施工合同中英文模板.
建设工程施工合同中英文对照版
建设工程施工合同中英文对照版中英文建设工程施工合同Contract for Construction Project本合同是由承包人（以下简称“甲方”）和业主（以下简称“乙方”）共同订立，旨在规定双方在建设工程项目中的权益和义务。
This contract is entered into by and between the Contractor (hereinafter referred to as "Party A") and the Owner (hereinafter referred to as "Party B") to regulate the rights and obligations of both parties in the construction project.总则 General Provisions第一条项目名称及工程地点：本工程名称为_________，位于_________。
Article 1: Project Name and Location: The name of the project is__________, located in __________.第二条总承包范围：甲方应按照乙方的要求，完成工程项目的设计、施工、验收等工作。
Article 2: Scope of General Contracting: Party A shall complete the design, construction, and acceptance of the project in accordance with PartyB's requirements.第三条施工期限：本工程的施工期限为_________，甲方必须按时完成工程，并交付乙方使用。
Article 3: Construction Period: The construction period of this project is __________. Party A must complete the project on time and deliver it to Party B for use.义务与责任 Obligations and Responsibilities第四条甲方责任：甲方应根据乙方的要求，制定合理的工程施工方案，并保证工程按照合同和法律法规的要求进行。
施工合同范本英文
施工合同范本英文Construction Contract TemplateThis Construction Contract ("Contract") is made and entered into on [date] between [Party A's name] ("Party A") and [Party B's name] ("Party B").1. Project DescriptionParty A agrees to engage Party B for the construction of [project name and detls] located at [project location].2. Contract Price and Payment TermsThe total contract price for the project is [amount in figures and words]. Party A shall make payments to Party B in accordance with the following schedule: [detl the payment schedule and conditions].3. Work ScheduleThe construction work is scheduled to mence on [start date] and be pleted [pletion date], subject to reasonable delays due to unforeseen circumstances.4. Quality StandardsThe construction work shall conform to the applicable industry standards and the specifications agreed upon both parties. Party B warrants that the pleted project will be free from defects for a period of [warranty period] after pletion.5. Changes and AmendmentsAny changes or amendments to the scope of work, specifications, or contract price shall be mutually agreed upon in writing both parties.6. Dispute ResolutionIn the event of any dispute or controversy arising out of or in connection with this Contract, the parties shall attempt to resolve the matter through amicable negotiation. If negotiation fls, the dispute shall be submitted to arbitration in accordance with the rules of [arbitration institution].7. TerminationThis Contract may be terminated either party in the event of a material breach of its terms and conditions the other party, after providing written notice and an opportunity to cure the breach.8. Force MajeureNeither party shall be liable for any delay or flure in performance of this Contract due to force majeure events, such as natural disasters, war, or government actions.9. Governing LawThis Contract shall be governed and construed in accordance with the laws of [jurisdiction].10. Entire AgreementThis Contract constitutes the entire agreement between the parties and supersedes all prior negotiations, understandings, and agreements.IN WITNESS WHEREOF, the parties have executed this Contract as of the date first above written.Party A: [Name and Signature]Party B: [Name and Signature]Date: [date]Please note that the above is a basic template and should be customized and reviewed legal professionals to meet the specific requirements and circumstances of each construction project.。
建筑施工合同英文翻译模板
建筑施工合同英文翻译模板Construction Contract Template。
This Construction Contract ("Contract") is entered into as of [Contract Date], by and between [Owner Name] ("Owner") and [Contractor Name] ("Contractor").1. Scope of Work。
Contractor agrees to perform all construction work necessary for the completion of [Project Name] ("Project") in accordance with the plans and specifications prepared by [Architect/Engineer Name] ("Architect/Engineer"). The scope of work includes but is not limited to:a. Site preparation。
b. Excavation and grading。
c. Foundation and structural work。
d. Framing and roofing。
e. Exterior and interior finishes。
f. Mechanical, electrical, and plumbing systems。
g. Landscaping and site improvements。
2. Contract Price。
The total contract price for the Project is [Contract Price]. This price includes all labor, materials, equipment, and overhead costs necessary for the completion of the Project.3. Payment Terms。
施工合同中英文模板
施工合同中英文模板CONSTRUCTION CONTRACTTHIS CONTRACT is made and entered into as of [Insert Date], by and between [Insert Client Name], hereinafter referred to as "Client," and [Insert Contractor Name], hereinafter referred to as "Contractor."1. SCOPE OF WORKThe Contractor agrees to perform the construction services described in the attached Statement of Work (SOW) for the project identified as [Insert Project Name].2. CONTRACT AMOUNTThe total contract price for the work described in the SOW is [Insert Total Contract Price]. This price includes all labor, materials, equipment, and services necessary to complete the work.3. PAYMENT TERMSThe Client shall make payments to the Contractor as follows: a. [Insert Percentage] percent of the total contract price upon signing of this contract.b. [Insert Percentage] percent of the total contract price upon completion of [Insert Milestone].c. The remaining balance upon satisfactory completion of the work and acceptance by the Client.4. SCHEDULEThe work shall commence on [Insert Start Date] and be completed by [Insert Completion Date].5. PERFORMANCE BONDThe Contractor shall provide a performance bond in the amount of [Insert Bond Amount] to guarantee the completion of the work.6. WARRANTYThe Contractor warrants that all work will be performed in a professional and workmanlike manner and in accordance with the SOW.7. TERMINATIONEither party may terminate this contract for cause upon written notice to the other party if there is a material breach of any of the terms of this contract.8. DISPUTESAny disputes arising out of or in connection with this contract shall be resolved by [Insert Method of Dispute Resolution, e.g., arbitration, mediation, etc.].9. APPLICABLE LAWThis contract shall be governed by and construed in accordance with the laws of [Insert Jurisdiction].10. ENTIRE AGREEMENTThis contract, including the attached SOW and any exhibits, constitutes the entire agreement between the parties andsupersedes all prior negotiations, representations, and agreements.11. AMENDMENTSThis contract may be amended only in writing signed by both parties.12. NOTICESAll notices required or permitted by this contract shall be in writing and delivered to the addresses set forth below or to such other addresses as either party may designate in writing.Client: [Insert Client Name and Address]Contractor: [Insert Contractor Name and Address]IN WITNESS WHEREOF, the parties have executed this contract as of the date first above written.CLIENT[Insert Client Name]By: [Insert Authorized Signature]CONTRACTOR[Insert Contractor Name]By: [Insert Authorized Signature]Title: [Insert Title]STATEMENT OF WORK (SOW)1. PROJECT DESCRIPTIONA detailed description of