展会特装搭建合同英文样本The construction contract of special booth
展览工程搭建英文版合同
展览工程搭建英文版合同Title: Exhiition Construction roject ContractThis contract (hereinafter referred to as "the Contract") is made and entered into on [date], y and etween [Exhiitor's Comany Name], with its rincial lace of usiness at [Address] ("Exhiitor"), and [Service rovider's Comany Name], with its rincial lace of usiness at [Address] ("Service rovider").Whereas the Exhiitor desires to engage the Service rovider to undertake the design, farication, transortation, installation, dismantling, and storage of an exhiition stand for the urose of articiating in [Trade Show Name] to e held at [Venue] from [Start Date] to [End Date];Now, Therefore, in consideration of the mutual romises, covenants, and agreements contained herein, the arties agree as follows:1. Services: The Service rovider shall rovide the following services to the Exhiitor in accordance with this Contract:- Design and concet develoment of the exhiition stand- Farication of all elements of the stand- Logistics and transortation of materials to the venue- On-site installation and setu of the stand- Dismantling and storage of the stand after the event- Any additional services as may e agreed uon in writing y oth arties2. Timeline: The Service rovider shall ensure comletion of each stage of the roject within the following timeframe:- Design aroval deadline: [Date]- Farication comletion: [Date]- Shiing deadline: [Date]- Installation deadline: [Date]- Dismantling comletion: [Date]- Storage arrangements: [Details]3. ayment Terms: The Exhiitor shall ay the Service rovider the total contract rice of [Amount] as follows:- Deosit ayment of [ercentage]% uon signing the Contract- rogress ayment of [ercentage]% uon comletion of farication- Final ayment of [ercentage]% uon successful installation of the stand4. Quality Assurance: The Service rovider guarantees that all work will e erformed to a high standard of quality and in accordance with industry est ractices. Any defects or errors must e reorted within [Numer] days of installation and will e corrected romtly y the Service rovider.5. Liaility and Insurance: The Service rovider shall maintain aroriate insurance coverage for all work erformed under this Contract. In case of damage or loss to third-arty roerty or individuals, the Service rovider assumes full liaility unless caused y the Exhiitor's negligence or willful misconduct.6. Intellectual roerty: All designs created for the exhiition stand remain the roerty of the Service rovider unless otherwise agreed in writing. The Exhiitor shall otain all necessary ermissions for any coyrighted or trademarked materials used in the design.7. Force Majeure: Neither arty shall e liale for delays or failure to erform due to events eyond their reasonale control, including ut not limited to acts of God, war, strikes, or other force majeure events.8. Governing Law and Disute Resolution: This Contract shall e governed y and construed in accordance with the laws of [Jurisdiction]. Any disutes arising out of or related to this Contract shall first e attemted to e resolved through negotiation. If unresolved, the arties agree to sumit the disute to mediation, failing which they may ursue legal action in the courts of [Jurisdiction].9. Termination: Either arty may terminate this Contract in the event of material reach y the other arty if such reach remains uncorrected after written notice has een given.10. Entire Agreement: This Contract constitutes the entire agreement etween the arties and suersedes all rior negotiations, understandings, and agreements, whether oral or written. No amendment, modification, or waiver of any rovision of this Contract shall e effective unless in writing and signed y oth arties.IN WITNESS WHEREOF, the arties have executed this Contract as of the date first aove written.[Exhiitor's Comany Name]y: [Name], [Title]rinted Name: _____________________Signature: _____________________Date: _____________________ [Service rovider's Comany Name] y: [Name], [Title]rinted Name: _____________________ Signature: _____________________ Date: _____________________。
展会合同模板英文版
展会合同模板英文版Exhibition Contract Template。
An exhibition contract is a legally binding agreement between the organizer of an exhibition and the participating exhibitor. It outlines the terms and conditions of the exhibition, including the booth rental, payment terms, and the rights and responsibilities of both parties. This article will provide a comprehensive overview of an exhibition contract template in English.1. Parties to the Contract。
The exhibition contract should clearly identify the parties involved in the agreement. This includes the name and contact information of the exhibition organizer and the participating exhibitor. It is important to accurately identify the legal entities of both parties to ensure that the contract is enforceable.2. Exhibition Details。
The contract should include detailed information about the exhibition, including the name, date, and location of the event. It should also specify the type of exhibition, such as a trade show, consumer exhibition, or industry-specific event. Additionally, the contract should outline the specific booth or exhibition space that is being rented by the exhibitor.3. Booth Rental and Payment Terms。
建筑合同范本 英语
建筑合同范本英语Construction Contract TemplateThis construction contract (the "Contract") is made and entered into on [date] between [Party A's name] (the "Owner") and [Party B's name] (the "Contractor").1. Project DescriptionThe Contractor agrees to undertake the construction project described as [project detls] (the "Project") at the location specified as [project location].2. Project TimelineThe Project is expected to mence on [start date] and be pleted [pletion date], subject to any extensions agreed upon in writing both parties.3. Contract PriceThe total contract price for the Project is [amount in figures] and [amount in words] (the "Contract Price"). This price includes all materials, labor, equipment, and other costs associated with the pletion of the Project.4. Payment TermsThe Owner will make payments to the Contractor as follows:[Percentage or amount] upon signing of this Contract.