最新工程设计合同(中英文)

合集下载

中英文建筑工程合同(Contract of Construction Project)

建设工程合同Contract of Construction Project合同编号：Contract Number:工程名称：Project Name:发包方（甲方）：_________________________Employer (Party A):_________________________承包方（乙方）：_________________________Contractor (Party B): _________________________根据《中华人民共和国合同法》和《建筑安装工程承包合同条例》及有关规定，为明确双方在施工过程中的权利、义务和经济责任，经双方协商同意签订本合同。

In order to make definite of the rights, obligations and economic responsibilities of both parties during the construction, the parties, in accordance with The PRC Contract Law and Construction Engineering Contract Regulations and relevant provisions, agree to sign this contract.第一条工程项目Article 1, Project item1．工程地点：Project site:2. 工程范围：Scope of project3. 工程造价：人民币元整(该造价为包工包料价)Project cost: PMB Yuan only(Cost of this contract is the contract price for labor and materials)第二条施工准备Article 2, Preparation for construction1．甲方协助乙方办理临时水电及垂直运输,提供建筑图纸及有关隐蔽障碍物的资料。

设计合同英文模板免费

设计合同英文模板免费This Design Contract ("Contract") is made effective as of [Date] by and between [Designer Name] ("Designer"), with an address at [Designer Address], and [Client Name] ("Client"), with an address at [Client Address].1. Scope of Work1.1 Designer agrees to provide the following design services to Client:- [Description of design services]1.2 Client agrees to provide Designer with all necessary information, materials, and feedback to complete the design services in a timely manner.2. Payment2.1 Client agrees to pay Designer a total fee of [Amount] for the design services, payable as follows:- [Payment schedule]2.2 Client agrees to pay Designer a deposit of [Amount] upon signing this Contract. The remaining balance shall be paid upon completion of the design services.2.3 All payments shall be made in [Currency] via [Payment method].3. Intellectual Property3.1 Designer retains all rights to the original designs created for Client. Client is granted a non-exclusive, perpetual, and worldwide license to use the designs for the intended purpose.3.2 Designer may use Client's name and project details for promotional purposes, unless otherwise agreed upon in writing.4. Revisions4.1 Client is entitled to [Number of revisions] rounds of revisions to the designs. Additional revisions may be subject to additional fees.4.2 Client agrees to provide prompt feedback on the designs to avoid delays in the project timeline.5. Delivery5.1 Designer agrees to deliver the final design files to Client in the following format: [File format].5.2 Client agrees to review the final design files and notify Designer of any necessary revisions within [Number of days] days of delivery.6. Termination6.1 Either party may terminate this Contract with written notice if the other party breaches any material term of the Contract and fails to remedy the breach within [Number of days] days of receiving notice.6.2 In the event of termination, Client shall pay Designer for all work completed up to the termination date.7. Confidentiality7.1 Both parties agree to keep confidential all information shared during the course of the project, including but not limited to design concepts, client lists, and project details.7.2 Designer agrees not to disclose Client's confidential information to third parties without Client's consent.8. Governing Law8.1 This Contract shall be governed by and construed in accordance with the laws of [State/Country].8.2 Any disputes arising out of this Contract shall be resolved through arbitration in [City], [State/Country].IN WITNESS WHEREOF, the parties have executed this Contract as of the date first written above.[Designer Name] [Client Name]______________________________ ______________________________Designer Signature Client Signature______________________________ ______________________________Date Date。

建设工程委托设计合同(中英文对照)

建设工程设计合同Construction Project Design Contract项目名称：Project Name:项目建设地点：Project Location:合同编号：Contract No.:设计证书等级：Grade of Design License:委托方：Client:承接方：Design Firm:签订日期：Signed on:委托方：（甲方）Client (Party A):承接方：（乙方）Design Firm (Party B):甲方委托乙方承担XX 项目（一期）工程设计，经双方协商一致，签订本合同。

Party A entrusts Party B to undertake the design for This Contract is made by the two parties after their mutual agreement.第一条本合同依据下列文件签订Article 1. This Contract is made on the basis of the following documents:1.1 《中华人民共和国合同法》、《中华人民共和国建筑法》和《建设工程勘察设计市场管理规定》。

1.1 《The Contract Law of the People’s Republic of China》,《The building regulations of thePeople’s Republic of China》and 《The developmental Law of the People’s Republic ofChina.1.2 国家及地方有关建设工程勘察设计管理法规和规章。

1.2 Relevant Building & Design Codes and Regulations of the State and of the ShanghaiMunicipality.1.3 建设工程的相关批准文件。

工程设计委托合同 (中英文)

工程设计委托合同（中英文）CONTRACT FOR CONSTRUCTION DESIGN客户方：设计方：双方本着公平、自愿和诚信的原则，经友好协商达成如下条款（包括基本条款以及其他条款两个部分）： Under the principles of fairness, free will and good will, IT IS HEREBY AGREED between both parties as follows (the Contract includes two parts, i.e. the General Articles and the Contingent Articles):-1.客户方委托设计方提供的建筑设计服务均以本合同各项条款、附录、附表以及双方为履行本合同相关内容所签订的补充协议等所约定的内容为准，设计方应按照双方的约定和客户方的要求完成― A‖工程设计的各项工作。

