技术合同英文范本(完整版)
英文技术开发合同6篇
英文技术开发合同6篇篇1Technical Development AgreementThis Technical Development Agreement (the "Agreement") is entered into as of [Date], by and between [Company Name], having its principal place of business at [Address] (the "Company"), and [Developer Name], having its principal place of business at [Address] (the "Developer").BackgroundThe Company is engaged in the business of [Brief description of Company's business], and the Developer possesses certain technical expertise in [Brief description of Developer's technical expertise].The Company wishes to engage the Developer to provide technical development services as described herein, and the Developer wishes to provide such services under the terms and conditions set forth in this Agreement.Agreement1. Scope of Services. The Developer shall provide technical development services to the Company as requested by the Company from time to time. The services to be provided by the Developer may include, but are not limited to, [Description of services to be provided].2. Compensation. The Company shall compensate the Developer for the services provided under this Agreement at the rate of [Rate] per hour. The Developer shall submit invoices to the Company on a [Weekly/Monthly] basis for payment.3. Term. This Agreement shall commence on the date first written above and shall continue until terminated by either party upon [Number] days' written notice.4. Confidentiality. The Developer agrees to keep all information and materials provided by the Company confidential and not to disclose such information to any third party without the Company's prior written consent.5. Intellectual Property. Any intellectual property created by the Developer in connection with the services provided under this Agreement shall belong to the Company, and the Developer hereby assigns all rights, title, and interest in and to such intellectual property to the Company.6. Termination. Either party may terminate this Agreement at any time for any reason upon [Number] days' written notice. Upon termination, the Developer shall cease providing services to the Company, and the Company shall compensate the Developer for services rendered up to the date of termination.7. Governing Law. This Agreement shall be governed by and construed in accordance with the laws of the State of [State].In Witness Whereof, the parties hereto have executed this Agreement as of the date first written above.[Company Name]By: ___________________________ Name: Title:[Developer Name]By: ___________________________ Name: Title:This Agreement constitutes the entire agreement between the parties with respect to the subject matter hereof and supersedes all prior agreements and understandings, whether written or oral, relating to such subject matter. This Agreement may be amended only by a written instrument signed by both parties.IN WITNESS WHEREOF, the parties have executed this Agreement as of the date first written above.[Company Name]By: __________________________ Name: Title:[Developer Name]By: __________________________ Name: Title:篇2Technical Development AgreementThis Technical Development Agreement (the "Agreement") is entered into as of [Date] by and between [Company Name], a [Company Type] organized and existing under the laws of [Jurisdiction], with its principal office located at [Company Address] (hereinafter referred to as "Company") and [Developer Name], an individual residing at [Developer Address] (hereinafter referred to as "Developer").WHEREAS, Company desires to engage Developer for the development of certain technical products and services as further described in Exhibit A attached hereto (the "Project"); andWHEREAS, Developer has the necessary expertise and resources to undertake the development of the Project in accordance with Company's specifications;Now, therefore, in consideration of the premises and mutual covenants contained herein, the parties hereto agree as follows:1. Services. Developer shall perform the development services for the Project as described in Exhibit A in a professional and timely manner, using commercially reasonable efforts to meet the milestones and deadlines set forth therein.2. Compensation. In consideration for the services provided by Developer under this Agreement, Company shall pay Developer a total fee of [Total Fee]. Payment shall be made in installments as set forth in Exhibit B attached hereto.3. Ownership. All intellectual property rights, including but not limited to copyrights, patents, trademarks, and trade secrets, developed by Developer in the course of performing the services under this Agreement shall belong exclusively to Company. Developer hereby assigns to Company all rights, titles, and interests in and to such intellectual property rights.4. Confidentiality. Developer shall keep confidential all information related to the Project and shall not disclose suchinformation to any third parties without the prior written consent of Company. This confidentiality obligation shall survive the termination of this Agreement.5. Term and Termination. This Agreement shall commence on the effective date set forth above and shall continue until the completion of the Project unless terminated earlier by either party upon thirty (30) days' written notice. In the event of termination, Company shall pay Developer for the services performed up to the date of termination.6. Governing Law. This Agreement shall be governed by and construed in accordance with the laws of [Jurisdiction]. Any disputes arising out of or related to this Agreement shall be resolved through arbitration in [Arbitration Location] in accordance with the rules of the American Arbitration Association.7. Entire Agreement. This Agreement constitutes the entire agreement between the parties with respect to the subject matter hereof and supersedes all prior agreements, understandings, and negotiations, whether oral or written.IN WITNESS WHEREOF, the parties hereto have executed this Agreement as of the date first above written.[Company Name] [Developer Name]_________________________ _________________________Company Signature Developer SignatureExhibit A - Project DescriptionExhibit B - Payment ScheduleThis is a sample Technical Development Agreement for reference purposes only. It is recommended that you consult with legal professionals to draft a customized agreement that meets your specific needs and requirements.篇3Technology Development ContractThis Technology Development Contract (the "Contract") is made and entered into as of [Insert Date], (the "Effective Date") by and between [Company Name], a corporation organized and existing under the laws of the [state/country], with its principal place of business located at [Company Address] (the "Developer"), and [Company Name], a corporation organized and existing under the laws of the [state/country], with its principal place of business located at [Company Address] (the "Client").1. Scope of WorkThe Developer agrees to provide technical development services to the Client in accordance with the specifications set forth in the Statement of Work (the "SOW") attached hereto as Exhibit A. The SOW shall include a description of the services to be provided, the timeline for completion, and the compensation to be paid.2. PaymentIn consideration for the services provided by the Developer under this Contract, the Client agrees to pay the Developer a fee of [Insert Amount] (the "Fee"). Payment shall be made in [Insert Payment Terms], with [Insert Percentage] due upon signing of the Contract, [Insert Percentage] due upon delivery of the completed work, and the balance due upon final acceptance by the Client.3. Ownership of Work ProductAll work products created by the Developer under this Contract, including but not limited to software code, designs, and documentation, shall be the exclusive property of the Client. The Developer agrees to assign all rights, title, and interest in andto the work product to the Client upon completion of the services.4. ConfidentialityThe Developer agrees to keep confidential all information provided by the Client in connection with the services, including but not limited to proprietary information, trade secrets, and intellectual property. The Developer shall not disclose such information to any third party without the Client's prior written consent.5. Term and TerminationThis Contract shall commence on the Effective Date and shall continue until the services described in the SOW are completed. Either party may terminate this Contract upon written notice to the other party if the other party materially breaches any provision of the Contract and fails to cure such breach within [Insert Cure Period] days of receiving written notice.6. Independent ContractorThe Developer is an independent contractor and not an employee of the Client. The Developer shall have sole control over the manner and means by which the services are performed,provided that the work is completed in accordance with the specifications set forth in the SOW.7. Governing LawThis Contract shall be governed by and construed in accordance with the laws of the [state/country] without regard to conflicts of law principles. Any disputes arising out of or relating to this Contract shall be resolved by binding arbitration in accordance with the rules of the American Arbitration Association.IN WITNESS WHEREOF, the parties hereto have executed this Contract as of the Effective Date.[Signature Page Follows]IN WITNESS WHEREOF, the parties hereto have executed this Contract as of the Effective Date.Developer: [Developer Name]Client: [Client Name]By: _________________ By: __________________Name: Name:Title: Title:Date: Date:篇4Technical Development ContractThis Technical Development Contract (the "Contract") is entered into on this __________ day of __________, 20__, by and between _______________________ (the "Client") and_______________________ (the "Developer").1. Scope of WorkThe Developer agrees to provide technical development services to the Client for the project described as_______________________ (the "Project"). The scope of work includes but is not limited to:- Designing and developing software or applications according to Client's specifications.- Testing and debugging the software to ensure proper functionality.- Providing ongoing technical support and maintenance for the software post-launch.- Meeting all deadlines and milestones as outlined in the project plan.2. PaymentThe Client agrees to pay the Developer a total fee of$__________ for the completion of the Project. Payment will be made in installments as follows:- 25% upon signing of the Contract.- 25% upon completion of the design phase.- 25% upon completion of the development phase.- 25% upon final delivery and acceptance of the Project.Payment can be made via check, wire transfer, or credit card, as agreed upon by both parties.3. Intellectual Property RightsAll intellectual property rights, including but not limited to copyrights, patents, and trademarks, related to the software developed under this Contract shall belong to the Client. The Developer agrees to transfer all such rights to the Client upon completion of the Project.4. ConfidentialityBoth parties agree to keep all information exchanged during the course of the Project confidential. This includes but is notlimited to source code, design documents, and any other proprietary information related to the software.5. TerminationEither party may terminate this Contract with written notice if the other party breaches any of the terms outlined herein. In the event of termination, the Developer shall be entitled to payment for services rendered up to the date of termination.6. Governing LawThis Contract shall be governed by the laws of the state of __________. Any disputes arising under this Contract shall be resolved through arbitration in accordance with the rules of the American Arbitration Association.In witness whereof, the parties have executed this Contract as of the date first written above.___________________________Client Name___________________________Developer NameThis document constitutes the entire agreement between the Client and the Developer and supersedes any prior agreements or understandings, whether written or oral.