the project, including the objectives, deliverables, and any specific requirements.2. WORK SCHEDULEA detailed schedule of the work, including milestones and deadlines.3. QUALITY REQUIREMENTSThe quality standards that the work must meet.4. SAFETY REQUIREMENTSSafety protocols and procedures that must be followed during the project.5. SUBMISSIONSA list of all documents, reports, or other submissions required from the Contractor.6. INSPECTION AND ACCEPTANCEProcedures for the Client's inspection of the work and acceptance of the project.7. CHANGE ORDERSProcedures for requesting and implementing changes to the scope of work.8. COMPLETION AND FINAL PAYMENTCriteria for determining when the work is complete and the conditions for final payment.9. WARRANTY AND MAINTENANCEDetails of any warranties provided by the Contractor and any maintenance services included.10. ADDITIONAL TERMSAny other specific terms and conditions relevant to the project.Please note that this is a template and should be reviewed by a legal professional to ensure it meets the specific needs and legal requirements of your project.。
施工合同范本排版(中英)
施工合同范本排版Contract for Construction甲方（委托方）：_________________________（以下简称甲方）Party A (Commissioning Party): _______________________ (hereinafter referred to as Party A)乙方（承包方）：_________________________（以下简称乙方）Party B (Contractor): _______________________ (hereinafter referred to as Party B)鉴于甲方拟委托乙方承担____________项目的施工工作，双方经友好协商，就相关事宜达成如下协议：Whereas Party A intends to commission Party B to undertake the construction work of the ____________ project, the two parties have reached the following agreement through friendly negotiation on relevant matters:一、工程概况1. Project Overview1.1 项目名称：____________________Project Name: ____________________1.2 工程地址：____________________Project Address: ____________________1.3 工程内容：____________________Project Content: ____________________1.4 工程开始日期：_______________，完工日期：_______________Start Date: ____________, Completion Date: ____________二、价款及支付方式2. Price and Payment Method2.1 本工程总价款为____________，由甲方按如下方式支付给乙方：____________________The total price of this project is _________, which shall be paid by Party A to Party B in the following manner: ____________________2.2 如工程发生变更或增项，应另行协商确定价格及支付方式。
完整工程施工合同英文版
Translation:Construction ContractParty A: (Developer)Party B: (Contractor)This contract is signed by the two Parties Party A and Party B according to the Contract Law of the People’s Republic of China, the Contraction law of the People’s Republic of China , and other relevant national laws and regulations, as well as the specific nature of this project. On the basis of honesty and credit, equality, voluntariness, party A and party B have reached consensus through negotiations and signed this contract.1.Project Introduction1.1 Name of Project:1.2 Location of Project: From to .1.3 Scope and content of the project: .1.4 The design of construction drawings: .2.Nature of Contracting: Contract for labor and materials .3.Construction periodThis project will take 20 days after the receive of the beginning notice from Party A (including reception time after completion),and including the beginning date and completion date.4.Quality of ProjectQuality of Project: qualified .5.Contract Amount5.1 Contract Amount: be RMB 400,000 Yuan tentatively (The actual settlement shall prevail).5.2 Adjustment of contract amount: .6.Final Audit of the project6.1 The condition and steps for Party A pay the project funds to Party B:Party A agrees to pay Party B for RMB150,000Yuan three days after the beginning of the project,the balance will be paid 97% after the qualified completion, and 3% warranty guarantee fee will be paid one years if there is no quality problem.6.2 Mode of payment: .6.3 Party B shall submit to Party A equivalent invoice before Party A’s each period payment, otherwise, Party A can refuse to pay until the receiving of t he Party B’s invoice.6.4 The invoice provided by Party B should be valid. Any falls invoice provided byParty B which are found by relevant office, the Party B should not only provide the valid invoice to Party A, but also bear the responsible caused by the invalid invoice.7.Variation of design and visa7.1During the process of the project, any contract list, technology checking list ( not include the variation, addition, substitution, and reduction on the drawings and project fee) concerning about this project shall only be regarded as effective with the confirmation of the representative Party A in writing.7.2 Any variation notice list, technology checking list, contract list, technology checking list ( include the drawings design) concerning about this project shall only be regarded as effective with the confirmation of the seal of Party A.7.3In the event of Party B fails to complete the project according to the drawing variation, Party B shall pay to Party Aas penalty for the breach.Party B will also bear the responsible and the reworking fee caused by the continued working regardless of the new design.7.4Party B shall take full responsibility for any loss caused by delaying for more than days applying for extension vise from Party A days after the receiving of changed design.8. Acceptance and Final Audit of the project8.1 Acceptance of the project8.1.1This project should meet the national quality acceptance standards and should beaccepted at the first inspection after completion. The Quality Acceptance Criteria of Construction of nation must be regarded as the acceptance standards for the project. Party B shall inform Party A in writing of all kinds of inspection and acceptance withi n 3 days.Party A shall arrange inspection and acceptance within 3 working days after receiving the notification.8.1.2Party B shall be responsible for the re-inspection cost, and the project period shall not be extended.8.2 Final Audit of the projectIf the result of re-inspection has passed acceptance standards, Party B shall submit the audit report and materials to Party A for verification within 7 days. (the materials include ).9.Obligations of Party A and Party B9.1. Obligations of Party A:9.1.1.Party A appoints as the on-site representative to supervise the fulfillment of contract obligations, to oversee the quality control and check the project progress, and to handle issues such as acceptance and variations and withdraw the representative at any time.9.1.2. Days before beginning of the project, Party A shall provide Party B .9.1.3. Party A shall confirm the variation and suggestion days after providing todesign drawings and scheme to Party B.9.1.4.Party A shall be responsible for coordinating the relationship with the engining.9.2. Obligations of Party B.Party B appoints WangZhirong as the on-site representative of Party B to take charge of fulfilling the contract obligations. The on-site representative of Party B shall organi ze the construction according to contract requirements so that the project can be comp leted according to the quality and quantity requirements and on a timely manner..Party B shall observe safetypolicies of on-site management by the state and Guangxi , Nanning government authorities and shall