本合同的附录、附表、其他条款以及补充协议等附件是本合同不可分割的部分，具有与本协定书同等的法律效力。

The architectural design services that the Client appoints the Designer to provide shall be in compliance with the provisions, appendixes and exhibits of the Contract, as well as with the provisions in the supplementary agreements in conjunction with the execution of the Contract that have entered or may be entered between the parties. The Designer shall carry out the design tasks for ―A‖ Project according to the agreement between both parties as well as the requirements of the Client. Appendixes, exhibits, other articles and supplementary agreements of the Contract are integral part of the Contract, and shall have the same legal binding force with the Contract.2.客户方委托设计方为― A‖工程提供的详细设计服务项目全部列于本合同附表2——《设计服务项目清单》中，同时设计方承诺按照该附表中客户方的要求提供列明的全部服务项目。

委托设计合同,英文

委托设计合同,英文篇一：建设工程委托设计合同(中英文对照) 建设工程设计合同Construction Project Design Contract 项目名称：Project Name:项目建设地点：Project Location:合同编号：Contract No.:设计证书等级：Grade of Design License:委托方：Client:承接方：Design Firm:签订日期：Signed on:委托方：（甲方）Client (Party A):承接方：（乙方）Design Firm (Party B):甲方委托乙方承担XX 项目（一期）工程设计，经双方协商一致，签订本合同。

Party A entrusts Party B to undertake the design for This Contract is made by the two parties after their mutual agreement.第一条本合同依据下列文件签订Article 1. This Contract is made on the basis of the following documents:《中华人民共和国合同法》、《中华人民共和国建筑法》和《建设工程勘察设计市场管理规定》。

《The Contract Law of the People’s Republic of China》《,The building regulations of thePeople’s Republic of China》and 《The developmental Law of the People’s Republic of China.国家及地方有关建设工程勘察设计管理法规和规章。

Relevant Building & Design Codes and Regulations of the State and of the ShanghaiMunicipality.建设工程的相关批准文件。

工程设计合同范本英文

工程设计合同范本英文ENGINEERING DESIGN CONTRACTThis Engineering Design Contract (hereinafter referred to as "Contract") is made and entered into on this _______ day of ___________, ______, and between: Party A (Client):________________________Address: ___________________________________________Contact Person: ____________Party B (Designer):________________________Address: ___________________________________________Contact Person: ____________WHEREAS, Party A desires to engage Party B to provide engineering design services for the project described herein; andWHEREAS, Party B is willing to provide such services to Party A on the terms and conditions set forth herein;NOW, THEREFORE, in consideration of the mutual covenants and agreements herein contned, the parties hereto agree as follows:1. Scope of Work1.1 Party B shall provide to Party A the following engineering design services (hereinafter referred to as the "Services") for the project described in Exhibit A attached hereto (the "Project"):(a) ____________;(b) ____________;(c) ____________;(d) ____________;(e) ____________.1.2 The Services shall be performed in accordance with the technical requirements, standards, and specifications provided Party A and applicable laws and regulations.2. Time of Performance2.1 Party B shall mence the performance of the Services on ____________ and plete the Services on ____________.2.2 Party B shall submit to Party A a detled work schedule for the performance of the Services within ______ days after the signing of this Contract.3. Contract Price3.1 In consideration for the provision of the Services, Party A shall pay PartyB a contract price of ____________ (currency) (hereinafter referred to as the "Contract Price").3.2 The Contract Price shall be pd Party A to Party B in accordance with the following payment schedule:(a) ____________;(b) ____________;(c) ____________;(d) ____________.4. Representations and Warranties4.1 Party B represents and warrants that it has the necessary qualifications, experience, and resources to perform the Services in a professional and workmanlike manner.4.2 Party B represents and warrants that the Services will conform to the technical requirements, standards, and specifications provided Party A and applicable laws and regulations.5. Intellectual Property Rights5.1 All intellectual property rights, including but not limited to patents, copyrights, and trade secrets, arising from or related to the performance of the Services shall belong to Party A.5.2 Party B shall indemnify and hold harmless Party A agnst any and all clms, damages, losses, liabilities, and expenses arising out of or related to any infringement of intellectual property rights the Services.6. Confidentiality6.1 Each party acknowledges that it may have access to confidential information of the other party in connection with this Contract. The parties agree to mntn the confidentiality of such information and not to use or disclose it to any third party without the prior written consent of the other party, except as required law.7. Force Majeure7.1 Neither party shall be liable for any flure or delay in the performance of its obligations under this Contract due to any cause beyond its reasonable control, including but not limited to acts of God, labor disputes, or governmental actions.8. Termination8.1 This Contract may be terminated either party upon written notice to the other party in the event of a material breach the other party that is not cured within ______ days after written notice.8.2 Upon termination of this Contract, Party B shall promptly return all documents and materials provided Party A, and Party A shall pay Party B for the Services performed up to the date of termination in accordance with the payment schedule set forth in Article 3.2.9. Governing Law and Dispute Resolution9.1 This Contract shall be governed and construed in accordance with the laws of ____________.9.2 Any disputes arising out of or in connection with this Contract shall be resolved through friendly negotiations between the parties. If no settlement can be reached, the disputes shall be submitted to arbitration in accordance with the rules of the ____________ Arbitration Commission.10. Miscellaneous10.1 This Contract constitutes the entire agreement between the parties with respect to the subject matter hereof and supersedes all prior agreements, negotiations, and understandings, whether written or oral.10.2 This Contract may not be amended or modified except a written instrument executed both parties.10.3 The headings in this Contract are for convenience only and shall not be used to interpret or construe its provisions.IN WITNESS WHEREOF, the parties hereto have executed this Engineering Design Contract as of the date first above written.Party A (Client):By: ______________________Name: ____________________Title: ____________________Party B (Designer):By: ______________________Name: ____________________Title: ____________________Exhibit A:。