篇5Technical Development AgreementThis Technical Development Agreement (“Agreement”) is entered into on this [insert date] by and between [Company Name], having its principal place of business at [insert address] (“Developer”) and [Client Name], having its principal place of business at [insert address] (“Client”).WHEREAS, Client desires to engage Developer to provide technical development services for the purpose of [insert description of project]; andWHEREAS, Developer is willing to perform such services for Client on the terms and conditions set forth herein.NOW, THEREFORE, in consideration of the mutual covenants and agreements contained herein, the parties agree as follows:1. Services. Developer shall provide technical development services for Client in accordance with the specifications outlined in Exhibit A attached hereto.2. Compensation. Client shall pay Developer a fee of [insert amount] for the services to be provided under this Agreement. Payment shall be made in [insert payment terms], as outlined in Exhibit B attached hereto.3. Term. This Agreement shall commence on [insert start date] and shall continue until the completion of the project or termination by either party.4. Confidentiality. Developer acknowledges that in the course of performing services for Client, Developer may have access to confidential information belonging to Client. Developer agrees to keep such information confidential and shall not disclose it to any third party without the prior written consent of Client.5. Ownership of Work Product. All work product created by Developer in connection with the services provided under this Agreement shall be the exclusive property of Client. Developer agrees to assign all rights, title, and interest in such work product to Client.6. Warranties. Developer warrants that the services provided under this Agreement shall be performed in a professional and workmanlike manner and shall conform to the specifications outlined in Exhibit A. Developer further warrants that it has theright to enter into this Agreement and that the services provided do not infringe upon the intellectual property rights of any third party.7. Indemnification. Developer shall indemnify and hold harmless Client from any claims, damages, losses, or expenses arising out of Developer's breach of this Agreement or negligence in the performance of its services.8. Termination. Either party may terminate this Agreement upon written notice if the other party materially breaches any provision of this Agreement and fails to cure such breach within [insert number] days of receiving written notice.9. General Provisions. This Agreement constitutes the entire understanding between the parties with respect to the subject matter hereof and supersedes all prior agreements and understandings, whether written or oral. This Agreement may not be amended except by written agreement signed by both parties.IN WITNESS WHEREOF, the parties have executed this Agreement as of the date first set forth above.[Developer Name][Client Name]Exhibit A: Project SpecificationsExhibit B: Payment Terms_______________________________[Signature] [Date]篇6Technical Development AgreementThis Technical Development Agreement ("Agreement") is entered into by and between [Company Name], a company organized and existing under the laws of [Country], having its principal place of business at [Address] ("Company"), and [Developer Name], an individual residing at [Address] ("Developer").1. Scope of ServicesDeveloper agrees to provide technical development services to Company. The services to be provided by Developer shall include but not be limited to designing, coding, testing, and implementing software solutions in accordance with Company's specifications. Developer shall perform the services in a timely and professional manner and in accordance with best industry practices.2. PaymentCompany agrees to pay Developer for the services rendered in accordance with the fee schedule attached as Schedule A to this Agreement. Payment shall be made [payment terms]. Developer shall invoice Company for the services rendered on a [payment frequency] basis.3. Ownership of Intellectual PropertyAny intellectual property developed by Developer in the course of providing the services under this Agreement shall be the exclusive property of Company. Developer hereby assigns to Company all right, title, and interest in and to any intellectual property developed herein.4. ConfidentialityDeveloper acknowledges that in the course of providing the services under this Agreement, Developer may have access to confidential information of Company, including but not limited to Company's proprietary software, technical data, and business strategies. Developer agrees to keep all confidential information confidential and not to disclose it to any third party without Company's prior written consent.5. Term and TerminationThis Agreement shall commence on [Commencement Date] and continue until [Termination Date], unless earlier terminated as provided herein. Either party may terminate this Agreement upon [notice period] written notice to the other party. Upon termination of this Agreement, Developer shall deliver to Company all materials and property belonging to Company and cease using Company's confidential information.6. IndemnificationDeveloper agrees to indemnify and hold harmless Company against all claims, damages, and liabilities arising out of Developer's breach of this Agreement or negligence in providing the services hereunder.7. Governing LawThis Agreement shall be governed by and construed in accordance with the laws of [Country]. Any dispute arising out of or in connection with this Agreement shall be resolved by arbitration in [City], [Country], in accordance with the rules of the [Arbitration Institution].IN WITNESS WHEREOF, the parties hereto have executed this Agreement as of the date first above written.[Company Name]By:Name:Title: [Developer Name] By:Name:。
技术服务合同模板_英文
This Technical Service Contract (the "Contract") is entered into as of [Date] (the "Effective Date") between [Company Name] ("Provider"), a company registered at [Company Address], and [Client Name] ("Client"), a company registered at [Client Address].RecitalsWHEREAS, the Provider is engaged in the business of providing technical services and has the necessary expertise and resources to provide such services;WHEREAS, the Client desires to engage the services of the Provider for the purposes described in this Contract;NOW, THEREFORE, in consideration of the mutual covenants and promises contained herein, the Provider and the Client agree as follows:1. Scope of Services1.1 The Provider shall provide the following technical services to the Client ("Services") as specified in the attached Schedule of Services:- Detailed description of the Services to be provided;- Any specific technical requirements or standards to be adhered to;- The duration of the Services to be provided;1.2 The Provider shall use reasonable efforts to ensure that the Services are provided in a timely and professional manner, in accordance with industry standards and the Client's requirements.2. Term and Termination2.1 This Contract shall commence on the Effective Date and shall continue for a period of [Number of Years] (the "Term") unless terminated earlier in accordance with the provisions of this Contract.2.2 Either party may terminate this Contract by giving the other party written notice of termination at least [Number of Days] days prior to the effective date of termination.2.3 In the event of termination, the Provider shall complete any work in progress and the Client shall pay the Provider for any work completed prior to the effective date of termination.3. Fees and Payment3.1 The Client shall pay the Provider the fees set forth in the attached Schedule of Fees ("Fees") for the Services provided under this Contract.3.2 The Fees shall be paid in accordance with the payment terms setforth in the attached Schedule of Fees.3.3 In the event of late payment, the Client shall pay interest on the overdue amount at the rate of [Percentage] per annum, calculated from the due date until the date of payment.4. Intellectual Property4.1 All intellectual property rights in the Services provided under this Contract shall vest in the Provider, except for any intellectual property rights owned by the Client prior to the Effective Date.4.2 The Client shall not use or disclose any of the Provider's confidential information without the Provider's prior written consent.5. Confidentiality5.1 The parties agree to maintain the confidentiality of all information disclosed to them by the other party in connection with this Contract.5.2 The obligations of confidentiality shall survive the termination or expiration of this Contract.6. Limitation of Liability6.1 The Provider shall not be liable for any indirect, special, or consequential damages arising out of or in connection with the provision of the Services.6.2 The total liability of the Provider to the Client under this Contract shall not exceed the total amount of Fees paid by the Client under this Contract.7. Governing Law and Dispute Resolution7.1 This Contract shall be governed by and construed in accordance with the laws of [Jurisdiction].7.2 Any disputes arising out of or in connection with this Contractshall be resolved through arbitration in accordance with the rules of the [Arbitration Institution].8. General Provisions8.1 This Contract constitutes the entire agreement between the parties and supersedes all prior agreements, understandings, or representations, whether written or oral.8.2 Any amendment or modification of this Contract shall be effective only if it is in writing and signed by both parties.IN WITNESS WHEREOF, the parties have executed this Technical Service Contract as of the Effective Date.[Provider's Name][。
英文技术服务合同6篇
英文技术服务合同6篇篇1Technical Service Contract本合同（以下简称“合同”）由以下双方签订：（以下简称“甲方”）（以下简称“乙方”）一、定义和范围本合同涉及的技术服务是指乙方根据甲方的需求，提供特定技术领域内的专业咨询、技术支持、系统维护、软件开发、数据分析及其他相关服务。
本合同旨在明确双方的权利和义务，确保服务的有效实施和履行。
二、服务内容1. 技术咨询：乙方应根据甲方的请求，提供专业领域的咨询意见和技术建议。
2. 技术支持：乙方应为甲方解决技术难题，提供必要的解决方案和操作指导。
3. 系统维护：乙方应负责甲方指定的系统或软件的日常维护，确保其稳定运行。
4. 软件开发：乙方应按照甲方的需求，开发特定软件或功能模块。
5. 数据分析：乙方应协助甲方进行数据处理和分析，提供数据报告和建议。
6. 其他相关服务：包括但不限于技术培训、项目管理和技术咨询等。
三、服务期限本合同的服务期限为______年，自______年______月______日起至______年______月______日止。
四、服务费用1. 甲方应向乙方支付的技术服务费用总计为______元人民币（大写）。
具体支付方式和时间表如下：（此处省略具体支付细节）2. 所有费用应支付至乙方指定的账户，任何额外费用需双方协商并书面确认。
五、知识产权1. 乙方提供的所有技术服务均应确保不侵犯任何第三方的知识产权。
如因乙方服务导致甲方涉及知识产权纠纷，乙方应承担全部法律责任。
2. 双方共同开发的技术成果，其知识产权归属和利益分配应在本合同中明确约定。
如无约定，按照相关法律法规处理。
六、保密条款1. 双方应对在合作过程中获知的对方商业秘密和技术秘密予以保密，未经对方书面同意，不得向第三方泄露。
2. 保密信息的披露仅限于本合同约定的目的和范围内，任何超出此范围的披露需事先取得对方同意。
七、违约责任1. 若任何一方违反本合同的任何条款，均应承担违约责任，并赔偿对方因此遭受的损失。
英文技术服务合同范本4篇
英文技术服务合同范本4篇Model contract for technical services in English甲方：乙方：签订日期：年月日英文技术服务合同范本4篇小泰温馨提示：合同是民事主体之间设立、变更、终止民事法律关系的协议。
依法成立的合同，受法律保护。
本文档根据服务合同内容要求和特点展开说明，具有实践指导意义，便于学习和使用，本文下载后内容可随意修改调整及打印。
本文简要目录如下：【下载该文档后使用Word打开，按住键盘Ctrl键且鼠标单击目录内容即可跳转到对应篇章】1、篇章1：英文技术服务合同范本2、篇章2：翻译服务合同英文模板文档3、篇章3：翻译服务合同英文模板文档4、篇章4：翻译服务合同英文模板文档篇章1:英文技术服务合同范本Contract No.:________________________.Date of Signature:____________________.Place of Signature:____________________.This Contract is made and entered into through friendly negotiation by and betweenChina____________________ （hereinafter referred to as “Client”）, as one party, and____________________ （hereinafter referred to as“Consultant”）,as the other party, concerning the technical consultancy service of__________, under the following terms and conditions:Article 1 Contents of Technical Consultancy Service1.1 Whereas Client desires to obtain thetechnical consultancy service of from Consultant and Consultant has agreed to perform such services.1.2 The Scope of Technical Services is defined in Appendix 1.1.3 The Time Schedule for the Services is shownin Appendix 2.1.4 The Manning Schedule is described in Appendix 3.1.5 Consultant shall complete the Serviceswithin__________months from the Effective Date of this Contract and furnish the final technical servicereport, including drawings, designing documents, all kinds of standards and photos, within____months. Consultant shall keep aware, free of charge, Client of the latest development of similar projects and any progress made in order to improve the designing of the project.Article 2 Both Parties' Responsibility and Liability2.1 Client shall furnish to Consultant the pertinent data, technical service reports, maps and information available to him and shall give to Consultant the reasonable assistance necessary for carrying out of his duties. Particularly Client shall nominate a general representative who shall be available at reasonable time.2.2 Client shall assist Consultant with the responsible authorities for obtaining visas, work permits and other documents required by Consultant to enter the country and to have access to the Site of the Project. The above expenses shall be borne by Consultant.2.3 Consultant shall furnish a sufficient number of competent personnel to perform its obligation hereunder, in addition to those personnel specifically listed in Appendix3.All personnel employed by Consultant in carrying out the work shall be exclusively Consultant's responsibility, and Consultant shall hold Client harmless from any claims of any kind by Consultant's personnel arising out of any acts by Consultant or its personnel in connection with the work performed hereunder.2.4 Consultant shall provide Client all the technical technical service reports and relevant documentation within the Scope of Technical Services and within the Time Schedule of the Time Schedule for the Services.2.5 Consultant shall assist Client＇S personnelin his country in obtaining visas and in arranging lodgings. Hotel and boarding expenses shall be borne by Client. Consultant shall supply to Client＇Spersonnel office space and necessary facilities as well as transportation.2.6 Consultant shall be responsible for and shall indemnify Client and his employee in respect of injury to person or damage to property occurring in connection with the services, to the extent that such damage or injury directly results from negligence of Consultant's personnel while engaged in activities under this shall be liable only to the work under this Contract.2.7 Any and all liability of Consultant with respect to this Contract shall be limited to the Total Contract Price received by Consultant for his profession services and shall terminate uponexpiration of the warranty period set forth in Article 7.3.Article 3 Price and Payment3.1 The total contract price is__________（say__________________only） in________（currency）. Thebreakdown prices of the above mentioned total contract price are as follows:Contract Price for Item 1: ______（say____________only） in________ （currency）; Contract Price for Item 2: ______（say ____________only）in________ （currency）; Contract Price for Item 3:______（say ____________only） in________ （currency）; Contract Price for Item 4: ______（say____________only） in________ （currency）.3.2 The total contract price will include all the service and technology provided by Consultant. Thetotal contract price shall be firm and fixed and shall not fluctuate with any inflation. The total contract price shall include