建筑设计服务合同(中英文)
建筑合同(中英版)7篇
建筑合同(中英版)7篇篇1甲方（雇主）：____________________地址：____________________________联系方式：________________________乙方（承包商）：____________________地址：____________________________联系方式：________________________鉴于甲方需要建设____________工程，乙方具备相关建筑资质和经验，双方经过友好协商，达成以下建筑合同：一、工程概况本合同工程为____________工程，位于____________，工程内容包括但不限于设计、施工、设备安装等。
乙方应按照甲方的要求进行施工，确保工程质量和进度。
二、合同金额及支付方式本合同总金额为________元人民币（美元________），包括设计费、施工费、材料费等所有费用。
支付方式如下：1. 预付款：甲方在本合同签订后支付乙方总金额的____%作为预付款。
2. 进度款：甲方根据工程进度，按照乙方提交的进度报告支付进度款。
3. 尾款：工程竣工验收合格后，甲方支付乙方剩余款项。
三、工程期限本工程自开工之日起，应在____个月内完成。
如遇特殊情况，双方可协商延长工期。
四、工程质量与保证乙方应确保工程质量符合国家标准和甲方要求。
施工过程中，乙方应接受甲方的质量监督和检查。
工程竣工后，乙方应提供质量保修服务，保修期为____年。
五、安全责任乙方应遵守国家有关安全生产的法律法规，采取必要的安全措施，确保施工现场安全。
因乙方原因导致的安全事故，由乙方承担全部责任。
六、违约责任如甲乙双方中任何一方违反本合同的约定，应承担违约责任。
具体违约责任如下：1. 如甲方未按约定支付款项，乙方有权停工，并追究甲方违约责任。
2. 如乙方未按约定完成工程，应承担逾期交付的违约责任。
3. 如因乙方施工质量问题导致工程返工或报废，乙方应承担全部责任。
2019年建设工程设计合同(中英文)-secret
建设工程设计合同Construction Project Design Contract项目名称：Project Name:项目建设地点：Project Location:合同编号：Contract No.:设计证书等级：Grade of Design License:委托方：Client:承接方：Design Firm:签订日期：Signed on:委托方（甲方）：Client (Party A):承接方（乙方）：Design Firm (Party B):甲方委托乙方承担XX项目（一期）工程设计,经双方协商一致,签订本合同. Party A entrusts Party B to undertake the design for . This Contract is made by the two parties after their mutual agreement.第一条本合同依据下列文件签订Article1. This Contract is made on the basis of the following documents:1.1《中华人民共和国合同法》、《中华人民共和国建筑法》和《建设工程勘察设计市场管理规定》.1.1 The Contract Law of the People’s Republic of Chin, The building regulations of the People’s Republic of China and The developmental Law of the People’s Republic of China.1.2国家及地方有关建设工程勘察设计管理法规和规章.1.2 Relevant Building & Design Codes and Regulations of the State and of the Shanghai Municipality.1.3建设工程的相关批准文件.1.3 The approval documents that are required for this construction project.第二条本合同工程设计项目的名称、地点、规模、投资、内容及标准Article2. The name, location, size, investment sum, function, design contents and standards:2.1工程项目的名称：XX项目（一期）2.1 Project name:2.2工程项目的地点：2.2 Project location:2.3工程项目的规模：总建筑面积约平方米（其中地下面积约平方米）,高度米.2.3 Project size: The total floor area is approximately ㎡(of which the floor area of the underground area is ㎡), the total height is ｍ.2.4工程特征及附注说明：商业办公综合楼2.4 Project features & remarks: A commercial cum office building complex2.5工程项目的投资总额：控制在 亿元人民币以下2.5 Project investment in total: Controlled Within million yuan RMB2.6工程项目的设计内容及标准：红线内的建筑、结构、机电、总体设计（包括3000㎡人防设计,不包括精装修设计、园艺设计和艺术泛光照明等专业设计）,施工图设计约为70000㎡（不包括五层到七层的SOHO 区域）.2.6 Design requirements and scope of work: The scope of work shall include master planning and building design that are located within the boundary line. For building design it shall comprise of the architectural, structural & M/E work. (including 3,000㎡of Air-raid shelter design, but excluding other specialists’ design, such as the Luxurious Interior Design, Landscaping Design and Facade Flood Lighting Design). The total floor area during the working drawing stage is 70,000㎡(excluding the SOHO Area, which is starting from the fifth floor level to the seventh floor level).第三条 甲方向乙方提交的有关资料及文件（见下表）Article3. Relevant documents which shall be issued by Party A to Party B:第四条乙方向甲方交付的设计文件（见下表）Article4. Design documents which shall be submitted by Party B to Party A (listed as follows):注：设计文件深度按照《建筑工程设计文件编制深度规定》（建设部2003年4月版）执行. Notes: The design documents shall be prepared in compliance with the Regulations on detailrequirements of design documents for construction project (issued by Ministry of construction dated in April, 2003).第五条设计费用及支付方法Article 5. Design fee and the mode of payment:5.1甲方应支付本合同项目的设计费为.（含所有乙方应缴纳的税费及其它政府规定应由乙方交纳的款项）5.1 Party A shall pay the design fee of RMB yuan for this project to Party B (this fee shall include taxes and all other duties that should be paid by Party B as required by the government regulations).5.2支付方法（见下表）：5.2 The payment method is (listed as the following):第六条双方责任Article6. Responsibilities of both parties:6.1甲方责任6.1 Responsibilities of Party A:6.1.1甲方按本合同第三条规定的内容,在规定的时间内向乙方提交资料及文件,并对其完整性、正确性及时限负责.甲方提交上述资料及文件超过规定期限15天以内,乙方按本合同第四条规定交付设计文件时间顺延；超过规定期限15天以上时,乙方有权重新确定提交设计文件的时间.6.1.1 According to the contents stated in Article 3 of this Contract, Party A shall submit materials and documents to Party B within the stipulated time as described and shall be responsible for the completeness, correctness and validity of such materials and documents. In the event that Party A has delayed the issuance of such materials and documents, but not exceeding 15 days from the stipulated time, Party B could consequently postpone the submittal of the design documents as stipulated in Article 4 of this Contract. In case that Party A has delayed the issuance of materials and documents for more than 15 days exceeding the stipulated time limit, Party B shall have the right to determine the new date for submitting the design documents.6.1.2甲方变更委托设计项目、规模、条件,或对提交资料作重大修改,以致造成乙方设计需返工时,双方除需另行协商签订补充合同、重新明确有关条款外,甲方应按乙方所耗工作量向乙方支付返工费.6.1.2 If Party A alters greatly the design project, scale, conditions which they have already entrusted to Party B, or the materials provided by Party A is wrong/incompleteor Party A makes major alterations to the approved design and the information given, as a result of which, has caused Party B to redo the design work, or has generated un-necessary abortive works, both parties shall enter into negotiation and to draw up a supplementary contract. Party A shall compensate Party B for the additional work load in accordance to the new agreement.6.1.3在合同履行期间,甲方单方提出解除合同的,乙方已开始设计工作的,甲方应根据乙方已进行的实际工作量支付设计费.6.1.3 Should Party A terminate the Contract during the contractual period, Party A shall pay Party B according to the actual work done.6.1.4甲方在收到乙方付款通知书后30天内,按本合同第五条规定的金额和时间向乙方支付设计费用；在收到付款通知书的60天仍未支付,每逾期支付一天,应承担应支付金额千分之一的逾期违约金.逾期超过30天以上时,乙方有权暂停履行下阶段工作,并书面通知甲方.