xxx工程合同中英文版
建设工程施工合同中英文对照版
建设工程施工合同中英文对照版中英文建设工程施工合同Contract for Construction Project本合同是由承包人（以下简称“甲方”）和业主（以下简称“乙方”）共同订立，旨在规定双方在建设工程项目中的权益和义务。
This contract is entered into by and between the Contractor (hereinafter referred to as "Party A") and the Owner (hereinafter referred to as "Party B") to regulate the rights and obligations of both parties in the construction project.总则 General Provisions第一条项目名称及工程地点：本工程名称为_________，位于_________。
Article 1: Project Name and Location: The name of the project is__________, located in __________.第二条总承包范围：甲方应按照乙方的要求，完成工程项目的设计、施工、验收等工作。
Article 2: Scope of General Contracting: Party A shall complete the design, construction, and acceptance of the project in accordance with PartyB's requirements.第三条施工期限：本工程的施工期限为_________，甲方必须按时完成工程，并交付乙方使用。
Article 3: Construction Period: The construction period of this project is __________. Party A must complete the project on time and deliver it to Party B for use.义务与责任 Obligations and Responsibilities第四条甲方责任：甲方应根据乙方的要求，制定合理的工程施工方案，并保证工程按照合同和法律法规的要求进行。
xxx工程合同中英文版
xxx engineering contract xxx工程合同Contract No.:合同编号：Party A: xxxCompany Limited甲方：xxx有限公司Party B:xxx Company Limited乙方：xxx有限公司This contract is made and entered into on the day of , 2014 by the following Parties in .本合同于2014年月日由以下当事方在签署。
Party A: xxx Company Limited,甲方：xxx有限公司，xxx经营的公司，住所地为xxx，（下称“甲方”），法定代表人：xxxParty B:xxx Company Limited,乙方：xxx有限公司，一家xxx经营的公司，注册地址是：xxx，（下称“乙方”），法定代表人：xxxParty A and Party B are called by a joint name of Both Parties under this contract, each of which is called as A Party.甲方和乙方在本合同项下统称为“双方”，单独称为“一方”。
1. Work Content and Requirements1. 工作内容、要求1.1 In accordance with the items stipulated in this Contract, Party B shall conduct the project as per the Projectstandard and quality standard stipulated by Ministry of Engineering of the Union of xx.1.1 依据本合同所限定的条款，乙方应以xx工程部规定的建筑标准和质量要求执行本工程。
xxx工程合同中英文版
xxx engineering contract xxx工程合同Contract No.:合同编号：Party A: xxxCompany Limited甲方：xxx有限公司Party B:xxx Company Limited乙方：xxx有限公司This contract is made and entered into on the day of , 2014 by the following Parties in .本合同于2014年月日由以下当事方在签署。
Party A: xxx Company Limited,甲方：xxx有限公司，xxx经营的公司，住所地为xxx，（下称“甲方”），法定代表人：xxxParty B:xxx Company Limited,乙方：xxx有限公司，一家xxx经营的公司，注册地址是：xxx，（下称“乙方”），法定代表人：xxxParty A and Party B are called by a joint name of Both Parties under this contract, each of which is called as A Party.甲方和乙方在本合同项下统称为“双方”，单独称为“一方”。
1. Work Content and Requirements1. 工作内容、要求1.1 In accordance with the items stipulated in this Contract, Party B shall conduct the project as per the Projectstandard and quality standard stipulated by Ministry of Engineering of the Union of xx.1.1 依据本合同所限定的条款，乙方应以xx工程部规定的建筑标准和质量要求执行本工程。
工程合同模板双语版
工程合同模板（双语版）Contract for Engineering Project (Bilingual Version)甲方（以下简称“甲方”）:Party A (hereinafter referred to as "Party A"):乙方（以下简称“乙方”）:Party B (hereinafter referred to as "Party B"):根据《中华人民共和国合同法》及相关法律法规的规定，甲乙双方在平等、自愿、公平、诚实信用的原则基础上，就甲方委托乙方承担 engineering project （以下简称“项目”）的相关事宜，经充分协商，达成以下协议：According to the "Contract Law of the People's Republic of China" and relevant laws and regulations, Party A and Party B have reached the following agreement in accordance with the principles of equality, voluntariness, fairness, and good faith, regarding the matters entrusted by Party A to Party B to assume the engineering project (hereinafter referred to as the "Project"):一、项目概述1. Overview of the Project1.1 项目名称：____________Project Name: ____________________1.2 项目地点：____________Project Location: ____________________1.3 项目内容：____________Project Content: ____________________1.4 项目预算：____________Project Budget: ____________________二、乙方的义务和责任2. Obligations and Responsibilities of Party B2.1 乙方应按照甲方的要求，按时完成项目。