all charges and expenses incurred by Consultant in performing his obligations both inhis own country and in the People's Republic of China and includes the expenses incurred in sending the Technical Documentation to Client's office by allkinds of forms.In the event of Force Majeure as defined in the Contract, the total contract price shall be readjusted through friendly negotiations between the parties. If Client requires services not contemplated in the Scope of Services the parties shall friendly discuss an amendment to thetotal contract price. Any such amendment shall be in writing countersigned by both parties. This document shall then form integral part of the Contract.3.3 All payments to be made by Client to Consultant under the present Contract shall be made by telegraphic transfer. In case of any payment by Client, the payment shall be effected through__________inChina to _________ for the account of Consultant.In consideration for the services provided by Consultant hereunder, Client shall effect the payment to Consultant in accordance with the following manner and percentage:3.3.1 _______ percent （________ %） of the total contract price, i.e._____________ （Say: ________ only）, shall be paid by Client to Consultant within ________ （____） days after the client has received the following documents provided by Consultant and found them in order.A. One（1） original and two（2） duplicate copies of Consultant's government approval, or a written statement of the competent authorities or relevant agency of Consultant's country certifying that such document is not required;B. One（1） original and one（1） duplicate copy of Irrevocable Letter of Guarantee for advance payment issued by Consultant's Bank in favor of Client covering_______（Say:________ only）, specimen of which is as per Appendix 4;C. Five （5） copies of profoma invoice covering the total contract price;D. Five （5） copies of manually signedcommercial invoice indicating the amount to be paid;E. Two （2） copies of sight draft.The said shall be delivered by Consultant notlater than ____days after the effective date of the________present Contract.3.3.2 ________percent （____%） of the Contract price for Item 1, i.e._________ （Say: __________ only）shall be paid by Client to Consultant within _____（__） days after Consultant has received thefollowing documents provided by Consultant and found them in order.A. Ten （10） copies of technical service report on Item 1;B. Five （5） copies of manually signedcommercial invoice indicating the amount to be paid;C. Two （2） copies of sight draft.3.3.3 ________ percent （____%） of the Contract price for Item 2, i.e. ___________ （Say: ____________ only） shall be paid by Client to Consultant within________ （___） days after Licensee has received the following documents provided by Consultant and found themin order.A. Ten （10） copies of technical service report on Item 1;B. Five （5） copies of manually signedcommercial invoice indicating the amount to be paid;C. Two （2） copies of sight draft.3.3.4 ________percent （____%） of the Contract price for Item 3, i.e._________ （Say: __________ only）shall be paid by Client to Consultant within _____（__） days after Consultant has received thefollowing documents provided by Consultant and found them in order.A. Ten （10） copies of technical service report on Item 1;B. Five （5） copies of manually signedcommercial invoice indicating the amount to be paid;C. Two （2） copies of sight draft.3.3.5 ________percent （____%） of the Contract price for Item 4, i.e._________ （Say: __________ only）shall be paid by Client to Consultant within _____（__） days after Consultant has received thefollowing documents provided by Consultant and found them in order.A. Ten （10） copies of technical service report on Item 1;B. Five （5） copies of manually signedcommercial invoice indicating the amount to be paid;C. Two （2） copies of sight draft.3.3.6 ________percent （____%） of the Total Contract price , i.e._________ （Say: __________ only）shall be paid by Client to Consultant within _____（__） days after Consultant has received thefollowing documents provided by Consultant and found them in order.A. Five （5） copies of manually signed commercial invoice indicating the amount to be paid;B. Two （2） copies of sight draft.3.4 In case Consultant is liable for paying to Client the penalty under the Contract, Client shall have the right to deduct it from any said payment.3.5 The banking charges of both parties incurred in China for the execution of the Contract shall be borne by Client and those incurred outside China shall be borne by Consultant.Article 4 Delivery Schedule4.1 The deadline for the arrival of the Technical service reports CIF _____ are:A. Technical service report on Item 1 :_________months after effectiveness of the Contract;B. Technical service report on Item 2 :_________months after effectiveness of the Contract;C. Technical service report on Item 3 :_________months after effectiveness of the Contract;D. Technical service report on Item 4 :________months after effectiveness of the Contract.4.2 Consultant will inform Client by Fax when the Technical service reports are airmailed to Client indicating the date and number of airway bill. Client will inform Consultant when the Technical service reports have been received.4.3 Should any document be missing or damaged during the transport Consultant shall be notified accordingly and within two （2） weeks the missing or damaged document shall be replaced by Consultant free of charge.Article 5 Confidentiality5.1 All data assembled, developed, compiled, reproduced, studied, and prepared in connection withthe work done hereunder and furnished to Consultant by Client shall be considered confidential and shall not be divulged to any person, firm or corporation other than Client or its designated representatives. This Clause shall remain binding on Consultant notwithstanding the termination of the Contract for any reason.5.2 Within the validity period of Contract, Both parties shall take proper measures to keep the materials or information strictly confidential. The other party shall not disclose or divulge to any third party without prior written consent of one party.5.3 Either party shall be obliged to keep confidential any secret information of the other party which either party and its personnel may obtain or be accessible to in the course of the performance of Contract. Either party shall not make use of or disclose such secret information obtained from the other party without prior written permission issued by the other party.Article 6 Taxes and Duties6.1 All taxes and duties in connection with and in the execution of Contract levied by the Chinese government on Client in accordance with the tax laws of PRC shall be borne by Client.6.2 All taxes and duties levied by the Chinese government on Consultant, in connection with and in the execution of Contract, according to Chinese tax laws and the agreement between the government of PRC and the government of Consultant's country for the reciprocal avoidance of double taxation and the prevention of fiscal evasion with respect to taxes on income shall be borne by Consultant.Client is legally obliged to withhold, as a withholding agent, the amount of taxes pro rata each taxable payment under Contract and pay them to the relevant Chinese tax authorities. After receiving the tax receipts issued by the relevant Chinese tax authorities for the aforesaid withholding taxes,Client shall forward them to Consultant without undue delay.6.3 All taxes and duties arising outside PRC in connection with and in the execution of Contract shall be borne by Consultant.Article 7 Warranty7.1 Consultant warrants that he has the experience and capability to efficiently and expeditiously perform the services in a satisfactory manner and that the services performed by him under this Contract shall be performed by competent personnel in accordance with accepted standards.7.2 In the event of a failure of Consultant to provide to Client satisfactory services within the scope of work described in Appendix at any time for any reason within the control of the Consultant,Client may notify Consultant of such dissatisfaction. Consultant shall be afforded a period of days to correct or remedy the matter. Should Consultant withinthe time afforded by Client fail to correct or remedy the matter to the satisfaction of Client, all charges shall cease forthwith until such time as Consultant is able to provide satisfactory services in accordance with the Scope of work described in Appendix.7.3 Consultant guarantees to Client that he shall, after receipt of notice from Client, promptly correct at no cost any errors in the services arising out of the negligent performance thereof.Article 8 Ownership of Technical Service Reports8.1 Final version of the technical service report submitted to Client and all relevant data such as maps, plans and supporting material compiled in performing the Scope of Services, shall be the property of Client. Such materials shall be sorted and indexed by Consultant prior to transmission to Client.8.2 Consultant shall be permitted to retaincopies thereof, provided however that such materials, including the material furnished by Client as statedin Article 5 of this Contract, shall not be used by Consultant for purposes not related with this Project without the prior written approval of Client.Article 9 Assignment9.1 Neither Client nor Consultant shall assign or sublet their rights or obligations hereunder without the prior written consent of the other party.Article 10 Termination10.1 If, due to the responsibility of Consultant, the technical service reports have not been delivered at dates according to the delivery schedules as stipulated in Article 4 of the Contract, Consultant shall be obliged to pay to Client penalty for such delay in delivery at the following rates:A. ______ percent （____%） of the total contract price per week for the first four weeks;B. _____ percent （____%） of the total contract price per week from the fifth week to the eighth week;C. ______ percent （____%） of the total contract price per week from the ninth week of delay.Odd days less than one（1） week shall be counted as one（1） week for calculating the liquidated damage.10.2 The total liquidated damage for latedelivery shall not exceed ______ percent （____%） of the total contract price. Payment of the liquidated damage for late delivery shall not releaseConsultant from its obligation to deliver technical service reports.10.3 Client may, without prejudice to any other remedy for Consultant's following breach of Contract, terminate Contract in whole or in part by a written notice of default send to Consultant, if ConsultantA. Fails to deliver any or all of technical service reports within______（____） days after the scheduled delivery date as specified in Article 1; orB. Fails to make the technical service reports meet the minimum level of Acceptance Standards as specified in Appendix 1.Consultant shall refund to Client all the payments effected by Client to Consultant plus an interest at the rate of______ percent （____%） per annum in case of such a termination.10.4 Either party may, without prejudice to any other remedy, terminate Contract in whole or in partby a written notice send to the other party, if the other party.A. fails to perform its confidentialityobligation under Contract; orB. fails to perform any other obligations under Contract except minor parts thereof, and does not remedy for its failure within a period of______ （____）days upon receipt of the written notice or a period agreed upon between the parties; orC. becomes bankrupt or insolvent; orD.Affected by any event of Force Majeure for more than ______ days.Article 11 Force Majeure11.1 Should either party be prevented from performing any of its obligations under Contract dueto event of Force Majeure, such as war, serious fire, typhoon, earthquake, flood and any other events which could not be expected, avoided and overcome, the affected party shall notify the other party of its occurrence by fax and send by registered airmail a certificate issued by the competent authorities or agency within fourteen （14） days following its occurrence.11.2 The affected party shall not be liable for any delay or failure in performing any or all of its obligations due to the event of Force Majeure. However, the affected party shall inform the other party by fax the termination or elimination of the event of Force Majeure without delay.11.3 Both parties shall proceed with their obligations immediately after the cease of the event of Force Majeure or removal of the effects. Thevalidity period of Contract and/or the scheduled period for relative execution of Contract shall be extended correspondingly.Article 12 Arbitration12.1 Any dispute arising from or in connection with this Contract shall be submitted to China International Economic and Trade Arbitration Commission，Shenzhen Commission for arbitration in accordance with the Commission's arbitration rules in effect at the time of applying for arbitration. The arbitral award is final and binding upon both parties and the applicable law is the material law of P.R.C.12.2 Notwithstanding any reference to arbitration, both Parties shall continue to perform their respective obligations under the Contract unless otherwise agreed.Article 13 Language and Standards13.1 Correspondance except this Contract between Client and Consultant, data and documents madeavailable by Client to Consultant and the technical service reports and drawings prepared by Consultant shall be in the English language.13.2 Measures shall be written in the metric system.Article 14 Governing Law14.1 The construction, validity and performanceof this Contract shall be governed by the laws of the People's Republic of China.Chapter 15 Effectiveness of the Contract and Miscellaneous15.1 Both parties shall make effort to obtain the approval from the respective authorities, if necessary, within thirty （30） days after Contract is signed by the authorized representatives of the two parties. Either Party shall notify in writing the other partyof the approval date. The later date of approval shall be taken as the Date of Effectiveness of Contract.15.2 Contract shall be valid and remain in force for_______（____） years from the Date of Effectiveness.15.3 The outstanding credit and debt between the parties under Contract shall not be affected upon the termination or expiration of Contract.15.4 Appendices hereof shall be integral parts of Contract and have the same legal force as the text of Contract itself. The text of Contract shall prevail in case of any discrepancies between the text of Contract and Appendices.15.5 All amendments, supplements, subtractions,or alterations to Contract shall be made in writ篇章2:翻译服务合同英文模板文档【按住Ctrl键点此返回目录】Technical Cooperation Agreement甲方：XX油脂化学有限公司Party A: XX Grease Chemical Co. , Ltd.Address: XXHigh-tech Industrial ParkLegal Representative: XXX本协议合作双方就组建技术研发团队事项，经过平等协商，在真实、充分地表达各自意愿互惠互利的基础上，根据《中华人民共和国合同法》的规定，达成如下协议，并由合作各方共同恪守。