independently and fully assumes responsible for the loss caused by violation.9.2.3Party B shall observe policies of on-site management by the state and local gover nment authorities as well as Party A's rules and regulations; Party B shall compensate for the losses to any facilities, equipment or pipelines both inside and outside of the co nstruction yard caused by party B.9.2.4.During construction, Party B should make such adjustment to the construction pl an and the progress schedule per Party A's instruction and change-orders.9.2.5. Party B should transfer the construction site within days after the qualified completion.10.Agreement on SafetyParty B must strictly adhere to the Safety and Technical Standards of Construction an d Infrastructure Installation and regulation of China, Guangxi Zhuang Autonomous Region, Nanning Safety Standards and other relevant regulations and standards.the construction spot should meet all standards of the People's Republic of China. And bearing the safety fees which are not caused by party A.11.The concerning material supply11.1. Party A or Party B should be responsible for the material ,equipments,which should meet the qualified design request with qualification guarantee books.11.2. Any material,equipment which is bought by the Party B, if not agree with the quality request or specification contain difference,should forbid any usage.the Party B should rebuy the equipment and bear the responsibility to make sure no delay on the project.if Party B refuses to change the materials, Party A has the right to terminate the contract and asks for loss from Party B.11.3 Any material,equipment which is bought by the Party A, if not agree with the quality request or specification contain difference,should forbid any usage.the Party A should rebuy the equipment and bear the responsibility to make sure no delay on the project.12.Warranty12.1.Warranty scope: as state in the contract.12.2.Warranty period: 1 year after the qualified completion.12.3During the warranty period, Party B shall fix within 2 days after receiving the notice from Party A. In the event of Party B fails to fix the defects on a timely manner, Party A has the right to hire a third Party to do the repair, and any costs incurred shall be burdened by Party B.12.4. Mode of notices: phone, fax, e-mail, and so on.12.4.1 in the way of call the phone or faxing: Party B ’s TEL:,Fax: . These contact ways will be regarded as the evidence of warranty notice to Party B after the calling and faxing.12.4.2.in the way of posting: Party B ’s address:. These contact ways will be regarded as the evidence of warranty notice to Party B after e-mailing.12.4.3. in the way of e-mailing: Party B ’s e-mail: . These contact ways will be regarded as the evidence of warranty notice to Party B after e-mailing.12.4.4. The fees of noticing Party B will be borne by Party B.12.5. Project quality retention fee(tip: the blue words will be suite for under the condition of withing the Project quality retention fee)12.5.1Project quality retention fee: , which will be deduce from the project funds of Party B.12.5.2 After the expire date, Party A will return the rest of the quality retention fees without interest to Party B. This will be applied by Party B within ten days after the completion of qualified project.13. Liabilities for Breach13.1.In the event of Party A fails to make payment according to the payment terms, Party A should pay a late fee to Party B; Daily rate of the late fee is % of the payment. If the delay of the payment is caused by Party A and is delayed for more tha n days, then Party B can terminate this contract.13.2In the event of Party B fails to complete the project according to the construction period in the contract, Party B shall pay % of the t otal contract amount for each day overdue as penalty for the breach. Daily rate of the l ate fee is % of the payment.13.3.Party A can terminate this contract and Party B shall take full responsibility for a ny loss caused by this when one of these condition takes place.13.3.1 Overdue over days.13.3.2Party B transfers the contract and any part of the contract and its corresponding to any third party without Party A's consent in writing.13.3.3.Be ordered to shut down by the administrative organ caused by Party B over days.13.3.4.Safety and quality accidents.13.3.5. The materials provided by Party B differs from the QAcertificate and the Report of Quality Assurance Test. And Party B can not make change on these material.13.4.Party B should make salary/wages payment to all construction staffs in time on a monthly basis, and will be fully responsible for any liabilities caused by any loss or da mage to Party A as a result of Party B's failure to pay salaries and wages according to the requirements. In the event of migrant workers create a disturbance on group site, Party A's premises, office space, Party B should paid penal sum Yuan each time.13.5.In the event anyParty shall fail to complete the work in time owing to reasons that the contractor shall be held liable， the Party shall pay a penalty for RMB Yuan, and bear all be loss of the other Party.13.6. penal sums and other penalty fees that Party B should to Party A , Party A can take out the same amount of money directly from the project fees. (including quality retention fee).14.Other provisions14.1 Party A and Par ty B will deal with each party’s property and life insurance and assume their insurance costs respectively.14.2.Both Parties shall timely discuss each other for the settlement of any disputearising during the execution of this Contract. In case that such discussion fails, any Party can appeal to local people's court.14.3.Supplementary agreement could be made between the two parties in case that any additional clause shall be added. The supplementary agreement shall have the same effect and power as this Contract.14.4.This Contract shall come into force beginning from the date when both parties have stamped it with official Seal (or special stamp for contract) and signed it.14.5This contract will be printed and signed in 4 copies and Party A shall hold 3 copies. Party B shall hold 1 copies. And all have the same power and effect.15.Attachments:Party A: Party B:Legal Representative: Legal Representative:Address: Accounting Bank:Tel: Bank Account No.:Date: 2023-07-28 Address:Tel:Date: 2023-07-28。
建筑施工合同中英文对照版本
xxx施工合同Construction Contract of xxxx发包方（甲方）xxxxParty A: xxxx承包方（乙方）xxxxParty B: xxxx本合同由如上列明的甲、乙双方按照《中华人民共和国合同法》、《建筑安装工程承包合同条例》以及国家相关法律法规的规定，结合本合同具体情况，于xx年x月x日在xx签订。
tract Law of the This contract is signed by the two Parties in xxxx on xxxx according to the “ConPeople’s Republic of China”, the “Regulation on Building and Installation Contracting Contract and other relevant national laws and regulations, as well as the specific nature of this project第一条总则Article 1 General Principles1.1合同文件Contract Documents本合同包含合同、展示、施工图纸、作法说明、招投标文件以及合同所指的其他文件，它们均被视为合同的一部分。
合同文件应该能够相互解释，互为说明。
组成本合同的文件及优先解释的顺序如下：本合同、中标通知书、投标书及其附件、标准、规范及有关技术文件、图纸、工程量清单及工程报价单或预算书。
合同履行中，发包人承包人有关工程的洽商、变更等书面下一或文件视为本合同的组成部分。