建设工程设计合同(中英文对照版)示范文本

建设工程设计合同Construction Project Design Contract项目名称：Project Name:项目建设地点：Project Location:合同编号：Contract No.:设计证书等级：Grade of Design License:委托方：Client:承接方：Design Firm:签订日期：Signed on:委托方（甲方）：Client (Party A):承接方（乙方）：Design Firm (Party B):甲方委托乙方承担XX项目（一期）工程设计，经双方协商一致，签订本合同。

Party A entrusts Party B to undertake the design for . This Contract is made by the two parties after their mutual agreement.第一条本合同依据下列文件签订Article1. This Contract is made on the basis of the following documents:1.1《中华人民共和国合同法》、《中华人民共和国建筑法》和《建设工程勘察设计市场管理规定》。

1.1 The Contract Law of the People’s Republic of Chin, The building regulations of the People’s Republic of China and The devel o pmental Law of the People’s Republic of China.1.2国家及地方有关建设工程勘察设计管理法规和规章。

1.2 Relevant Building & Design Codes and Regulations of the State and of the Shanghai Municipality.1.3建设工程的相关批准文件。

建设工程设计合同文本中英文对照

建设工程设计合同文本中英文对照一、合同目的与范围Ojective and Scoe of the Contract:本合同的目的是明确甲乙双方在建设工程设计项目中的权利、义务和责任。

合同范围涵盖了从初步设计到施工图纸的所有阶段。

The urose of this contract is to clarify the rights, oligations, and resonsiilities of oth arties in the construction engineering design roject. The scoe of the contract covers all stages from reliminary design to construction drawings.二、设计要求与标准Design Requirements and Standards:乙方需根据甲方提供的要求和相关法规标准，完成工程设计任务。

设计成果应满足功能需求、安全规范和审美标准。

arty shall comlete the engineering design tasks in accordance with the requirements rovided y arty A and relevant regulatory standards. The design results should meet functional needs, safety secifications, and aesthetic standards.三、设计周期与阶段Design eriod and hases:工程设计将分为三个主要阶段：概念设计、初步设计和施工图设计。

每个阶段的完成时间应在合同中明确规定。

The engineering design will e divided into three main hases: concetual design, reliminary design, and construction drawing design. The comletion time for each hase should e clearly defined in the contract.四、费用支付与结算ayment and Settlement:甲方应按合同约定向乙方支付设计费用。

工程设计合同(标准中英)

建设工程设计合同（二）Engineering Service Contract (Ⅱ)（专业建设工程设计合同）(Professional Engineering Service Contract For Construction Project)工程名称：Name of the project:工程地点：Location of the project:合同编号：（由设计人编填）Contract No.:(Filled in by the Designer)设计证书等级：Level of the design certificate:发包人：Employer:设计人：Designer:签定日期：Date of contract:江苏省建设厅江苏省工商行政管理局Jiangsu Provincial Administration for Industry and Commerce发包人:Employer: (Party A)设计人:Designer: (Party B)发包人委托设计人承担工程设计,工程地点为,经双方协商一致,签订本合同,共同执行。

The Employer entrust the Designer to undertake the engineering design of *** and the location for the project is within the plant of .After friendly consultation, the Parties hereby sign this Contract as follows：第一条本合同签订依据。

Article 1 Basis for the conclusion of this Contract1.1《中华人民共和国合同法》、《中华人民共和国建筑法》、《建设工程勘察设计市场管理规定》。

1.1 The ConTraCT Law of The PeoPLe’s rePubLiC of China; The ConsTruCTion Law of The PeoPLe’s rePubLiC of China; reguLaTionson the Administration of the Market for Survey and Design of Engineering Construction.1.2 国家及地方有关建设工程勘察设计管理法规和规章。