英文技术开发合同5篇
英文技术开发合同5篇篇1Contract for Technical Development甲方（客户）：__________________乙方（开发方）：__________________签订日期：____________________一、合同背景及目的本合同由甲方和乙方共同签署，目的在于明确双方在技术开领域的合作关系及具体事务处理细节。
甲方委托乙方进行特定的技术开发工作，乙方同意接受委托并按照本合同的要求完成相关任务。
二、开发内容与技术要求1. 开发内容：具体描述开发的系统名称、功能及目标。
（例如：开发一套智能物流管理系统，实现货物追踪、数据分析及优化物流路径等功能。
）2. 技术要求：明确开发的软件应满足的技术标准和规范，包括但不限于系统稳定性、兼容性、安全性等方面的要求。
三、开发周期与进度安排1. 开发周期：自合同签订之日起至完成所有开发任务并交付验收的总时长。
2. 进度安排：详细列明开发各阶段的时间节点及主要任务，包括需求分析、设计、编码、测试等阶段的具体时间安排。
四、知识产权与保密条款1. 知识产权归属：明确开发成果的知识产权归属，是归属于甲方还是双方共同拥有。
如归属甲方，则乙方不得擅自将相关技术用于其他用途或转让给第三方。
2. 保密条款：双方应对在合作过程中获知的对方商业秘密和技术秘密承担保密义务，未经对方书面同意，不得向任何第三方泄露。
五、费用与支付方式1. 开发费用：详细列明本次技术开发的费用总额及构成，包括各个阶段的工作费用。
费用的确定应遵循公平合理原则。
2. 支付方式：约定支付的时间节点（如预付款、进度款、尾款等）及支付条件。
同时明确如发生变更时双方应如何调整费用。
六、验收与交付1. 验收标准：根据开发内容和技术要求制定详细的验收标准。
2. 交付物：明确开发完成后应交付的文档、软件等物品及其格式和存储方式。
七、风险承担与违约责任1. 风险承担：明确在开发过程中可能遇到的风险及责任承担方式，包括但不限于技术风险、市场风险及不可抗力等因素。
技术开发的英文合同5篇
技术开发的英文合同5篇篇1TECHNOLOGY DEVELOPMENT CONTRACTContract No.: [Insert Contract Number]Date: [Insert Date]1. Scope of Work:The Developer agrees to undertake the development of [describe the technology to be developed in detail] (hereinafter referred to as the "Technology") for the Principal. The Technology shall be developed in accordance with the specifications and requirements provided by the Principal.2. Development Period:The period of development shall commence on [Start Date] and continue until [End Date], unless extended by mutual agreement in writing.3. Project Milestones:The Developer shall achieve the following milestones within the specified timeframes:* Milestone 1: [Describe milestone 1 with timeline]* Milestone 2: [Describe milestone 2 with timeline]* ... (as per the requirements of the project)4. Intellectual Property Rights:All intellectual property rights arising out of or in connection with the Technology shall be owned by the Principal. The Developer shall assign all such rights to the Principal upon completion of the project.5. Payments:The Principal shall pay the Developer the following fees for the development work:* Development Fee: [Amount]* Milestone Payments: [Describe milestone payments with amounts and conditions]* Any other fees or expenses: [Specify other fees/expenses, if any, with amounts]All payments shall be made within [specified timeframes] from the date of invoice.6. Confidentiality:Both parties shall maintain confidentiality of all information disclosed to each other during the course of this Contract. Neither party shall disclose any confidential information to third parties without the prior written consent of the other party.7. Warranty and Liability:The Developer shall ensure that the Technology developed is free from defects in material and workmanship for a period of [Warranty Period]. The Developer shall indemnify and hold harmless the Principal from any claims, losses, or damages arising out of any defects in the Technology.8. Termination:9. Force Majeure:Neither party shall be liable for any failure to perform its obligations due to events beyond its reasonable control, such as acts of war, riots, natural disasters, etc. The affected party shall notify the other party of such events and provide evidence to support its claim.10. General Terms:* This Contract constitutes the entire agreement between the parties and no modifications shall be made except by a written agreement signed by both parties.* The laws of [Country/State] shall apply to this Contract.* Any disputes arising out of or in connection with this Contract shall be settled through friendly negotiations. If no settlement is reached, the dispute shall be referred to [specify dispute resolution mechanism, e.g., arbitration].* This Contract shall be governed by and construed in accordance with the laws of [Country/State].* This Contract may be executed in [number of counterparts] counterparts, each of which shall be deemed an original and all of which shall constitute one and the same instrument.In witness whereof, the parties have executed this Contract on the dates indicated below.Developer:Principal:(Authorized Representative) (Authorized Representative)Date: Date:Place: Place:------------------------------------------------------------------------ 签名与印章应分别在上述打印日期下方占据指定空间位置的位置上对齐插入以加强正式感与合法性表达。
技术合同英文范本(合同范本)
编号：JY-HT-01561技术合同英文范本(合同范本)Any parties with a cooperative relationship can sign a contract to protect legal rights甲方：________________________乙方：________________________签订日期：_____年____月____日技术合同英文范本(合同范本)技术合同英文范文篇一甲方：party a：乙方：party b：合同编号： contract no日期：date：签约地点：signed at：特约定：甲方基于下文所列各种因素，特与乙方达成了协议并一致同意：由甲方在订约日期之翌日起_____天之内为乙方建造并完成_____(涉约建筑)。
涉约建筑之规模及所需的钢筋、水泥、砖块、石子和其它建筑材料之数量，均在作为合同附件的设计图和施工细则中予以说明。
witnesses that the party a for considerations hereinafter named, contracts and agrees with the party b that party a will, within_____ days, next followingthe date hereof, build and finish a libarary building for party b. ( the building hereinafter is referred to as the said building.) the said building is of the following dimensions, with reinforced concrete, brick, stones and other materials, as are described in plans and specifications gereto annexed.基于上述情况，乙方及其法定代表郑重承诺向甲方支付人民币_____元整。
英文技术开发合同7篇
英文技术开发合同7篇篇1Development Contract for Technology in English甲方（委托方）：____________________（Name of Client）地址：____________________（Address）联系方式：____________________（Contact Information）乙方（开发方）：____________________（Name of Developer）地址：____________________（Address）联系方式：____________________（Contact Information）鉴于甲方需要对特定技术进行开发，而乙方具备相关技术开发的实力和经验，双方在平等、自愿、公平的基础上，经过友好协商，达成以下技术开发合同协议：一、合同目的和背景本合同旨在明确甲、乙双方在技术开发项目中的权利与义务，确保双方合作顺利进行，共同实现技术开发的成功。
二、开发内容和目标（详细说明开发项目的名称、内容、目标、预期成果等）三、开发时间和进度安排（明确开发项目的起始日期、预计完成日期、各个阶段的时间节点和主要任务等）四、知识产权归属1. 乙方在本合同期间所完成的技术成果及其知识产权归甲方所有。
2. 未经甲方书面同意，乙方不得将本合同约定的技术成果转让给第三方。
3. 双方共同保守本合同约定的技术秘密和商业秘密。
五、费用支付和结算方式1. 甲方应按照约定的时间和金额支付乙方的开发费用。
2. 开发费用包括研发费用、材料费、差旅费等，具体金额和支付方式由双方另行约定。
3. 若因甲方原因导致开发进度延误，甲方应相应调整支付时间。
六、质量保证和技术支持1. 乙方应保证开发的技术成果符合约定的质量要求。
2. 甲方在开发过程中遇到技术问题，乙方应提供必要的技术支持。
3. 乙方应确保所提供的技术成果不侵犯第三方的知识产权。
最新技术合同英文范本(合同范本)
最新技术合同英文范本(合同范本)Party A:Party B:Both parties have signed this contract based on the relevant provisions of the Guarantee Law of the People's Republic of China, the Regulations on Construction and Installation Engineering Contracts, and other relevant regulations through friendly negotiations.Article 1: Project Information(1) Project Name:(2) Project Location:(3) Project Content and Scope of Contract:1. Landscape design scheme and drawing design.2. Backfilling planting soil to the building elevation.3. Soil leveling, base fertilizer construction, planting, purchasing of plants, pruning, shaping, management and maintenance during the greening construction period, maintenance and management.4. Clearing debris before and after backfilling the planting soil.5. Water supply and drainage engineering, including connecting green spots, trench excavation, pipeline laying, construction of water meter (gate valve) well, installation and commissioning of water supply fittings, etc.6. Construction of the park, including trench excavation,site laying, maintenance, etc.7. Lighting engineering, including trench excavation,pipeline laying, installation and commissioning of electrical system, etc.Article 3: Project ScheduleThe commencement date of the project shall be based on the written commencement order issued by Party A. The trial operation period shall be days. The delivery and use of the project shall meet the following requirements:Planned completion date: From year month day to year month day.Total construction period: calendar days (construction and maintenance period for water supply and drainage, lighting, park construction is years, and greening maintenance periodis months).In the event of force majeure or Party A's reasons (including design changes proposed by Party A), after Party B submits a written request for extension and is confirmed by the supervising engineer and Party A, the approved extensionperiod shall not exceed Party A's delivery date.Article 3: Contracting Method and Project Cost3.1 Party B shall organize construction in accordance withthe construction drawing requirements determined by Party A and the construction acceptance specifications for this project. The construction, materials, construction period, quality, safety, and civilized construction shall beinspected and accepted by Party B.3.2 Contract amount: The total cost of the project is RMB [amount], which is a lump sum contract price, including risks, taxes, and other related project costs.Article 4: Payment Method1. After the completion of the total project volume isverified and confirmed by both parties, Party A shall pay [percentage] of the total contract price within [number] days.2. After the completion of the project, the total projectcost shall be paid [percentage].3. After all project acceptance is qualified, Party A shall verify within [number] days upon receiving the final completion report and settlement documents submitted by Party B, and provide confirmation or modification suggestions. The total price shall be paid within [number] months.4. After the expiry of the warranty period (based on the longest warranty period), the remaining balance [percentage]of the project cost shall be paid in one lump sum within [number] days. (The warranty period for park construction, lighting, water supply and drainage is [number] years, andthe maintenance period for greening is [number] months).Article 5: Responsibilities of Both PartiesParty A's Responsibilities:1. Responsible for providing Party B with the original civil engineering drawings and materials required for design and construction.2. During the construction process, issue written change notices for construction plans that need to be modified or additional items, which will serve as the basis for Party B's construction changes and project settlement.3. Responsible for coordinating different specialties and interface interfaces in the project, and provide Party B with the necessary water and electricity for construction, but the water and electricity fees shall be borne by Party B.4. Responsible for organizing project acceptance.5. Party A shall appoint an on-site project manager as the site representative, supervise the progress and quality of the project, inspect concealed works during acceptance, handle intermediate delivery acceptance visa procedures, urge Party B to organize various technical documents and reports as required, be responsible for visa, and organize final acceptance.Party B's Responsibilities:1. Within 7 days after signing the contract, Party B shall optimize and improve the construction drawings provided by Party A, submit them for approval, and submit the construction organization plan for Party A's approval.2. Purchase, transport, and storage of construction, equipment, and materials shall be carried out in accordance with the approved construction drawings. After key equipment is delivered to the construction site, Party B shall provide corresponding certificates to Party A for confirmation and signature.3. Responsible for the installation and construction of all equipment systems, and assign on-site representative engineers to directly contact Party A's site representative and report the construction organization structure.4. Party B shall strengthen the management of the construction team, follow the management system formulated by Party A, achieve safe and civilized construction, and take full responsibility for safety, fire prevention, and theft prevention during the construction process.5. Responsible for all commissioning work of the system and submit a commissioning report.6. After completion, Party B shall not damage completed civil works and installation facilities, ensuring good sanitation conditions; if destructive construction is truly necessary due to technical requirements, Party B shall obtain Party A's signed permit in advance, and Party A shall bear the cost of civil works and installation expenses not caused by Party B.7. Party B shall provide Party A with two copies of completion drawings, related electronic documents, computer technology, and system operation manuals.8. Before construction, Party B shall provide the project schedule and a list of key engineering technical personnel, strictly follow the approved project schedule by Party A, and ensure that the engineering and technical personnel for installation and commissioning are in place on time.9. Party B shall pay water and electricity fees used during the