This contract includes the contract itself, exhibits, construction drawings, explanations ofwork procedures, tender documents, as well as other documents specified by the contract. The contract documents should be mutually explainable and mutually descriptive. The documents that constituted the contract and the priority hierarchy of explanations of the documents are as follows: this contract; the official letter of winning the tender; Letter of bidding and its annex, standards, guidelines, and relevant technical documents, drawings, Billof Quantity (BOQ), quotation of prices, and project budget. During the implementation of thecontract, any written agreements or documents between two parties such as change-ordersare also regarded will be deemed as part of this contract.1.1.1项目概况Project Introduction1.1.2工程名称：xxxxName of Project: xxxx1.1.3工程地点：xxxxLocation of Project: xxxx1.1.3.1工程范围：除了本合同其他条款另有说明外，乙方应提供为履行合同所需的所有服务，用品以及其他保障工程进行所需的必要花费以完成下列工作：Scope of the project: unless otherwise explained by other articles in this contract, Party Bshall provide all services, utensils, and other necessary cost for the implementation of this contract; the scope of project includes, but not limited to:※室内装饰工程，详见附件一和附件二Inner decoration, see appendix 1 & 2※室外装饰工程（门窗、屋面、台阶等），详见附件一和附件二Fa?ade(including doors, windows, roof and stairs) see appendix 1 & 2※电器工程，详见附件一和附件二Electronic Engineering, see appendix 1 & 2※空调工程，详见附件一和附件二Air Conditioning System, see appendix 1 & 2※给排水及采暖工程，详见附件一和附件二Water Supply, Sewage and Heating System, see appendix 1 & 2※消防工程Fire Control System, see appendix 1 & 2※其他图纸上所列项目（任何对原定设计的变更应提供新的图纸并有甲方的签字确认）以上所有的工程项目以下统称为“工程”。
建筑施工合同中英文对照版本
xxxx施工合同Construction Contract of xxxx发包方（甲方）xxxxParty A: xxxx承包方（乙方）xxxxParty B: xxxx本合同由如上列明的甲、乙双方按照《中华人民共和国合同法》、《建筑安装工程承包合同条例》以及国家相关法律法规的规定，结合本合同具体情况，于xx年x月x日在xx签订。
This contract is signed by the two Parties in xxxx on xxxx according to the “Contract Law of the People’s Republic of China”, the “Regulation on Building and Installation Contracting Contract”, and other relevant national laws and regulations, as well as the specific nature of this project第一条总则Article 1 General Principles1.1合同文件Contract Documents本合同包含合同、展示、施工图纸、作法说明、招投标文件以及合同所指的其他文件，它们均被视为合同的一部分。
合同文件应该能够相互解释，互为说明。
组成本合同的文件及优先解释的顺序如下：本合同、中标通知书、投标书及其附件、标准、规范及有关技术文件、图纸、工程量清单及工程报价单或预算书。
合同履行中，发包人承包人有关工程的洽商、变更等书面下一或文件视为本合同的组成部分。
This contract includes the contract itself, exhibits, construction drawings, explanations of work procedures, tender documents, as well as other documents specified by the contract. The contract documents should be mutually explainable and mutually descriptive. The documents that constituted the contract and the priority hierarchy of explanations of the documents are as follows: this contract; the official letter of winning the tender; Letter of bidding and its annex, standards, guidelines, and relevant technical documents, drawings, Bill of Quantity (BOQ), quotation of prices, and project budget. During the implementation of the contract, any written agreements or documents between two parties such as change-orders are also regarded will be deemed as part of this contract.1.1.1项目概况Project Introduction1.1.2工程名称：xxxxName of Project: xxxx1.1.3工程地点：xxxxLocation of Project: xxxx1.1.3.1工程范围：除了本合同其他条款另有说明外，乙方应提供为履行合同所需的所有服务，用品以及其他保障工程进行所需的必要花费以完成下列工作：Scope of the project: unless otherwise explained by other articles in this contract, Party B shall provide all services, utensils, and other necessary cost for the implementation of this contract; the scope of project includes, but not limited to:※室内装饰工程，详见附件一和附件二Inner decoration, see appendix 1 & 2※室外装饰工程（门窗、屋面、台阶等），详见附件一和附件二Façade(including doors, windows, roof and stairs) see appendix 1 & 2※电器工程，详见附件一和附件二Electronic Engineering, see appendix 1 & 2※空调工程，详见附件一和附件二Air Conditioning System, see appendix 1 & 2※给排水及采暖工程，详见附件一和附件二Water Supply, Sewage and Heating System, see appendix 1 & 2※消防工程Fire Control System, see appendix 1 & 2※其他图纸上所列项目（任何对原定设计的变更应提供新的图纸并有甲方的签字确认）以上所有的工程项目以下统称为“工程”。
施工合同范本英文
施工合同范本英文Construction Contract TemplateThis Construction Contract ("Contract") is made and entered into on [date] between [Party A's name] ("Party A") and [Party B's name] ("Party B").1. Project DescriptionThe project ("Project") involves the construction of [description of the project] at the location of [project location].2. Contract Price and Payment TermsThe total contract price for the Project is [amount in figures and words]. Party A shall make payments to Party B as follows: [detl the payment schedule and conditions].3. Project ScheduleThe Project is scheduled to mence on [start date] and be pleted [pletion date]. Any delays in the schedule shall be subject to the provisions of this Contract.4. Workmanship and MaterialsParty B shall ensure that the construction work is carried out in a professional and workmanship-like manner, and that all materials used are of good quality and in accordance with the specifications agreed upon.5. Inspection and AcceptanceParty A shall have the right to inspect the progress and quality of the work at reasonable intervals. Upon pletion of the Project, a final inspection and acceptance shall be conducted. If the Project meets the requirements and specifications, Party A shall issue an acceptance certificate.6. WarrantyParty B warrants that the pleted Project will be free from defects in workmanship and materials for a period of [warranty period] from the date of acceptance.7. Force MajeureNeither party shall be liable for any delay or flure to perform its obligations under this Contract if such delay or flure is caused events beyond its reasonable control, such as natural disasters, wars, or government actions.8. Dispute ResolutionIn the event of any dispute arising out of or in connection with this Contract, the parties shall attempt to resolve it through friendly negotiation. If negotiation fls, the dispute shall be submitted to arbitration or litigation in accordance with the laws and jurisdiction applicable.9. TerminationThis Contract may be terminated mutual agreement of the parties or in accordance with the provisions herein.10. MiscellaneousThis Contract constitutes the entire agreement between the parties and supersedes all prior negotiations and understandings. Any amendments or additions to this Contract must be in writing and signed both parties.IN WITNESS WHEREOF, the parties have executed this Construction Contract as of the date first above written.Party A: [signature and name]Party B: [signature and name]。
建筑施工合同中英文对照版本
建筑施工合同中英文对照版本甲方：Party A乙方：Party B根据《中华人民共和国合同法》及相关法律法规的规定，甲乙双方在平等、自愿、公平、诚信的原则基础上，就甲方委托乙方进行建筑施工事宜，经友好协商，达成以下协议：Article 1: General Provisions1.1 This Contract shall be effective from the date of signing by both Parties and shall expire upon the completion of the Construction Project.1.2除非本合同另有规定，本合同未尽事宜，可由双方另行协商达成补充协议，补充协议与本合同具有同等法律效力。
1.3除非本合同另有规定，本合同一式两份，甲乙双方各执一份，两份合同具有同等法律效力。