建设工程设计英文合同范本

建设工程设计英文合同范本---Article 1: Definitions and Interretation1.1 "Client" refers to the arty who entrusts the design work to the Designer;1.2 "Designer" refers to the arty who undertakes the design work for the Client;1.3 "Design Work" refers to the rofessional services rovided y the Designer in accordance with the requirements of the Client, including ut not limited to drawings, secifications, calculations, reorts, etc.;1.4 "Design eriod" refers to the time limit agreed uon y oth arties for comleting the Design Work.Article 2: Design Tasks and Scoe2.1 The Client shall rovide the Designer with relevant information, data, and technical requirements for the Design Work;2.2 The Designer shall conduct the Design Work in accordance with national and industry standards, as well as the requirements of the Client;2.3 The Designer shall sumit the Design Work to the Client within the agreed Design eriod;2.4 The Designer shall e resonsile for revising and imroving the Design Work ased on the feedack from the Client.Article 3: Design Fee3.1 The Client shall ay the Design Fee to the Designer according to the following schedule: (a) 30% of the total Design Fee uon signing this contract; () 50% of the total Design Fee uon sumission of reliminary design; (c) 10% of the total Design Fee uon sumission of construction drawings; (d) 10% of the total Design Fee uon comletion of the entire Design Work.3.2 The Client shall ear any additional costs arising from changes in design requirements or scoe during the course of the Design Work.Article 4: Intellectual roerty Rights4.1 All intellectual roerty rights related to the Design Work shall elong to the Client;4.2 The Designer shall have no right to use, disclose, transfer or authorize others to use any art of the Design Work without rior written consent from the Client.Article 5: Confidentiality5.1 oth arties shall kee confidential all technical and usiness information otained during the erformance of this contract;5.2 Neither arty shall disclose any confidential information to any third arty without rior written consent from the other arty.Article 6: Liaility for reach of Contract6.1 If either arty fails to erform its oligations under this contract, it shall ear liaility for reach of contract;6.2 If the Designer fails to comlete the Design Work within the agreed Design eriod due to reasons attriutale to itself, it shall ay liquidated damages to the Client at a rate of 1% er day of the total Design Fee for each day overdue.Article 7: Disute Resolution7.1 Any disute arising from this contract shall e first resolved through friendly consultation etween oth arties; if consultation fails, either arty may ring a lawsuit to a court with jurisdiction over the matter.Article 8: Force Majeure。

建设工程设计合同中英文

建设工程设计合同中英文合同编号：[填写合同编号]签订日期：[填写签订日期]甲方（业主）：[业主全称]乙方（设计单位）：[设计单位全称]鉴于甲方拟建设的项目需要专业的工程设计服务，经双方协商一致，特订立本合同，以便共同遵守执行。