construction process to Party A on a monthly basis.Article 6: Engineering Quality Standards and Warranty Period 1. Engineering Quality Standards: Comply with the national and industry standards of China.2. Warranty Period: Both parties agree that the warranty period for this project is two years, which shall be calculated from the date of acceptance and delivery.3. After receiving a fault notification during the warranty period, Party B shall arrive at the site within [number] hours for handling. During the warranty period, Party B is responsible for warranty or return due to installationquality issues. If Party B does not carry out repairs within a reasonable time specified by Party A, Party A has the right to request another qualified unit to carry out repairs, and the cost shall be borne by Party B. Damages caused byimproper use by Party A are not covered by the warranty. Party B is responsible for repairs, but the cost shall be borne by Party A.Article 7: Project Acceptance1. Party B shall complete all adjustments of the systemwithin the specified time to achieve successful operation of the equipment. After [number] days of trial operation, Party B shall apply for project acceptance in writing to Party A. Party A shall determine the acceptance time and arrange for final acceptance.2. Prior to acceptance, Party B shall timely provide Party A with all relevant technical documents (including system operation manuals, technical standards and software), completion drawings, equipment material lists, corresponding floppy disks and manuals, commissioning reports, and related records and acceptance completion documents.3. The engineering quality shall meet the inspection evaluation standards, and after both parties have signed for confirmation, the acceptance date shall be the completion date.4. Concealed works acceptance: After Party B's self-inspection, fill out the concealed works record form and notify Party A for on-site acceptance. After acceptance is qualified, both parties shall sign for confirmation and proceed with the next construction process.5. Material and equipment acceptance: Purchasing equipment and materials shall be carried out according to the construction progress and delivered to the construction site. Party B must submit product qualification certificates and inspection reports for materials and equipment purchased bythemselves. Non-compliant materials or equipment that do not meet the quality standards or specifications shall not be used. Party A and the supervising personnel shall jointly inspect the purchased materials. Party B shall be responsible for any losses caused to the project. Party A may conduct spot checks on-site equipment and materials at any time. If any goods that do not meet the requirements of the equipment list are found, Party B shall be responsible for return and replacement until it meets the equipment list requirements. Party B shall be responsible for the storage of materials and equipment.6. Without acceptance and transfer, Party A shall not use the system. If it is really necessary to use partial or all of the system due to special circumstances, Party A shall obtain Party B's consent and complete the transfer procedures. After the transfer, Party A shall assume the duty of care, but it does not mean that the partial or all of the system has passed the inspection. The partial and all systems shallstill be accepted according to the contract provisions.7. Prior to project handover inspection, Party B shall instruct the operating personnel of Party A in advance. If the system project passes the inspection, Party B shall hold a training class on-site to teach Party A's operating personnel system knowledge, fault judgment and troubleshooting methods until all personnel can flexibly operate the system.8. Before project handover, Party B shall take responsibility for the protection of all equipment and materials on-site. During this period, Party B shall be responsible for maintenance and compensation, and Party A shall not bear any responsibility.Article 8: Breach of Contract Liability1. If Party A fails to pay the fees on time, Party A shall pay overdue payment interest according to the overdue payment method of the People's Bank of China, and the penalty shall be jointly borne at the time of final payment.2. If the project is delayed due to Party B's reasons, PartyB shall be fined an amount of RMB 10,000, and the total amount of fines shall not exceed [percentage] of the project cost.3. If Party B stops operating without Party A's consent, Party B shall breach the contract and Party A shall have the right to impose a penalty of more than RMB 10,000 as a penalty for Party B's breach. If it exceeds Party A'sdelivery date, Party B shall bear all losses incurred by Party A.4. If during the construction process, it is found that the project is substandard or Party B unilaterally reduces the project volume, the specifications or brands of project materials, or there are inconsistencies in the construction drawings, material and equipment lists, Party B shall breach the contract and pay liquidated damages. The penalty shall start from RMB 10,000 and be calculated based on [percentage] of the total contract price. The penalty amount shall be deducted from the project payment.5. Party B shall bear all losses caused by quality and safety accidents caused by Party B.。
技术支援英文合同3篇
技术支援英文合同3篇篇1合同编号：[具体编号]甲方（客户）：[甲方公司名称]地址：[甲方公司地址]乙方（服务提供商）：[乙方公司名称]地址：[乙方公司地址]根据《中华人民共和国合同法》及相关法律法规的规定，甲乙双方在平等、自愿、公平、诚实信用的基础上，就甲方所需的技术支援服务达成以下协议：一、服务内容乙方将为甲方提供技术支援服务，具体内容如下：1. 技术咨询：就甲方提出的技术问题提供解答和建议。
2. 技术培训：为甲方人员提供相关技术培训。
3. 故障排除：协助甲方解决技术故障，确保设备正常运行。
4. 系统升级：根据甲方需求，协助完成相关系统的升级工作。
5. 其他技术支援服务：[其他服务内容]二、服务期限本合同的服务期限自XXXX年XX月XX日起至XXXX年XX月XX 日止。
三、服务费用及支付方式1. 服务费用：人民币[金额]元。
2. 支付方式：[支付方式描述]。
3. 付款期限：[付款期限描述]。
四、双方责任与义务1. 甲方应确保所需服务的设备、环境等条件满足要求，配合乙方完成服务任务。
2. 乙方应按照合同约定的内容和期限提供服务，确保服务质量。
3. 乙方在提供服务过程中，应保护甲方的商业秘密和技术秘密，不得泄露或非法使用。
4. 双方应共同遵守国家法律法规，维护数据安全。
五、保密条款1. 双方同意对在执行本合同过程中了解到的对方商业秘密和技术秘密予以保密。
2. 未经对方许可，任何一方不得向第三方泄露、披露或公开涉及对方商业秘密和技术秘密的信息。
3. 保密期限为本合同生效之日起至合同终止后两年。
六、违约责任1. 若因乙方原因未按合同约定提供服务，乙方应承担违约责任，并赔偿甲方因此造成的损失。
2. 若甲方未按合同约定支付服务费用，甲方应承担违约责任。
3. 若因不可抗力导致合同无法履行，双方应及时沟通，协商解决。
七、争议解决因执行本合同所引起的任何争议，双方应通过友好协商解决；协商不成的，任何一方均有权向有管辖权的人民法院提起诉讼。
技术合同英文范文(完整版)
合同编号：YT-FS-6676-50技术合同英文范文(完整版)Clarify Each Clause Under The Cooperation Framework, And Formulate It According To The Agreement Reached By The Parties Through Consensus, Which Is Legally Binding On The Parties.互惠互利共同繁荣Mutual Benefit And Common Prosperity技术合同英文范文(完整版)备注：该合同书文本主要阐明合作框架下每个条款，并根据当事人一致协商达成协议，同时也明确各方的权利和义务，对当事人具有法律约束力而制定。
文档可根据实际情况进行修改和使用。
法律顾问服务合同legal counseling agreement聘请方： (下称甲方)consigner:地址：address：法定代表人：legal representative:受聘方：consignee: (hereinafter referred to as “party b”)地址：上海市淮海中路283号香港广场26楼address:26/f，hongkang plaza 283 huaihai road shanghai本合约由上列甲乙双方于中华人民共和国上海市订立。
this agreement is made and entered into by and between the two parties in shanghai, the people’s republic of china鉴于：whereas：甲方为促进业务发展，防范法律风险，决定聘请乙方为其常年法律顾问;party a want to promote its business and keep away law risks, decides to assign party b as its long-term law consultant.乙方系一家在中国境内注册设立并经中国政府特许、可持续运营的劳动法律服务机构，经与甲方商洽，同意接受聘请，担任其常年法律顾问;为此，now, therefore甲乙双方本着相互信任、合作共赢的原则，经友好、充分之协商，就聘请合约的条款及内容达成如下协议：the two parties based on principle of trusting and win-win cooperating, after friendly and thorough negotionation, the parties agreed the following terms and conditions on the consigning.第一条聘约期间article one consignment periods1.1 甲方聘请乙方作为常年法律顾问的期间为壹年，自____至_____;聘期届满后，本合约自动终止。
英文技术服务合同样本5篇
英文技术服务合同样本5篇篇1TECHNOLOGY SERVICE CONTRACTThis Technology Service Contract is made on [Date], between [Company A], with its principal place of business located at [Address], hereinafter referred to as "Service Provider" and [Company B], with its principal place of business located at [Address], hereinafter referred to as "Client," in accordance with the laws of the [Country/State].1. Scope of ServicesService Provider agrees to provide the following technical services to Client:* Detailed list of services (including but not limited to technology consulting, software development, system integration, technical support, etc.)* Description of tasks, milestones, deliverables, and project management related to each service item.2. Contract TermThe term of this Contract shall begin on the date of signing and shall continue until the services are fully performed or until the Contract is terminated in accordance with its terms.3. Fees and Payment* The total fees for the services to be provided by Service Provider shall be [Amount]. The fees shall be paid in full according to the payment schedule agreed upon by both parties.* Any additional services not listed in the Scope of Services section shall be agreed upon separately and shall be subject to additional fees.* All fees are exclusive of taxes, which Client shall be responsible for paying.4. ConfidentialityBoth parties shall maintain confidentiality regarding any information or data disclosed during the performance of this Contract. This includes any business secrets, proprietary information, technical know-how, and other confidential matters.5. Intellectual Property Rights* Service Provider shall retain ownership of all intellectual property rights related to the services provided unless otherwise agreed in writing.* Client shall have non-exclusive, non-transferable rights to use any deliverables resulting from the services provided under this Contract.* Any joint intellectual property developed during the term of this Contract shall be owned equally by both parties.6. Warranty and LiabilityService Provider shall ensure that the services provided are performed in a professional and workmanlike manner and are free from defects. If any defects are found, Service Provider shall promptly rectify them at no additional cost to Client. Service Provider shall not be liable for any indirect, consequential, or exemplary damages arising from the performance or breach of this Contract.7. TerminationThis Contract may be terminated by either party in the case of default by the other party, if the default is not rectified within a reasonable period of time. Termination shall be subject towritten notice and compliance with all applicable laws and procedures.8. Force MajeureNeither party shall be liable for any delay or failure in performance due to unforeseen circumstances or acts of God, such as natural disasters, wars, riots, or other events beyond their reasonable control.9. Miscellaneous* This Contract constitutes the entire agreement between the parties and supersedes all prior agreements or understandings, whether oral or written, regarding the subject matter hereof.* Any amendments or modifications to this Contract must be made in writing and signed by both parties.* Any disputes arising out of or in connection with this Contract shall be settled through friendly negotiations. If no settlement can be reached, either party may submit the dispute to [Dispute Resolution Mechanism/Court] for resolution.* This Contract shall be governed by the laws of [Country/State].* The headings in this Contract are for reference purposes only and shall not affect the interpretation or construction of any provisions herein.* The words "include," "includes," and "including" shall be deemed to be followed by the phrase "without limitation."In witness whereof, the parties have executed this Technology Service Contract:Service Provider:__________ (Signature)Title/NameDateClient:__________ (Signature)Title/Name篇2甲方（客户）：__________地址：__________联系方式：__________乙方（服务提供商）：__________地址：__________联系方式：__________鉴于甲方需要乙方提供特定的技术服务，双方经过友好协商，达成如下协议：一、服务内容（Scope of Services）1. 乙方将为甲方提供______技术服务。
技术合同英文范本3篇.doc
技术合同英文范本3篇有技术，不怕没有工作!英文技术合同对推进我国对外贸易事业的发展具有重要意义，在现代发展中使用越来越多。
技术合同英文范文篇一甲方：party a：乙方：party b：合同编号：contract no日期：date：签约地点：signed at：特约定：甲方基于下文所列各种因素，特与乙方达成了协议并一致同意：由甲方在订约日期之翌日起_____天之内为乙方建造并完成_____(涉约建筑)。
涉约建筑之规模及所需的钢筋、水泥、砖块、石子和其它建筑材料之数量，均在作为合同附件的设计图和施工细则中予以说明。
witnesses that the party a for considerations hereinafter named, contracts and agrees with the party b that party a will, within_____ days, next following the date hereof, build and finish a libarary building for party b. ( the building hereinafter is referred to as the said building.) the said building is of the following dimensions, with reinforced concrete, brick, stones and other materials, as are described in plans and specifications gereto annexed.基于上述情况，乙方及其法定代表郑重承诺向甲方支付人民币_____元整。
支付方法商定如下：in consideration of the foregoing, party b shall, for itself and its legal representatives, promise to pay party a the sum of one million rmb yuan in manner as follows, to wit：在上述工程开工之日，支付人民币_____元整在_____年_____月_____日，支付人民币_____元整甲方：party a：乙方：party b：合同编号：contract no日期：date：签约地点：signed at：技术合同英文范文篇二合同contract日期：合同号码：date: contract no.:买方：(the ;buyers) 卖方：(the sellers)兹经买卖双方同意按照以下条款由买方购进，卖方售出以下商品：this contract is made by and between the buyers and the sellers; whereby the buyers agree to buy and the sellers agree to sell the under-mentioned goods subject to the terms and conditions asstipulated hereinafter: (1) 商品名称: name of commodity：(2) 数量：quantity:(3) 单价：unit price:(4) 总值：total value:(5) 包装：packing:(6) 生产国别：country of origin : (7) 支付条款：terms of payment: (8) 保险：insurance:(9) 装运期限：time of shipment: (10) 起运港：port of lading: (11) 目的港：port of destination:(12)索赔：在货到目的口岸45天内如发现货物品质，规格和数量与合同不附，除属保险公司或船方责任外，买方有权凭中国商检出具的检验证书或有关文件向卖方索赔换货或赔款。
英文技术服务合同样本6篇