甲方上级对设计文件部审批或本合同项目停缓建,甲方均应支付应付的设计费.6.1.4 Party A shall pay the design fee to Party B within Thirty (30) days upon receiving the Notice of Payment from Party A according to the amount and the time stipulated in Article 5. In case that such payment is delayed for Sixty (60) days upon receiving the Notice of Payment, then a penalty of 0.1% of the due amount of payment on a daily basis shall be paid by Party A. In case that such payment is delayed for a period over 30 days, Party B shall have the right to suspend their design work for the next phase and shall inform Party A in writing. In case that the management of Party A does not approve the design documents or the construction of the project of this Contract is stopped or.. postponed, Party A shall nevertheless pay the due design fee.6.1.5甲方要求乙方比合同规定时间提前提交设计文件时,甲方应支付赶工费. 6.1.5 If Party A requests Party B to submit the design documents ahead of the stipulated time as mentioned in the Contract, Party A shall make additional payment for fast and immediate service.6.1.6为一方派往现场的工作人员提供工作方便条件.6.1.6 Party A shall provide site office and all relevant office stationary for Party B’s personnel who are being sent to work site during the construction stage.6.1.7甲方应保护乙方的设计版权,未经乙方同意,甲方对乙方交付的设计文件不得复制或向第三方转让或用于本合同外的项目,如发生以上情况,乙方有权索赔.6.1.7 Party A shall protect the design copyright of Party B. Without Party B’s consent, Party A shall not duplicate of transfer to a third party or use the design documents for other projects. If the above-mentioned is happened, Party B shall have the right to claim.6.2乙方责任：6.2 Responsibilities of Party B:6.2.1乙方按本合同第四条规定的内容、时间及份数向甲方交付设计文件.6.2.1 Party B shall submit to Party A the required design documents in right content, time and copies according to the clause of Article 4.6.2.2乙方对设计文件出现的遗漏或错误应在施工前负责修改或补充.由于乙方设计错误造成工程质量事故损失,乙方除负责采取补救措施外,应免收损失部分的设计费,并根据损失程度向甲方偿付赔偿金,赔偿金额根据乙方与保险公司签订的设计责任保险合同计算.6.2.2 Party B shall be responsible for correcting any omission or mistake in their design documents before the construction. If the design mistake made by Party B has caused losses to Party A, Party B shall not only be responsible for taking the remedial measures, but also shall remit the design fee for the part of such losses and shall pay compensation to Party A according to the degree of such loss. The amount of the compensation shall be determined by party B and his insurance company and to be in accordance to the professional indemnity insurance coverage.6.2.3由于乙方自身原因,延误了按本合同第四条规定的设计文件交付时间,每延误一天,应减收该项目应收设计费的千分之一.6.2.3 If it is Party B’s own fault to have delayed the submission of the design documents according to the stipulated time as described in Article 4, Party B shalldeduct 0.1% of the due amount of the design fee on a daily basis for the delay period.6.2.4合同生效后,乙方单方提出解除合同的,乙方应当按照有关规定赔偿甲方损失.6.2.4 After the Contract comes into forces, if Party B proposes to terminate the Contract, Party B shall compensate Party A’s losses according to the releva nt regulations.6.2.5乙方交付设计文件后,应参加甲方及相关职能部门的设计审查会议及根据审查结论负责不超出原定计划任务书范围内的必要调整补充；负责向甲方及施工各单位进行设计交底,处理有关的设计问题和参加竣工验收.乙方应派相关人员参加施工期间的例会.乙方应优化设计以帮助业主将造价控制在预算内.6.2.5 After the design documents has been submitted, Party B shall also attend the approval meetings held by Party A and the relevant competent authorities and shall be responsible for making the necessary adjustments, revisions and supplements which does not exceed the scope of the documents of design requirements as originally defined based on the comments of such meetings. Party B shall be responsible for explaining design details to Party A and the main contractor; and shall be responsible for solving all the relevant design problems and to attend the handing over meeting. Party B shall send the relevant personnel to participate in the regular site meetings suring the construction. Party B should optimize the design to assist Party A in meeting the project budget.6.2.6乙方不得向第三方扩散、泄露、转让甲方提交的产品图纸、技术经济资料.如发生以上情况,甲方有权向乙方索赔.6.2.6 Party B is not allowed to disclose and transfer to a third party any product drawing, technical and economic data etc. which are provided by Party A. In case that the above-mentioned is happened, Party A shall have the right to claim.6.2.7未经甲方同意乙方不得将本项目的设计工作全部或部分转包给第三者.6.2.7 Party B is not allowed to subcontract the design work completely or partially to any third party without the permission of Party A.第七条其他约定Article7. Other provisions7.1甲方要求乙方派专人长期驻施工现场进行配合与解决有关问题时,双方应另行签订技术咨询服务合同.7.1 When Party A requires Party B to send site personnel to the construction site for a long period, the two parties shall negotiate for these additional work and sign a supplementary service Contract.7.2乙方为本合同项目所采用的国家或地方标准图,由甲方自费向有关出版部门购买.7.2 Party A shall pay for all the relevant publications and standard collections of drawings issued by the state and local government which are needed by Party B for the purpose of designing the project.7.3本合同第四条规定乙方交付的设计文件份数超过本合同第四条规定的份数,乙方另收工本费.7.3 If Party B is requested to submit design documents, of which, the number of copies are more than those stipulated in Article 4 of this Contract, Party A shall pay for those additional copies.7.4本工程项目中,建筑材料、设备的加工订货,甲方需要乙方设计人员配合时,所需费用由甲方承担.7.4 If Party A requires Party B to provide personnel to assist them for procurement purposes, such as the procurement of building material, equipments, etc.; the expenses needed shall be borne by Party A.7.5甲方委托乙方承担本合同内容之外的工作服务,另行支付费用.7.5 If Party A entrusts Party B to undertake those work and services which are beyond this Contract, Party A shall pay additional fee.7.6由于不可抗拒因素致使合同无法履行时,双方应及时协商解决.7.6 When this Contract can not be executed because of the unforeseeable natural forces, the two parities shall timely negotiate to solve the problem.7.7本建设工程设计合同在履行过程中发生纠纷,双方应及时协商解决.协商不成时,双方同意由上海市仲裁委员会仲裁.7.7 Both parties shall timely discuss each other for the settlement of any dispute arising during the execution of this Contract. In case that such discussion fails, bothparties have agreed appealing to Shanghai Municipal Arbitration Commission can be accepted.7.8甲方聘请为甲方的顾问,协助甲方进行设计管理和建筑设计咨询.