第一条合同目的本合同旨在规定甲乙双方在[具体工程项目名称]的设计工作中的权利、义务及责任，确保工程设计满足相关法律法规和技术标准要求，保障工程质量和安全。

第二条设计范围与内容1. 乙方根据甲方提供的项目需求和技术参数，负责项目的初步设计、施工图设计及后续设计变更等工作。

2. 设计工作包括但不限于建筑设计、结构设计、给排水设计、电气设计、暖通设计等专业领域。

3. 乙方应确保设计文件符合国家及地方的建设规范、标准和法规。

第三条设计周期与提交1. 设计工作自合同签订之日起开始，至工程竣工验收合格之日结束。

2. 乙方应在约定的时间内完成各阶段设计工作，并按照甲方要求提交相应的设计文件。

第四条费用支付1. 设计费用总额为[具体金额]元人民币，分为预付款、进度款和尾款三个阶段支付。

2. 甲方应在合同签订后[具体天数]天内支付预付款，金额为设计费用总额的[具体比例]%。

3. 随着设计工作的进展，甲方将根据乙方提交的设计文件支付相应的进度款。

4. 最终尾款将在工程竣工验收合格后的[具体天数]天内结清。

第五条违约责任1. 如乙方未能按合同约定时间提交设计文件，应按未提交部分设计费用的[具体比例]%向甲方支付违约金。

2. 如因乙方设计错误导致工程质量问题或安全事故，乙方应承担相应的法律责任和经济赔偿。

第六条争议解决合同执行过程中发生的任何争议，双方应首先通过友好协商解决；协商不成时，可提交至甲方所在地人民法院诉讼解决。

第七条其他事项1. 本合同的修改和补充应以书面形式进行，经双方授权代表签字盖章后生效。

2. 本合同一式两份，甲乙双方各执一份，具有同等法律效力。

甲方（盖章）：_________________ 日期：____年__月__日乙方（盖章）：_________________ 日期：____年__月__日。

建设工程设计合同英文版

建设工程设计合同英文版Construction Engineering Design ContractWHEREAS, the Client intends to construct a [Description of the Project] (the "Project"); and1. Scope of Services:2. Design Fees:2.2 The Design Fee shall be payable in installments as follows: [Payment Schedule]. The Client shall make all payments within [Number] days from the date of receipt of an invoice.3. Ownership of Documents:4. Project Changes:4.2 Any changes requested by the Client must be agreed upon in writing by both parties before implementation.5. Delays and Force Majeure:6. Confidentiality:6.1 Both parties shall maintain the confidentiality of all proprietary information, trade secrets, and other confidential information received from the other party in connection with the Project.6.2 This obligation of confidentiality shall continue even after the termination of this Contract.7. Termination:7.1 Either party may terminate this Contract for a material breach by the other party, provided that a written notice is given specifying the nature of the breach and a reasonable opportunity is given to cure such breach.8. Governing Law and Jurisdiction:This Contract shall be governed by and construed in accordance with the laws of [Country/State]. Any disputes arising under or in connection with this Contract shall be subject to the exclusive jurisdiction of the courts in[City/Region].IN WITNESS WHEREOF, the parties hereto have executed this Construction Engineering Design Contract as of the date first above written.[Client Name]By:______________________Name: ____________________Title: _____________________By:______________________Name: ____________________。

建设工程设计合同中英文版本

编号：_______________本资料为word版本，可以直接编辑和打印，感谢您的下载建设工程设计合同中英文版本甲方：___________________乙方：___________________日期：___________________Construction Project Design Contract项目名称：Project Name:项目建设地点：Project Location:合同编号：Contract No.:设计证书等级：Grade of Design License:委托方：Client:承接方：Design Firm:签订日期：Signed on:委托方（甲方）：Client （Party A）:承接方（乙方）：Design Firm （Party B）:甲方委托乙方承担XX项目（一期）工程设计，经双方协商一致，签订本合同。

Party A entrusts Party B to undertake the design for . This Contract is made by the two parties after their mutual agreement.第一条本合同依据下列文件签订Article1. This Contract is made on the basis of the following documents:1.1〈〈中华人民共和国合同法》、〈〈中华人民共和国建筑法》和〈〈建设工程勘察设计市场管理规定》。

1.1 The Contract Law of the People ' s Republic of Chin, The building regulations of thePeople ' s Republic of China and The developmental Law of the People ' s Republic of China.1.2国家及地方有关建设工程勘察设计管理法规和规章。

工程设计合同范本英文

工程设计合同范本英文合同编号：_______合同名称：工程设计合同甲方（委托方）：_______乙方（设计方）：_______根据《中华人民共和国合同法》及相关法律法规的规定，甲乙双方在平等、自愿、公平、诚实信用的原则基础上，就甲方委托乙方进行工程设计事宜，达成如下协议：一、工程概况1.1 工程名称：_______1.2 工程地点：_______1.3 工程性质：_______1.4 工程规模：_______二、设计范围及内容2.1 设计范围：乙方根据甲方提供的工程需求，负责完成工程的设计工作，包括但不限于方案设计、初步设计、施工图设计等阶段。

2.2 设计内容：乙方应按照甲方的要求和国家的相关规定，完成工程的设计方案、设计图纸、设计说明、工程概算、施工图等设计文件。

三、设计费用3.1 设计费用总额：_______（1）一次性支付：甲方在合同签订后_______日内，将设计费用一次性支付给乙方。

（2）分期支付：甲方按照设计进度，分_______期支付设计费用，具体支付时间和金额如下：第一期：_______元，支付时间：_______年_______月_______日前；第二期：_______元，支付时间：_______年_______月_______日前；第三期：_______元，支付时间：_______年_______月_______日前；（3）其他支付方式：_______四、设计周期4.1 设计周期：乙方应在合同签订后_______日内完成方案设计，_______日内完成初步设计，_______日内完成施工图设计。

4.2 设计周期调整：如因甲方原因导致设计周期需要调整，乙方应在接到甲方书面通知后_______日内完成调整。

五、设计文件提交及审查5.1 设计文件提交：乙方按照约定的设计周期，将设计文件提交给甲方。

5.2 设计文件审查：甲方应在收到乙方提交的设计文件后_______日内完成审查，并将审查意见书面通知乙方。

全面版工程设计合同英文版

全面版工程设计合同英文版Comprehensive Engineering Design ContractThis document outlines the terms and conditions of the engineering design contract between the Client and the Engineering Firm. It covers the scope of work, project timeline, deliverables, payment terms, and other important aspects of the project.Parties Involved- Client: [Name of the client]- Engineering Firm: [Name of the engineering firm]Scope of WorkThe engineering firm agrees to provide comprehensive design services for [description of the project]. This includes conceptual design, detailed engineering, and coordination with other project stakeholders.Project TimelineThe project is expected to be completed within [duration of the project]. The engineering firm will provide regular updates to the client on the progress of the project.DeliverablesThe engineering firm will deliver the following documents to the client:- Conceptual design drawings- Detailed engineering plans- Specifications and technical documents- Final project reportPayment TermsThe client agrees to pay the engineering firm [total amount] for the design services. Payment will be made in installments as follows: - [Percentage]% upon signing the contract- [Percentage]% upon completion of the conceptual design phase- [Percentage]% upon completion of the detailed engineering phase - [Percentage]% upon delivery of the final project reportConfidentialityBoth parties agree to keep all project-related information confidential and not disclose it to any third parties without written consent.TerminationEither party has the right to terminate the contract in writing if the other party fails to fulfill their obligations. In such a case, the terminated party will be compensated for the work completed up to that point.Governing LawThis contract is governed by the laws of [jurisdiction]. Any disputes arising out of this contract will be resolved through arbitration.This comprehensive engineering design contract is a legally binding document that outlines the responsibilities and obligations of both parties. By signing this document, the client and the engineering firm agree to abide by its terms and conditions.Signed:Client ___________________ Date ___________ Engineering Firm ___________________ Date ___________。

