开发合同英文模版
英文技术开发合同6篇
![英文技术开发合同6篇](https://img.taocdn.com/s3/m/e17b1283ac51f01dc281e53a580216fc700a5326.png)
英文技术开发合同6篇篇1Technical Development AgreementThis Technical Development Agreement (the "Agreement") is entered into as of [Date], by and between [Company Name], having its principal place of business at [Address] (the "Company"), and [Developer Name], having its principal place of business at [Address] (the "Developer").BackgroundThe Company is engaged in the business of [Brief description of Company's business], and the Developer possesses certain technical expertise in [Brief description of Developer's technical expertise].The Company wishes to engage the Developer to provide technical development services as described herein, and the Developer wishes to provide such services under the terms and conditions set forth in this Agreement.Agreement1. Scope of Services. The Developer shall provide technical development services to the Company as requested by the Company from time to time. The services to be provided by the Developer may include, but are not limited to, [Description of services to be provided].2. Compensation. The Company shall compensate the Developer for the services provided under this Agreement at the rate of [Rate] per hour. The Developer shall submit invoices to the Company on a [Weekly/Monthly] basis for payment.3. Term. This Agreement shall commence on the date first written above and shall continue until terminated by either party upon [Number] days' written notice.4. Confidentiality. The Developer agrees to keep all information and materials provided by the Company confidential and not to disclose such information to any third party without the Company's prior written consent.5. Intellectual Property. Any intellectual property created by the Developer in connection with the services provided under this Agreement shall belong to the Company, and the Developer hereby assigns all rights, title, and interest in and to such intellectual property to the Company.6. Termination. Either party may terminate this Agreement at any time for any reason upon [Number] days' written notice. Upon termination, the Developer shall cease providing services to the Company, and the Company shall compensate the Developer for services rendered up to the date of termination.7. Governing Law. This Agreement shall be governed by and construed in accordance with the laws of the State of [State].In Witness Whereof, the parties hereto have executed this Agreement as of the date first written above.[Company Name]By: ___________________________ Name: Title:[Developer Name]By: ___________________________ Name: Title:This Agreement constitutes the entire agreement between the parties with respect to the subject matter hereof and supersedes all prior agreements and understandings, whether written or oral, relating to such subject matter. This Agreement may be amended only by a written instrument signed by both parties.IN WITNESS WHEREOF, the parties have executed this Agreement as of the date first written above.[Company Name]By: __________________________ Name: Title:[Developer Name]By: __________________________ Name: Title:篇2Technical Development AgreementThis Technical Development Agreement (the "Agreement") is entered into as of [Date] by and between [Company Name], a [Company Type] organized and existing under the laws of [Jurisdiction], with its principal office located at [Company Address] (hereinafter referred to as "Company") and [Developer Name], an individual residing at [Developer Address] (hereinafter referred to as "Developer").WHEREAS, Company desires to engage Developer for the development of certain technical products and services as further described in Exhibit A attached hereto (the "Project"); andWHEREAS, Developer has the necessary expertise and resources to undertake the development of the Project in accordance with Company's specifications;Now, therefore, in consideration of the premises and mutual covenants contained herein, the parties hereto agree as follows:1. Services. Developer shall perform the development services for the Project as described in Exhibit A in a professional and timely manner, using commercially reasonable efforts to meet the milestones and deadlines set forth therein.2. Compensation. In consideration for the services provided by Developer under this Agreement, Company shall pay Developer a total fee of [Total Fee]. Payment shall be made in installments as set forth in Exhibit B attached hereto.3. Ownership. All intellectual property rights, including but not limited to copyrights, patents, trademarks, and trade secrets, developed by Developer in the course of performing the services under this Agreement shall belong exclusively to Company. Developer hereby assigns to Company all rights, titles, and interests in and to such intellectual property rights.4. Confidentiality. Developer shall keep confidential all information related to the Project and shall not disclose suchinformation to any third parties without the prior written consent of Company. This confidentiality obligation shall survive the termination of this Agreement.5. Term and Termination. This Agreement shall commence on the effective date set forth above and shall continue until the completion of the Project unless terminated earlier by either party upon thirty (30) days' written notice. In the event of termination, Company shall pay Developer for the services performed up to the date of termination.6. Governing Law. This Agreement shall be governed by and construed in accordance with the laws of [Jurisdiction]. Any disputes arising out of or related to this Agreement shall be resolved through arbitration in [Arbitration Location] in accordance with the rules of the American Arbitration Association.7. Entire Agreement. This Agreement constitutes the entire agreement between the parties with respect to the subject matter hereof and supersedes all prior agreements, understandings, and negotiations, whether oral or written.IN WITNESS WHEREOF, the parties hereto have executed this Agreement as of the date first above written.[Company Name] [Developer Name]_________________________ _________________________Company Signature Developer SignatureExhibit A - Project DescriptionExhibit B - Payment ScheduleThis is a sample Technical Development Agreement for reference purposes only. It is recommended that you consult with legal professionals to draft a customized agreement that meets your specific needs and requirements.篇3Technology Development ContractThis Technology Development Contract (the "Contract") is made and entered into as of [Insert Date], (the "Effective Date") by and between [Company Name], a corporation organized and existing under the laws of the [state/country], with its principal place of business located at [Company Address] (the "Developer"), and [Company Name], a corporation organized and existing under the laws of the [state/country], with its principal place of business located at [Company Address] (the "Client").1. Scope of WorkThe Developer agrees to provide technical development services to the Client in accordance with the specifications set forth in the Statement of Work (the "SOW") attached hereto as Exhibit A. The SOW shall include a description of the services to be provided, the timeline for completion, and the compensation to be paid.2. PaymentIn consideration for the services provided by the Developer under this Contract, the Client agrees to pay the Developer a fee of [Insert Amount] (the "Fee"). Payment shall be made in [Insert Payment Terms], with [Insert Percentage] due upon signing of the Contract, [Insert Percentage] due upon delivery of the completed work, and the balance due upon final acceptance by the Client.3. Ownership of Work ProductAll work products created by the Developer under this Contract, including but not limited to software code, designs, and documentation, shall be the exclusive property of the Client. The Developer agrees to assign all rights, title, and interest in andto the work product to the Client upon completion of the services.4. ConfidentialityThe Developer agrees to keep confidential all information provided by the Client in connection with the services, including but not limited to proprietary information, trade secrets, and intellectual property. The Developer shall not disclose such information to any third party without the Client's prior written consent.5. Term and TerminationThis Contract shall commence on the Effective Date and shall continue until the services described in the SOW are completed. Either party may terminate this Contract upon written notice to the other party if the other party materially breaches any provision of the Contract and fails to cure such breach within [Insert Cure Period] days of receiving written notice.6. Independent ContractorThe Developer is an independent contractor and not an employee of the Client. The Developer shall have sole control over the manner and means by which the services are performed,provided that the work is completed in accordance with the specifications set forth in the SOW.7. Governing LawThis Contract shall be governed by and construed in accordance with the laws of the [state/country] without regard to conflicts of law principles. Any disputes arising out of or relating to this Contract shall be resolved by binding arbitration in accordance with the rules of the American Arbitration Association.IN WITNESS WHEREOF, the parties hereto have executed this Contract as of the Effective Date.[Signature Page Follows]IN WITNESS WHEREOF, the parties hereto have executed this Contract as of the Effective Date.Developer: [Developer Name]Client: [Client Name]By: _________________ By: __________________Name: Name:Title: Title:Date: Date:篇4Technical Development ContractThis Technical Development Contract (the "Contract") is entered into on this __________ day of __________, 20__, by and between _______________________ (the "Client") and_______________________ (the "Developer").1. Scope of WorkThe Developer agrees to provide technical development services to the Client for the project described as_______________________ (the "Project"). The scope of work includes but is not limited to:- Designing and developing software or applications according to Client's specifications.- Testing and debugging the software to ensure proper functionality.- Providing ongoing technical support and maintenance for the software post-launch.- Meeting all deadlines and milestones as outlined in the project plan.2. PaymentThe Client agrees to pay the Developer a total fee of$__________ for the completion of the Project. Payment will be made in installments as follows:- 25% upon signing of the Contract.