[Percentage or amount] upon reaching certn milestones as defined in the Contract.The remning balance upon satisfactory pletion and acceptance of the Project.5. Workmanship and MaterialsThe Contractor shall perform the work in a professional and workmanlike manner and shall use materials of good quality that conform to the specifications and standards set forth in this Contract.6. Changes and AmendmentsAny changes or amendments to the scope of work, specifications, or Contract Price must be made in writing and signed both parties.7. WarrantyThe Contractor warrants that the work performed under this Contract will be free from defects in workmanship and materials for a period of [warranty period] from the date of pletion.8. TerminationEither party may terminate this Contract in the event of a material breach the other party, provided that written notice of the breach and an opportunity to cure are given.9. Dispute ResolutionIn the event of a dispute arising out of or in connection with this Contract, the parties shall attempt to resolve the dispute through amicable negotiation. If negotiation fls, the dispute shall be submitted to arbitration in accordance with the rules of [arbitration institution].10. Governing LawThis Contract shall be governed and construed in accordance with the laws of [jurisdiction].This Contract constitutes the entire agreement between the parties and supersedes all prior negotiations, understandings, and agreements.IN WITNESS WHEREOF, the parties have executed this Contract as of the date first above written.Party A (Owner): [Owner's Name and Signature]Party B (Contractor): [Contractor's Name and Signature]Date: [Date of Execution]。
展览工程搭建英文版合同
展览工程搭建英文版合同合同编号：[填写合同编号]日期：[填写日期]甲方（承包商）：[填写承包商名称]乙方（客户）：[填写客户名称]鉴于甲方是一家专业从事展览工程设计与搭建的公司，而乙方意欲委托甲方为其即将举办的展览会设计和搭建展位，双方本着平等自愿的原则，经过友好协商，达成如下合同条款：第一条工程描述1.1 展位位置：[详细描述]1.2 展位面积：[具体数值]平方米1.3 设计要求：[详细描述设计风格、功能区划分等]1.4 材料规格：[列出主要材料及规格]1.5 技术标准：[明确技术执行标准]第二条工期与交付2.1 工程开工日期：[具体日期]2.2 工程竣工日期：[具体日期]2.3 延期条款：[说明延期责任及后果]第三条费用与支付3.1 合同总价：[金额]美元3.2 预付款：[百分比]%的预付款在合同签订后[天数]天内支付3.3 进度款：根据工程进度分阶段支付3.4 尾款：在工程验收合格后[天数]天内支付剩余款项第四条质量保证4.1 质量标准：[明确质量标准及验收条件]4.2 保修期：[时间范围]4.3 保修内容：[详细列出保修范围及服务]第五条变更与调整5.1 变更程序：[说明变更流程及需双方同意的条件]5.2 成本调整：[变更导致的成本变动处理方式]第六条法律责任与争议解决6.1 违约责任：[明确双方违约的法律后果]6.2 争议解决：[首选协商解决，其次可提交至仲裁机构或法院] 第七条其他事项7.1 保密协议：[双方对信息的保密义务]7.2 知识产权：[关于设计稿及图纸的权利归属]7.3 附加条款：[如有特殊情况，可增加附加条款]第八条合同生效与签署8.1 本合同自双方授权代表签字盖章之日起生效。
8.2 本合同一式两份，甲乙双方各执一份，具有同等法律效力。
甲方代表（签字）：__________ 日期：____年__月__日乙方代表（签字）：__________ 日期：____年__月__日。
展会搭建合同书
展会搭建合同书英文回答：Exhibition Stand Construction Contract。
This contract is entered into between [Company Name] ("Contractor") and [Client Name] ("Client") on [Date].1. Scope of Work。
The Contractor agrees to design, build, and dismantle an exhibition stand for the Client at [Exhibition Name], which will take place at [Venue Name] from [Start Date] to [End Date]. The exhibition stand shall be constructed in accordance with the plans and specifications provided by the Client.2. Design and Construction。
The Contractor shall be responsible for all aspects ofthe stand's design and construction, including:Creating a detailed design plan that meets theClient's requirements。
Sourcing and purchasing all necessary materials and equipment。
Constructing the stand in a professional and timely manner。
展会英文合同范本
展会英文合同范本甲方（参展方）：_____________乙方（主办方）：_____________鉴于甲方希望参加由乙方组织的展会，乙方同意为甲方提供相应的展位和相关服务，双方本着平等、自愿、公平和诚实信用的原则，经协商一致，订立本合同，共同遵守。
第一条展会信息1. 展会名称：_____________________2. 展会时间：_____________________3. 展会地点：_____________________4. 展会主题：_____________________5. 展会规模：_____________________6. 展会内容：_____________________第二条展位信息1. 展位编号：_____________________2. 展位面积：_____________________3. 展位位置：_____________________4. 展位费用：_____________________5. 展位布置：甲方负责展位的内部布置，乙方提供基本的展位设施。
第三条费用支付1. 甲方应于本合同签订之日起____天内支付展位费用的____%作为定金。
2. 余款应在展会开始前____天内支付完毕。
3. 甲方逾期支付的，应按日支付未付款项____%的违约金。
第四条甲方权利与义务1. 甲方有权在展会期间使用其展位进行产品展示和商业洽谈。
2. 甲方应遵守展会规则，不得从事违法活动。
3. 甲方应按时支付合同约定的费用。
4. 甲方应自行负责展位的保险事宜。
第五条乙方权利与义务1. 乙方负责展会的组织和管理工作。
2. 乙方应提供合同约定的展位及相关服务。
3. 乙方应保证展会的正常进行。
4. 乙方有权根据展会规则对甲方的行为进行监督和管理。
第六条合同变更和解除1. 合同一经签订，双方均不得擅自变更或解除。
2. 如遇不可抗力因素导致合同无法履行，双方应协商解决。
3. 一方严重违约，另一方有权解除合同，并要求违约方承担相应的违约责任。
展会合同模板英文
展会合同模板英文Exhibition Contract Template。
This Exhibition Contract (the "Contract") is entered into as of [Date], by and between [Exhibitor Name] ("Exhibitor") and [Event Organizer Name] ("Organizer").1. Exhibition Space。
Exhibitor agrees to rent exhibition space at the [Event Name] (the "Event") to be held at [Venue Name] on [Event Dates]. The Organizer agrees to provide the Exhibitor with the designated exhibition space as outlined in the floor plan provided by the Organizer.2. Payment。
Exhibitor agrees to pay the Organizer the total rental fee of [Amount] for the exhibition space. Payment shall be made in full upon signing of this Contract. Failure to makepayment may result in the forfeiture of the exhibition space.3. Use of Space。
Exhibitor agrees to use the designated exhibition space solely for the purpose of exhibiting and promoting the products or services as outlined in the application for exhibition space. Exhibitor shall not sublet, assign, or share the exhibition space without the prior written consent of the Organizer.4. Set-Up and Breakdown。
展台搭建合同(中英文版)
THE CONTRACT FOR EXHIBITION STAGE PUTTING UP SERVICE展台搭建服务合同This contract is made on 2016/ / .该合同签订于2016年月日Parties to this contract are as follows:合同双方：Customer: (客户方:)Contractor: (合同方:)Customer agrees to sign this contract on the agreement that the contractor will go on and finish the following project (hereinafter referred to as “This Project” ):基于合同方将执行并完成下述所列项目（以下简称“项目”），客户方同意签订此项同意书。
After numerous friendly negotiations between the customer and the contractor, both agree on the fabrication cost of this project.经共同友情协商，客户方和合同方对该项目的制作费用已达成一致意见。
The contract was signed by the customer and the contractor, and the contract clauses of protocol of both sides are as follows:合同由客户方和合同方共同签署，双方合同条款为以下所述：Article 1条款1The obligations of both sides: In order to obtain the amount of money that article 2 stipulates.双方的义务：按条款2规定，合同所列的项目制造费用The contractor must construct the stage meticulously according to the design proposal approved in the course of bid of both sides, in charge of coordination work with exhibition sponsor, and make sure the stage can be used normally during this exhibition period. (Design proposal as an appendix of this contract.)合同方必须细致的按照双方同意的设计书的要求建造和搭建展台，负责和展会赞助商的协调工作，确保展台在展会举行期间正常使用。