英文技术服务合同样本6篇篇1Technical Service AgreementThis Technical Service Agreement ("Agreement") is entered into as of [Date], by and between [Company A], with its principal place of business at [Address A], and [Company B], with its principal place of business at [Address B], collectively referred to as the "Parties".WHEREAS, [Company A] is in the business of providing technical services to clients; andWHEREAS, [Company B] is in need of technical services for its operations; andWHEREAS, [Company A] agrees to provide such technical services to [Company B] on the terms and conditions set forth herein;Now, therefore, in consideration of the mutual promises and covenants contained herein, the Parties agree as follows:1. Services. [Company A] shall provide technical services to [Company B] as requested by [Company B]. The specific scope ofservices, including deliverables, timelines, and fees, shall be set forth in separate work orders or project plans agreed upon by both Parties.2. Term. This Agreement shall commence on the Effective Date and shall continue until terminated by either Party upon [Number] days written notice to the other Party.3. Fees. [Company B] shall pay [Company A] fees for the services provided under this Agreement. The fees shall be set forth in the work orders or project plans and shall be due [Number] days from the date of invoice.4. Confidentiality. Each Party agrees to keep confidential all information received from the other Party and not to disclose such information to any third party without the prior written consent of the other Party. This provision shall survive the termination of this Agreement.5. Intellectual Property. Any intellectual property developed or created by [Company A] in the course of providing services to [Company B] shall be the exclusive property of [Company A], unless otherwise agreed upon in writing by both Parties.6. Termination. Either Party may terminate this Agreement upon [Number] days written notice if the other Party materiallybreaches any provision of this Agreement and fails to cure such breach within the [Number]-day period.7. Governing Law. This Agreement shall be governed by and construed in accordance with the laws of the state of [State], without regard to principles of conflicts of law.IN WITNESS WHEREOF, the Parties have executed this Agreement as of the Effective Date set forth above.[Company A]By: _________________________Name: _______________________Title: ________________________[Company B]By: _________________________Name: _______________________Title: ________________________Date: _________________________篇2Technical Service AgreementThis Technical Service Agreement (the "Agreement") is entered into and made effective as of [Date] (the "Effective Date") by and between [Tech Service Provider], located at [Address] ("Tech Service Provider") and [Client], located at [Address] ("Client").1. Services ProvidedThe Tech Service Provider agrees to provide the following services to the Client:- [List of services to be provided by Tech Service Provider]- [List any additional services to be provided]2. Term of AgreementThis Agreement shall commence on the Effective Date and shall continue for a period of [Length of time] months/years, unless earlier terminated in accordance with the terms of this Agreement.3. Fees and PaymentClient agrees to pay Tech Service Provider for the services provided under this Agreement. The fees for the services are listed in Attachment A. Payment shall be made [List payment terms: monthly, quarterly, etc.].4. TerminationEither party may terminate this Agreement early upon written notice to the other party. If the Client terminates the Agreement, they shall be responsible for paying any remaining fees due under the Agreement.5. ConfidentialityDuring the term of this Agreement, both parties may have access to confidential information of the other party. Both parties agree to keep all confidential information confidential and not disclose it to a third party without prior written consent.6. Ownership of Work ProductAny work product developed by Tech Service Provider in connection with the services provided under this Agreement shall be the property of the Client. Tech Service Provider agrees to assign all rights to the work product to the Client.7. Limitation of LiabilityIn no event shall either party be liable for any consequential, indirect, incidental, special, or punitive damages arising out of or in connection with this Agreement, even if the party has been advised of the possibility of such damages.8. Governing LawThis Agreement shall be governed by and construed in accordance with the laws of [State/Country].This Agreement constitutes the entire agreement between the parties with respect to the services provided by Tech Service Provider to the Client and supersedes all prior agreements and understandings, whether written or oral. This Agreement may be modified only by a written agreement signed by both parties.IN WITNESS WHEREOF, the parties hereto have executed this Agreement as of the Effective Date.[Signature]Tech Service Provider[Signature]ClientAttachment A: Fee Schedule[Include fee schedule]篇3Technical Service AgreementThis Technical Service Agreement ("Agreement") is entered into by and between [Company Name], with a principal place of business at [Company Address], ("Provider") and [Client Name], with a principal place of business at [Client Address], ("Client") on [Date].1. Scope of ServicesProvider agrees to provide technical services to Client in accordance with the terms and conditions set forth in this Agreement. The specific services to be provided shall be as set forth in Exhibit A attached hereto. Provider shall use commercially reasonable efforts to perform the services in a timely and professional manner.2. FeesClient shall pay Provider the fees specified in Exhibit A for the services provided hereunder. Fees shall be paid within [Number] days of receipt of an invoice from Provider. Any fees not paid when due shall accrue interest at the rate of [Interest Rate]% per month.3. Term and TerminationThis Agreement shall commence on the date first written above and shall continue until terminated by either party upon[Number] days written notice. Either party may terminate this Agreement immediately upon the occurrence of a material breach by the other party which remains uncured for [Number] days after written notice.4. ConfidentialityProvider agrees to hold all Confidential Information (as defined below) of Client in strict confidence and not to use or disclose such information except as necessary to perform the services hereunder. "Confidential Information" means any information, whether oral, written or in any medium, that is marked as confidential or is of a confidential nature, including but not limited to business plans, customer lists, and financial information.5. Limitation of LiabilityProvider shall not be liable to Client or any third party for any indirect, incidental, special, or consequential damages, including but not limited to lost profits, arising out of or in connection with the services provided hereunder. Provider’s total liability under this Agreement shall be limited to the total fees paid by Client to Provider in the [Number] months preceding the event giving rise to the claim.6. Governing LawThis Agreement shall be governed by and construed in accordance with the laws of the State of [State], without giving effect to its conflicts of laws principles. Any disputes arising under this Agreement shall be resolved by binding arbitration in accordance with the rules of the American Arbitration Association.7. Entire AgreementThis Agreement, including all exhibits and attachments, constitutes the entire agreement between the parties with respect to the subject matter hereof and supersedes all prior agreements, whether written or oral, relating to such subject matter. This Agreement may be modified only by a written instrument signed by both parties.IN WITNESS WHEREOF, the parties hereto have executed this Agreement as of the date first written above.[Provider Name]By:_______________________Name:Title:[Client Name]By:_______________________Name:Title:篇4Technical Service Contract SampleThis Technical Service Contract (the "Contract") is entered into as of [Effective Date] by and between [Company Name], with a registered address at [Company Address] (the "Client") and [Service Provider Name], with a registered address at [ServiceProvider Address] (the "Service Provider").1. Scope of Services: The Service Provider agrees to provide technical support and assistance to the Client related to [description of services] as detailed in Exhibit A attached hereto. The services shall be performed in a professional and timely manner, and in accordance with industry standards.2. Term: This Contract shall commence on the Effective Date and shall continue for a period of [Contract Duration] unless earlier terminated by either party in accordance with the termination provisions set forth herein.3. Compensation: In consideration for the services provided by the Service Provider, the Client shall pay the Service Provider [Payment Amount] in [Payment Frequency]. Payment shall be made within [Payment Term] days of the receipt of an invoice from the Service Provider.4. Confidentiality: The Service Provider agrees to maintain the confidential information of the Client in strict confidence and not to disclose, use or reproduce such information for any purpose other than providing the services under this Contract.5. Termination: Either party may terminate this Contract upon [Number of Days] days written notice to the other party. In the event of termination, the Client shall pay for all services performed by the Service Provider up to the date of termination.6. Indemnification: The Service Provider shall indemnify, defend and hold harmless the Client from and against any and all claims, liabilities, damages, costs and expenses arising out of or related to the services provided under this Contract.7. Governing Law: This Contract shall be governed by and construed in accordance with the laws of [Jurisdiction]. Any disputes arising out of or in connection with this Contract shall be resolved by arbitration in [Arbitration Location] in accordance with the rules of the [Arbitration Association].8. Entire Agreement: This Contract constitutes the entire agreement between the parties with respect to the subject matter hereof and supersedes all prior agreements and understandings, whether written or oral.IN WITNESS WHEREOF, the parties hereto have executed this Contract as of the Effective Date first written above.[Client Name][Service Provider Name]By: __________________________ By:__________________________Name:Name:Title:Title:Exhibit A: Description of Services[Insert description of services]篇5Technical Service Contract SampleThis Technical Service Contract ("Contract") is entered into by and between [Service Provider], a company organized and existing under the laws of [Country], with its principal place of business located at [Address] ("Service Provider"), and [Client], a company organized and existing under the laws of [Country], with its principal place of business located at [Address] ("Client").Agreement1. Scope of Services. Service Provider shall provide technical services to Client as specified in Exhibit A attached hereto. The services shall be performed in a professional and workmanlike manner, and in accordance with industry standards.2. Term. This Contract shall commence on [Start Date] and shall continue for a period of [Term] months unless terminated earlier as provided herein.3. Compensation. Client shall pay Service Provider a fee as specified in Exhibit A for the services provided under this Contract. Payment shall be made within [Number] days of receipt of an invoice from Service Provider.4. Expenses. Service Provider shall be responsible for all expenses, costs, and fees incurred in the performance of servicesunder this Contract, unless otherwise agreed upon in writing by both parties.5. Confidentiality. Service Provider shall keep confidential all information obtained in connection with the performance of services under this Contract and shall not disclose such information to any third party without the prior written consent of Client.6. Ownership of Work Product. Any work product created by Service Provider in the performance of services under this Contract shall be the exclusive property of Client.7. Termination. Either party may terminate this Contract upon [Number] days written notice to the other party. In the event of termination, Client shall pay Service Provider for all services performed prior to the effective date of termination.8. Governing Law. This Contract shall be governed by and construed in accordance with the laws of [State/Country].In witness whereof, the parties hereto have caused this Contract to be executed as of the date first above written.[Service Provider] [Client]By: By: Name: Name: Title: Title: Date: Date:Exhibit A - Scope of Services1. Description of Services:2. Fee:3. Payment Terms:4. Start Date:5. Term:This Technical Service Contract Sample is provided for informational purposes only and should not be considered legal advice. It is recommended that you consult with a legal professional before entering into any contractual arrangement.篇6Technical Service ContractThis Technical Service Contract ("Contract") is entered into on [Date] by and between [Client], with a business address at [Address] ("Client"), and [Service Provider], with a business address at [Address] ("Service Provider").1. Scope of ServicesService Provider agrees to provide technical services to Client as described in Exhibit A. The services may include, but arenot limited to, software maintenance, troubleshooting, system upgrades, and consulting services.2. TermThe term of this Contract shall commence on [Date] and shall continue until [Date] unless terminated earlier in accordance with the provisions of this Contract.3. FeesClient agrees to pay Service Provider fees for the services rendered. The fees shall be as outlined in Exhibit B. Payment shall be due within 30 days of receipt of the invoice.4. ConfidentialityBoth parties agree to keep all information exchanged during the course of this Contract confidential. This includes all business information, technical information, and trade secrets.5. WarrantiesService Provider warrants that all services will be performed in a professional manner and in accordance with industry standards. If any defects or issues arise within [Time Period] after the services are rendered, Service Provider agrees to rectify them at no additional cost to Client.6. TerminationEither party may terminate this Contract with [Notice Period] written notice. In the event of termination, Client shall pay for all services rendered up to the date of termination.7. Governing LawThis Contract shall be governed by the laws of the state of [State] and any disputes arising under this Contract shall be resolved in the state courts of [State].8. Entire AgreementThis Contract constitutes the entire agreement between the parties and supersedes any prior agreements or understandings, oral or written, relating to the subject matter herein.In witness whereof, the parties hereto have executed this Contract as of the date first above written.[Client]By: ___________________________Name: _________________________Title: __________________________[Service Provider]By: ___________________________ Name: _________________________ Title: __________________________ Exhibit A: Description of Services Exhibit B: Fee Schedule。