工程设计合同范本英文

工程设计合同范本英文ENGINEERING DESIGN CONTRACTThis Engineering Design Contract (hereinafter referred to as "Contract") is made and entered into as of [Insert Date], by and between [Insert Client Name], a [Insert Client's Entity Type] with its principal place of business at [InsertClient's Address] (hereinafter referred to as "Client"), and [Insert Design Firm Name], a [Insert Design Firm's Entity Type] with its principal place of business at [Insert Design Firm's Address] (hereinafter referred to as "Design Firm").1. SCOPE OF WORK1.1 The Design Firm shall provide professional engineering design services for the project known as [Insert Project Name], as more fully described in the Project Specifications attached hereto as Exhibit A (the "Project").1.2 The services shall include, but are not limited to, the following: [Insert Specific Services].1.3 The Design Firm shall perform the services in accordance with the professional standards and practices applicable to the industry at the time of performance.2. DESIGN FEES AND PAYMENT TERMS2.1 The total design fee for the services provided under this Contract shall be [Insert Total Design Fee], payable as follows: [Insert Payment Schedule].2.2 The Client shall make payments to the Design Firm in accordance with the payment schedule set forth in Exhibit B attached hereto.3. DELIVERY OF DESIGN DOCUMENTS3.1 The Design Firm shall deliver to the Client the design documents, including but not limited to, drawings, specifications, and reports, as specified in the Project Specifications within [Insert Time Frame] after the effective date of this Contract.3.2 The Client shall have the right to review and approve the design documents. Any requested changes shall be communicated to the Design Firm in writing within [Insert Review Period] of receipt of the documents.4. OWNERSHIP AND COPYRIGHT4.1 Upon full payment of the design fees, the Client shall own all rights, title, and interest in the design documents, subject to the Design Firm's right to use the documents for its portfolio and promotional purposes.4.2 The Client acknowledges that the design documents are the intellectual property of the Design Firm and are protected by copyright laws.5. WARRANTY AND LIABILITY5.1 The Design Firm warrants that the design services will be performed in a professional and workmanlike manner and will comply with the Project Specifications.5.2 The Design Firm's liability for any breach of thisContract shall be limited to the design fees paid by the Client.5.3 The Client agrees to indemnify and hold harmless the Design Firm from any claims, damages, or losses arising from the use of the design services, except for those caused bythe gross negligence or willful misconduct of the Design Firm.6. TERMINATION6.1 Either party may terminate this Contract by writtennotice if the other party breaches any material term of this Contract and fails to cure such breach within [Insert Cure Period] after receipt of written notice.6.2 Upon termination, the Client shall pay the Design Firmfor all services performed and expenses incurred up to thedate of termination.7. CONFIDENTIALITY7.1 The parties agree to keep confidential all information obtained from the other party in connection with thisContract and to use such information solely for the purposes of this Contract.8. FORCE MAJEURE8.1 Neither party shall be liable for any failure or delay in performing its obligations under this Contract to the extent that such failure or delay is caused by events beyond the reasonable control of that party.9. GOVERNING LAW9.1 This Contract shall be governed by and construed in accordance with the laws of [Insert Governing Law Jurisdiction], without giving effect to any choice of law or conflict of law provisions.10. ENTIRE AGREEMENT10.1 This Contract, including the Exhibits and attachments hereto, constitutes the entire agreement between the parties with respect to the subject matter hereof and supersedes all prior and contemporaneous agreements and understandings, whether written or oral.IN WITNESS WHEREOF, the parties have executed this Contract as of the date first above written.[Insert Client Name] [Insert Design Firm Name]By: ___________________________[Authorized Signature] By:___________________________[Authorized Signature] Date:___________________________Date: __________________________________________ EXHIBITSA. Project SpecificationsB. Payment Schedule[Insert Any Other Exhibits or Attachments as Applicable]。