费用由甲方另行支付.7.8 Party A has engaged to act as Party A’s consultants to assist Party A to provide the management and design consultation services. The fee will be paid by Party A directly and separately.7.9本合同未尽事宜,双方可签订补充协议,补充协议与本合同具有同等效力.7.9 Supplementary agreement could be made between the two parties in case that any additional clause shall be added. The supplementary agreement shall have the same effect and power as this Contract.7.10本合同一式八份,甲执四份,乙执三份,政府部门一份.7.10 This Contract shall be made in 8 copies. Party A shall hold 4 copies. Party B shall hold 3 copies. The government authority department shall hold one copy.7.11本合同以中英对照书写,如有矛盾,应以中文文本为准.7.11 This Contract is prepared in both Chinese and English languages, in the event of conflicts in any of the provisions between the two versions; provisions specified in the Chinese language version shall take precedence.7.12本合同双方签章后,在30日内报项目所在地建设行政主管部门备案.双方认为必要时,到项目所在地工商行政管理部门签证.上方履行完合同规定的义务后,本合同即行终止.7.12 This Contract, within 30 days after it has been signed and stamped by both parties, shall be submitted to the local government authority for endorsement. When it is considered necessary, both parties could send this Contract to the local industrial and commercial administration departments for registration. This Contract is to be terminated and expired itself after both parties have performed their duties as stipulated in this Contract.7.13本合同经甲、乙双方盖章签字后自年月日生效.（以下无正文）7.13 This Contract shall come into force beginning from the date when both partieshave stamped it and signed it on month year .委托方单位名称： 承接方单位名称：（盖章） （盖章）Party A: Party B:(Stamp) (Stamp)单位地址： 单位地址：Address: Address:邮政编码： 邮政编码：Post Code: Post Code:电 话：电 话：Tel: Tel:电 传： 电 传：Fax: Fax:开户银行： 开户银行：Name of bank: Name of bank:银行账号： 银行账号：Bank account: Bank account:签订合同代表（签字）： 签订合同代表（签字）： Contract Signing Representative: Contract Signing Representative:本合同于 年 月 日签于上海.This Contract is signed in Shanghai on (date) (month) (year) . 法定代表人： 法定代表人：Legal Representative: Legal Representative:市勘察设计市场管理部门意见： 市勘察设计市场管理部门意见： （盖章） （盖章）备案日期： 签证日期：年 月 日 年 月 日。
建筑合同(中英版)4篇
建筑合同(中英版)4篇全文共4篇示例，供读者参考篇1Architecture Contract（建筑合同）1. Definition（定义）An architecture contract is a legal agreement between a client and an architect in which the terms and conditions of a construction project are outlined. This contract ensures that both parties understand their roles and responsibilities, as well as the scope of work, budget, and timeline of the project.建筑合同是客户与建筑师之间的法律协议，其中概述了建筑项目的条款和条件。
该合同确保双方了解自己的角色和责任，以及项目的工作范围、预算和时间表。
2. Purpose（目的）The purpose of an architecture contract is to protect the interests of both the client and the architect. By clearly defining the terms and conditions of the project, both parties can avoid misunderstandings and disputes that may arise during the construction process. Additionally, the contract helps toestablish a clear framework for communication anddecision-making throughout the project.建筑合同的目的是保护客户和建筑师双方的利益。
中英文建筑合同范本
Contract for ConstructionContract No.: [Contract Number]Date: [Date of Contract]Signing Place: [Place of Signing]Party A: [Contractor's Name]Address: [Contractor's Address]Postal Code: [Contractor's Postal Code]Telephone: [Contractor's Telephone Number]Fax: [Contractor's Fax Number]Party B: [Client's Name]Address: [Client's Address]Postal Code: [Client's Postal Code]Telephone: [Client's Telephone Number]Fax: [Client's Fax Number]Subject to the terms and conditions set forth below, Party A agrees to construct and complete the [Description of the Building] (hereinafter referred to as the "Project") for Party B.1. Scope of WorkParty A agrees to construct and complete the Project in accordance with the plans and specifications provided by Party B. The details of the Project, including the dimensions, materials, and construction schedule, shall be as agreed upon by the parties in writing.2. Time of CompletionParty A agrees to complete the construction of the Project within [Number of Days] from the date of commencement of the work. Thecommencement date shall be the date when Party A begins the construction activities as agreed upon by the parties.3. Materials and QualityParty A shall use quality materials and construction methods asspecified by Party B in the plans and specifications. The materials used shall be of standard quality and shall meet the applicable codes and regulations.4. PaymentThe total cost of the Project shall be [Total Cost]. The payment shall be made by Party B to Party A in accordance with the payment schedule agreed upon by the parties. The payment schedule shall be based on the progress of the work and shall be as set forth in the contract.5. DefaultIn the event that Party A fails to complete the Project within the agreed time, Party A shall be in default. In such event, Party B shall be entitled to terminate the contract and claim damages for the delay.6. Dispute ResolutionAny disputes arising out of or in connection with this contract shall be resolved by arbitration in accordance with the rules of the [Arbitration Institution]. The decision of the arbitrator(s) shall be final and binding upon the parties.7. Governing LawThis contract shall be governed by and construed in accordance with the laws of [Jurisdiction].In Witness Whereof, the parties hereto have executed this contract as of the date first above written.Party A: [Contractor's Name]By: [Contractor's Authorized Representative]Date: [Date]Party B: [Client's Name]By: [Client's Authorized Representative]Date: [Date](This is a sample contract for construction and may not be suitable for your specific needs. It is recommended that you consult with a legal professional to draft a contract that meets your specific requirements.)。
建筑设计合同英文模板
建筑设计合同英文模板Architectural Design Contract Template。
This Architectural Design Contract (“Contract”) is entered into as of [Date], by and between [Client Name] (“Client”) and [Architect Name] (“Architect”).1. Scope of Work。