展位制作合同书英文
展位制作合同书英文Exhibit Booth Production ContractThis Contract (hereinafter referred to as "the Contract") is made and entered into on [Insert Date], by and between [Insert Client's Name], hereinafter referred to as "Client," and [Insert Exhibit Booth Production Company's Name], hereinafter referred to as "Production Company."1. Scope of WorkThe Production Company agrees to provide the following services related to the production of an exhibit booth for the Client's participation in [Insert Event Name] to be held at [Insert Event Location] on [Insert Event Dates]:- Design and creation of the exhibit booth layout.- Fabrication and assembly of the booth structure.- Graphic design and production of visual elements.- Provision of necessary equipment and furnishings.- On-site installation and dismantling services.2. Contract PriceThe total cost for the services outlined in Section 1 is [Insert Total Contract Price]. This price includes all materials, labor, and equipment necessary for the completion of the project as specified.3. Payment TermsThe Client shall make payment to the Production Company as follows:- A deposit of [Insert Deposit Percentage]% of the total contract price upon signing of this contract.- [Insert Milestone Payment Details, if applicable].- The final payment of [Insert Remaining Balance Percentage]% upon completion and acceptance of the exhibit booth.4. Delivery and AcceptanceThe Production Company shall deliver the completed exhibit booth by [Insert Delivery Date]. The Client shall have [Insert Time Frame for Inspection] after delivery to inspect and accept the booth. Acceptance is contingent upon the booth meeting the specifications and requirements outlined in this contract.5. Warranties and RepresentationsThe Production Company warrants that all work will be performed in a professional manner and will meet industry standards for quality and safety. The Production Company represents and warrants that it has the right to use all materials and designs in the creation of the exhibit booth.6. Intellectual PropertyThe Client retains all intellectual property rights to the exhibit booth design and any associated materials. The Production Company agrees not to reproduce or distribute the design or materials without the express written consent of the Client.7. TerminationEither party may terminate this contract for cause uponwritten notice to the other party in the event of a material breach that is not cured within [Insert Cure Period] days of receipt of the notice.8. ConfidentialityBoth parties agree to keep all information related to this contract and the services provided confidential, except as required by law or with the express written consent of the other party.9. Governing LawThis contract shall be governed by and construed inaccordance with the laws of [Insert Governing Jurisdiction].10. Dispute ResolutionAny disputes arising out of or in connection with thiscontract shall be resolved through arbitration in accordance with the rules of [Insert Arbitration Institution].11. Entire AgreementThis contract constitutes the entire agreement between the parties and supersedes all prior negotiations, understandings, or agreements.12. AmendmentsThis contract may only be amended in writing and signed byboth parties.IN WITNESS WHEREOF, the parties have executed this contractas of the date first above written.[Insert Client's Name] [Insert Production Company's Name]By: \_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_ By:\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_[Authorized Signature] [Authorized Signature]Date: \_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_ Date: \_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_Please note that this is a template and should be reviewedand customized by a legal professional to ensure it meets the specific needs and legal requirements of the parties involved.。
建筑施工英文合同范本
建筑施工英文合同范本Construction ContractThis Construction Contract (the "Contract") is made and entered into as of [date] and between [Contractor's Name] (the "Contractor") and [Client's Name] (the "Client").1. Project DescriptionThe Contractor shall undertake the construction project described as follows: [Describe the project in detl, including location, scope, and specifications]2. Contract PriceThe total contract price for the pletion of the project is agreed to be [amount in figures] ($[amount in words]). This price includes all materials, labor, equipment, and other costs associated with the project, unless otherwise specified.3. Payment ScheduleThe Client shall make payments to the Contractor as follows:[Percentage or amount] upon the signing of this Contract.[Percentage or amount] upon the pletion of [specific milestone or stage].The remning balance upon the substantial pletion and acceptance of the project.4. Project TimelineThe Contractor shall mence work on or before [start date] and shall plete the project [pletion date], subject to extensions for causes beyond the Contractor's control as provided herein.5. Workmanship and MaterialsThe Contractor shall perform the work in a good and workmanlike manner and shall use materials of good quality that conform to the project specifications.6. Changes and AmendmentsAny changes or amendments to the scope of work, specifications, or contract price shall be made in writing and signed both parties.7. Inspection and AcceptanceThe Client shall have the right to inspect the work at reasonable intervals. The project shall be considered accepted upon the Client's written notice of acceptance or upon the expiration of [number of days] after substantial pletion without written notice of rejection.8. WarrantiesThe Contractor warrants that the work will be free from defects in materials and workmanship for a period of [warranty period] from the date of acceptance.9. Force MajeureNeither party shall be liable for delays or flures in performance caused events beyond their reasonable control, such as natural disasters, wars, or government actions.10. TerminationThis Contract may be terminated either party in the event of a material breach the other party, subject to prior written notice and an opportunity to cure.11. Dispute ResolutionAny disputes arising under this Contract shall be resolved through arbitration or litigation as mutually agreed the parties.12. Governing LawThis Contract shall be governed and construed in accordance with the laws of [jurisdiction].IN WITNESS WHEREOF, the parties have executed this Contract as of the date first above written.Contractor: [Contractor's Name]Signature: [Contractor's Signature]Date: [Date]Client: [Client's Name]Signature: [Client's Signature]Date: [Date]。