Article 2: Construction Scope and Objectives2.1 Party A entrusts Party B with the Construction Project (hereinafter referred to as the "Project") located at ____________ (hereinafter referred to as the "Construction Site").2.2 The Construction Scope of the Project shall include, but not limited to, the following:(1)____________;(2)____________;(3)____________;2.3 The objectives of the Project are to complete the construction within the agreed timeand budget, and to achieve the required quality standards.Article 3: Construction Period3.1 The Construction Period of the Project shall be ____________ days from the date of signing this Contract.3.2 Party B shall notify Party A in writing if it expects to extend the Construction Period. The extension shall not be unreasonably denied by Party A. The extension period shall be agreed upon by both Parties.Article 4: Construction Cost4.1 The total Construction Cost of the Project shall be ____________ RMB (Renminbi), including taxes and other related fees.4.2 The payment schedule shall be as follows:(1)____________ RMB upon signing this Contract;(2)____________ RMB upon the completion ofthe____________ phase of the Project;(3)____________ RMB upon the finalcompletion of the Project.4.3 Party A shall pay Party B theConstruction Cost within 30 days after receiving the relevant invoices and supporting documents.Article 5: Quality and Standards5.1 The construction work shall comply with the relevant laws, regulations, codes, standards, and specifications required by the Construction Project.5.2 Party B shall be responsible for the quality of the construction work. Party B shall repair or replace any defective work within areasonable time after the completion of the Project at its own expense.Article 6: Safety and EnvironmentalProtection6.1 Party B shall ensure the safety of the construction site, and shall take necessary measures to protect the environment and prevent pollution.6.2 Party B shall be responsible for anyinjury or damage caused by its employees or agents during the performance of this Contract.Article 7: Force Majeure7.1 Neither Party shall be liable for the failure or delay in the performance of its obligations under this Contract due to force majeure events such as acts of God, war, strikes, riots, etc.7.2 The Party affected by the force majeure shall notify the other Party in writing as soon as possible, and shall take necessary measures to minimize the losses.Article 8: Dispute Resolution8.1 Any disputes arising out of or in connection with this Contract shall be firstly resolved through friendly negotiation.8.2 If the negotiation fails, the disputes shall be submitted to the____________ people's court with jurisdiction over the place of performance of this Contract.Article 9: Miscellaneous9.1 This Contract may not be assigned by either Party without the prior written consent of the other Party.9.2 This Contract shall be governed by and construed in accordance with the laws of the People's Republic of China.9.3 In case any clause of this Contract is found to be invalid or unenforceable, the validity and enforceability of the remaining clauses shall not be affected.9.4 The headings in this Contract are for convenience only and shall not be used to interpret the contents of the clauses.Article 10: SignatureThe Parties have executed this Contract as of the date first above written.Party A: ________________Representative: ________________Date: ________________Party B: ________________ Representative: ________________ Date: ________________。
建设工程施工合同英文(3篇)
第1篇This contract is made and entered into by and between the Contractor, [Contractor's Name], having its principal place of business at [Contractor's Address], hereinafter referred to as "Contractor", and the Owner, [Owner's Name], having its principal place of business at [Owner's Address], hereinafter referred to as "Owner", on the [Date of the Contract] (hereinafter referred to as "Effective Date").1. Scope of WorkThe Contractor shall, at the Owner's request and subject to the provisions of this contract, perform the construction work for the Project described in the attached Project Description (hereinafter referred to as "Project") in accordance with the specifications, drawings, and other documents provided by the Owner.2. Project DescriptionThe Project shall include the construction of a [type of project, e.g., residential building, commercial building, industrial facility] with the following specifications and requirements:a. General description of the Project: [Provide a brief description of the Project, including the purpose, location, and size.]b. Scope of work: [List all the construction activities to be performed, such as excavation, foundation work, structural framing, roofing, electrical and plumbing installations, and interior finishing.]c. Quality standards: [Specify the required quality standards for the materials, workmanship, and construction processes.]d. Project schedule: [Provide a detailed timeline for the construction activities, including the start and completion dates.]3. Contract PriceThe total contract price for the Project is [Contract Price]. The Contractor shall be paid as follows:a. Initial payment: [Specify the percentage of the total contract price to be paid upon the execution of this contract.]b. Progress payments: [Define the schedule and percentage of the total contract price to be paid at various stages of the construction work, based on the actual progress and quality of work performed.]c. Final payment: [Specify the percentage of the total contract price to be paid upon the completion and acceptance of the Project.]4. Payment TermsThe Owner shall make payments to the Contractor within [Number of days] days after the receipt of a valid invoice from the Contractor.5. Time for CompletionThe Contractor shall complete the construction work within the agreed-upon time frame, which is [Number of days] days from the date of the Notice to Proceed. The Contractor shall be entitled to an extension of time for reasons beyond its control, such as adverse weather conditions, delays in the delivery of materials, or other unforeseen circumstances.6. Changes to the WorkThe Owner may, at its sole discretion, make changes to the scope of work during the construction process. Any changes shall be made in writing and shall include the revised specifications, drawings, and other documents. The Contractor shall be entitled to an equitable adjustmentin the contract price and time for completion, as determined by the Owner and the Contractor.7. Inspections and AcceptanceThe Owner shall have the right to inspect the construction work at any time during the construction process. The Contractor shall provide access to the Project for inspections and shall comply with all applicable laws, regulations, and standards. Upon completion of the construction work, the Owner shall inspect the Project and accept it if it meets the requirements specified in this contract.8. Termination of the ContractEither party may terminate this contract in the event of a breach of the contract by the other party. In such cases, the terminating party shall provide written notice of termination to the other party, and the provisions of this contract regarding payment and dispute resolution shall apply.9. Dispute ResolutionIn the event of any dispute arising out of or in connection with this contract, the parties shall endeavor to resolve the dispute amicably. If the dispute