Architect agrees to provide architectural design services for the project located at [Project Address]. The scope of work shall include but not be limited to the following:a. Site analysis and feasibility study。
b. Conceptual design and schematic drawings。
c. Design development and construction drawings。
d. Permitting and regulatory compliance。
e. Construction administration and site visits。
f. Coordination with other design professionals and consultants。
2. Compensation。
Client agrees to pay Architect a total fee of [Total Fee] for the services outlined in the Scope of Work. The fee shall be paid in installments as follows:a. [Percentage]% upon signing of this Contract。
建筑设计服务合同中英文
CONTRACT OF CONSTRUCTION DESIGN客户方Client设计方Designer双方本着公平、自愿和诚信的原则，经友好协商达成如下条款（包括基本条款以及其他条款两个部分）：Under the principles of fairness, free will and good will, IT IS HEREBY AGREED between both parties as follows (the Contract includes two parts, i.e. the General Articles and the Contingent Articles):1.客户方委托设计方提供的建筑设计服务均以本合同各项条款、附录、附表以及双方为履行本合同相关内容所签订的补充协议等所约定的内容为准，设计方应按照双方的约定和客户方的要求完成工程设计的各项工作。
本合同的附录、附表、其他条款以及补充协议等附件是本合同不可分割的部分，具有与本协定书同等的法律效力。
The architectural design services that the Client appoints the Designer to provide shall be in compliance with the provisions, appendixes and exhibits of the Contract, as well as with the provisions in the supplementary agreements in conjunction with the execution of the Contract that have entered or may be entered between the parties. The Designer shall carry out the design tasks for Project according to the agreement between both parties as well as the requirements of the Client. Appendixes, exhibits, other articles and supplementary agreements of the Contract are integral part of the Contract, and shall have the same legal binding force with the Contract.2.为工程提供的详细设计服务项目全部列于本合同附表2《设计服务项目清单》中，同时设计方承诺按照该附表中客户方的要求提供列明的全部服务项目。
建设工程设计合同(中英文对照版)
建设工程设计合同（二）（专业建设工程设计合同）Engineering Service Contract (Ⅱ)(Professional Engineering Service Contract For Construction Project)工程名称：工程地点:合同编号：（由设计人编填）设计证书等级：发包人：设计人：签订日期:Name of the project:Location of the project:Contract No.:(Filled in by the Designer)Level of the design certificate:Employer:Designer:Date of contract: November 25, 2004监制中华人民共和国建设部国家工商行政管理部Supervised by: Jiangsu Provincial Department of ConstructionJiangsu Provincial Administration for Industry and Commerce发包人：设计人:发包人委托设计人承担______________________________工程设计，工程地点为_______________ ，经双方协商一致，签订本合同，共同执行。
Employer: (Party A)Designer: (Party B)The Employer entrust the Designer to undertake the engineering design of the 10/0.4KV transformer station and the location for the project is within the plant of After friendly consultation, the Parties hereby sign this Contract as follows：第一条本合同签订论据1.1《中华人民共和国合同法》、《中华人民共和国建筑法》和《建设工程勘察设计市场管理规定》。
建筑合同(中英版)6篇
建筑合同(中英版)6篇篇1甲方（雇主）：____________________地址：____________________________联系方式：________________________乙方（承包商）：____________________地址：____________________________联系方式：________________________鉴于甲方需要建设____________________（具体工程名称），并决定委托乙方完成此项建筑工程，现甲乙双方就相关事宜达成如下协议：一、工程概况甲方委托乙方承担工程名称、地点、规模、内容等详见本合同附录一《工程概况》。
乙方应按照设计要求、技术规范及标准进行施工，确保工程质量和安全。
工程开工时间定于________年____月____日，竣工时间为________年____月____日。
承包总价暂定为人民币______元整。
详细的价格及费用详见本合同附录二《工程造价清单》。
具体支付细节在本合同的第五条支付条款中有详细解释。
本合同涉及的所有内容必须遵守中国的相关法律法规。
任何因违反法规而导致的损失，将依法承担法律责任。
二、甲方责任与义务甲方有权监督乙方履行合同的情况，并按时支付工程款项。
甲方有权了解工程的施工进度、质量安全等情况，并要求乙方及时汇报施工情况。
同时，甲方需及时向乙方提供工程设计图纸和技术规范等必要文件资料。
对于由于甲方提供资料延误或其他甲方原因导致工程进度延误造成的损失，由甲方自行承担。
甲方应保证工程的合法性和合理性，避免因违反法律法规而引起的纠纷和损失。
对于乙方提出的合理建议和意见，甲方应积极考虑并予以解决。
对于乙方履行合同过程中的行为，甲方应给予必要的支持和协助。
对于施工现场的安全问题，甲乙双方共同承担责任，严格执行国家安全生产法律法规和相关规定。
三、乙方责任与义务篇2甲方（雇主）：____________________地址：____________________________联系方式：________________________乙方（承包商）：____________________地址：____________________________联系方式：________________________鉴于甲方需要建造特定的建筑物，并且有意雇用乙方作为其建筑承包商来执行该项目的建筑任务，甲乙双方在平等、自愿、公平的基础上，经过友好协商，达成如下协议：一、合同概述本合同涉及甲方委托乙方进行建筑项目的施工工作。
建设工程设计合同文本中英文对照
建设工程设计合同文本中英文对照一、合同目的与范围Ojective and Scoe of the Contract:本合同的目的是明确甲乙双方在建设工程设计项目中的权利、义务和责任。
合同范围涵盖了从初步设计到施工图纸的所有阶段。
The urose of this contract is to clarify the rights, oligations, and resonsiilities of oth arties in the construction engineering design roject. The scoe of the contract covers all stages from reliminary design to construction drawings.二、设计要求与标准Design Requirements and Standards:乙方需根据甲方提供的要求和相关法规标准，完成工程设计任务。
设计成果应满足功能需求、安全规范和审美标准。
arty shall comlete the engineering design tasks in accordance with the requirements rovided y arty A and relevant regulatory standards. The design results should meet functional needs, safety secifications, and aesthetic standards.三、设计周期与阶段Design eriod and hases:工程设计将分为三个主要阶段：概念设计、初步设计和施工图设计。
每个阶段的完成时间应在合同中明确规定。
The engineering design will e divided into three main hases: concetual design, reliminary design, and construction drawing design. The comletion time for each hase should e clearly defined in the contract.四、费用支付与结算ayment and Settlement:甲方应按合同约定向乙方支付设计费用。
专业建设工程设计合同-中英文版
建设工程设计合同Engineering Service Contract（专业建设工程设计合同）(Professional Engineering Service Contract For ConstructionProject)工程名称：Name of the project:工程地点：Location of the project:合同编号：（由设计人编填）Contract No.:(Filled in by the Designer)设计证书等级：Level of the design certificate:发包人：Employer:设计人：Designer:签定日期：Date of contract:江苏省建设厅江苏省工商行政管理局Supervised by: Jiangsu Provincial Department of ConstructionJiangsu Provincial Administration for Industry and Commerce发包人:Employer: (Party A)设计人:Designer: (Party B)发包人委托设计人承担工程设计,工程地点为,经双方协商一致,签订本合同,共同执行。
The Employer entrust the Designer to undertake the engineering design of *** and the location for the project is within the plant of .After friendly consultation, the Parties hereby sign this Contract as follows：第一条本合同签订依据。
Article 1 Basis for the conclusion of this Contract1.1《中华人民共和国合同法》、《中华人民共和国建筑法》、《建设工程勘察设计市场管理规定》。
建设工程设计英文合同范本