新技术合同英文范本(合同范本)
新技术合同英文范本(合同范本)Party A:Party B:Based on the relevant provisions of the Guarantee Law of the People's Republic of China and the Regulations on Construction and Installation of Engineering Contracts, Party A and Party B have reached a friendly agreement to sign this contract.Article 1: Project Description(1) Project Name:(2) Project Location:(3) Project Content and Scope of Contract:1. Landscape design plan and drawing design for garden greening project.2. Backfill planting soil to the building elevation.3. Soil leveling, basal fertilization, planting, procurement of green plants, pruning, shaping, management and maintenance during the greening construction and maintenance period.4. Cleaning of debris before and after backfilling planting soil.5. Water supply and drainage works including connection to the green area, excavation of pipe trench, laying of pipes, construction of water meter (valve) well, installation and commissioning of water supply fittings, etc.6. Park construction works including excavation of trench, ground laying, and warranty.7. Lighting works including excavation of trench, laying of pipes, installation and commissioning of electrical systems, etc.Article 3: Project DurationThe commencement date of this project shall be based on the written commencement order issued by Party A, and the trial operation period shall be days. The project delivery date shall meet the following requirements:Planned completion time: Year Month Day to Year Month DayTotal construction period: calendar days (including years for water supply and drainage, lighting, and park construction, and months for greening maintenance).In case of force majeure or reasons caused by Party A (including design changes proposed by Party A), after receiving a written request for extension from Party B and confirmation by the supervising engineer and Party A, the approved extension period shall be granted. However, the extension period shall not exceed Party A's delivery date.Article 3: Contracting Method and Project Cost1.1 Party B shall organize the construction in accordance with Party A's specified construction drawings and the construction acceptance specifications of this project. The contractor, materials, construction period, quality, safety, and civilized construction shall be verified through the acceptance of this project by Party A.1.2 Contract Amount: The total cost of the project is RMB________, which is a lump-sum contract price and includes risks, taxes, and other relevant project expenses.Article 4: Payment Method1. Upon completion of the total project quantity, Party Ashall verify the project quantity and cost with Party B, and make a payment of ________% of the total contract pricewithin ________ days.2. After the completion of the project, ________% of thetotal project cost shall be paid.3. After all projects are inspected and accepted, Party Ashall verify the final account and make a payment of ________% within ________ days after receiving Party B's final account report and settlement materials. The total price shall bepaid within ________ months.4. The remaining balance of ________% of the project payment shall be paid in full ________ days after the expiration ofthe warranty period (based on the longest warranty period). (The warranty period for park construction, lighting, andwater supply and drainage is ________ years, and the maintenance period for greening is ________ months).Article 5: Responsibilities of Both Parties(A) Party A's Responsibilities1. Responsible for providing Party B with the original civil engineering drawings and information required for design and construction.2. During the construction process, issue written change notices for construction schemes or additional items thatneed modification, which serve as the basis for Party B's construction changes and project settlement.3. Responsible for coordinating different specialties and interface interfaces in the project, and providing water andelectricity required for Party B's construction (water and electricity fees shall be borne by Party B).4. Responsible for organizing project acceptance.5. Designate a project manager as the on-site representative to supervise the project progress and quality, inspect concealed works during acceptance, handle intermediate delivery of project acceptance certification procedures, urge Party B to organize various technical documents and reports as required, responsible for certification, and organizefinal acceptance.(B) Party B's Responsibilities1. Within 7 days after the signing of the contract, Party B shall optimize and improve the construction drawings provided by Party A, submit them for approval, and submit the construction organization plan for approval by Party A.2. Purchase, transportation, and storage of construction, equipment, and materials shall be carried out according to the approved construction drawings. After the key equipment is transported to the construction site, Party B shall provide relevant certificates to Party A for confirmation and signature.3. Responsible for the installation and construction of all system equipment and wiring, assign on-site representative engineers to directly communicate with Party A's on-site representative, and report the construction organization structure.4. Party B shall strengthen the management of the construction team, follow the management system formulated by Party A, achieve safe and civilized construction, and take full responsibility for safety, fire prevention, and anti-theft during the construction process.5. Responsible for all commissioning work of the system and submit the commissioning report.6. Upon completion of Party B's work, Party B shall not damage the completed civil engineering and installation facilities and ensure a good sanitary condition. If destructive construction is required for technical reasons, Party A's written permission shall be obtained in advance. The cost of non-Party B caused civil engineering and installation expenses shall be borne by Party A.7. Party B shall provide Party A with two copies of as-built drawings, relevant electronic files, computer technology, and system operation manuals.8. Before construction, Party B shall provide the construction schedule and a list of major engineering technicians, strictly follow the approved construction schedule of Party A, and ensure that the engineering technicians for installation and commissioning are in place on time.9. Party B shall pay Party A for the use of water and electricity during the construction process on a monthly basis.Article 6: Quality Standards and Warranty Period1. Quality Standards: Conform to the national and industry standards of China.2. Warranty Period: The warranty period for this project is two years, which shall be calculated from the date of acceptance and delivery of the project.3. Upon receiving a fault notification during the warranty period, Party B shall respond and arrive at the site within________ hours. During the warranty period, Party B shall be responsible for repairing or replacing any equipment that has quality issues. If Party B fails to repair within areasonable time specified by Party A, Party A has the rightto request other qualified units to perform the repairs, and the cost shall be borne by Party B. Damages caused byimproper use by Party A shall not be covered by the warranty. Party B shall be responsible for the repairs, but the cost shall be paid by Party A.Article 7: Project Acceptance1. After completing all adjustments of the system within the specified time to achieve the successful operation of the equipment, Party B shall submit a written application for project acceptance to Party A after ________ days of trial operation. Party A shall determine the acceptance date and arrange for final acceptance.2. Before acceptance, Party B shall promptly provide Party A with all relevant technical documents (including system operation manuals, technical standards and software), as-built drawings, equipment and material lists, corresponding original disks and instructions, commissioning reports,related records, and acceptance completion documents.3. The project quality shall meet the inspection andevaluation standards, and both parties shall sign and confirm. The acceptance date shall be the completion date.4. Concealed works acceptance: After self-inspection by Party B, fill in the concealed works record form and notify Party A for on-site acceptance. After acceptance, both parties shall sign and confirm the commencement of the next construction process.5. Material and equipment acceptance: Purchase equipment according to the construction progress and transport them to the construction site. Party B's self-purchased materials and equipment must submit product qualification certificates and inspection reports. Items that do not meet the quality standards or specifications shall not be used; Party A and the supervising engineer shall jointly inspect the purchased materials; Party B shall be responsible for any losses caused to the project; Party A may randomly inspect on-site equipment and materials. If goods that do not meet the requirements of the equipment list are found, Party B shall be responsible for returning or replacing the goods until they meet the equipment list requirements. Party B shall be responsible for the storage of materials and equipment.6. Without acceptance and transfer, Party A shall not use the system. If it is necessary to use partial or all of the system due to special circumstances, with the consent of Party B, the transfer procedures shall be completed. After the transfer, Party A shall assume the responsibility for care, but it does not mean that the partial or all of the system has passed the inspection. The partial and all of the system shall still be subject to the completion acceptance as stipulated in the contract.7. Before project handover inspection, Party B shall provide operational knowledge to Party A's operators in advance. If the system project passes the inspection, Party B shall hold a training class on-site to impart system knowledge, fault diagnosis, and troubleshooting methods to Party A's operators until all personnel can flexibly use the operation skills. 8. Before project handover, Party B shall be responsible for the protection of all equipment and materials on-site. Duringthis period, Party B shall be responsible for maintenance and compensation, and Party A shall not be responsible.Article 8: Breach of Contract Liability1. If Party A fails to make payment of each installment feeto Party B on time, Party A shall pay overdue paymentinterest in accordance with the payment method of China's People's Bank, and the late payment shall be jointly borne at the time of Party A's final payment.2. If Party B's project completion is delayed due to PartyB's reasons, an overdue penalty of RMB 10,000 shall be imposed, with the total penalty not exceeding ________% ofthe project cost.3. If Party B stops operation without Party A's consent,Party B shall be in breach of contract and Party A shall have the right to impose a penalty of no less than RMB 10,000 as a penalty for Party B's breach. If the delay exceeds Party A's delivery date, Party B shall bear all losses incurred byParty A.4. During the construction process, if it is found that the project is inferior in quality, or Party B reduces theproject quantity without authorization, the specifications, brands, construction drawings, and material equipment list do not match, Party B shall be in breach of contract and shall pay a penalty. The penalty starting point shall be RMB 10,000, calculated based on ________% of the total contract price,and so on, with deductions made from the project payment accordingly.5. Party B shall bear all losses caused by Party B's quality and safety accidents.Article 9: Dispute ResolutionIn the event of a dispute arising from the performance ofthis contract, both parties shall discuss in a spirit offriendliness and fairness. If no agreement can be reachedthrough negotiation, either party may bring a lawsuit to thePeople's Court of Zhuanghe City.Article 10: Effectiveness of the Contract1. This contract shall come into effect upon the signaturesand seals of both parties, and shall become invalid uponcompletion of the project acceptance, expiration of thewarranty period, and settlement of the final payment.2. This contract is made in duplicate, with each partyholding one copy, both having equal legal effect.(No text beyond this point)Party A: Party B: Legal Representative: Legal Representative: Authorized Agent: Authorized Agent: Date: Date:。
