
conformity with the stipulations of the contract except those claims for which the insurance company or the owners of the vessel are liable, the buyers shall, have the right on the strength of the inspection certificate issued by the c.c.i.c and the relative documents to claim for compensation to the sellers
(13)不可抗力：由于人力不可抗力的原由发生在制造，装载或运输的过程中导致卖方延期交货或不能交货者，卖方可免除责任,在不可抗力发生后，卖方须立即电告买方及在14天内以空邮方式向买方提供事故发生的证明文件，在上述情况下，卖方仍须负责采取措施尽快发货。
force majeure :
the sellers shall not be held responsible for
the delay in shipment or non-deli-very of the goods due to force majeure, which might occur during the process of manufacturing or in the course of loading or transit. the sellers shall advise the buyers immediately of the occurrence mentioned above the within fourteen days there after . the sellers shall send by airmail to the buyers for their acceptancea certificate of the accident. under such circumstances the sellers, however, are still under the obligation to take all necessary measures to hasten the deliveryof the goods.
(14)仲裁：凡有关执行合同所发生的一切争议应通过友好协商解决，如协商不能解决，则将分歧提交中国国际贸易促进委员会按有关仲裁程序进行仲裁，
仲裁将是终局的，双方均受其约束，仲裁费用由败诉方承担。
arbitration :
all disputes in connection with the execution of this contract shall be settled friendly through negotiation. in case no settlement can be reached, the case then may be submitted for arbitration to the arbitration commission of the china council for the promotion of international trade in accordance with the provisional rules of procedure promulgated by the said arbitration commission . the arbitration committee shall be final and binding upon both parties. and the arbitration fee shall be borne by the losing
parties.
买方：卖方:
(授权签字) (授权签字)
请在该处输入组织/单位名称
Please Enter The Name Of Organization / Organization Here。