- 25% upon completion of the design phase.- 25% upon completion of the development phase.- 25% upon final delivery and acceptance of the Project.Payment can be made via check, wire transfer, or credit card, as agreed upon by both parties.3. Intellectual Property RightsAll intellectual property rights, including but not limited to copyrights, patents, and trademarks, related to the software developed under this Contract shall belong to the Client. The Developer agrees to transfer all such rights to the Client upon completion of the Project.4. ConfidentialityBoth parties agree to keep all information exchanged during the course of the Project confidential. This includes but is notlimited to source code, design documents, and any other proprietary information related to the software.5. TerminationEither party may terminate this Contract with written notice if the other party breaches any of the terms outlined herein. In the event of termination, the Developer shall be entitled to payment for services rendered up to the date of termination.6. Governing LawThis Contract shall be governed by the laws of the state of __________. Any disputes arising under this Contract shall be resolved through arbitration in accordance with the rules of the American Arbitration Association.In witness whereof, the parties have executed this Contract as of the date first written above.___________________________Client Name___________________________Developer NameThis document constitutes the entire agreement between the Client and the Developer and supersedes any prior agreements or understandings, whether written or oral.篇5Technical Development AgreementThis Technical Development Agreement (“Agreement”) is entered into on this [insert date] by and between [Company Name], having its principal place of business at [insert address] (“Developer”) and [Client Name], having its principal place of business at [insert address] (“Client”).WHEREAS, Client desires to engage Developer to provide technical development services for the purpose of [insert description of project]; andWHEREAS, Developer is willing to perform such services for Client on the terms and conditions set forth herein.NOW, THEREFORE, in consideration of the mutual covenants and agreements contained herein, the parties agree as follows:1. Services. Developer shall provide technical development services for Client in accordance with the specifications outlined in Exhibit A attached hereto.2. Compensation. Client shall pay Developer a fee of [insert amount] for the services to be provided under this Agreement. Payment shall be made in [insert payment terms], as outlined in Exhibit B attached hereto.3. Term. This Agreement shall commence on [insert start date] and shall continue until the completion of the project or termination by either party.4. Confidentiality. Developer acknowledges that in the course of performing services for Client, Developer may have access to confidential information belonging to Client. Developer agrees to keep such information confidential and shall not disclose it to any third party without the prior written consent of Client.5. Ownership of Work Product. All work product created by Developer in connection with the services provided under this Agreement shall be the exclusive property of Client. Developer agrees to assign all rights, title, and interest in such work product to Client.6. Warranties. Developer warrants that the services provided under this Agreement shall be performed in a professional and workmanlike manner and shall conform to the specifications outlined in Exhibit A. Developer further warrants that it has theright to enter into this Agreement and that the services provided do not infringe upon the intellectual property rights of any third party.7. Indemnification. Developer shall indemnify and hold harmless Client from any claims, damages, losses, or expenses arising out of Developer's breach of this Agreement or negligence in the performance of its services.8. Termination. Either party may terminate this Agreement upon written notice if the other party materially breaches any provision of this Agreement and fails to cure such breach within [insert number] days of receiving written notice.9. General Provisions. This Agreement constitutes the entire understanding between the parties with respect to the subject matter hereof and supersedes all prior agreements and understandings, whether written or oral. This Agreement may not be amended except by written agreement signed by both parties.IN WITNESS WHEREOF, the parties have executed this Agreement as of the date first set forth above.[Developer Name][Client Name]Exhibit A: Project SpecificationsExhibit B: Payment Terms_______________________________[Signature] [Date]篇6Technical Development AgreementThis Technical Development Agreement ("Agreement") is entered into by and between [Company Name], a company organized and existing under the laws of [Country], having its principal place of business at [Address] ("Company"), and [Developer Name], an individual residing at [Address] ("Developer").1. Scope of ServicesDeveloper agrees to provide technical development services to Company. The services to be provided by Developer shall include but not be limited to designing, coding, testing, and implementing software solutions in accordance with Company's specifications. Developer shall perform the services in a timely and professional manner and in accordance with best industry practices.2. PaymentCompany agrees to pay Developer for the services rendered in accordance with the fee schedule attached as Schedule A to this Agreement. Payment shall be made [payment terms]. Developer shall invoice Company for the services rendered on a [payment frequency] basis.3. Ownership of Intellectual PropertyAny intellectual property developed by Developer in the course of providing the services under this Agreement shall be the exclusive property of Company. Developer hereby assigns to Company all right, title, and interest in and to any intellectual property developed herein.4. ConfidentialityDeveloper acknowledges that in the course of providing the services under this Agreement, Developer may have access to confidential information of Company, including but not limited to Company's proprietary software, technical data, and business strategies. Developer agrees to keep all confidential information confidential and not to disclose it to any third party without Company's prior written consent.5. Term and TerminationThis Agreement shall commence on [Commencement Date] and continue until [Termination Date], unless earlier terminated as provided herein. Either party may terminate this Agreement upon [notice period] written notice to the other party. Upon termination of this Agreement, Developer shall deliver to Company all materials and property belonging to Company and cease using Company's confidential information.6. IndemnificationDeveloper agrees to indemnify and hold harmless Company against all claims, damages, and liabilities arising out of Developer's breach of this Agreement or negligence in providing the services hereunder.7. Governing LawThis Agreement shall be governed by and construed in accordance with the laws of [Country]. Any dispute arising out of or in connection with this Agreement shall be resolved by arbitration in [City], [Country], in accordance with the rules of the [Arbitration Institution].IN WITNESS WHEREOF, the parties hereto have executed this Agreement as of the date first above written.[Company Name]By:Name:Title: [Developer Name] By:Name:。
软件开发合同 (中英文)
![软件开发合同 (中英文)](https://img.taocdn.com/s3/m/e77764926e1aff00bed5b9f3f90f76c661374cff.png)
软件开发合同 (中英文)软件开发合同 (Software Development Agreement)合同概述 (Contract Overview)本合同由以下各方于(填入合同签订日期)签署,《甲方公司》(以下简称"甲方"),位于(填入甲方地址),和《乙方公司》(以下简称"乙方"),位于(填入乙方地址)。
甲方和乙方一同称为"双方"。
软件开发工作 (Software Development Work)甲方要求乙方根据甲方的规格和要求开发一款软件(以下简称"软件")。
双方同意合作进行软件的开发工作,并达到以下目标:1. 定义软件的功能和特性。
2. 设计和开发软件的用户界面。
3. 编写和测试软件的代码。
4. 修复软件中的错误和漏洞。
交付时间表 (Delivery Schedule)1. 双方同意在合同签订后的(填入交付期限)内完成软件的开发工作,并按照以下交付时间表交付所需的里程碑:a. 第一阶段:(填入阶段详细描述),交付日期:(填入交付日期)。
b. 第二阶段:(填入阶段详细描述),交付日期:(填入交付日期)。
c. 第三阶段:(填入阶段详细描述),交付日期:(填入交付日期)。
2. 双方同意在每个交付日期之前进行进度评估,并及时沟通任何可能影响交付的问题。
付款条件 (Payment Terms)乙方同意按照以下付款条件收取服务费用:1. 在合同签订后的(填入支付条件期限)内,甲方将支付给乙方合同总金额的(填入百分比)作为预付款。
2. 在每个交付日期后的(填入支付条件期限)内,甲方将支付给乙方相应里程碑的(填入百分比)作为进度付款。
3. 在软件开发工作完成并经甲方验收后的(填入支付条件期限)内,甲方将支付给乙方剩余费用。
保密条款 (Confidentiality)双方同意在本合同期间和合同结束后保守对方提供的商业和技术信息的机密性,并仅在履行本合同目的的情况下使用该信息。
英文技术开发合同5篇
![英文技术开发合同5篇](https://img.taocdn.com/s3/m/2c8d532f00f69e3143323968011ca300a6c3f6b8.png)
英文技术开发合同5篇篇1Contract for Technical Development甲方(客户):__________________乙方(开发方):__________________签订日期:____________________一、合同背景及目的本合同由甲方和乙方共同签署,目的在于明确双方在技术开领域的合作关系及具体事务处理细节。
甲方委托乙方进行特定的技术开发工作,乙方同意接受委托并按照本合同的要求完成相关任务。
二、开发内容与技术要求1. 开发内容:具体描述开发的系统名称、功能及目标。
(例如:开发一套智能物流管理系统,实现货物追踪、数据分析及优化物流路径等功能。
)2. 技术要求:明确开发的软件应满足的技术标准和规范,包括但不限于系统稳定性、兼容性、安全性等方面的要求。
三、开发周期与进度安排1. 开发周期:自合同签订之日起至完成所有开发任务并交付验收的总时长。
2. 进度安排:详细列明开发各阶段的时间节点及主要任务,包括需求分析、设计、编码、测试等阶段的具体时间安排。
四、知识产权与保密条款1. 知识产权归属:明确开发成果的知识产权归属,是归属于甲方还是双方共同拥有。
如归属甲方,则乙方不得擅自将相关技术用于其他用途或转让给第三方。
2. 保密条款:双方应对在合作过程中获知的对方商业秘密和技术秘密承担保密义务,未经对方书面同意,不得向任何第三方泄露。
五、费用与支付方式1. 开发费用:详细列明本次技术开发的费用总额及构成,包括各个阶段的工作费用。
费用的确定应遵循公平合理原则。
2. 支付方式:约定支付的时间节点(如预付款、进度款、尾款等)及支付条件。
同时明确如发生变更时双方应如何调整费用。
六、验收与交付1. 验收标准:根据开发内容和技术要求制定详细的验收标准。
2. 交付物:明确开发完成后应交付的文档、软件等物品及其格式和存储方式。
七、风险承担与违约责任1. 风险承担:明确在开发过程中可能遇到的风险及责任承担方式,包括但不限于技术风险、市场风险及不可抗力等因素。
技术开发的英文合同5篇
![技术开发的英文合同5篇](https://img.taocdn.com/s3/m/fedcd2d9b8d528ea81c758f5f61fb7360b4c2ba5.png)