cannot be resolved amicably, the parties shall submit the dispute to arbitration in accordance with the rules of the [Applicable Arbitration Institution].10. Governing LawThis contract shall be governed by and construed in accordance with the laws of [Applicable Jurisdiction].IN WITNESS WHEREOF, the parties have executed this contract as of the Effective Date.Contractor:_________________________Printed Name:_________________________Title:_________________________Owner:_________________________Printed Name:_________________________Title:_________________________Date:_________________________Date:第2篇This Contract is made and entered into on [Date] between [Contractor's Name], having its registered office at [Contractor's Address] (hereinafter referred to as "Contractor") and [Client's Name], havingits registered office at [Client's Address] (hereinafter referred to as "Client"), for the construction of the [Project Name] Project (hereinafter referred to as "Project").1. Scope of WorkThe Contractor shall undertake the construction work of the Project, including but not limited to the following:1.1 Civil engineering works, such as foundation, superstructure, and interior decoration;1.2 Installation of electrical and mechanical equipment;1.3 Construction of outdoor facilities and landscape;1.4 Provision of labor, materials, and machinery for the Project;1.5 Compliance with relevant construction regulations and standards.2. Project DurationThe construction period of the Project shall be [Duration], starting from [Start Date] to [End Date]. Any delay in the Project due to reasons attributable to the Contractor shall be at the Contractor's own expense.3. Payment Terms3.1 The Client shall pay the Contractor in accordance with the following payment schedule:a) [Percentage] of the total contract price upon the signing of the Contract;b) [Percentage] of the total contract price upon the completion of the foundation work;c) [Percentage] of the total contract price upon the completion of the superstructure work;d) [Percentage] of the total contract price upon the completion of the interior decoration work;e) [Percentage] of the total contract price upon the completion of the outdoor facilities and landscape work;f) The remaining [Percentage] of the total contract price upon the final acceptance of the Project.3.2 The payment method shall be made by bank transfer within [Number] days after the receipt of the Contractor's invoice.4. Quality Requirements4.1 The Contractor shall ensure that the construction work meets the following quality requirements:a) Compliance with relevant construction regulations and standards;b) Satisfy the Client's requirements for the Project;c) Meet the requirements for quality inspection and acceptance.5. Termination of the Contract5.1 Either party may terminate this Contract upon [Specific Condition] upon written notice to the other party.5.2 In the event of termination of this Contract, the Contractor shall promptly stop the construction work and remove all equipment and materials from the construction site.6. Dispute ResolutionIn the event of any disputes arising from the execution of this Contract, the parties shall endeavor to resolve the disputes through friendly negotiations. If the disputes cannot be resolved through negotiations, the parties may submit the disputes to the relevant arbitration commission for arbitration.7. Governing LawThis Contract shall be governed by and construed in accordance with the laws of [Country/State].8. Amendments and AddendaAny amendment or addenda to this Contract shall be made in writing and signed by both parties.IN WITNESS WHEREOF, the parties hereto have executed this Contract as of the date first above written.Contractor:[Contractor's Name][Contractor's Signature]Client:[Client's Name][Client's Signature]第3篇This Construction Engineering Contract ("Contract") is made and entered into as of [Date], between [Name of Contractor] ("Contractor"), a [type of entity] with its principal place of business at [Contractor'sAddress], and [Name of Client] ("Client"), a [type of entity] with its principal place of business at [Client's Address].WHEREAS, the Client intends to have the Contractor construct [describe the project], and the Contractor is willing to undertake such construction work on the terms and conditions set forth in this Contract.NOW, THEREFORE, in consideration of the mutual covenants and agreements contained herein, the parties hereto agree as follows:1. Scope of WorkThe Contractor shall construct the [describe the project] in accordance with the plans, specifications, and schedules attached hereto and incorporated herein by reference (collectively, "Documents"). The Contractor shall complete the construction work in accordance with the provisions of this Contract.2. Contract PriceThe total contract price for the construction work shall be [amount] (the "Contract Price"). The Contract Price shall be payable as follows:- [Percentage]% upon the execution of this Contract.- [Percentage]% upon the issuance of the first progress payment certificate.- [Percentage]% upon the issuance of the second progress payment certificate.- [Percentage]% upon the issuance of the third progress payment certificate.- The remaining [Percentage]% upon the issuance of the final certificate of completion.3. Time of CompletionThe Contractor shall complete the construction work within [number] months from the date of the Notice to Proceed, which shall be issued bythe Client upon the satisfactory completion of the pre-construction activities.4. Quality of WorkThe Contractor shall perform the construction work in a professional and workmanlike manner and in accordance with the applicable laws, regulations, and industry standards. The Contractor shall use only quality materials and equipment as specified in the Documents.5. Payment and Change OrdersAll payments shall be made in United States Dollars. Any changes to the scope of work, including changes to the Documents, shall be made by written change order executed by both parties. The change order shall specify the additional or reduced costs and time for completion.6. InsuranceThe Contractor shall maintain, during the term of this Contract, all necessary insurance policies including, but not limited to, general liability insurance, workers' compensation insurance, and professional liability insurance. The insurance policies shall name the Client as an additional insured.7. SafetyThe Contractor shall ensure that all work is performed in a safe manner, in compliance with all applicable safety regulations. The Contractor shall provide all necessary safety equipment and training for its employees.8. Dispute ResolutionAny disputes arising out of or in connection with this Contract shall be resolved through good faith negotiations between the parties. If the parties are unable to resolve the dispute within [number] days, any unresolved dispute shall be submitted to arbitration in accordance with the rules of the [name of arbitration association].9. Governing LawThis Contract shall be governed by and construed in accordance with the laws of the State of [State].10. Entire AgreementThis Contract constitutes the entire agreement between the parties and supersedes all prior agreements and understandings, whether written or oral.IN WITNESS WHEREOF, the parties hereto have executed this Contract as of the date first above written.[Contractor's Name]By: ___________________________Name: [Contractor's Authorized Representative]Title: [Contractor's Authorized Representative Title][Client's Name]By: ___________________________Name: [Client's Authorized Representative]Title: [Client's Authorized Representative Title][Additional Attachments]- Plans and specifications- Insurance certificates- Change order forms- Safety plan。