建筑合同范本英文版
建筑合同范本英文版Construction ContractThis Construction Contract (the "Contract") is made and entered into on [date] and between [Owner's Name] (the "Owner") and [Contractor's Name] (the "Contractor").1. Project DescriptionThe Contractor agrees to undertake the construction of [project name and description] located at [project location] for the Owner.2. Contract PriceThe total contract price for the pletion of the project is $[amount] (in words: [written amount]). This price includes all labor, materials, equipment, and other costs associated with the project.3. Payment ScheduleThe Owner shall make payments to the Contractor as follows:[Percentage or amount] upon signing of this contract.[Percentage or amount] upon pletion of [milestone or stage].The remning balance upon satisfactory pletion and acceptance of the project.4. Project TimelineThe Contractor shall mence work on [start date] and plete the project [pletion date], subject to any extensions agreed upon in writing the Owner.5. Workmanship and MaterialsThe Contractor shall perform the work in a professional and workmanlike manner and shall use materials of good quality and in accordance with industry standards.6. Changes and AmendmentsAny changes or amendments to the scope of work or contract terms shall be made in writing and signed both parties.7. Inspection and AcceptanceThe Owner shall have the right to inspect the work at various stages. The project shall be deemed accepted upon the Owner's written confirmation of satisfaction.8. WarrantiesThe Contractor warrants that the work will be free from defects in workmanship and materials for a period of [warranty period] after acceptance.9. Dispute ResolutionIn the event of a dispute, the parties shall attempt to resolve the matter through amicable negotiation. If unsuccessful, the dispute shall be submitted to arbitration in accordance with the rules of [arbitration institution].10. TerminationThis contract may be terminated either party in the event of a material breach of its terms and conditions.11. Entire AgreementThis Contract constitutes the entire agreement between the parties and supersedes all prior negotiations and understandings.IN WITNESS WHEREOF, the parties have executed this Contract as of the date first above written.Owner's Signature: [Owner's Name]Contractor's Signature: [Contractor's Name]。
展台搭建英文合同模板
展台搭建英文合同模板This Exhibition Stand Construction Contract (the "Contract") is entered into and made effective as of [Date], by and between [Exhibitor Name], with a mailing address of [Exhibitor Address] (the "Exhibitor"), and [Contractor Name], with a mailing address of [Contractor Address] (the "Contractor").1. Scope of Work1.1 The Contractor agrees to design, fabricate, deliver, install, and dismantle an exhibition stand for the Exhibitor at the [Name of Exhibition] on [Dates of Exhibition]. The stand shall include [Description of Stand Features].1.2 The Contractor shall provide a detailed design plan for the exhibition stand for approval by the Exhibitor prior to fabrication. Any changes to the design plan after approval may result in additional costs for the Exhibitor.1.3 The Contractor shall ensure that the exhibition stand complies with all safety regulations and requirements of the exhibition venue.2. Payment2.1 The total fee for the exhibition stand construction is [Total Amount]. A deposit of [Deposit Amount] is due upon signing of this Contract, with the remaining balance due upon completion of the stand installation.2.2 The Contractor shall provide the Exhibitor with an itemized invoice for all costs associated with the exhibition stand construction. Any additional costs incurred during the construction process shall be approved in writing by the Exhibitor before being added to the invoice.2.3 Late payments shall be subject to a penalty of [Penalty Percentage] per month until paid in full.3. Delivery and Installation3.1 The Contractor shall deliver the exhibition stand to the exhibition venue on [Delivery Date] and complete the installation by [Installation Date]. The Contractor shall coordinate with the exhibition venue for any necessary permits or approvals for the installation.3.2 The Exhibitor shall be responsible for providing access to the exhibition venue for the Contractor and ensuring that all necessary equipment and utilities are available for the installation of the exhibition stand.4. Dismantling and Removal4.1 The Contractor shall dismantle the exhibition stand and remove all materials from the exhibition venue within [Number of Days] days following the conclusion of the exhibition.4.2 The Contractor shall ensure that all materials are properly disposed of or recycled in compliance with local regulations.5. Intellectual Property Rights5.1 The design plans and all intellectual property rights associated with the exhibition stand shall remain the property of the Contractor. The Exhibitor shall not use the design plans or reproduce the exhibition stand without the written consent of the Contractor.6. Limitation of Liability6.1 The Contractor shall not be liable for any damages or losses incurred by the Exhibitor asa result of delays or changes to the exhibition stand construction beyond the Contractor's control.7. Termination7.1 Either party may terminate this Contract with written notice if the other party fails to perform its obligations under the Contract. In the event of termination, the terminating party shall be entitled to a refund of any amounts paid for services not rendered.8. Governing Law8.1 This Contract shall be governed by the laws of [State/Country], without regard to its conflict of laws principles.IN WITNESS WHEREOF, the parties hereto have executed this Contract as of the date first above written.[Exhibitor Name]By: _______________________________Name: _____________________________Title: ______________________________[Contractor Name]By: _______________________________Name: _____________________________Title: ______________________________This Contract is hereby accepted and approved:Exhibition OrganizerBy: _______________________________Name: _____________________________ Title: ______________________________。