技术开发的英文合同5篇篇1TECHNOLOGY DEVELOPMENT CONTRACTContract No.: [Insert Contract Number]Date: [Insert Date]1. Scope of Work:The Developer agrees to undertake the development of [describe the technology to be developed in detail] (hereinafter referred to as the "Technology") for the Principal. The Technology shall be developed in accordance with the specifications and requirements provided by the Principal.2. Development Period:The period of development shall commence on [Start Date] and continue until [End Date], unless extended by mutual agreement in writing.3. Project Milestones:The Developer shall achieve the following milestones within the specified timeframes:* Milestone 1: [Describe milestone 1 with timeline]* Milestone 2: [Describe milestone 2 with timeline]* ... (as per the requirements of the project)4. Intellectual Property Rights:All intellectual property rights arising out of or in connection with the Technology shall be owned by the Principal. The Developer shall assign all such rights to the Principal upon completion of the project.5. Payments:The Principal shall pay the Developer the following fees for the development work:* Development Fee: [Amount]* Milestone Payments: [Describe milestone payments with amounts and conditions]* Any other fees or expenses: [Specify other fees/expenses, if any, with amounts]All payments shall be made within [specified timeframes] from the date of invoice.6. Confidentiality:Both parties shall maintain confidentiality of all information disclosed to each other during the course of this Contract. Neither party shall disclose any confidential information to third parties without the prior written consent of the other party.7. Warranty and Liability:The Developer shall ensure that the Technology developed is free from defects in material and workmanship for a period of [Warranty Period]. The Developer shall indemnify and hold harmless the Principal from any claims, losses, or damages arising out of any defects in the Technology.8. Termination:9. Force Majeure:Neither party shall be liable for any failure to perform its obligations due to events beyond its reasonable control, such as acts of war, riots, natural disasters, etc. The affected party shall notify the other party of such events and provide evidence to support its claim.10. General Terms:* This Contract constitutes the entire agreement between the parties and no modifications shall be made except by a written agreement signed by both parties.* The laws of [Country/State] shall apply to this Contract.* Any disputes arising out of or in connection with this Contract shall be settled through friendly negotiations. If no settlement is reached, the dispute shall be referred to [specify dispute resolution mechanism, e.g., arbitration].* This Contract shall be governed by and construed in accordance with the laws of [Country/State].* This Contract may be executed in [number of counterparts] counterparts, each of which shall be deemed an original and all of which shall constitute one and the same instrument.In witness whereof, the parties have executed this Contract on the dates indicated below.Developer:Principal:(Authorized Representative) (Authorized Representative)Date: Date:Place: Place:------------------------------------------------------------------------ 签名与印章应分别在上述打印日期下方占据指定空间位置的位置上对齐插入以加强正式感与合法性表达。
英文技术开发合同7篇
![英文技术开发合同7篇](https://img.taocdn.com/s3/m/4f9b1747a9114431b90d6c85ec3a87c240288aa4.png)
英文技术开发合同7篇篇1Development Contract for Technology in English甲方(委托方):____________________(Name of Client)地址:____________________(Address)联系方式:____________________(Contact Information)乙方(开发方):____________________(Name of Developer)地址:____________________(Address)联系方式:____________________(Contact Information)鉴于甲方需要对特定技术进行开发,而乙方具备相关技术开发的实力和经验,双方在平等、自愿、公平的基础上,经过友好协商,达成以下技术开发合同协议:一、合同目的和背景本合同旨在明确甲、乙双方在技术开发项目中的权利与义务,确保双方合作顺利进行,共同实现技术开发的成功。
二、开发内容和目标(详细说明开发项目的名称、内容、目标、预期成果等)三、开发时间和进度安排(明确开发项目的起始日期、预计完成日期、各个阶段的时间节点和主要任务等)四、知识产权归属1. 乙方在本合同期间所完成的技术成果及其知识产权归甲方所有。
2. 未经甲方书面同意,乙方不得将本合同约定的技术成果转让给第三方。
3. 双方共同保守本合同约定的技术秘密和商业秘密。
五、费用支付和结算方式1. 甲方应按照约定的时间和金额支付乙方的开发费用。
2. 开发费用包括研发费用、材料费、差旅费等,具体金额和支付方式由双方另行约定。
3. 若因甲方原因导致开发进度延误,甲方应相应调整支付时间。
六、质量保证和技术支持1. 乙方应保证开发的技术成果符合约定的质量要求。
2. 甲方在开发过程中遇到技术问题,乙方应提供必要的技术支持。
3. 乙方应确保所提供的技术成果不侵犯第三方的知识产权。
软件开发合同英文模板
![软件开发合同英文模板](https://img.taocdn.com/s3/m/8a35dc40876fb84ae45c3b3567ec102de2bddfc9.png)
Software Development AgreementThis Software Development Agreement Agreement is entered into as of Effective Date, by and between Client Name,a Clients Jurisdiction corporation with a principal place of business at Clients Address Client,and Developer Name,a Developers Jurisdiction corporation with a principal place of business at Developers Address Developer.1.Purpose of the AgreementThis Agreement sets forth the terms and conditions under which Developer agrees to develop and deliver the software product described in Exhibit A Software Product to Client.2.Scope of Work2.1Developer shall develop the Software Product in accordance with the specifications provided in Exhibit A Specifications.2.2Developer shall provide all necessary personnel,software,hardware,and other resources required to complete the development of the Software Product.2.3Client shall provide Developer with access to any necessary resources,information, and personnel to facilitate the development process.3.Development Schedule3.1Developer shall complete the development of the Software Product in accordance with the schedule set forth in Exhibit B Development Schedule.3.2Developer shall notify Client immediately if it becomes apparent that the Development Schedule will not be met,and Developer shall propose a revised schedule.4.Fees and Payment4.1Client shall pay Developer the total fees set forth in Exhibit C Fees for the development of the Software Product.4.2Fees shall be paid in installments as set forth in Exhibit C.4.3All payments shall be made in Currency.5.Intellectual Property Rights5.1Upon completion and acceptance of the Software Product,Developer hereby assigns and transfers to Client all right,title,and interest in and to the Software Product, including all intellectual property rights.5.2Developer represents and warrants that it has the right to grant the rights and licenses provided in this Agreement.6.Warranty and Maintenance6.1Developer warrants that the Software Product will perform in accordance with the Specifications for a period of Warranty Period from the date of acceptance.6.2Developer shall provide maintenance and support for the Software Product for a period of Maintenance Period from the date of acceptance.7.Confidentiality7.1Both parties agree to keep all information received from the other party during the term of this Agreement confidential.7.2Confidential information shall not be disclosed to any third party without the prior written consent of the disclosing party.8.Termination8.1Either party may terminate this Agreement upon Number days written notice if the other party breaches any material term or condition of this Agreement and fails to cure such breach within Number days after receipt of written notice.8.2Upon termination,Client shall pay Developer for all work completed as of the date of termination.erning LawThis Agreement shall be governed by and construed in accordance with the laws of the Governing Jurisdiction,excluding its conflict of law principles.10.Entire AgreementThis Agreement,including all Exhibits,constitutes the entire agreement between the parties and supersedes all prior negotiations,understandings,and agreements between the parties,whether written or oral.Exhibit A:Software Product SpecificationsDetailed description of the software product specificationsExhibit B:Development ScheduleDetailed development schedule including milestones and deadlinesExhibit C:Fees and Payment ScheduleBreakdown of fees and payment scheduleIN WITNESS WHEREOF,the parties have executed this Agreement as of the Effective Date.Client Name Developer NameBy:By:Authorized Signatory Authorized SignatoryTitle Title。
研发合同模板英文
![研发合同模板英文](https://img.taocdn.com/s3/m/eaf777692e60ddccda38376baf1ffc4ffe47e2a1.png)
研发合同模板英文Research and Development Contract Template。
A research and development (R&D) contract is a legal agreement between two parties, typically a company and a research institution, that outlines the terms and conditions of a research project. The purpose of the contract is to establish the scope of work, the responsibilities of each party, the payment terms, and the intellectual property rights associated with the research and development activities.This article provides a comprehensive overview of the key components of an R&D contract and offers a template that can be used as a starting point for drafting a customized agreement.1. Parties to the Contract。
The R&D contract should clearly identify the parties involved in the agreement. This includes the name and contact information of the company commissioning the research, as well as the name and contact information of the research institution or individual researcher responsible for carrying out the work.2. Scope of Work。
模具开发协议(中英文)6篇
![模具开发协议(中英文)6篇](https://img.taocdn.com/s3/m/f3ad4251773231126edb6f1aff00bed5b9f373ed.png)
模具开发协议(中英文)6篇篇1Mold Development AgreementThis Mold Development Agreement ("Agreement") is entered into by and between [Company A], with its principal place of business at [address], and [Company B], with its principal place of business at [address], on [date].1. Scope of WorkCompany A engages Company B to develop and manufacture molds for the production of [product] according to the specifications provided by Company A. Company B agrees to design, prototype, test, and manufacture the molds in accordance with industry standards and best practices.2. PaymentCompany A agrees to pay Company B a total of [amount] for the development and production of the molds. Payment shall be made in [number] installments as follows: [details of payment schedule]. Company A shall be responsible for all costs associated with shipping, handling, and customs duties.3. Intellectual Property RightsAll intellectual property rights, including but not limited to patents, copyrights, trademarks, and trade secrets, related to the molds developed under this Agreement shall belong exclusively to Company A. Company B shall not use, disclose, or reproduce any confidential information shared by Company A without prior written consent.4. WarrantyCompany B warrants that the molds developed under this Agreement shall be free from defects in materials and workmanship for a period of [number] years from the date of delivery. In the event of any defects, Company B shall repair or replace the molds at no additional cost to Company A.5. ConfidentialityBoth parties agree to keep all terms and conditions of this Agreement confidential and not to disclose any information to third parties without prior written consent. This obligation shall survive the termination of this Agreement.6. TerminationEither party may terminate this Agreement by providing written notice to the other party at least [number] days inadvance. Upon termination, Company B shall return all molds, prototypes, and materials to Company A.7. Governing LawThis Agreement shall be governed by the laws of [jurisdiction] without regard to conflicts of law principles. Any disputes arising out of or relating to this Agreement shall be resolved through arbitration in [city], [jurisdiction].8. Entire AgreementThis Agreement constitutes the entire understanding between Company A and Company B regarding the development of molds and supersedes all prior agreements, whether written or oral. Any modifications to this Agreement must be made in writing and signed by both parties.IN WITNESS WHEREOF, the parties hereto have executed this Agreement as of the date first written above.