建设工程设计英文合同范本---Article 1: Definitions and Interretation1.1 "Client" refers to the arty who entrusts the design work to the Designer;1.2 "Designer" refers to the arty who undertakes the design work for the Client;1.3 "Design Work" refers to the rofessional services rovided y the Designer in accordance with the requirements of the Client, including ut not limited to drawings, secifications, calculations, reorts, etc.;1.4 "Design eriod" refers to the time limit agreed uon y oth arties for comleting the Design Work.Article 2: Design Tasks and Scoe2.1 The Client shall rovide the Designer with relevant information, data, and technical requirements for the Design Work;2.2 The Designer shall conduct the Design Work in accordance with national and industry standards, as well as the requirements of the Client;2.3 The Designer shall sumit the Design Work to the Client within the agreed Design eriod;2.4 The Designer shall e resonsile for revising and imroving the Design Work ased on the feedack from the Client.Article 3: Design Fee3.1 The Client shall ay the Design Fee to the Designer according to the following schedule: (a) 30% of the total Design Fee uon signing this contract; () 50% of the total Design Fee uon sumission of reliminary design; (c) 10% of the total Design Fee uon sumission of construction drawings; (d) 10% of the total Design Fee uon comletion of the entire Design Work.3.2 The Client shall ear any additional costs arising from changes in design requirements or scoe during the course of the Design Work.Article 4: Intellectual roerty Rights4.1 All intellectual roerty rights related to the Design Work shall elong to the Client;4.2 The Designer shall have no right to use, disclose, transfer or authorize others to use any art of the Design Work without rior written consent from the Client.Article 5: Confidentiality5.1 oth arties shall kee confidential all technical and usiness information otained during the erformance of this contract;5.2 Neither arty shall disclose any confidential information to any third arty without rior written consent from the other arty.Article 6: Liaility for reach of Contract6.1 If either arty fails to erform its oligations under this contract, it shall ear liaility for reach of contract;6.2 If the Designer fails to comlete the Design Work within the agreed Design eriod due to reasons attriutale to itself, it shall ay liquidated damages to the Client at a rate of 1% er day of the total Design Fee for each day overdue.Article 7: Disute Resolution7.1 Any disute arising from this contract shall e first resolved through friendly consultation etween oth arties; if consultation fails, either arty may ring a lawsuit to a court with jurisdiction over the matter.Article 8: Force Majeure。
英文建筑设计合同模板
英文建筑设计合同模板Effective Date: [Date]This agreement is made and entered into as of the Effective Date between [Client Name], located at [Client Address] (hereinafter referred to as the Client) and [Architect Name], located at [Architect Address] (hereinafter referred to as the Architect).WHEREAS, the Client desires to engage the services of the Architect to provide architectural design services for [Project Name], located at [Project Location]; andWHEREAS, the Architect is willing to provide architectural design services for the Project in accordance with the terms and conditions set forth in this Agreement.NOW, THEREFORE, in consideration of the mutual covenants contained herein and for other good and valuable consideration, the receipt and sufficiency of which are hereby acknowledged, the parties hereto agree as follows:1. Scope of WorkThe Architect shall provide architectural design services for the Project as outlined in Exhibit A attached hereto, which may be amended or supplemented by written agreement of the parties. The Architect shall use his professional skill and judgment to perform all necessary services in a timely and professional manner.2. CompensationThe Client shall pay the Architect a fee in the amount of [Fee Amount] for the Architect's services rendered under this Agreement. The fee shall be paid in installments as set forth in Exhibit B attached hereto. The Client shall also reimburse the Architect for any reasonable and necessary expenses incurred in the performance of services under this Agreement.3. ChangesAny changes to the scope of work or schedule shall be agreed upon by the parties in writing. The Architect shall be entitled to an adjustment in the fee and schedule as a result of any changes requested by the Client.4. Ownership of DocumentsAll drawings, specifications, reports, and other documents prepared by the Architect shall be the property of the Client upon full payment of the Architect's fee. The Client may use, modify, or reproduce the documents for the Project as necessary.5. TerminationEither party may terminate this Agreement upon written notice to the other party in the event of a material breach of this Agreement by the other party. Upon termination, theparties shall settle any financial obligations and the Architect shall deliver all documents and materials related to the Project to the Client.6. InsuranceThe Architect shall maintain professional liability insurance coverage in the amount of [Coverage Amount]. The Client shall be named as an additional insured on the policy. The Architect shall provide a certificate of insurance to the Client upon request.7. Governing LawThis Agreement shall be governed by the laws of the State of [State]. Any disputes arising out of or related to this Agreement shall be resolved by arbitration in accordance with the rules of the American Arbitration Association.IN WITNESS WHEREOF, the parties hereto have executed this Agreement as of the Effective Date.CLIENT: ARCHITECT:_______________________ ________________________[Client Name] [Architect Name]Exhibit A: Scope of WorkExhibit B: Fee ScheduleThis Agreement constitutes the entire agreement between the parties with respect to the subject matter hereof and supersedes all prior agreements and understandings, whether written or oral. This Agreement may not be modified or amended except in writing signed by both parties.。