中英文版施工合同-xxx工程合同中英文版
中英文版施工合同-xxx工程合同中英文版甲方（业主）： [Party A (Owner)]乙方（承包商）： [Party B (Contractor)]第一部分：合同条款第一条工程概况1.1 工程名称：[Name of the Project]1.2 工程地点：[Location of the Project]1.3 工程范围：[Scope of the Project]1.4 工程内容：[Content of the Project]第二条合同价格2.1 合同总价：[Total Contract Price]2.2 价格调整：[Price Adjustment]第三条工程质量3.1 质量标准：[Quality Standards]3.2 质量保证：[Quality Assurance]第四条工程进度4.1 开工日期：[Commencement Date]4.2 竣工日期：[Completion Date]4.3 进度计划：[Progress Schedule]第五条工程变更5.1 变更通知：[Change Notification]5.2 变更费用：[Change Costs]第六条工程验收6.1 验收标准：[Acceptance Standards]6.2 验收程序：[Acceptance Procedures]第七条付款方式7.1 预付款：[Advance Payment]7.2 进度款：[Progress Payment]7.3 最终结算：[Final Settlement]第八条违约责任8.1 违约定义：[Definition of Breach]8.2 违约赔偿：[Compensation for Breach]第九条争议解决9.1 争议解决方式：[Dispute Resolution Method]9.2 适用法律：[Applicable Law]第十条其他条款10.1 保密协议：[Confidentiality Agreement]10.2 合同变更：[Contract Modification]10.3 合同终止：[Contract Termination]第二部分：附加条款[Additional Clauses as per the specific requirements of the project]第三部分：签字页甲方（业主）代表签字：[Signature of Party A's Representative]乙方（承包商）代表签字：[Signature of Party B's Representative]日期：[Date]Construction ContractContract No.: [Contract No.]Date of Contract: [Date of Contract]Party A (Owner): [Party A (Owner)]Party B (Contractor): [Party B (Contractor)] Part I: Contract TermsArticle 1: Project Overview1.1 Project Name: [Name of the Project]1.2 Project Location: [Location of the Project] 1.3 Project Scope: [Scope of the Project]1.4 Project Content: [Content of the Project]Article 2: Contract Price2.1 Total Contract Price: [Total Contract Price] 2.2 Price Adjustment: [Price Adjustment]Article 3: Project Quality3.1 Quality Standards: [Quality Standards]3.2 Quality Assurance: [Quality Assurance]Article 4: Project Schedule4.1 Commencement Date: [Commencement Date]4.2 Completion Date: [Completion Date]4.3 Progress Schedule: [Progress Schedule]Article 5: Project Changes5.1 Change Notification: [Change Notification]5.2 Change Costs: [Change Costs]Article 6: Project Acceptance6.1 Acceptance Standards: [Acceptance Standards]6.2 Acceptance Procedures: [Acceptance Procedures]Article 7: Payment Method7.1 Advance Payment: [Advance Payment]7.2 Progress Payment: [Progress Payment]7.3 Final Settlement: [Final Settlement]Article 8: Liability for Breach of Contract8.1 Definition of Breach: [Definition of Breach]8.2 Compensation for Breach: [Compensation for Breach]Article 9: Dispute Resolution9.1 Dispute Resolution Method: [Dispute Resolution Method] 9.2 Applicable Law: [Applicable Law]Article 10: Other Terms10.1 Confidentiality Agreement: [Confidentiality Agreement] 10.2 Contract Modification: [Contract Modification]10.3 Contract Termination: [Contract Termination]Part II: Additional Terms[Additional terms as per the specific requirements of the project]Part III: Signature PageSignature of Party A's Representative: [Signature of Party A's Representative]Signature of Party B's Representative: [。
建设工程施工合同中英文翻译件范本8篇
建设工程施工合同中英文翻译件范本8篇篇1建设工程施工合同Contract of Construction Engineering一、合同当事人The Parties to the Contract1. 发包方（甲方）：- 单位名称：江苏某某建设集团有限公司- 地址：南京市某某区某某街某某号- 法定代表人：张先生- 电话：+86-12345678901- 电子邮箱：[*****************](mailto:*****************)2. 承包方（乙方）：- 单位名称：南京某某建筑有限公司- 地址：南京市某某区某某街某某号- 法定代表人：李女士- 电话：+86-10987654321- 电子邮箱：[**************](mailto:**************)二、合同标的The Subject of the Contract本合同标的为江苏某某建设集团有限公司委托南京某某建筑有限公司承建的“某某花园”住宅楼建设项目。
项目位于南京市某某区，合同总价为人民币壹亿元整（￥1,000,000,000元）。
三、工程范围和内容Scope and Content of the Works1. 土建工程：包括基础工程、主体结构、屋面工程等。
2. 装饰工程：包括内外装饰、门窗安装等。
3. 水电安装：包括给水、排水、电气照明等。
4. 其他附属设施：包括道路、绿化、景观等。
四、工期和进度Time Limit and Progress of the Works1. 开工日期：本合同自签订之日起生效，工期为36个月。
2. 进度要求：乙方需按照甲方提供的施工进度计划表执行，确保每月完成计划工程量。
3. 延期处理：如因乙方原因造成工期延误，乙方需承担相应的违约责任和赔偿责任。
五、质量与验收Quality and Acceptance1. 质量标准：乙方必须按照国家和地方现行施工规范及标准施工，确保工程质量达到合格标准。
建筑合同（中英版）（通用12篇）
建筑合同(中英版)（通用12篇）建筑(中英版) 篇1甲方：Party A：乙方：Party B：合同编号： Contract No日期：Date：签约地点：Signed at：特约定：甲方基于下文所列各种因素，特与乙方达成了协议并一致同意：由甲方在订约日期之翌日起_____天之内为乙方建造并完成_____（涉约建筑）。
涉约建筑之规模及所需的钢筋、水泥、砖块、石子和其它建筑材料之数量，均在作为附件的设计图和施工细则中予以说明。
Witnesses that the Party A for considerations hereinafter named, contracts and agrees with the Party B that Party A will, within_____ days, next following the date hereof, build and finish a Libarary Building for Party B. ( the building hereinafter is referred to as the said building.) The said building is of the following dimensions, with reinforced concrete, brick, stones and other materials, as are described in plans and specifications gereto annexed.基于上述情况，乙方及其法定代表郑重承诺向甲方支付人民币_____元整。
支付方法商定如下：In consideration of the foregoing, Party B shall, for itself and its legal representatives, promise to pay Party A the sum of one million RMB yuan in manner as follows, to wit：在上述工程开工之日，支付人民币_____元整在_____年_____月_____日，支付人民币_____元整在_____年_____月_____日，支付人民币_____元整在_____年_____月_____日，支付人民币_____元整在_____年_____月_____日，支付人民币_____元整余额人民币_____元整于工程完成之日付清。
(完整word版)中英文版施工合同示范文本
Construction Contract工程合同PO No.: XXXXXXXBuyer:. Date of signature:甲方:签约日期：Seller:乙方:This Purchase Order is made by and between the Buyer and the Seller: Whereby the Buyer agrees to buy and the Seller agrees to sell the under mentioned commodity according to the terms and conditions stipulated below:甲乙双方经友好协商，一致就供应下列产品，达成如下条款：1. Scope of Supply and Price工作范围及价格明细2. Technical Requirement, Quality Requirement, Standard & Warranty Period:Seller shall carried out the construction in strict accordance with the National Standard and the requirements stipulated in the Technical Agreement No. ________which both party signed (see attached documents). The warranty period shall be 1 year after placement of Goods in service.技术要求、质量要求、技术标准和质保期限: 按国家标准和双方签定的技术协议（编号：______见附件）施工，质保期为投产后1年。
3. Job Sites:施工地点：4. Construction Equipment, Tools & Field Personnel Management:施工设备工具及现场人员管理：(1) All the construction equipment and tools shall be provided by Seller.所有施工用设备及工具由乙方自带。
中英文版建设工程施工合同
中英文版建设工程施工合同Construction Engineering Contract合同编号： [Contract No.]合同日期： [Date of Contract]甲方（业主）： [Party A (Owner)]乙方（承包商）： [Party B (Contractor)]第一部分通用条款Part I General Provisions第1条定义Article 1 Definitions本合同中使用的术语和表达，除非另有明确说明，应按照本合同的规定解释。
The terms and expressions used in this contract shall be interpreted in accordance with the provisions of this contract, unless otherwise expressly stated.第2条合同文件Article 2 Contract Documents构成本合同的文件包括但不限于：本合同协议书、中标通知书、投标书及其附件、本合同专用条款、本合同通用条款、标准、规范及有关技术文件、图纸、工程量清单和工程报价单或预算书。