[Company A]By: [Signature]Name: [Printed Name]Title: [Title][Company B]By: [Signature]Name: [Printed Name]Title: [Title]篇2Mould Development AgreementThis Mould Development Agreement ("Agreement") is made and entered into as of [Date], by and between [Company Name], a company organized and existing under the laws of [Country], having its principal place of business at [Address] ("Company"), and [Supplier Name], a company organized and existing under the laws of [Country], having its principal place of business at [Address] ("Supplier").WHEREAS, Company desires to engage Supplier for the design, development, and production of moulds for use in manufacturing products as specified by Company; andWHEREAS, Supplier has the capability, experience, and expertise in the design, development, and production of moulds;NOW, THEREFORE, in consideration of the mutual promises, covenants, and agreements contained herein, the parties agree as follows:1. Scope of WorkSupplier shall design, develop, and produce moulds according to the specifications provided by Company. Supplier shall deliver the moulds in a timely manner and in accordance with the quality standards agreed upon by the parties.2. ConfidentialitySupplier shall keep all information related to the mould design, development, and production confidential and shall not disclose such information to any third party without the prior written consent of Company.3. PaymentCompany shall pay Supplier the agreed-upon amount for the design, development, and production of the moulds. Payment shall be made in installments as specified in the Payment Schedule attached as Schedule A.4. OwnershipUpon full payment of the agreed-upon amount, the moulds designed, developed, and produced by Supplier shall become the property of Company.5. TerminationEither party may terminate this Agreement with written notice if the other party breaches any material term of this Agreement. Upon termination, Supplier shall deliver all moulds and related materials to Company.6. Governing LawThis Agreement shall be governed by and construed in accordance with the laws of [Country]. Any dispute arising out of or relating to this Agreement shall be resolved through arbitration in [City], in accordance with the rules of [Arbitration Association].IN WITNESS WHEREOF, the parties have executed this Agreement as of the date first above written.[Company Name]By: ________________________Name: _______________________Title: _______________________[Supplier Name]By: ________________________Name: _______________________Title: _______________________Schedule APayment Schedule1. 50% upon signing of this Agreement2. 25% upon delivery of initial mould design3. 25% upon delivery of final approved mould篇3Mold Development AgreementThis Agreement is made and entered into on this [Date] by and between [Company Name], (hereinafter referred to as the "Buyer") and [Mold Manufacturer Name], (hereinafter referred to as the "Manufacturer").Whereas, the Buyer wishes to engage the Manufacturer to design, develop, and produce molds for the production of [Product], in accordance with the Buyer's specifications and requirements.Now, therefore, in consideration of the mutual covenants set forth herein, the parties agree as follows:1. Scope of Work:a. The Manufacturer shall design, develop, and produce molds for the production of [Product] in accordance with the specifications provided by the Buyer.b. The molds shall be of high quality, durable, and suitable for the intended use.c. Any modifications or changes to the molds shall be subject to the Buyer's approval.2. Payment:a. The Buyer agrees to pay the Manufacturer the total sum of [Amount] for the design, development, and production of the molds.b. Payment shall be made in [Number] installments as follows: [Payment Schedule].c. Any additional costs incurred due to modifications or changes requested by the Buyer shall be borne by the Buyer.3. Delivery:a. The Manufacturer agrees to deliver the molds to the Buyer within [Timeframe] from the date of signing this Agreement.b. The Buyer shall inspect the molds upon delivery and notify the Manufacturer of any defects or issues within [Number] days.c. The Manufacturer shall rectify any defects or issues identified by the Buyer at no additional cost.4. Intellectual Property:a. The design and development of the molds shall be the intellectual property of the Manufacturer.b. The Buyer shall have the exclusive right to use the molds for the production of [Product] as per this Agreement.5. Confidentiality:a. Both parties agree to keep all information shared during the course of this Agreement confidential.b. The Manufacturer shall not disclose any details about the molds or the production process to any third party without the Buyer's consent.6. Termination:a. Either party may terminate this Agreement by providing written notice to the other party.b. In the event of termination, the Buyer shall pay the Manufacturer for the work completed up to the date of termination.7. Governing Law:This Agreement shall be governed by and construed in accordance with the laws of [Jurisdiction].In witness whereof, the parties have executed this Agreement on the date first above written.Buyer: [Buyer Name] Manufacturer: [Manufacturer Name]Signature: _________________ Signature: _________________Date: ________________ Date: ________________篇4Mold Development AgreementThis Mold Development Agreement ("Agreement") is entered into as of [Date] by and between [Company Name], a company organized and existing under the laws of [Jurisdiction],with its principal place of business at [Address] ("Client"), and [Mold Manufacturer], a company organized and existing under the laws of [Jurisdiction], with its principal place of business at [Address] ("Mold Manufacturer").1. Scope of WorkMold Manufacturer agrees to design, engineer, and manufacture molds for Client in accordance with the specifications provided by Client. The molds may be used for the production of [Products].2. PaymentClient agrees to pay Mold Manufacturer [Amount] for the design, engineering, and manufacturing of the molds. Payment shall be made in [Number] installments as follows: [Payment Schedule]. Payment shall be made within [Number] days of receipt of invoice.3. ChangesIf Client wishes to make changes to the specifications after the molds have been designed, engineered, or manufactured, Client must provide written notice to Mold Manufacturer. Any additional costs incurred due to changes requested by Client shall be borne by Client.4. ConfidentialityBoth parties agree to keep all information exchanged during the course of this Agreement confidential. This includes but is not limited to, design specifications, engineering data, and pricing information.5. Intellectual Property RightsAll intellectual property rights, including but not limited to, patents, trademarks, and copyrights arising from the development of the molds shall belong to Client.6. WarrantyMold Manufacturer warrants that the molds shall be free from defects in materials and workmanship for a period of [Number] years from the date of delivery. In the event of a defect, Mold Manufacturer shall repair or replace the molds at no cost to Client.7. TerminationEither party may terminate this Agreement by providing [Number] days written notice to the other party. In the event of termination, Client shall pay Mold Manufacturer for all work completed up to the date of termination.8. Governing LawThis Agreement shall be governed by the laws of [Jurisdiction]. Any disputes arising out of this Agreement shall be resolved through arbitration in [Jurisdiction].IN WITNESS WHEREOF, the parties hereto have executed this Agreement as of the date first above written.[Client Name]By: _______________________Name: [Name]Title: [Title][Mold Manufacturer]By: _______________________Name: [Name]Title: [Title]篇5Mold Development AgreementThis agreement is made and entered into on [Date], by and between [Company Name], with a principal place of business at[Address], hereinafter referred to as "Company", and [Supplier Name], with a principal place of business at [Address], hereinafter referred to as "Supplier".WHEREAS, Company desires to develop a new mold for the production of [Product], and Supplier has the necessary expertise and capabilities to provide mold development services.NOW, THEREFORE, in consideration of the mutual covenants contained herein, the parties agree as follows:1. Scope of Work:Company agrees to provide Supplier with the necessary specifications, drawings, and requirements for the mold development project.Supplier shall use its best efforts to design and manufacture a high-quality mold that meets Company's specifications.2. Payment:Company agrees to pay Supplier a total project fee of [Amount] for the mold development services.Payment shall be made in installments as follows: [Payment Schedule].Supplier shall provide Company with an invoice for each payment installment.3. Ownership of Mold:Upon completion of the mold development project and payment in full, the mold shall become the exclusive property of Company.Supplier agrees to transfer all rights, title, and interest in the mold to Company.4. Confidentiality:Both parties agree to keep all project-related information confidential and not disclose it to any third party without the other party's consent.Supplier shall take all necessary measures to protect the confidentiality of Company's proprietary information.5. Warranty:Supplier warrants that the mold will be free from defects in materials and workmanship for a period of [Warranty Period].If any defects are found during the Warranty Period, Supplier agrees to repair or replace the mold at no additional cost to Company.6. Termination:Either party may terminate this agreement in writing if the other party breaches any of its obligations under this agreement.Upon termination, Company shall pay Supplier for all services rendered up to the date of termination.7. Governing Law:This agreement shall be governed by and construed in accordance with the laws of [State/Country].Any disputes arising out of or in connection with this agreement shall be resolved through arbitration in [City], [State/Country].IN WITNESS WHEREOF, the parties hereto have executed this agreement as of the date first above written.