建筑合同（中英版）（通用12篇）
建筑合同(中英版)（通用12篇）建筑(中英版) 篇1甲方：Party A：乙方：Party B：合同编号： Contract No日期：Date：签约地点：Signed at：特约定：甲方基于下文所列各种因素，特与乙方达成了协议并一致同意：由甲方在订约日期之翌日起_____天之内为乙方建造并完成_____（涉约建筑）。
涉约建筑之规模及所需的钢筋、水泥、砖块、石子和其它建筑材料之数量，均在作为附件的设计图和施工细则中予以说明。
Witnesses that the Party A for considerations hereinafter named, contracts and agrees with the Party B that Party A will, within_____ days, next following the date hereof, build and finish a Libarary Building for Party B. ( the building hereinafter is referred to as the said building.) The said building is of the following dimensions, with reinforced concrete, brick, stones and other materials, as are described in plans and specifications gereto annexed.基于上述情况，乙方及其法定代表郑重承诺向甲方支付人民币_____元整。
支付方法商定如下：In consideration of the foregoing, Party B shall, for itself and its legal representatives, promise to pay Party A the sum of one million RMB yuan in manner as follows, to wit：在上述工程开工之日，支付人民币_____元整在_____年_____月_____日，支付人民币_____元整在_____年_____月_____日，支付人民币_____元整在_____年_____月_____日，支付人民币_____元整在_____年_____月_____日，支付人民币_____元整余额人民币_____元整于工程完成之日付清。
建设工程设计合同中英文
建设工程设计合同(中英文）CONTRACT OF CONSTRUCTION PROJECT DESIGN项目名称： Project Name:项目建设地点： Project Location:合同编号：Contract No.:设计证书等级： Grade of Design License:签订日期： Signed on:委托方：（甲方） Client (Party A):承接方：（乙方） Design Firm (Party B):甲方委托乙方承担XX 项目（一期）工程设计，经双方协商一致，签订本合同。
Party A entrusts Party B to undertake the design for This Contract is made by the twoparties after their mutual agreement.第一条本合同依据下列文件签订Article 1. This Contract is made on the basis of the following documents:1.1 《中华人民共和国合同法》、《中华人民共和国建筑法》和《建设工程勘察设计市场管理规定》。
《The Contract Law of the People’s Republic of China》,《The building regulations of the People’s Republic of China》 and 《The developmental Law of the People’s Republic of China.1.2 国家及地方有关建设工程勘察设计管理法规和规章。
Relevant Building & Design Codes and Regulations of the State and of the Shanghai Municipality.1.3 建设工程的相关批准文件。
建设工程设计合同中英文版本
建设工程设计合同中英文版本Construction Project Design Contract项目名称：Project Name:项目建设地点：Project Location:合同编号：Contract No.:设计证书等级：Grade of Design License:委托方：Client:承接方：Design Firm:签订日期：Signed on:委托方（甲方）：Client （Party A）:承接方（乙方）：Design Firm （Party B）: 甲方委托乙方承担XX 项目（一期）工程设计，经双方协商一致，签订本合同。
Party A entrusts Party B to undertake the design for . This Contract is made by the two parties after their mutual agreement.第一条本合同依据下列文件签订Article1. This Contract is made on the basis of the following documents:1.1 《中华人民共和国合同法》、《中华人民共和国建筑法》和《建设工程勘察设计市场管理规定》。
1.1 The Contract Law of the People ' s Republic of Chin, The building regulations of the People 's Republic of China and The developmental Law of the People ' s Republic of China.1.2 国家及地方有关建设工程勘察设计管理法规和规章。
1.2 Relevant Building & Design Codes and Regulations of the State and of the Shanghai Municipality.1.3 建设工程的相关批准文件。
建设工程设计英文合同
建设工程设计英文合同Title: Construction Engineering Design ContractThis contract is made on [date] etween [name of client], hereinafter referred to as "the Client," and [name of designer or design firm], hereinafter referred to as "the Designer."Whereas the Client desires to engage the Designer to rovide rofessional engineering design services for the [descrition of the roject], and the Designer agrees to rovide such services in accordance with the terms and conditions set forth elow.1. Scoe of Services:The Designer shall rovide the following engineering design services:a) reliminary concetual design.) Detailed design and engineering drawings.c) Technical secifications and construction documents.d) roject management and coordination with other consultants.e) On-site insections and evaluations during the construction hase.f) Assistance in the resolution of technical issues that may arise during the roject imlementation.2. Duration and Timeline:The services shall commence on [start date] and continue until the comletion of the roject, exected y [end date]. The Designer shall adhere to the agreed-uon timeline, ensuring that all milestones are met within the secified deadlines.3. Remuneration:The Client shall ay the Designer in accordance with the following schedule:a) An initial deosit of [ercentage]% uon signing of the contract.) rogress ayments ased on comletion of secific milestones.c) Final ayment uon satisfactory comletion of all services.4. Intellectual roerty Rights:All designs, drawings, secifications, and related documents roduced y the Designer under this contract shall remain the roerty of the Client. The Designer grants a license to the Client for the use of these materials solely for the urose of the roject descried herein.5. Liaility and Indemnification:The Designer shall erform its services with the degree of skill and care reasonaly exected from a qualified engineering design rofessional. The Designer shall indemnify the Client against any negligent act or omission resulting in loss or damage.6. Change Orders and Additional Work:Any deviation from the original scoe of work shall e executed through a written change order, which may result in additional fees and an adjusted timeline.7. Disute Resolution:Any disutes arising from or related to this contract shall first e attemted to e resolved through mutual negotiation. If negotiation fails, the arties may sumit the disute for resolution y mediation or inding aritration as er the terms detailed in the contract.8. Governing Law and Jurisdiction:This contract shall e governed y and construed in accordance with the laws of [jurisdiction where the roject is located]. Any legal action or roceeding arising out of or relating to this contract shall e rought exclusively within the jurisdiction of the courts of [jurisdiction].9. Termination:Either arty may terminate this contract uon written notice to the other arty in the event of material reach or failure to fulfill oligations as er the contract terms.10. Miscellaneous:a) This contract constitutes the entire agreement etween the arties and suersedes any rior negotiations, reresentations, or agreements, whether oral or written.) Any amendment to this contract must e in writing and signed y oth arties.c) This contract may not e assigned y the Designer without the Client's rior written consent.y signing elow, oth arties acknowledge their agreement to the terms outlined within this contract.Client: [Client's Name] _________________________________Designer: [Designer's Name or Design Firm's Name] _________________________________Date: _____________________________________________。