建筑合同范本 英语
建筑合同范本英语Construction Contract TemplateThis construction contract (the "Contract") is made and entered into on [date] between [Party A's name] (hereinafter referred to as "Party A") and [Party B's name] (hereinafter referred to as "Party B").1. Project DescriptionParty A intends to undertake a construction project at [project location], and Party B agrees to undertake the construction work in accordance with the requirements and specifications provided Party A.2. Work Scope and SpecificationsThe scope of work includes but is not limited to [list the mn tasks and activities]. The construction work shall ply with the applicable industry standards and the specific requirements as detled in the attached plans and specifications.3. Project TimelineThe construction project is expected to mence on [start date] and be pleted [pletion date]. Any delays in the project schedule due to reasons attributable to Party B may result in penalties as stipulated in this Contract.4. Project Cost and Payment TermsThe total cost of the project is agreed upon as [total amount]. Party A shall make payments to Party B in the following manner: [Describe the payment schedule and conditions, including milestones and retnage if applicable].5. Quality Assurance and InspectionParty B shall ensure that the construction work meets the quality standards specified. Party A or its authorized representatives shall have the right to inspect the progress and quality of the work at reasonable intervals.6. Change OrdersAny changes to the scope of work, specifications, or project timeline shall be made through a written change order signed both parties. The cost and schedule implications of such changes shall be mutually agreed upon.7. Warranties and LiabilitiesParty B warrants that the pleted project will be free from defects in materials and workmanship for a period of [warranty period] after pletion. In the event of any defects or non-pliance during the warranty period, Party B shall rectify the issues at its own expense.8. Termination and Dispute ResolutionThis Contract may be terminated either party in the event of a material breach of its terms and conditions. In the case of any disputes arising from this Contract, the parties shall attempt to resolve the matter through amicable negotiation. If negotiation fls, the dispute shall be submitted to arbitration or litigation as mutually agreed.9. Governing Law and JurisdictionThis Contract shall be governed and construed in accordance with the laws of [applicable jurisdiction]. Any legal actions related to this Contract shall be brought in the courts of [designated jurisdiction].This Contract constitutes the entire agreement between the parties and supersedes all prior negotiations and understandings. By signing below, both parties indicate their acceptance and mitment to the terms and conditions herein.Party A: [Signature and Name]Party B: [Signature and Name]Date: [date]Please note that the above is a basic template and should be customized and reviewed legal professionals to meet the specific needs and circumstances of each construction project.。
展览合同范本英文
展览合同范本英文Exhibition ContractThis Exhibition Contract (the "Contract") is made and entered into as of [date] by and between the following parties:Party A: [Name of Party A]Address: [Address of Party A]Party B: [Name of Party B]Address: [Address of Party B]WHEREAS, Party A desires to exhibit certain items at the exhibition organized by Party B; andWHEREAS, Party B agrees to provide the necessary facilities and services for the exhibition.NOW, THEREFORE, in consideration of the mutual covenants and agreements hereinafter set forth, the parties hereto agree as follows:1. Exhibition DetailsThe exhibition shall be held at [location of exhibition] from [start date] to [end date]. Party A shall be entitled to exhibit [description of items to be exhibited].2. Obligations of Party A(a) Party A shall deliver the items for exhibition to the designated location by [specified date].(b) Party A shall ensure the proper display and maintenance of the exhibited items during the exhibition period.(c) Party A shall comply with all rules and regulations of the exhibition.3. Obligations of Party B(a) Party B shall provide the exhibition space and necessary facilities as agreed.(b) Party B shall ensure the security and safety of the exhibition area.(c) Party B shall promote and publicize the exhibition as appropriate.4. Fees and Payments(a) Party A shall pay to Party B the exhibition fee of [amount] by [payment due date].(b) Any additional expenses incurred by Party A during the exhibition shall be borne by Party A.5. Insurance(a) Party A is responsible for insuring the exhibited items against loss or damage.(b) Party B shall maintain appropriate insurance coverage for the exhibition area.6. TerminationIn the event of a material breach of this Contract by either party, the non-breaching party may terminate this Contract upon written notice.7. Liability and Indemnification(a) Party A shall indemnify Party B against any claims, damages, or losses arising out of Party A's participation in the exhibition.(b) Party B shall not be liable for any indirect, consequential, or special damages.8. ConfidentialityThe parties agree to keep all information related to the exhibition confidential.9. Governing Law and JurisdictionThis Contract shall be governed by and construed in accordance with the laws of [applicable law]. Any disputes arising under this Contract shall be resolved in the courts of [jurisdiction].10. Miscellaneous(a) This Contract constitutes the entire agreement between the parties and supersedes all prior agreements and understandings.(b) Any amendments to this Contract must be in writing and signed by both parties.IN WITNESS WHEREOF, the parties have signed this Contract as of the date first written above.Party A: [Signature of Party A]Party B: [Signature of Party B]。
建筑合同范本 英语