[Company Name]By:_____________________[Supplier Name]By:_____________________篇6Mold Development AgreementThis Mold Development Agreement (the “Agreement”) is entered into on this ___ day of _______, 20__, by and between [Company Name], a company organized and existing under the laws of [Country], with its principal place of business at [Address] (“Company”), and [Manufacturer Name], a company organized and existing under the laws of [Country], with its principal place of business at [Address] (“Manufacturer”).WHEREAS, Company desires to engage Manufacturer for the development and production of molds for specific products of Company; andWHEREAS, Manufacturer has the necessary expertise, resources, and capabilities to develop and produce molds in accordance w ith Company’s specifications and requirements;NOW, THEREFORE, in consideration of the mutual covenants and agreements contained herein, the parties hereto agree as follows:1. Project Scope: Manufacturer agrees to design, develop, and produce molds for specific products of Company in accordance with the specifications and requirements provided by Company.2. Ownership: Company shall have full ownership rights over the molds developed by Manufacturer pursuant to this Agreement. Manufacturer shall not have any claim of ownership or rights over the molds.3. Confidentiality: Both parties agree to keep all information exchanged during the course of the project confidential and to use it solely for the purpose of fulfilling their obligations under this Agreement.4. Payment Terms: Company shall pay Manufacturer a fixed fee of [Amount] for the development and production of the molds. Payment shall be made in [Number] installments as follows: [Payment Schedule].5. Timeline: Manufacturer agrees to complete the development and production of the molds within [Number] days/weeks/months from the date of this Agreement.6. Quality Assurance: Manufacturer warrants that the molds developed and produced under this Agreement shall meet the quality standards specified by Company. In case of any defects or issues, Manufacturer shall rectify the same at no additional cost to Company.7. Termination: Either party may terminate this Agreement by providing a written notice of [Number] days to the other party. In case of termination, Company shall pay Manufacturer for the work completed up to the date of termination.8. Governing Law: This Agreement shall be governed by and construed in accordance with the laws of [Country].IN WITNESS WHEREOF, the parties hereto have executed this Agreement as of the date first above written.[Company Name]By: ____________________[Manufacturer Name]By: ____________________This Mold Development Agreement is hereby accepted and agreed to by the parties as of the date first above written.【模具开发协议】《模具开发协议》(“协议”)于20__年___月___日由[公司名称](下称“公司”)与[制造商名称](下称“制造商”)签署。
英文技术开发合同4篇
![英文技术开发合同4篇](https://img.taocdn.com/s3/m/92df0923178884868762caaedd3383c4ba4cb470.png)
英文技术开发合同4篇篇1Technical Development ContractThis Technical Development Contract (“Contract”) is entered into on [Date] by and between [Company name], located at [Address], (“Company”) and [Developer name], located at [Address], (“Developer”).1. Scope of WorkDeveloper agrees to provide technical development services to Company for the following project: [Project description]. The scope of work includes but is not limited to: [List of specific tasks or deliverables].2. PaymentCompany agrees to pay Developer the sum of [Amount] for the completion of the project. Payment will be made in installments according to the following schedule: [Payment schedule]. In the event of any delays or changes to the project scope, the payment schedule may be adjusted accordingly.3. DeliverablesDeveloper agrees to deliver all work in a timely and professional manner. Company will have the opportunity to review and approve all deliverables before final payment is made. Any revisions requested by Company must be completed by Developer within [Number] days.4. TimelineThe project is expected to be completed by [Date]. Developer agrees to provide regular updates on the progress of the project and notify Company of any delays or issues that may arise.5. Intellectual PropertyAll work created by Developer for Company during the course of this project will be the sole property of Company. Developer agrees not to use any proprietary information or trade secrets of Company for any other purpose.6. ConfidentialityBoth parties agree to keep all information regarding the project confidential and not to disclose any details to third parties without prior written consent.7. IndemnificationDeveloper agrees to indemnify and hold harmless Company from any claims or liabilities arising out of Developer’s work on the project.8. TerminationEither party may terminate this Contract with written notice if the other party fails to fulfill its obligations under the terms of this Contract. Upon termination, any outstanding payments will be due immediately.9. Governing LawThis Contract shall be governed by the laws of the state of [State] and any disputes arising out of this Contract shall be resolved through arbitration in [City].10. Entire AgreementThis Contract constitutes the entire agreement between Company and Developer and supersedes any prior agreements or understandings, whether written or oral.In witness whereof, the parties hereto have executed this Contract as of the date first above written.[Company name]By: _______________________Title: ______________________[Developer name]By: _______________________Title: ______________________Signature: _______________________Date: _______________________篇2Technical Development ContractThis Technical Development Contract (the "Contract") is entered into between [Company Name], having its principal place of business at [Company Address] (hereinafter referred to as the "Company"), and [Developer Name], an independent contractor with their principal place of business at [Developer Address] (hereinafter referred to as the "Developer").WHEREAS, the Company is desirous of engaging the Developer to develop certain technical solutions for the Company; andWHEREAS, the Developer has the necessary skills and expertise to perform such development services for the Company;NOW, THEREFORE, in consideration of the premises and mutual promises and covenants contained herein, the parties hereto agree as follows:1. Scope of WorkThe Developer agrees to provide technical development services to the Company in accordance with the specifications outlined in Exhibit A attached hereto and incorporated herein by reference.2. PaymentThe Company agrees to pay the Developer the sum of [Payment Amount] for the services provided under this Contract. Payment shall be made in installments as outlined in Exhibit B attached hereto.3. Term and TerminationThis Contract shall commence on [Start Date] and shall continue until the completion of the services outlined in Exhibit A. Either party may terminate this Contract upon written noticeto the other party in the event of a material breach of the terms and conditions contained herein.4. ConfidentialityThe Developer agrees to keep all confidential information of the Company confidential and not disclose or use such information for any purpose other than the performance of the services under this Contract.5. Intellectual PropertyAll intellectual property developed by the Developer in connection with the services provided under this Contract shall be owned by the Company.6. Independent ContractorThe Developer is an independent contractor and not an employee of the Company. The Developer shall be solely responsible for all taxes, insurance, and other obligations arising from the services provided under this Contract.7. Governing LawThis Contract shall be governed by and construed in accordance with the laws of the State of [State], without regard to its conflict of law principles.IN WITNESS WHEREOF, the parties hereto have executed this Contract as of the date first above written.[Company Name]By: __________________________Name: [Authorized Signatory]Title: [Title][Developer Name]By: __________________________Name: [Developer Signature]Title: [Title]Exhibit A - SpecificationsExhibit B - Payment ScheduleThis Contract constitutes the entire agreement between the parties and supersedes any prior agreements or understandings, whether written or oral, relating to the subject matter herein. This Contract may be amended or modified only in writing signed by both parties.篇3Technical Development ContractThis Technical Development Contract (the "Contract") is entered into on [Date], by and between [Client Name], located at [Client Address], and [Developer Name], located at [Developer Address].1. Scope of WorkThe Developer agrees to provide technical development services for the Client, as outlined in the Scope of Work attached hereto as Exhibit A. The Developer will use its best efforts to complete the development work in a timely manner and in accordance with the specifications provided by the Client.2. Payment TermsThe Client agrees to pay the Developer a total fee of [Amount] for the development work. The payment will be made in installments as outlined in the Payment Schedule attached hereto as Exhibit B. The Client agrees to pay the Developer within [Number] days of receipt of the invoice.3. Intellectual Property RightsThe Developer agrees that all work created under this Contract, including but not limited to software code, designs, and documentation, shall be the exclusive property of the Clientupon payment in full of the fees outlined in this Contract. The Client shall have the right to use, reproduce, and modify the work in any way it sees fit.4. ConfidentialityBoth Parties agree to keep all information related to this Contract confidential and not disclose it to any third party without the other Party's consent. This includes all documents, designs, code, and other materials shared between the Parties during the course of the project.5. TerminationEither Party may terminate this Contract at any time by providing written notice to the other Party. In the event of termination, the Client agrees to pay the Developer for all work completed up to the date of termination, in accordance with the Payment Schedule outlined in Exhibit B.6. Governing LawThis Contract shall be governed by and construed in accordance with the laws of [State/Country]. Any disputes arising under this Contract shall be resolved through arbitration in [City], in accordance with the rules of the American Arbitration Association.In witness whereof, the Parties have executed this Contract as of the date first above written.