建筑合同(中英版)6篇
建筑合同(中英版)6篇篇1Building ContractA building contract is a legal agreement between the owner of a property and a building contractor, outlining the terms and conditions under which a construction project will be carried out. This document is essential for ensuring that both parties understand their rights and responsibilities throughout the construction process. In this article, we will discuss the key components of a building contract and its importance in the construction industry.1. Parties involvedThe building contract will identify the parties involved in the project, including the owner of the property and the building contractor. It may also include subcontractors, architects, engineers, and other professionals who will be involved in the construction process.2. Scope of workThe contract will outline the scope of work to be performed, including the specific tasks that the building contractor is responsible for, such as site preparation, construction, and cleanup. It will also specify the materials and equipment to be used in the project.3. ScheduleThe contract will include a timeline for the completion of the project, including key milestones and deadlines. This is important for both parties to ensure that the project stays on track and is completed in a timely manner.4. Payment termsThe contract will outline the payment terms for the project, including the total cost of the construction, payment schedule, and any additional costs that may arise during the project. This is essential for avoiding disputes over payment and ensuring that the project stays within budget.5. Changes and disputesThe contract will include provisions for handling changes to the project scope, as well as procedures for resolving disputes that may arise during the construction process. This is important for maintaining a positive working relationship between theparties and ensuring that any issues are resolved quickly and fairly.6. Insurance and liabilityThe contract will specify the insurance coverage required for the project, including liability insurance for the building contractor and any subcontractors. This is essential for protecting both parties in the event of accidents or damages during the construction process.Building contracts are critical documents in the construction industry, as they provide a legal framework for the building project and ensure that both parties understand their rights and responsibilities. It is important for both owners and building contractors to carefully review and negotiate the terms of the contract before signing to avoid any misunderstandings or disputes later on. By having a clear and comprehensive building contract in place, both parties can work together to successfully complete the construction project on time and within budget.篇2Architecture ContractBuilding a new structure involves a lot of planning, designing, and execution. In order to ensure that a project is completedsuccessfully, it is essential to have a proper agreement in place. This agreement, known as an architecture contract, outlines the responsibilities of both the client and the architect, as well as the terms and conditions of the project.An architecture contract is a legal document that establishes the scope of work, the schedule, and the cost of a construction project. It also specifies the roles and responsibilities of the architect, the client, and any other parties involved in the project. By signing this contract, both parties agree to abide by the terms and conditions laid out in the document.There are several key components that should be included in an architecture contract. These include:1. Scope of Work: This section outlines the specific tasks that the architect will be responsible for, such as creating designs, obtaining permits, and overseeing construction.2. Schedule: The contract should include a timeline for the project, including milestones and deadlines for completion.3. Fees: The contract should detail the architect's fees, including how they will be calculated and when they are due.4. Changes: This section should outline the procedure for making changes to the project scope, schedule, or budget.5. Termination: The contract should specify the conditions under which either party can terminate the agreement.In addition to these components, an architecture contract should also address issues such as insurance, liability, and dispute resolution. It is important for both parties to fully understand and agree to the terms of the contract before signing it.In conclusion, an architecture contract is a crucial document that helps to ensure the success of a construction project. By clearly outlining the responsibilities and expectations of both parties, this agreement helps to minimize misunderstandings and disputes, and provides a framework for the successful completion of the project.篇3Architecture Contract (中英版)Introduction建筑合同是指项目委托方和承包方之间所签订的协议，规定了双方在建筑项目中的权利和义务。
有关建筑合同(中英版)6篇
有关建筑合同(中英版)6篇篇1建筑合同甲方（发包方）：____________________乙方（承包方）：____________________鉴于甲方需要建设____________工程，乙方具备相关建筑资质和经验，双方根据平等、自愿、公平的原则，就本工程建设事宜，达成如下协议：一、工程概况工程名称：____________________工程地点：____________________工程规模：____________________工程内容：包括但不限于是地基工程、主体结构、建筑装饰装修工程等。
二、工程期限开工日期：____________________竣工日期：____________________如遇特殊情况，双方协商工期顺延。