建筑合同范本英语Construction Contract TemplateThis Construction Contract ("Contract") is made and entered into on [date] between [Party A's Name] ("Party A") and [Party B's Name] ("Party B").1. Project DescriptionThe project ("Project") consists of the construction of [describe the project in detl, including location, type of building, and scope of work].2. Contract Price and Payment TermsThe total contract price for the Project is [amount in figures and words]. Party A shall make payments to Party B as follows: [detl the payment schedule and methods, including any milestones or progress payments].3. Project TimelineThe Project is expected to be pleted [pletion date]. The schedule for various stages of the Project is as follows: [list the key milestones and their respective deadlines].4. Workmanship and MaterialsParty B shall perform the construction work in a professional and workmanlike manner and shall use materials of good quality and in accordance with the specifications and standards agreed upon.5. Changes and AmendmentsAny changes or amendments to the scope of work, design, or other aspects of the Project shall be mutually agreed upon in writing both parties and may result in adjustments to the contract price and timeline.6. Inspection and AcceptanceParty A shall have the right to inspect the progress and quality of the work at reasonable intervals. Upon pletion of the Project, Party A shall conduct a final inspection and acceptance. If the Project meets the agreed-upon standards and requirements, Party A shall provide written acceptance.7. Warranties and LiabilitiesParty B warrants that the work performed and the materials used shall be free from defects for a period of [warranty period]. In the event of any defects or deficiencies during the warranty period, Party B shall rectify them at no additional cost to Party A.8. Force MajeureNeither party shall be liable for any delay or flure in performance of this Contract due to causes beyond their reasonable control, such as natural disasters, war, or government actions.9. Dispute ResolutionIn the event of any dispute arising out of or in connection with this Contract, the parties shall attempt to resolve it through friendly negotiation. If negotiation fls, the dispute shall be submitted to arbitration or litigation in accordance with the laws and jurisdiction applicable.10. TerminationThis Contract may be terminated mutual agreement or in accordance with the terms and conditions specified herein.This Contract constitutes the entire agreement between the parties and supersedes all prior negotiations and understandings.[Party A's Signature and Date][Party B's Signature and Date]。
参展英文合同范本
参展英文合同范本Exhibition Participation ContractThis Exhibition Participation Contract (the "Contract") is made and entered into as of [date] (the "Effective Date") and between:Exhibitor:Name: [Exhibitor's Name]Address: [Exhibitor's Address]Contact Person: [Contact Person's Name]Contact Information: [Telephone Number/E Address]Organizer:Name: [Organizer's Name]Address: [Organizer's Address]Contact Person: [Contact Person's Name]Contact Information: [Telephone Number/E Address]1. Exhibition Detls1.1 The exhibition is end [Exhibition Name] and will be held at [Venue Address] from [Start Date] to [End Date].1.2 The exhibition hours will be from [Opening Time] to [Closing Time] each day.2. Exhibition Space2.1 The Organizer agrees to provide the Exhibitor with the exhibition space described as [Space Description] (the "Exhibition Space") at the exhibition venue.2.2 The Exhibitor shall use the Exhibition Space only for the purpose of exhibiting and promoting the products or services specified in this Contract.3. Exhibition Fee3.1 The Exhibitor agrees to pay the Organizer an exhibition fee of [Fee Amount] (the "Exhibition Fee") within [Payment Deadline] after the execution of this Contract.3.2 The Exhibition Fee is non-refundable except as otherwise provided in this Contract.4. Exhibitor's Obligations4.1 The Exhibitor shall set up and decorate the Exhibition Space in accordance with the Organizer's requirements and the exhibition regulations.4.2 The Exhibitor shall ensure that the exhibited products or services ply with all applicable laws, regulations, and standards.4.3 The Exhibitor shall staff the Exhibition Space during the exhibition hours and provide professional and courteous service to visitors.4.4 The Exhibitor shall not sublet or transfer the Exhibition Space to any third party without the prior written consent of the Organizer.5. Organizer's Obligations5.1 The Organizer shall provide the Exhibitor with the Exhibition Space in a condition suitable for exhibition.5.2 The Organizer shall make reasonable efforts to promote the exhibition and attract visitors.5.3 The Organizer shall provide necessary security and facilities during the exhibition period.6. Insurance6.1 The Exhibitor is responsible for obtning insurance coverage for its exhibits, personnel, and equipment during the exhibition period.6.2 The Organizer shall not be liable for any loss or damage to the Exhibitor's property or any injury to the Exhibitor's personnel except for cases of gross negligence or willful misconduct on the part of the Organizer.7. Intellectual Property7.1 The Exhibitor warrants that it has the right to exhibit and promote the products or services displayed at the exhibition and that such exhibition does not infringe the intellectual property rights of any third party.7.2 The Exhibitor shall indemnify and hold the Organizer harmless from any clms or liabilities arising from any infringement of intellectual property rights.8. Cancellation and Termination8.1 If the Exhibitor fls to pay the Exhibition Fee within the specified period, the Organizer has the right to cancel this Contract and reallocate the Exhibition Space.8.2 Either party may terminate this Contract in the event of a material breach the other party, provided that written notice of the breach and the intention to terminate is given and the breaching party fls to remedy the breach within a reasonable period of time.9. Force MajeureNeither party shall be liable for any flure or delay in performing its obligations under this Contract due to force majeure events, such as natural disasters, wars, strikes, or government actions, provided that the affected party promptly notifies the other party of the force majeure event