[Client Name] [Developer Name]_________________________ _________________________[Client Signature] [Developer Signature]Exhibit A: Scope of WorkExhibit B: Payment ScheduleThis Contract is effective as of the date first above written.篇4Technology Development ContractThis Technology Development Contract ("Contract") is entered into on [Insert Date] (the "Effective Date") by and between [Insert Company Name] with an address at [Insert Company Address] ("Developer") and [Insert Client Name] with an address at [Insert Client Address] ("Client").1. Scope of WorkClient hereby engages Developer to develop [Insert Description of Project]. The project will involve [Insert Details of Project Scope and Deliverables]. Developer will provide allnecessary skills, resources, and expertise to complete the project in adherence to the agreed-upon timeline.2. PaymentClient agrees to pay Developer a total fee of [Insert Amount] for the development of the project. Payment shall be made in [Insert Number of Installments] installments as follows: [Insert Payment Schedule]. Developer shall not commence work on the project until the first payment is received.3. ConfidentialityBoth parties agree to keep all confidential information shared during the course of the project confidential. This includes but is not limited to project details, proprietary information, and trade secrets. Confidential information shall not be shared with any third party without prior written consent.4. Intellectual Property RightsUpon completion of the project, all intellectual property rights, including copyrights, patents, and trademarks, shall belong to Client. Developer agrees to transfer all rights to Client upon full payment of the agreed-upon fee.5. Warranty and Limitation of LiabilityDeveloper warrants that the project will be completed in a professional and workmanlike manner. In the event of any defects or errors in the project, Developer shall promptly correct the issue at no additional cost to Client. Developer's liability under this Contract shall not exceed the total fee paid by Client.6. TerminationEither party may terminate this Contract with [Insert Number of Days] days' written notice. In the event of termination, Developer shall be compensated for work completed up to the date of termination.7. Governing LawThis Contract shall be governed by and construed in accordance with the laws of [Insert Jurisdiction]. Any disputes arising under this Contract shall be resolved through arbitration in [Insert Arbitration Venue].8. Entire AgreementThis Contract constitutes the entire agreement between Developer and Client and supersedes any prior agreements or understandings, whether written or oral. Any modifications to this Contract must be made in writing and signed by both parties.IN WITNESS WHEREOF, the parties hereto have executed this Contract as of the Effective Date.Developer: [Insert Signature]Date: [Insert Date]Client: [Insert Signature]Date: [Insert Date]This Technology Development Contract is hereby accepted and approved.[Insert Company Name][Insert Client Name]。
技术开发合同英文 示范文本
![技术开发合同英文 示范文本](https://img.taocdn.com/s3/m/3150b4c5294ac850ad02de80d4d8d15abe2300ad.png)
技术开发合同英文示范文本I. Parties Involved.Party A (The Entrusting Party):Full name: [Company/Individual Name of Party A]Address: [Address of Party A]Contact person: [Name of Contact Person]Phone number: [Phone Number]Email: [Email Address]Party B (The Contractor):Full name: [Company/Individual Name of Party B]Address: [Address of Party B]Contact person: [Name of Contact Person]Phone number: [Phone Number]Email: [Email Address]II. Background and Purpose.Party A has some specific technological needs in [describe the general area, like "mobile app development" or "new manufacturing process improvement"]. Party B is an expert in relevant technology fields and has the ability to carry out the development work. So, the two parties reach this contract to jointly promote the development of this technology.III. Technical Development Content.1. Project Name.The name of this technology development project is: [Project Name]2. Specific Technical Requirements.Party A hopes that Party B can develop a system/technology/product with the following functions:[Function 1, describe it in detail, e.g., "A user friendly interfacethat allows users to easily input their personal information."][Function 2][Function 3]...The technology should meet the following performance standards:[Performance Standard 1, such as "The response time should be within 2 seconds."][Performance Standard 2][Performance Standard 3]...3. Development Plan and Milestones.Party B will follow the following development plan:In the first [number] weeks/months, complete the basic framework design. This includes [describe what is included in the basic framework].By the end of [specific time period], finish the key function development. For example, [mention the key functions to be completed].In the final [number] weeks/months, conduct comprehensive testing and debugging to ensure that all functions work properly and meet the performance standards.Party A has the right to check the progress at each milestone. If Party B fails to meet the milestone requirements on time, Party B should take immediate remedial measures and inform Party A in advance.IV. Intellectual Property Rights.1. Ownership of Intellectual Property.All intellectual property rights related to the developed technology, including but not limited to patents, copyrights, and trade secrets, shall belong to Party A. Party B agrees to transfer all relevant rights to PartyA upon completion of the project.However, Party B can use the relevant technology for internal research and improvement purposes, but not for any commercial use without thewritten permission of Party A.2. Confidentiality.Both parties shall keep the technical information, business secrets,and any other confidential information related to this project confidential.The confidentiality period is [number] years from the date of signing this contract.V. Consideration and Payment Terms.1. Total Consideration.Party A shall pay Party B a total of [amount in currency] for this technology development project.2. Payment Schedule.An initial payment of [amount] shall be made within [number] days after signing this contract. This payment is to cover Party B's initial research and preparation costs.After Party B completes the key milestone [describe the milestone], Party A shall pay [amount].The final payment of [amount] will be made upon successful completion of the project and acceptance by Party A.VI. Project Acceptance.1. Acceptance Criteria.Party A will accept the project based on the technical requirements and performance standards specified in this contract.Party B shall submit all relevant technical documents, including design documents, test reports, and user manuals, to Party A for review.2. Acceptance Procedure.Party B shall notify Party A in writing when the project is ready for acceptance.Party A shall organize relevant personnel to conduct acceptance tests within [number] days after receiving the notice.If the project fails to pass the acceptance test, Party B shall make necessary modifications and re submit for acceptance within [number] days.VII. Liability for Breach of Contract.1. By Party A.If Party A fails to make payments on time according to the payment schedule, Party A shall pay a late fee of [percentage] of the overdue amount per day.If Party A unilaterally terminates the contract without justifiable reasons, Party A shall compensate Party B for all losses already incurred and the expected profit of the unfinished part of the project.2. By Party B.If Party B fails to complete the project on time or fails to meet the technical requirements and performance standards, Party B shall refund all payments already received from Party A and compensate Party A for any losses caused thereby.If Party B discloses confidential information of Party A, Party B shall bear all legal liabilities and compensate Party A for all losses.VIII. Governing Law and Dispute Resolution.1. Governing Law.This contract shall be governed by the laws of [specific jurisdiction, like "the laws of the State of California" or "the laws of the People's Republic of China"].2. Dispute Resolution.In case of any disputes arising from this contract, the two parties shall first try to resolve them through friendly negotiation.If the negotiation fails, either party can submit the dispute to [specific arbitration body or court] for arbitration or litigation.IX. Miscellaneous.1. Amendments and Supplements.Any amendments or supplements to this contract shall be made in writing and signed by both parties.2. Entire Agreement.This contract constitutes the entire agreement between the two parties with respect to the subject matter hereof and supersedes all prior oral or written agreements and understandings relating to the same.3. Severability.If any provision of this contract is held to be invalid or unenforceable, the validity and enforceability of the remaining provisions shall not in any way be affected.This contract is made in duplicate, with each party holding one copy. The contract shall come into force as of the date of signing by both parties.Party A (Signature): [Authorized Signature of Party A]Date: [Date of Signing]Party B (Signature): [Authorized Signature of Party B]Date: [Date of Signing]。
模具开发合同范本-中英文版
![模具开发合同范本-中英文版](https://img.taocdn.com/s3/m/0f380f4d0166f5335a8102d276a20029bc646313.png)
Open Mould ContractContract No.:Date:PartyA甲方:PratyB:乙方:经过友好协商和在公平、平等的原则基础上,双方约定如下:After friendly consultations and proceeding on principles of fairness and equality,the Parties have agreed the following:二、模具开发周期及要求/Work Day &Requirement1) 模具的开发周期/ Mould Work Day首件样件完成时间/Time of finishing first product of mold:从接到订单到首件样品完成需要30天/30days from building time ARO (after receipt of order)to first POM (product of mold) sample pour;2) 模具验收/ MouldInspection:模具必须符合买方的技术要求。
The product shall completely fit the technical requirements.3) 由于模具的开发周期和质量问题造成甲方项目延期,乙方将赔偿甲方的一切损失。
If the PartyAproject delayed due to the work day and the quality of the mouldthe PartyBshould compensate the PartyAor all the losses。
三、模具的维护/Mold Maintenance正常使用寿命内的模具在生产过程中发生的损坏或磨损,相关的维修及保养等都由乙方负责。
If the mouldis within the normal working life but damaged or worn during the production process, the Party B should be responsible for the related repair and maintenance.四、开模费用的支付/Open mouldPayment Terms在铸件得到甲方确认后1年之内100%电汇。
开发产品英文合同范本
![开发产品英文合同范本](https://img.taocdn.com/s3/m/ed00b2590640be1e650e52ea551810a6f524c80c.png)