英文工程设计合同模板

Engineering Design Contract Template(1) Engineer. The Engineer is [Engineer's Name], a professional engineer licensed in [State/Province], with a primary place of business at [Engineer's Address].(2) Client. The Client is [Client's Name], a [type of business entity], with a primary place of business at [Client's Address].(3) The Engineer and the Client (collectively referred to as the "Parties") hereby enter into this Engineering Design Contract (the "Contract") effective as of [Effective Date].1. ServicesThe Engineer agrees to provide the following services to the Client (the "Services"):(a) Design Services. The Engineer will provide architectural and engineering design services for the [Project Name], located at [Project Location], in accordance with the project scope, specifications, and requirements as provided by the Client from time to time.(b) Consulting Services. The Engineer may also provide consulting services related to the Services, including but not limited to,technical advice, project management, and coordination of subcontractors and consultants.2. Scope of WorkThe Engineer will perform the Services in accordance with the following scope of work:(a) Project Design. The Engineer will develop and prepare the project design documents, including plans, specifications, calculations, and other technical drawings, in accordance with applicable codes, standards, and regulations.(b) Project Coordination. The Engineer will coordinate with the Client, subcontractors, consultants, and other professionals involved in theproject to ensure timely completion and compliance with the project requirements.(c) Permit Applications. The Engineer will assist the Client in obtaining all necessary permits, approvals, and authorizations from relevant authorities for the project.(d) Construction Observation. The Engineer may provide construction observation services to ensure that the work is performed in accordance with the design documents and specifications.3. TermThe term of this Contract shall commence on the Effective Date and continue until the completion of the Services. The Engineer agrees to complete the Services within [Project Completion Date], subject to any delays or extensions as agreed by the Parties.4. CompensationThe Client agrees to compensate the Engineer for the Services as follows:(a) Fixed Fee. The Client shall pay the Engineer a fixed fee of [Fixed Fee Amount] for the completion of the Services. The fixed fee shall be inclusive of all design work, consulting services, and other related activities performed by the Engineer.(b) Additional Services. The Engineer may provide additional services at the Client's request that are not within the original scope of work. The Client agrees to pay the Engineer's hourly rate of [Hourly Rate] for such additional services.(c) Expenses. The Engineer may incur certain expenses in connection with the performance of the Services, including but not limited to, printing costs, travel expenses, and consultant fees. The Client agrees to reimburse the Engineer for all reasonable and properly documented expenses upon submission of detailed invoices.5. Payment TermsThe Client agrees to make payments to the Engineer in accordance with the following terms:(a) Advance Payment. The Client shall pay the Engineer an advance payment of [Advance Payment Percentage] of the fixed fee within [Advance Payment Due Date] as a deposit to cover initial design and consulting costs.(b) Progress Payments. The Client shall make progress payments to the Engineer in installments based on the completion of milestones or phases of the Services, as agreed by the Parties.(c) Final Payment. The Client shall make the final payment to the Engineer upon the completion of the Services and satisfaction of all outstanding expenses.6. ConfidentialityThe Parties agree to maintain strict confidentiality regarding all confidential information exchanged between them during the term of this Contract. Confidential information shall include, but not be limited to, project specifications, design documents, financial information, and any other proprietary or sensitive data.7. IndemnificationThe Client shall indemnify and hold harmless the Engineer against any claims, damages, losses, or expenses (including reasonable attorney's fees) arising out of or resulting from the performance of the Services, except to the extent directly caused by the negligence or willful misconduct of the Engineer.8. Governing Law and Dispute ResolutionThis Contract shall be governed by and construed in accordance with the laws of [Governing Jurisdiction]. Any disputes arising out of or in connection with this Contract shall be resolved by binding arbitrationin accordance with the rules of the [Arbitration Institution], and the decision of the arbitrator(s) shall be final and binding upon the Parties.9. Entire AgreementThis Contract constitutes the entire agreement between the Parties and supersed。