and makes reasonable efforts to resume performance as soon as possible.10. ConfidentialityBoth parties agree to keep confidential all information related to this Contract and the exhibition that is not publicly avlable.11. Dispute ResolutionAny dispute arising out of or in connection with this Contract shall be resolved through friendly negotiation. If the negotiation fls, the dispute shall be submitted to arbitration in accordance with the rules of [Arbitration Institution]. The arbitration award shall be final and binding on both parties.12. Governing LawThis Contract shall be governed and construed in accordance with the laws of [Jurisdiction].13. Entire AgreementThis Contract constitutes the entire agreement between the parties with respect to the subject matter hereof and supersedes all prior negotiations, understandings, and agreements.IN WITNESS WHEREOF, the parties have executed this Contract as of the Effective Date.Exhibitor: [Exhibitor's Signature]Name: [Exhibitor's Name] Date: [Date]Organizer: [Organizer's Signature] Name: [Organizer's Name] Date: [Date]。
参展英文合同范本
参展英文合同范本Exhibition Participation ContractThis Exhibition Participation Contract (the "Contract") is made and entered into and between [Organizer's Name] (the "Organizer") and [Exhibitor's Name] (the "Exhibitor") on [date of contract].1. Exhibition DetlsThe exhibition will be held at [location of exhibition] from [start date] to [end date].2. Obligations of the ExhibitorThe Exhibitor agrees to:Pay the exhibition fee in accordance with the terms and amounts specified.Set up and mntn its exhibition booth in a professional and presentable manner.Comply with all rules and regulations of the exhibition.3. Obligations of the OrganizerThe Organizer agrees to:Provide the Exhibitor with the allocated exhibition space as agreed.Ensure proper management and organization of the exhibition.4. Intellectual Property RightsThe Exhibitor warrants that it has the legal rights to display and promote the products or services at the exhibition.5. TerminationEither party may terminate this Contract in the event of a material breach the other party, subject to prior written notice.6. LiabilityNeither party shall be liable for indirect, incidental, or consequential damages.7. Dispute ResolutionAny disputes arising from this Contract shall be resolved through negotiation. If negotiation fls, the dispute shall be submitted to arbitration in accordance with the applicable laws.8. MiscellaneousThis Contract constitutes the entire agreement between the parties and supersedes all prior agreements and understandings.IN WITNESS WHEREOF, the parties have executed this Contract as of the date first written above.[Organizer's Signature] [Organizer's Name][Exhibitor's Signature] [Exhibitor's Name]Please note that this is a basic template and may need to be customized and adapted according to the specific circumstances and requirements of your exhibition. It is advisable to consult with a legal professional to ensure the contract is prehensive and enforceable.。
英文展会合同模板
英文展会合同模板这是小编精心编写的合同文档，其中清晰明确的阐述了合同的各项重要内容与条款，请基于您自己的需求，在此基础上再修改以得到最终合同版本，谢谢！标题：英文展会合同模板Contract for Exhibition ServicesThis Contract (the "Contract") is made and entered into as of [Date], by and between [Your Company Name] (the "Organizer") and [Exhibitor's Company Name] (the "Exhibitor").1. Exhibition DetailsThe Exhibitor agrees to participate in the [Exhibition Name] (the "Event"), organized by the Organizer, which will be held at [Venue] on [Date].2. Booth Space AllocationThe Organizer shall allocate a booth space to the Exhibitor, as per the following specifications:- Booth Number: [Booth Number]- Size: [Size of Booth]- Location: [Location within the Venue]3. Fees and PaymentThe Exhibitor agrees to pay the Organizer the total exhibition fee of [Currency and Amount] ("Exhibition Fee") as follows:- [Percentage] upon signing this Contract- [Percentage] on or before [Date]- [Percentage] on or before [Date]Payment shall be made by bank transfer to the Organizer's designated account.4. Exhibitor's ObligationsThe Exhibitor shall:- Set up and dismantle their booth in a timely and safe manner, in accordance with the Organizer's guidelines.- Ensure that all exhibits and promotional materials comply with local regulations and do not infringe on any third-party rights.- Obtain necessary permits and licenses for their activities during the Event.- Staff the booth with knowledgeable and professional representatives throughout the Event's opening hours.5. Organizer's ObligationsThe Organizer shall:- Provide the allocated booth space, as specified in Clause 2.- Promote the Event and attract visitors, but does not guarantee a specific number of attendees.- Provide basic utilities such as electricity, water, and waste disposal, as per the Venue's standard services.6. Cancellation and Refund PolicyIn the event of cancellation by the Exhibitor, the following terms apply: - Cancellation before [Date], a full refund will be provided, minus a [Percentage] administrative fee.- Cancellation between [Date] and [Date], a [Percentage] refund will be provided.- Cancellation after [Date], no refund will be provided.7. IndemnificationThe Exhibitor agrees to indemnify and hold harmless the Organizer, its employees, agents, and affiliates, against any claims, losses, or damages arising out of or in connection with the Exhibitor's participation in the Event.8. Governing Law and Dispute ResolutionThis Contract shall be governed by and construed in accordance with the laws of [Country]. Any disputes arising out of or in connection with this Contract shall be resolved by arbitration in [City], in accordance with the rules of the [Arbitration Institution].9. Entire AgreementThis Contract constitutes the entire agreement between the Parties and supersedes all prior discussions, negotiations, and understandings, whether written or oral.By signing below, both Parties acknowledge and agree to the terms andconditions set forth in this Contract. Organizer:[Your Company Name]By: ___________________________ Name:Title:Date:Exhibitor:[Exhibitor's Company Name]By: ___________________________ Name:Title:Date:。
- 1、下载文档前请自行甄别文档内容的完整性，平台不提供额外的编辑、内容补充、找答案等附加服务。
- 2、"仅部分预览"的文档,不可在线预览部分如存在完整性等问题,可反馈申请退款(可完整预览的文档不适用该条件!)。
- 3、如文档侵犯您的权益，请联系客服反馈,我们会尽快为您处理(人工客服工作时间：9:00-18:30)。