三、工程价款及支付方式工程总价款：____________________元（人民币大写）支付方式：甲方应按工程进度支付工程款，具体支付节点和金额按照双方约定执行。
四、工程质量与验收1. 乙方应严格按照国家相关建筑标准和规范进行施工，确保工程质量。
2. 双方应制定详细的质量验收标准，并进行阶段性验收和竣工验收。
3. 若工程质量不符合约定，乙方应负责无偿修复或返工。
五、工程变更与调整1. 甲方有权根据实际需要调整工程内容和规模。
2. 双方应及时就工程变更进行书面确认，并调整工程价款。
3. 若因工程变更导致工期延误，双方应协商顺延工期。
六、安全施工与文明施工1. 乙方应制定严格的安全施工措施，确保施工现场安全。
2. 乙方应遵守文明施工规范，保持施工现场整洁。
3. 若因乙方安全措施不当导致安全事故，乙方应承担全部责任。
七、违约责任1. 若一方违反合同约定，应承担违约责任，并赔偿对方因此造成的损失。
2. 若因乙方原因导致工程延期，乙方应承担违约责任，并支付违约金。
3. 若甲方未按约定支付工程款，乙方有权停工，并要求甲方支付违约金。
八、保密条款双方应对本合同内容及相关技术资料予以保密，未经对方同意，不得泄露给第三方。
建筑设计服务合同中英文
建筑设计服务合同中英文Contract for Architectural Design Services本合同由以下双方于_____________________日期签署:This contract is entered into between the following parties on _________________(date):甲方(客户)：__________________________Party A (Client): __________________________地址：__________________________Address: __________________________乙方(建筑设计师/公司)：__________________________地址：__________________________Address: __________________________鉴于甲方需要乙方提供建筑设计服务，甲乙双方在平等互利的基础上达成以下协议：Whereas Party A requires architectural design services from Party B, the parties have reached the following agreement on the basis of equality and mutual benefit:一、服务描述1. Service Description1.1乙方将根据甲方的需求和要求提供建筑设计服务，包括但不限于以下内容：Party B shall provide architectural design services to Party A based on the latter's needs and requirements, including butnot limited to:1.1.1提供建筑设计概念和方案。
- 1、下载文档前请自行甄别文档内容的完整性，平台不提供额外的编辑、内容补充、找答案等附加服务。
- 2、"仅部分预览"的文档,不可在线预览部分如存在完整性等问题,可反馈申请退款(可完整预览的文档不适用该条件!)。
- 3、如文档侵犯您的权益，请联系客服反馈,我们会尽快为您处理(人工客服工作时间：9:00-18:30)。
CONTRACT OF CONSTRUCTION DESIGN客户方Client设计方Designer双方本着公平、自愿和诚信的原则，经友好协商达成如下条款（包括基本条款以及其他条款两个部分）：Under the principles of fairness, free will and good will, IT IS HEREBY AGREED between both parties as follows (the Contract includes two parts, i.e. the General Articles and the Contingent Articles):1.客户方委托设计方提供的建筑设计服务均以本合同各项条款、附录、附表以及双方为履行本合同相关内容所签订的补充协议等所约定的内容为准，设计方应按照双方的约定和客户方的要求完成工程设计的各项工作。
本合同的附录、附表、其他条款以及补充协议等附件是本合同不可分割的部分，具有与本协定书同等的法律效力。
The architectural design services that the Client appoints the Designer to provide shall be in compliance with the provisions, appendixes and exhibits of the Contract,as well as with the provisions in the supplementary agreements in conjunction with the execution of the Contract that have entered or may be entered between the parties. The Designer shall carry out the design tasks for Project according to the agreement between both parties as well as the requirements of the Client. Appendixes, exhibits, other articles and supplementary agreements of the Contract are integral part of the Contract, and shall have the same legal binding force with the Contract.2.为工程提供的详细设计服务项目全部列于本合同附表2《设计服务项目清单》中，同时设计方承诺按照该附表中客户方的要求提供列明的全部服务项目。
All detailed items of the design services that the Client appoints the Designer to provide for Project are included in Exhibit 2 List of Design Service Items . The Designer shall pledge that all service items listed shall be provided in accordancewith the requirements of the Client.3．设计方提交工程D阶段的图纸设计深度，须满足附表3《客户方对设计成果的深度要求》的要求。
The depth of the drawings and designs for Stage D of the Project submitted bythe Designer shall comply with the provisions in Exhibit 3 Requirements from the Client on the Depth of the Design Results.4.对于设计方提供的各项服务内容和设计成果，应及时根据客户方的要求、反馈意见或中国相关审批机关提出的修改意见以及相关的法律法规对方案进行必要的修改和调整，并按照附表 4《设计方交图时间表》约定的时间内交付客户方。
The services and the design results provided by the Designer shall be amended and adjusted in a timely manner according to the requirements and feedback of the Client, the deliberations of the competent authorities of China, as well as relevant laws and regulations, and shall be delivered to the Client within the time frame provided in Exhibit 4 Designer's Submission Schedule for Drawings .5. 客户方在此承诺按照本合同的各项约定，在设计方按照客户方的要求完成附表2中相应阶段的工作内容并得到客户方的书面确认通知后，客户方将根据附表5《费用、开支及付款方式》的相关约定向设计方支付相应工作阶段所列明的设计费用。
The Client hereby pledges that after the Designer completes its tasks listed in Exhibit 2 in accordance with the requirements of the Client and after the Client issues to the Designer a written notice for confirmation, the Client shall advance to the Designer due design fees prescribed for different stages of the completion of tasks according to the Contract and Exhibit 5 Costs, Expenses, and Payment Terms .6．客户方须按照本合同附表6《关于中方设计单位》中约定工作内容和要求在中华人民共和国境内指定一家建筑设计事务所（设计院或公司），提供与工程相关的服务，并在设计方的协调指导下完成工程设计的相关工作。
The Client shall designate within the territory of the People's Republic of China an architectural design firm, institute or company in accordance with the work tasks and requirements prescribed in Exhibit 6 Regarding the Chinese Design Firm in order to provide services in association with the Project and to carry out other design-related tasks with the guidance and coordination of the Designer.7. 在工程实施的整个期间，双方约定将严格按照本合同附表7《双方配合工作方式》中提到的各项内容进行配合。
During the course of construction of Project, both parties agree to coordinate with each other in strict accordance with the provisions in Exhibit 7 Coordination between the Parties.8．考虑到项目下一步市场推广、宣传的需要，设计方应提供主要设计人员名单、执业资质以及业绩介绍等作为本合同的附表8《设计方主要设计师介绍》。
In view of the next-step market promotion and promulgation activities, the Designer shall fill Exhibit 8 Introductions to Major Designing Personnel of the Designers with the names, professional qualifications and summary of accomplishments of the key designers from the Designer.9．在履行本合同期间，双方如有争议，应友好协商解决。
对于不能协商解决的争议与纠纷应当一律提交中国国际经济贸易仲裁委员会进行仲裁，并以中华人民共和国的相关法律作为仲裁的依据，同时双方约定该机构的仲裁为最终裁决。
In the event of any dispute between the parties during the execution of the Contract, both parties shall work to solve it via friendly negotiations. Any dispute or conflict that cannot be solved via negotiations shall be referred to China International Trade Arbitration Committee , and relevant laws of the Peop le's Republic of China shall apply. The parties shall also regard the award given by the arbitration committee as final.10. 本合同中文、英文版本各4份，合同双方执中文、英文版本合同各2份，不同文字版本的合同具有同等法律效力。