工程设计英文版合同

工程设计英文版合同Article 1: arties InvolvedThis agreement is made on [date], etween [Comany A], with its registered office at [address], hereinafter referred to as "the Client," and [Comany ], with its registered office at [address], hereinafter referred to as "the Contractor."Article 2: roject DescritionThe Contractor agrees to rovide engineering design services for the roject titled [roject Name], which involves [rief descrition of the roject, e.g., architectural design, structural engineering, etc.]. The Client has rovided detailed secifications and requirements, which are attached to this contract as Exhiit A.Article 3: Scoe of ServicesThe services to e rovided y the Contractor include, ut are not limited to, concetual design, reliminary design, final design, rearation of construction documents, and design suervision during the construction hase. The Contractor shall ensure that the designs conform to the standards and regulations of [jurisdiction] and international est ractices.Article 4: ayment TermsThe Client shall ay the Contractor according to the following schedule: [details of ayment milestones ased on comletion of secific design stages]. ayments will e made in US dollars via wire transfer to the Contractor's designated ank account.Article 5: TimelineThe Contractor shall comlete the design work within the timeframe secified in Exhiit . Any changes to the timeline must e agreed uon in writing y oth arties.Article 6: Intellectual roertyAll designs, drawings, and related documents roduced y the Contractor remain the roerty of the Client uon comletion of ayment. The Contractor warrants that all works are original and do not infringe uon any third-arty intellectual roerty rights.Article 7: Confidentialityoth arties agree to maintain confidentiality regarding all information shared under this contract. Disclosure to third arties is only ermitted with rior written consent from the other arty.Article 8: Liaility and WarrantyThe Contractor warrants that the engineering design services will e erformed with rofessional skill and diligence. The liaility of the Contractor for any errors or omissions is limited to the scoe of the agreed services and shall not exceed the total fee aid to the Contractor under this contract.Article 9: TerminationEither arty may terminate this contract uon written notice if the other arty fails to fulfill its oligations as er the terms set forth in this agreement.Article 10: Governing Law and Disute ResolutionThis contract shall e governed y and construed in accordance with the laws of [jurisdiction]. Any disutes arising from or related to this contract shall first e attemted to e resolved through negotiation. If negotiation fails, the arties agree to sumit the disute to aritration in accordance with the rules of [aritration institution].Article 11: Final rovisionsThis contract constitutes the entire agreement etween the arties and suersedes all rior negotiations, reresentations, or agreements. Any amendments or modifications to this contract must e in writing and signed y oth arties.Uon signing this contract, oth the Client and the Contractor acknowledge that they have read and understood all terms and conditions, and they voluntarily enter into this agreement for the mutual enefit of oth arties.Client: [Comany A]Authorized Reresentative: _______________Signature: _______________Date: _______________Contractor: [Comany ]Authorized Reresentative: _______________Signature: _______________Date: _______________。

工程合同范本英文

工程合同范本英文Engineering ContractThis Engineering Contract (the "Contract") is made and entered into as of [date] and between [Party A Name] (hereinafter referred to as "Party A") and [Party B Name] (hereinafter referred to as "Party B").1. Project DescriptionParty A here engages Party B to undertake the [Project Name] project (the "Project"). The scope and detls of the Project are as described in Appendix A attached hereto.2. Project ScheduleThe Project is expected to mence on [start date] and be pleted [pletion date]. However, the schedule may be adjusted subject to mutual written agreement of both parties.3. Project Cost and Payment TermsThe total cost of the Project is agreed to be [total amount] (inclusive of all taxes and expenses). Party A shall make the following payments to Party B: An advance payment of [advance amount] within [number of days] after the signing of this Contract.Interim payments as per the milestones achieved as detled in Appendix B.The final payment of [final amount] upon successful pletion and acceptance of the Project.4. Quality and StandardsParty B shall ensure that the Project is pleted in accordance with the industry standards and the specifications agreed upon in this Contract. Any defects or deviations from the agreed standards shall be rectified Party B at its own cost.5. Changes and AmendmentsAny changes or amendments to the scope, schedule, or cost of the Project shall be mutually agreed upon in writing and signed both parties.6. Intellectual Property RightsAll intellectual property rights arising from the Project shall belong to Party A, unless otherwise agreed in writing.7. ConfidentialityBoth parties undertake to keep all information related to the Project confidential and not to disclose it to any third party without the prior written consent of the other party.8. Force MajeureNeither party shall be liable for any delay or flure in performance of this Contract due to force majeure events, such as natural disasters, wars, or government actions. However, the affected party shall promptly notify the other party and take all reasonable measures to minimize the impact.9. Dispute ResolutionIn the event of any dispute arising out of or in connection with this Contract, the parties shall first attempt to resolve it through friendly negotiations. If the negotiations fl, the dispute shall be submitted to arbitration in accordance with the rules of [arbitration institution].10. TerminationThis Contract may be terminated either party in the event of a material breach the other party, provided that written notice of termination is given and the breaching party fls to rectify the breach within a specified period.11. Governing Law and JurisdictionThis Contract shall be governed and construed in accordance with the laws of [jurisdiction]. Any legal action arising from or related to this Contract shall be brought in the courts of [jurisdiction].IN WITNESS WHEREOF, the parties have executed this Contract as of the date first above written.Party A: [Party A Signature] [Party A Name] [Party A Address] [Contact Detls] Party B: [Party B Signature] [Party B Name] [Party B Address] [Contact Detls] Appendix A: Project DescriptionAppendix B: Payment MilestonesPlease note that this is a basic template and should be tlored to meet the specific requirements and circumstances of your particular engineering project.。

最新工程设计合同(中英文)

中英文建筑工程合同(Contract of Construction Project)

设计合同英文模板免费

建设工程委托设计合同(中英文对照)

工程设计委托合同 (中英文)

委托设计合同,英文

工程设计合同范本 英文

建设工程设计合同(中英文对照版)示范文本

建设工程设计合同文本中英文对照

工程设计合同(标准中英)

建设工程设计英文合同范本

建设工程设计合同中英文

建设工程设计合同英文版

建设工程设计合同中英文版本

工程设计合同范本 英文

全面版工程设计合同英文版

工程设计合同范本英文

英文工程设计合同模板

工程设计英文版合同

工程合同范本 英文

工程设计合同范本英文

工程设计合同范本英文

工程合同范本英文