开发产品英文合同范本Product Development ContractThis Product Development Contract (the "Contract") is made and entered into as of [date], and between:Party A: [Company/Individual Name A]Address: [Company/Individual Address A]Contact Person: [Contact Person A]E: [Contact E A]Party B: [Company/Individual Name B]Address: [Company/Individual Address B]Contact Person: [Contact Person B]E: [Contact E B]WHEREAS, Party A desires to have Party B develop a specific product as specified in this Contract; andWHEREAS, Party B has the expertise and capabilities to undertake such product development.NOW, THEREFORE, in consideration of the mutual covenants and agreements contned herein, and for other good and valuable consideration, the receipt and sufficiency of which are here acknowledged, the parties agree as follows:Article 1: Product Description1.1 Party A shall provide detled specifications and requirements for the product to be developed to Party B.1.2 Party B shall use its best efforts to develop the product in accordance with the agreed specifications and requirements.Article 2: Development Timeline2.1 The development timeline for the product shall be as agreed upon the parties and specified in a separate schedule attached hereto or as otherwise mutually agreed.2.2 Party B shall notify Party A of any delays or potential delays in the development process and work with Party A to find solutions.Article 3: Deliverables3.1 Party B shall deliver the pleted product to Party A in the form and format specified Party A.3.2 The deliverables shall include but not be limited to the final product software, documentation, user manuals, and any other related materials.Article 4: Payment Terms4.1 Party A shall pay Party B the agreed-upon fees for the product development in accordance with the following payment schedule: [Payment Amount 1] upon signing of this Contract;[Payment Amount 2] upon the pletion of certn milestone stages as specified in the development timeline;[Payment Amount 3] upon the final delivery and acceptance of the product.4.2 All payments shall be made in [payment currency] wire transfer to the bank account specified Party B.Article 5: Intellectual Property Rights5.1 All intellectual property rights (IPR) arising from the product development, including but not limited to patents, copyrights, trademarks, and trade secrets, shall vest in Party A.5.2 Party B shall assign to Party A all rights, , and interest in and to the IPR related to the product.5.3 Party B shall cooperate with Party A to obtn any necessary licenses or consents for the use of the IPR.Article 6: Confidentiality6.1 Both parties shall mntn the confidentiality of all information and materials disclosed to them the other party in connection with this Contract.6.2 The obligations of confidentiality shall survive the termination or expiration of this Contract for a period of [confidentiality period] years.Article 7: Warranty and Liability7.1 Party B warrants that the developed product will meet the agreed specifications and requirements.7.2 If the product fls to meet the warranty, Party B shall undertake to rectify the defect or replace the product free of charge within a reasonable time.7.3 Party B shall not be liable for any indirect, incidental, or consequential damages arising out of the product development or its use.Article 8: Termination8.1 This Contract may be terminated either party in the event of a material breach the other party.8.2 In the event of termination, the parties shall settle all outstanding matters, including payment of fees and return of any materials.Article 9: Governing Law and JurisdictionThis Contract shall be governed and construed in accordance with the laws of [applicable jurisdiction]. The parties here submit to the exclusive jurisdiction of the courts in [jurisdiction].Article 10: Amendments and WversAny amendment or wver of this Contract shall be in writing and signed both parties.Article 11: Entire AgreementThis Contract constitutes the entire agreement between the parties with respect to the subject matter herein and supersedes all prior agreements and understandings relating thereto.Article 12: NoticesAny notice or munication required or permitted under this Contract shall be in writing and delivered personal delivery, courier service, or registered or certified , postage prepd, to the addresses set forth above or to such other addresses as may be designated written notice.In witness whereof, the parties have executed this Product Development Contract as of the date first above written.Party A: [Company/Individual Name A]By: [Authorized Signatory]Date: [Date]Party B: [Company/Individual Name B]By: [Authorized Signatory]Date: [Date]Please note that this is a sample contract and you may need to modify it according to your specific requirements and circumstances. It is advisable to seek legal advice if necessary to ensure its validity and enforceability.。
开发合同范本 英文
![开发合同范本 英文](https://img.taocdn.com/s3/m/d507483b1fb91a37f111f18583d049649b660ecd.png)
开发合同范本英文Development ContractThis Development Contract ("Contract") is made and entered into as of [date] and between [Client Name] ("Client") and [Developer Name] ("Developer").1. Project DescriptionThe Developer agrees to undertake the development of [project name and description] for the Client.2. Project TimelineThe project is expected to be pleted [pletion date]. The Developer will provide regular progress updates to the Client.3. CompensationThe Client will pay the Developer a total pensation of [amount] in the following installments: [payment schedule detls].4. Intellectual Property RightsAll intellectual property rights arising from the development work shall belong to the Client.5. ConfidentialityBoth parties agree to mntn the confidentiality of all information related tothe project.6. Warranty and SupportThe Developer warrants that the developed product will meet the specified requirements and will provide [duration] of support after project pletion.7. TerminationThis Contract may be terminated either party in case of a material breach of the terms.8. Dispute ResolutionAny disputes arising under this Contract shall be resolved through arbitration in accordance with the laws of [applicable jurisdiction].9. Entire AgreementThis Contract constitutes the entire agreement between the parties and supersedes all prior negotiations and understandings.IN WITNESS WHEREOF, the parties have executed this Contract as of the date first above written.Client: [Client Name and Signature]Developer: [Developer Name and Signature]Please note that the above is a basic template and should be customized to meet the specific requirements and circumstances of your particular development project. Legal advice may be sought to ensure the contract is prehensive and enforceable.。
技术开发的英文合同
![技术开发的英文合同](https://img.taocdn.com/s3/m/ea16d025a88271fe910ef12d2af90242a895ab3b.png)
Technical Development ContractContract Number: [Contract Number]Date: [Date of Contract Signing]Party A: [Name and Address of Party A]Party B: [Name and Address of Party B]I. Basic Information1.1. This Contract is entered into by and between Party A and Party B, whereby Party A entrusts Party B to conduct technical development in accordance with the terms and conditions specified in this Contract.1.2. The objective of the technical development is to [Specific Objective of the Technical Development].II. Rights and Obligations of the Parties2.1. Party A shall provide Party B with necessary technical information, documents, and other materials required for the technical development.2.2. Party B shall, based on its professional knowledge and skills, carry out the technical development work in accordance with the requirements of Party A and ensure the quality and timeliness of the work.2.3. Party B shall, upon completion of the technical development work, submit the technical results to Party A for review and acceptance.2.4. Both parties shall maintain confidentiality of the technical information and documents related to this Contract, and shall not disclose them to any third party without the consent of the other party.III. Technical Development Schedule and Payment3.1. The schedule for the technical development work is as follows: [Detailed Schedule].3.2. Party A shall pay Party B the following amounts as consideration for the technical development work: [Detailed Payment Terms].IV. Intellectual Property Rights4.1. Unless otherwise agreed by the parties, all intellectual property rights arising from the technical development work under this Contract shall be owned by Party A.4.2. Party B shall, during and after the term of this Contract, take all necessary measures to protect the intellectual property rights of Party A, and shall not use, disclose, or allow any third party to use or disclose such intellectual property rights without the consent of Party A.V. Termination and Breach of Contract5.1. This Contract may be terminated by mutual agreement of the parties or in accordance with the provisions of applicable laws and regulations.5.2. If any party breaches this Contract, the other party shall have the right to terminate this Contract and claim compensation for losses.VI. Dispute ResolutionAny disputes arising from or in connection with this Contract shall be resolved through friendly consultation by the parties. If no settlement can be reached through consultation, the dispute may be submitted to [Designated Arbitration Institution/Court] for arbitration/litigation in accordance with the laws and regulations of [Applicable Jurisdiction].VII. Other Matters7.1. This Contract is made in both Chinese and English. If there is any inconsistency between the two versions, the Chinese version shall prevail.7.2. This Contract shall come into effect upon signature by both parties and shall remain valid until the completion of the technical development work and payment of all amounts due under this Contract.7.3. This Contract consists of [Number of Pages] pages, including this page and the attachments hereto. This Contract and its attachments constitute the entire agreement between the parties and supersede any previous agreements or understandings between them.7.4. This Contract may be modified or supplemented only by a written agreement signed by both parties.Party A:Signature: __________________Date: __________________ Party B:Signature: __________________ Date: __________________。
开发合同英文模版
![开发合同英文模版](https://img.taocdn.com/s3/m/8b537605b14e852459fb5757.png)