The construction contract of special boothContract Number: 20150402Place: Shanghai Pudong New AreaDate: April 2, 2015 Party A:(hereinafter referred to as Party A)Contact:Tel:Fax:Cell phone:Party B: (hereinafter referred to as Party B) Contact:Tel:Fax:Cell phone:Accordance with the "People's Republic of China Contract Law" and the relevant laws and regulations, combined with construction features of special booth, both parties based in equality, voluntariness, consensus, for the "2015", the Shanghai New International Expo Center - (- ---------------------------) which the special booth planning, production, stand construction, decoration, stand dismantling works and services etc. reached the following agreements:I. Project OverviewProject Name:Project time:Location:Project Area:Project Progress:Party B shall begin stand construction work at 13:00 on June 25, 2015;Party B shall complete the stand construction work on June 27, 2015;Party B shall be responsible for dismantling work after the show closing on June 30, 2015 . II. Cost of the project:The total construction cost of the contracted project (including tax): ¥ (RMB ); Notes:1, charged exhibition space (Raw) management fee will be paid by the Party B, and the total cost above shall contain such fee.2, the electric box application and usage fees will be paid by the Party B, and the total cost above shall contain such fees.III. The project funds and payment date:Party A within three working days from signing the contract date shall pay the 70% contracted total cost ¥ (RMB ) as advance payment.When Party A accept the finished booth constructed by Party B, Party A will pay for the remaining 30% balance ¥ (RMB ) to Party B be in cash or bank transfer.After Party B receiving the balance, the full invoice shall be delivered to the Party A.Party B has the right to refuse to start the construction before receiving the prepayment. IV. The liability of Party A and Party BParty A’s responsibilities:1) fully pay to Party B on schedule;2) to provide standard files including LOGO vector files, pictures, inkjet and other image files (for AI format, vector file or other available formats) within the specified time.3) assist the Party B related coordination. (Eg: raw space management fee, apply and pay the electric box etc.)4) when stand construction completed, Party A shall cooperate with Party B to check and accept it and any doubt should be noted on the spot, or it will be considered acceptable. 5) from the booth setup to move-out, any damages of venues, space, facilities (such as electrical boxes, stadium floor, etc.) caused by Party A which shall take in charge of the compensation in accordance with the provisions of venues.6) shall go to the factory of Party B to check booth producing progress and quality.Party B's responsibilities:1) party b is responsible for the preliminary design, factory production, the production of art (not including photo, prints and other graphic image design), material transportation, field construction, electrical installation and exhibition move-in;2) to ensure the safety of the construction, security problems in the process of construction, or any improper construction safety problems should be undertaken by party b;3) the booth maintenance and cleaning work during the show;4) to ensure the engineering quality and engineering construction progress, if construction delay caused by party b, the overtime expenses shall be borne by party b and construction will be subject to confirmed by the party a's renderings. Renderings and quotation are attached.5) from the booth setup to move-out, any damages of venues, space, facilities (such as electrical boxes, stadium floor, etc.) caused by Party B which shall take in charge of the compensation in accordance with the provisions of venues.V. design changeDuring the period of construction, the design change will be processed in the following way: The written file of the change of original design should be send to Party B at least 15 days before booth settlement.Regarding the change, both parties should negotiate and carry on the construction plan by the written final design, otherwise party B shall have the right to refuse to change.As a result of the change, the added expenditure and the already cost according to the original design scheme shall be borne by party A.VI. Negotiation for increasing the workIf party A request to increase quantity of work during engineering construction, the two sides can negotiate and sign “project negotiation records”.After signed by both sides’ responsible persons of the engineering, party A needs to pay the increased cost to party B then the added work can be incorporated into this contract andconstructed at the same time.VII. Problem solvingWhen there is a dispute between both parties, the specific project problems can be amicably settled through negotiation by both parties. If such negotiations fail, can sue to this contract signed place Shanghai pudong new area people's court for disputes resolution.1. After signing the contract, in addition to legal irresistible factors such as natural disasters, earthquakes, war, any party has no right to unilaterally terminate this contract, if any party cancel the contract unilaterally, it should compensate for the other party for 30% of the total contracted money.2. Due to party A or party B violates other clauses in the contract or other agreement, it shall born the corresponding legal responsibility and the related economic losses for the other party.VIII. The contract comes into force and termination1. Come into force as of the date of signing the contract;2. After party B finishing the engineering, party A accepting and paying off the total payment, the booth dismantling and completing the cleaning job, the contract will be terminated;3. Other matters, both parties can sign compensatory agreement separately according to the specific situation;4. This contract is in duplicate, with equal legal effect, and both parties each hold one copy as fax and copy valid.Beneficiary Bank Name:Beneficiary Bank Address:Beneficiary Name:Payee Address:Beneficiary Bank account:Beneficiary Bank Code:Party A (Signature and stamp):Responsible person:Date:Party B (Signature and stamp):Responsible person:Date:微信：jaco8749013。