技术合同范本英文
技术合同范本英文Title: Technical Contract Template in EnglishThis Technical Contract (hereinafter referred to as the "Contract") is made and entered into as of [Insert Date], and between [Insert Party A's Name] (hereinafter referred to as "Party A") and [Insert Party B's Name] (hereinafter referred to as "Party B").WHEREAS, Party A is a pany engaged in the field of [Insert Field of Activity] with expertise in [Insert Specific Expertise];WHEREAS, Party B is a pany engaged in the field of [Insert Field of Activity] and requires Party A's expertise for the development of [Insert Project Description];NOW, THEREFORE, in consideration of the mutual covenants and agreements set forth herein, the Parties agree as follows:1. DefinitionsFor the purposes of this Contract, the following terms shall have the following meanings:a. "Project" refers to the development of [Insert Project Description] Party A for Party B.b. "Deliverables" refers to the tangible and intangible items produced Party A in the course of pleting the Project, including but not limited to software, documentation, and other related materials.c. "Intellectual Property Rights" (IPR) refers to all专利权 (patents),著作权(copyrights),商标权 (trademarks), trade secrets, and any other intellectual property rights recognized under applicable laws.d. "Confidential Information" refers to any data, materials, products, technology, puter programs, specifications, manuals, business plans, software, marketing plans, financial information, and other information disclosed or submitted, in writing, orally, or any other media, to the other Party.2. Scope of Worka. Party A agrees to provide the services necessary for the pletion of the Project, which shall include, but not be limited to, the following:i. Development of the Project in accordance with the specifications and requirements provided Party B.ii. Delivery of the Deliverables to Party B in a timely and efficient manner.iii. Providing technical support and mntenance services for the Project as specified in this Contract.b. Party B agrees to provide Party A with all necessary information, materials, and access to resources required for the pletion of the Project.3. Payment Termsa. Party B agrees to pay Party A the total Contract Price of [Insert Total Contract Price] for the services rendered under this Contract.b. Payment shall be made in [Insert Number] installments as follows:i. [Insert Percentage] of the total Contract Price upon signing of this Contract.ii. [Insert Percentage] of the total Contract Price upon pletion of [Insert Milestone].iii. [Insert Percentage] of the total Contract Price upon final delivery and acceptance of the Deliverables.4. Intellectual Property Rightsa. Party A retns all right, , and interest in and to the Intellectual Property Rights associated with the Project, except for the rights granted to Party B under this Contract.b. Party B shall have a non-exclusive, worldwide, royalty-free license to use, reproduce, distribute, and create derivative works of the Deliverables for its internal business purposes.5. Confidentialitya. Each Party agrees to mntn the confidentiality of the Confidential Information of the other Party and not to use or disclose such Confidential Information except as expressly permitted under this Contract.b. The confidentiality obligations shall survive the termination or expiration of this Contract for a period of [Insert Number] years.6. Term and Terminationa. The term of this Contract shall begin on the Effective Date and shall continue until the pletion of the Project, unless terminated earlier in accordance with this Contract.b. Either Party may terminate this Contract upon written notice to the other Party if the other Party breaches any material term or condition of this Contract and fls to cure such breach within [Insert Number] days after receipt of written notice.7. Warranties and Representationsa. Party A warrants that it has the necessary expertise and resources to plete the Project in accordance with the terms of this Contract.b. Party B warrants that it has the legal right and authority to enter into this Contract and that the Project does not infringe upon the Intellectual Property Rights of any third party.8. Dispute ResolutionAny disputes arising out of or in connection with this Contract shall be resolved through binding arbitration in accordance with the rules of the [Insert Arbitration Association].9. Miscellaneousa. This Contract constitutes the entire agreement between the Parties and supersedes all prior agreements, negotiations, and understandings, whether written or oral.b. This Contract may be amended, modified, or supplemented only a written instrument executed both Parties.c. This Contract shall be governed and construed in accordance with the laws of [Insert Jurisdiction].IN WITNESS WHEREOF, the Parties have executed this Technical Contract as of the date first above written.[Signature of Party A] _________________________[Name of Party A] ___________________________[Signature of Party A's Representative] ___________[Title of Party A's Representative] _______________[Signature of Party B] _________________________[Name of Party B] ___________________________[Signature of Party B's Representative] ___________[Title of Party B's Representative] _______________Noun Definitions:Patent Rights: Legal rights granted to an inventor for a limited period, preventing others from making, using, selling, or importing the invention without permission.Copyrights: Legal rights that protect the original expression of an idea in a literary, artistic, or musical work.Trademarks: A recognizable sign, symbol, word, or phrase that identifies a product or service and distinguishes it from others.Trade Secrets: Confidential information that gives a business a petitive edge and is not publicly known.Confidential Information: Information that is not publicly known and is intended to be kept secret between the parties involved.Intellectual Property Rights (IPR): Legal rights protecting the fruits of human intellect, including patents, copyrights, trademarks, and trade secrets.Deliverables: Tangible and intangible items produced as part of a project, such as software, documentation, and other related materials.。
英文技术服务合同范本
英文技术服务合同范本Technical Service Agreement1. Scope of Services:2. Obligations of Service Provider:2.2 Service Provider shall assign qualified and trained personnel to perform the services.2.4 Service Provider shall keep all proprietary information of Client confidential and shall not disclose it to any third party except as required by law or with the prior written consent of Client.3. Obligations of Client:3.1 Client shall provide Service Provider with necessary access to the systems, equipment, and premises required to perform the services.3.2 Client shall cooperate with Service Provider and provide any information or documentation reasonably requested to facilitate the provision of the services.4. Term and Termination:4.2 Either party may terminate this Agreement upon written notice to the other party in the event of a material breach of any provision of this Agreement, which remains uncured for aperiod of [Number of Days] days after receiving written notice of such breach from the non-breaching party.4.3 In the event of termination, Client shall pay Service Provider for the services rendered up to the effective date of termination.5. Fees and Payment:5.1 Client agrees to pay Service Provider the fees as set forth in Schedule B attached hereto and incorporated herein by reference. Fees shall be payable [monthly/quarterly/annually] within [Number of Days] days from the date of invoice.5.2 Client shall reimburse Service Provider for all reasonable and necessary expenses incurred in the performance of the services, provided they are pre-approved by Client in writing.6. Limitation of Liability:6.1 Service Provider shall not be liable for any indirect, incidental, consequential, or special damages arising out of or in connection with the performance of the services, even if advised of the possibility of such damages.6.2 Service Provider's liability to Client for any direct damages under this Agreement shall be limited to the total fees paid by Client to Service Provider during the twelve (12) months preceding the event giving rise to the liability.7. Governing Law and Dispute Resolution:7.1 This Agreement shall be governed by and construed in accordance with the laws of [Jurisdiction].8. Entire Agreement:8.1 This Agreement constitutes the entire agreement between the parties with respect to the subject matter hereof and supersedes all prior oral or written agreements, understandings, or representations relating to such subject matter.8.2 This Agreement may only be amended or modified inwriting and signed by both parties.IN WITNESS WHEREOF, the parties hereto have executed this Technical Service Agreement as of the Effective Date.[Client Name]By: [Authorized Signatory]Title: [Title][Service Provider Name]By: [Authorized Signatory]Title: [Title]Schedule A[Description of Services]Schedule B。
英文版技术协议合同书（范本）（5）
英文版技术协议合同书英文版技术协议合同书英文版技术协议合同书范文一Part A 甲方：雇主Part B 乙方：技术服务提供商Setio n oneServie Items第一条服务项目 1.1PARTYA here b reta ins PA RTY Bto pro vide t heser vies o utline d in E xhibit s A an d B hi h areinorpo ratedand ma de a p art of thisAgreem ent in urredb PART Y B at the r equestof PA RTY Ain ren dering servi es her eunder.甲方收到乙方送交的收据复印件或其它相关开支证明后，应当立即将乙方按照甲方要求提供本协议项下服务项目而产生的合理差旅费ear s; the foreg oing o bligat ion sh all no t appl toCo nfiden tial I nforma tion:hih an be sh on tohave b een kn on toPARTYB prio r to i ts ree ipt fr om PAR TY A;hih is or la full b eesge nerall knonto the publi; hihis laf ull aq uiredfrom t hird p arties ho ha ve a r ight t o disl ose su h Conf identi al Inf ormati on; hi h b mu tual a greeme nt isreleas ed fro m aon fident ial st atus;and hi h PART Y B is requi red bla toreleas e, pro videdthat P ARTY A is gi ven ad vane r ittennotieof suh requi rement b PAR TY B s o that PARTY A maontest or li mit su hrele ase.对于由甲方因本协议提供给乙方的所有信息资料，以及由于提供本协议项下服务项目而由乙方获取的所有信息资料，包括但不限于与本协议双方当事人业务关系有关的任何信息资料，以及任何在双方当事人业务协作期间开发的信息资料有证据显示在甲方向乙方提供保密资料之前，乙方已经获得了该保密资料; 公众领域内的资料或合法进入公众领域的资料; 以合法的方式从有权披露该保密资料的第三方获取的保密资料; 乙方应法律要求披露的保密资料，但乙方应当将该法律要求提前以书面形式通知甲方，以便甲方可以反对或限制该等披露。
- 1、下载文档前请自行甄别文档内容的完整性，平台不提供额外的编辑、内容补充、找答案等附加服务。
- 2、"仅部分预览"的文档,不可在线预览部分如存在完整性等问题,可反馈申请退款(可完整预览的文档不适用该条件!)。
- 3、如文档侵犯您的权益，请联系客服反馈,我们会尽快为您处理(人工客服工作时间：9:00-18:30)。
合同编号：YT-FS-1908-76
技术合同英文范本(完整
版)
Clarify Each Clause Under The Cooperation Framework, And Formulate It According To The Agreement Reached By The Parties Through Consensus, Which Is Legally Binding On The Parties.
互惠互利共同繁荣
Mutual Benefit And Common Prosperity
技术合同英文范本(完整版)
备注：该合同书文本主要阐明合作框架下每个条款，并根据当事人一致协商达成协议，同时也明确各方的权利和义务，对当事人具有法律约束力而制定。
文档可根据实际情况进行修改和使用。
合同 contract
日期：合同号码：
date: contract no.:
买方： (the ;buyers) 卖方： (the sellers) 兹经买卖双方同意按照以下条款由买方购进，卖方售出以下商品：
this contract is made by and between the buyers and the sellers; whereby the buyers agree to buy and the sellers agree to sell the under-mentioned goods subject to the terms and conditions as stipulated hereinafter:
(1) 商品名称:
name of commodity：
(2) 数量：
quantity:
(3) 单价：
unit price:
(4) 总值：
total value:
(5) 包装：packing:
(6) 生产国别：country of origin : (7) 支付条款：
terms of payment: (8) 保险：insurance:
(9) 装运期限：
time of shipment: (10) 起运港：
port of lading: (11) 目的港：
port of destination:
(12)索赔：在货到目的口岸45天内如发现货物品质，规格和数量与合同不附，除属保险公司或船方责任外，买方有权凭中国商检出具的检验证书或有关文件向卖方索赔换货或赔款。
claims:
within 45 days after the arrival of the goods at the destination, should the quality, specifications or quantity be found not in conformity with the stipulations of the contract except those claims for which the insurance company or the owners of the vessel are liable, the buyers shall, have the right on the strength of the inspection certificate issued by the c.c.i.c and the relative documents to claim for compensation to the sellers
(13)不可抗力：由于人力不可抗力的原由发生在
制造，装载或运输的过程中导致卖方延期交货或不能交货者，卖方可免除责任,在不可抗力发生后，卖方须立即电告买方及在14天内以空邮方式向买方提供事故发生的证明文件，在上述情况下，卖方仍须负责采取措施尽快发货。
force majeure :
the sellers shall not be held responsible for the delay in shipment or non-deli-very of the goods due to force majeure, which might occur during the process of manufacturing or in the course of loading or transit. the sellers shall advise the buyers immediately of the occurrence mentioned above the within fourteen days there after . the sellers shall send by airmail to the buyers for their acceptancea certificate of the accident. under such circumstances the sellers, however, are still under the obligation to take all necessary
measures to hasten the deliveryof the goods.
(14)仲裁：凡有关执行合同所发生的一切争议应通过友好协商解决，如协商不能解决，则将分歧提交中国国际贸易促进委员会按有关仲裁程序进行仲裁，仲裁将是终局的，双方均受其约束，仲裁费用由败诉方承担。
arbitration :
all disputes in connection with the execution of this contract shall be settled friendly through negotiation. in case no settlement can be reached, the case then may be submitted for arbitration to the arbitration commission of the china council for the promotion of international trade in accordance with the provisional rules of procedure promulgated by the said arbitration commission . the arbitration committee shall be final and binding upon both parties. and the arbitration
fee shall be borne by the losing parties.
买方：卖方:
(授权签字) (授权签字)
这里填写您企业或者单位的信息
Fill In The Information Of Your Enterprise Or Unit Here。