Technology Development (Commission) ContractEntrustingParty(PartyA):Location:_________________________________________________LegalRepresentative:_______________________________________ Project Contact Person: ____________________________________ _Contact Information:Address:_________________________________________________Tel: __________________________ Fax: _______________________Email: ____________________________________________ _____Entrusted Party (Party B):Location:______________________________________________Legal Representative: ______________________________________Project Contact Person: _______________________________ _____Contact Information: _________________________ ________ __Address: _____________________________________ _______Tel: ________________________ Fax: _________________ _____Email: ____________________________________________ _____In the Contract, Party A entrust Party B to research and develop _____________________ Project. The R&D fund and remuneration shall be born by Party A. Party B accepts the entrustment and hereby conducts the R&D work. In accordance with the Contract Law of the People’s Republic of China, and on the principle of reality and mutual agreement through negotiations on the basis of equality, the following articles are reached and abided by the two parties:Article 1 The requirements of the R&D project in theContract1. Technical Objective:_______________________________________________________ _______________________________________________________ _______________________________________________________________ ____2. Technical Content:_______________________________________________________ _______________________________________________________ _______________________________________________________ ____________3. Technical Method and Strategy:_______________________________________________________ _______________________________________________________ _______________________________________________________ ____________Article 2 Party B shall submit the R&D plan to Party A within___ days after this Contract comes into effect. The plan should include the following content:1.______________________________________________________2._____________________________________________________ _3._____________________________________________________ _4._____________________________________________________ _Article 3Party B shall accomplish the R&D work according to the following schedule:1._____________________________________________________2._____________________________________________________ _3._____________________________________________________ _4.Article 4 Party A shall provide the following technical data and cooperation to Party B:1. Technical Data List:______________________________________________________ ____________________________________________________________________________________________________________ 2. Delivery Date and Manner:________________________________________________________________________________________________________________________________________________________________ 3. Other cooperation matters:_________________________________________________________________________________________________________________________________________________________________ After the performance of the Contract, the above technical data shall be handled by the following ways:_______________________________________________________ ___________________________________________________________ ____Article 5 Party A shall pay the R&D fund and remuneration according to the following terms:1. The total amount of the R&D fund and remuneration is _____Including: (1) __________________________________________;(2) __________________________________________;(3) __________________________________________;(4) __________________________________________。
房地产开发合同,英文
![房地产开发合同,英文](https://img.taocdn.com/s3/m/4eb21341e55c3b3567ec102de2bd960590c6d9b8.png)
房地产开发合同,英文1 开发协议1This development agreement (“Agreement”) is made at [ ] this [ ] day of [ ] Two Thousand and FourteenBY AND BETWEEN本开发协议(“本协议”)由以下双方于xx年月日订立。
, a pany incorporated and registered under the provisions of the having its registered office at hereinafter referred to as “the Owner” (which expression shall unless it be repugnant to the context or meaning thereof be deemed to mean and include its suessors and permitted assigns) of the FIRST PART; ,一家根据规定成立的公司,其办事处位于(以下简称甲方的“业主”)(除非与本文件中的上下文或含义矛盾,否那么此表述应被视为及包括其继承者及经批准的受让人);AND及, a pany incorporated and registered under the provisions of the having its registered office at XXXX hereinafter referred to as “the Developer” (which expression shall unless it be repugnant to the context or meaning thereof be deemed to mean and includes its suessors) of the SECOND PART;,一家根据规定成立的公司,其办事处位于XXX市XX区XXX(以下简称乙方的“开发商”)(除非与本文件中的上下文或含义矛盾,否那么此表述应被视为及包括其继承者);The Owner and the Developer are hereinafter collectively referred to as the “Parties” and individually as a “Party”. 业主及开发商以下统称为“订约方”,及分别被称为“一方”。
- 1、下载文档前请自行甄别文档内容的完整性,平台不提供额外的编辑、内容补充、找答案等附加服务。
- 2、"仅部分预览"的文档,不可在线预览部分如存在完整性等问题,可反馈申请退款(可完整预览的文档不适用该条件!)。
- 3、如文档侵犯您的权益,请联系客服反馈,我们会尽快为您处理(人工客服工作时间:9:00-18:30)。
Technology Development (Commission) ContractEntrustingParty(PartyA):Location: _________________________________________________Legal Representative:_______________________________________Project Contact Person: ____________________________________ _Contact Information:Address: _________________________________________________Tel: __________________________ Fax: _______________________Email: ____________________________________________ _____Entrusted Party (Party B):Location: ______________________________________________Legal Representative: ______________________________________Project Contact Person: _______________________________ _____Contact Information: _________________________ ________ __Address: _____________________________________ _______Tel: ________________________ Fax: _________________ _____Email: ____________________________________________ _____In the Contract, Party A entrust Party B to research and develop _____________________ Project. The R&D fund and remuneration shall be born by Party A. Party B accepts the entrustment and hereby conducts the R&D work. In accordance with the Contract Law of the People’s Republic of China, and on the principle of reality and mutual agreement through negotiations on the basis of equality, the following articles are reached and abided by the two parties:Article 1 The requirements of the R&D project in the Contract1. Technical Objective:_______________________________________________________________________________ __________________________________________________________________________________________________2. Technical Content:_______________________________________________________________________________ _______________________________________________________________________________ ___________________3. Technical Method and Strategy:_______________________________________________________________________________ _______________________________________________________________________________ ___________________Article 2 Party B shall submit the R&D plan to Party A within___ days after this Contract comes into effect. The plan should include the following content:1.______________________________________________________2.______________________________________________________3.______________________________________________________4.______________________________________________________Article 3 Party B shall accomplish the R&D work according to the following schedule:1._____________________________________________________2.______________________________________________________3.______________________________________________________4.Article 4 Party A shall provide the following technical data and cooperation to Party B:1. Technical Data List:__________________________________________________________________________________________________________________________________________________________________2. Delivery Date and Manner:________________________________________________________________________________________________________________________________________________________________3. Other cooperation matters:_________________________________________________________________________________________________________________________________________________________________After the performance of the Contract, the above technical data shall be handled by the following ways:______________________________________________________________________________________________________________________Article 5 Party A shall pay the R&D fund and remuneration according to the following terms:1. The total amount of the R&D fund and remuneration is _____Including: (1) __________________________________________;(2) __________________________________________;(3) __________________________________________;(4) __________________________________________。
The payment shall be made by Party A to Party B based on_________ (one-time calculation, installment payment or royalty payment). The detailed payment mode and date are as following:(1) _______________________________________________(2) _______________________________________________(3) _______________________________________________(4) _______________________________________________3. The information of Party B’s Bank Name, Bank Address and account number is as following: Bank Name: ________________________________________Bank Address: ________________________________________Account Name: ________________________________________4. With the two parties’ confirmation, Party A shall pay the R&D fund and remuneration to PartyB by means of the profit sharing which is generated from the R&D achievements. Party B has the right to check Party A’s relevant accounts in the manner of _____ ____.Article 6 The R&D fund shall be used by Party B in the form of __________. Party A has the right to inspect Party B’s R&D work and the utilization of R&D fund by the means of _________, but Party A should avoid disturbing the normal work of Party B.Article 7 Any changes occurred in the Contract shall be confirmed in a written form through the negotiation of the two parties. Under the following circumstances, one party may submit the request for modification of the rights and obligations stipulated in the Contract, and the other party shall make a reply within ___days. If it fails to reply within the time limit, the request shall be regarded as being accepted.1._______________________________________________;2._______________________________________________;3._______________________________________________;4._______________________________________________。