The documents constituting this contract include, but are not limited to: this contract agreement, the notice of award, the tender and its attachments, the special provisions of this contract, the general provisions of this contract, standards, specifications and relevant technical documents, drawings,bill of quantities, and the engineering quotation or budget.第3条语言和法律Article 3 Language and Law本合同使用中文和英文两种语言，两种文本具有同等法律效力。
施工合同中英文模板
施工合同中英文模板Construction ContractTHIS CONTRACT is made and entered into on the [Date] between [Contractor Name], hereinafter referred to as "Contractor," and [Client Name], hereinafter referred to as "Client."WHEREAS, the Client desires to engage the services of the Contractor for the construction of a project described as [Project Description], and the Contractor agrees to perform the work according to the terms and conditions set forth herein.NOW, THEREFORE, in consideration of the mutual promises and covenants contained herein, the parties agree as follows:1. Scope of Work: The Contractor shall provide all labor, materials, and equipment necessary to complete the work as outlined in the attached [Scope of Work] document.2. Payment Terms: The total contract price is [Total Contract Price]. The Client shall make payments to the Contractor as follows: [Payment Schedule].3. Commencement and Completion: The work shall commence on [Commencement Date] and shall be completed by [Completion Date].4. Delays: The Contractor shall not be liable for any delay caused by factors beyond its control, including but not limited to acts of God, labor disputes, or shortages of materials.5. Changes and Variations: Any changes to the work shall be documented in writing and agreed upon by both parties. The cost and time implications of such changes shall be adjusted accordingly.6. Warranties: The Contractor warrants that all work will be performed in a professional manner and will comply with all applicable laws and regulations.7. Dispute Resolution: Any disputes arising out of orrelating to this contract shall be resolved by arbitration in accordance with the rules of the [Arbitration Body].8. Termination: This contract may be terminated by either party upon written notice if the other party breaches any material term of this contract and fails to cure such breach within [Cure Period] days after receipt of written notice.9. Governing Law: This contract shall be governed by and construed in accordance with the laws of the [Jurisdiction].10. Entire Agreement: This contract, including all attachments, constitutes the entire agreement between the parties and supersedes all prior negotiations, representations, and understandings.IN WITNESS WHEREOF, the parties have executed this contract as of the date first above written.[Contractor Name]By: [Authorized Signatory]Address: [Contractor Address][Client Name]By: [Authorized Signatory]Address: [Client Address]施工合同本合同由 [日期] 签订于 [承包商名称]，以下简称“承包商”，与[客户名称]，以下简称“客户”。
- 1、下载文档前请自行甄别文档内容的完整性，平台不提供额外的编辑、内容补充、找答案等附加服务。
- 2、"仅部分预览"的文档,不可在线预览部分如存在完整性等问题,可反馈申请退款(可完整预览的文档不适用该条件!)。
- 3、如文档侵犯您的权益，请联系客服反馈,我们会尽快为您处理(人工客服工作时间：9:00-18:30)。
Con structi on Con tract工程合同PO No. :XXXXXXX Buyer:. Date of sig nature:甲方: 签约日期:Seller:乙方：This Purchase Order is made by and betwee n the Buyer and the Seller: Whereby the Buyer agrees to buy and the Seller agrees to sell the under mentioned commodity according to the terms and conditions stipulated below:甲乙双方经友好协商.一致就供应下列产品，达成如下条款:1.Scope of Supply and Price工作范围及价格明细2.Tech ni cal Requireme nt. Quality Requireme nt, Sta ndard &Warra nty Period:Seller shall carried out the construction in strict accordance with the National Standard and the requirementsstipulated in the Tech ni cal Agreeme nt No. which both party sig ned (see attached docume nts). Thewarranty period shall be 1 year after placement of Goods in service.技术要求、质员要求、技术标准和质保期限:按国家标准和双方签定的技术协议（编号: 见附件）施工.质保期为投产后1年.3.Job Sites:施工地点:4.Con structi on Equipme nt, Tools &Field Pers onnel Man ageme nt:施工设备工具及现场人员管理：(1)Al 1 the con structi on equipme nt and tools shall be provided by Seller.所有施工用设备及工具由乙方自带。
(2)Buyer will coord in ate and arra nge the electricity and water supply on the site. 现场施工用水电由甲方协调安排(3)Buyer will be responsible for al 1 the lifting work during the construction on site.现场施工过程中的吊装工作由甲方负责。
(4)Seller shall be responsible for the manageraent of its field personnel safety: Seller should provide reasonable protection and insurance for its personnel * s safety. All the personnel injury and property damage caused by Seller * s failure of management shall be borne by Seller.现场施工人员管理由乙方负责.乙方应对人员的安全等方面提供合理的保障.由于乙方管理原因造成的人身伤亡及财产损失由乙方承担.5.Construction Time, delay and Postpone 合同工期、工期延误、工期顺延:(1)Buyer shall issue a Notice to Seller about the construction one week prior the date of the construction start.甲方提前一周通知乙方施匸时间•(2)Ccmstruction period will be 15 days from the date of issuance of the order to coounence the construction from Buyer.fl甲方发出开工令之日算起.工程工期15天.(3)C<Histruction period may be postponed as Buyer agreed after he certified that the delay not caused by Seller.非乙方原因造成工期延误.須经甲方确认后工期顺延.(4)The start time of the construction shall be subject to the order to coounence by Buyer. Seller shall unconditionally fol low theoveral1 project schedule of Buyer. Buyer shall be entitled to evaluate and adjustSeller * s construction plan.开工时间以甲方开工令为准.乙方应无条件服从甲方的密体进度计划.甲方有权对乙方制定的工期安拌进行审核、调整.(5)Liquidated Damage: If seiler fails to complete the construction on time as stipulated in the Contract. Selleragrees to pay a penalty at the rate of 1% of the Total Value per day of delay. No bonus for early completion.合同工期的延期损失赔偿费：工期侮延期一天，乙方承担的工期逹约罚款为乙方承包范損内的工程结算价款的1% .提前工期不予奖励.6.Standard and method of acceptance inspection:Subject to the requirement in the Attached Technical Agreement.验收标准、方法：按照技术协议的要求进行验收.7.Payment Term结算方式和期限：*(1)50% of the Total Contract Value will be paid by T/T within 10 working days after the first lot of materialarrived at the site and accepted by Buyer, Seiler shall provide VAT invoice with the total contract value to Buyer. *第一批材料到现场后经甲方验收合格，乙方开具合同全额的17%増偵税发票10个工作日内，付合同总金额50%.(2) 40% of the Total Contract Value will be paid by T/T within 10 working days after the completed and accepted by Buyer.*施工完成经甲方验收合格10个工作日内支付合同总金额的40 %。
(3) 10% of the Total Contract Value will be paid by T/T after one year normal operation of the facility and theWarranty Period expired. *剩下的10%作为成保金.设备正常运行1年后付清.(4) In case of the site construction in Iran, Buyer will be responsible for visa, round-trip fares and traveling expense, food and acconmodation, and 30 US Dollar daily subsidies for each ofconstructionSeller 's personnel on Iran Site. All of the cost will be paid by T/T within 10 working days after construction the completed and Buyer received related bills provided by Seller and accepted these bills..若需乙方前往伊朗項目现场施工，甲方负责乙方施工人员的签证、往返车旅费、食祐.并补助乙方何人/天.以上费用30美金 于现场施工完毕后.乙方提交相关票据，甲方收到票据核实无误10个工作日内结算.B. Delay and Penalty 违约责任:mistake of construction quality. Seller shall repair and replace immediately at to solve defect or mistakecould not be , Buyer shall have right to return the Goods and claim to Seller for如果乙方施工质量出现问题.乙方需无偿即时修夏或更换.如再不能解决.甲方可向乙方退货、索赔.construction(1) If there is any defect or its own cost. If Seller fails loss there caused.。