工程合同中英文版
工程合同中英文版工程合同范本甲方（业主）：________乙方（承包商）：________鉴于甲乙双方就工程项目的施工达成以下协议，特此签订本合同：一、合同目的本合同旨在明确甲乙双方在工程项目中的合作条款，包括但不限于工程的设计、施工、监理、验收、付款等事宜。
二、工程概况1. 工程名称：________2. 工程地点：________3. 工程规模：________4. 工程标准：按照国家及行业相关标准执行。
三、合同金额合同总金额为人民币（大写）________元整（¥_______）。
四、工程期限工程开工日期为____年____月____日，竣工日期为____年____月____日。
五、质量要求乙方必须保证工程质量符合国家标准及甲方要求，对于不合格的工程，乙方应负责无偿修复直至合格。
六、付款方式1. 预付款：甲方需在合同签订后____天内支付合同金额的____%作为预付款。
2. 进度款：根据工程进度分阶段支付，每阶段完成后甲方应在____天内支付该阶段对应的款项。
3. 竣工款：工程竣工并经验收合格后，甲方应在____天内支付剩余的合同款项。
七、违约责任如一方违反合同约定，应承担违约责任，并赔偿对方因此遭受的损失。
八、争议解决因本合同引起的任何争议，双方应首先通过友好协商解决；协商不成时，可提交至甲方所在地人民法院诉讼解决。
九、其他事项1. 本合同自双方签字盖章之日起生效。
2. 本合同一式两份，甲乙双方各执一份，具有同等法律效力。
3. 未尽事宜，双方可另行签订补充协议。
甲方（签字）：________________________ 日期：____年____月____日乙方（签字）：________________________ 日期：____年____月____日Contract for Construction rojectarty A (Owner): ________arty (Contractor): ________Whereas arty A and arty have reached the following agreement on the construction roject, this contract is herey signed:I. urose of the ContractThe urose of this contract is to secify the cooeration terms etween arty A and arty in the construction roject, including ut not limited to design, construction, suervision, accetance, ayment, and other related matters.II. roject Overview1. roject Name: ________2. roject Location: ________3. roject Scale: ________4. roject Standards: To e carried out in accordance with national and industry standards. III. Contract AmountThe total contract amount is in Renmini (caitalized) ________ Yuan only (¥_______).IV. roject DurationThe commencement date of the roject is ________ and the comletion date is ________.V. Quality Requirementsarty must ensure that the quality of the roject meets national standards and arty A's requirements. For any sustandard work, arty shall e resonsile for rectifying it without charge until it meets the required standards.VI. ayment Method1. Advance ayment: arty A shall ay __% of the contract amount as an advance ayment within __ days after signing the contract.2. rogress ayment: aid in stages according to the rogress of the roject, with each stage's corresonding ayment to e made y arty A within __ days after comletion.3. Comletion ayment: Uon comletion and assing accetance of the roject, arty A shall ay the remaining contract funds within __ days.VII. Liaility for reachIf one arty reaches the contract, they shall ear the liaility for reach and comensate the other arty for any resulting losses.VIII. Disute ResolutionAny disute arising from this contract shall firstly e resolved through friendly negotiation; if negotiation fails, the disute may e sumitted to the eole's Court at arty A's location for resolution.IX. Miscellaneous1. This contract shall ecome effective uon signature and seal y oth arties.2. This contract is made in dulicate, with each arty holding one coy, oth having equal legal effect.3. For matters not covered herein, oth arties may sign additional sulementary agreements. arty A (Signature): _____________________ Date: __ Year __ Month __ Dayarty (Signature): _____________________ Date: __ Year __ Month __ Day。
工程协议合同中英文版
工程协议合同中英文版一、合同基本信息- 甲方（Client）：[甲方名称]- 乙方（Contractor）：[乙方名称]- 签订日期（Date）：[签订日期]- 项目名称（roject Name）：[项目名称]- 项目地点（roject Location）：[项目地点]二、合同目的和范围本合同旨在明确甲乙双方就[项目名称]项目的建设、管理、维护等方面的责任、权利和义务。
项目范围包括但不限于设计、施工、材料供应、项目管理等。
三、合同金额和支付方式- 合同总金额（Total Contract rice）：[合同总金额]- 付款条件（ayment Terms）：根据项目进度分阶段支付，具体支付比例和时间点详见附件。
四、工作计划和时间表乙方应在合同签订后的[具体天数]天内提交详细的工作计划和时间表，甲方在收到后的[具体天数]天内提出意见或确认。
五、质量保证和验收标准乙方应保证所有工作符合行业标准和甲方的特定要求。
项目完成后，甲方有权进行验收，并在接受前提出必要的修改建议。
六、变更和调整任何对原合同内容的变更或调整都需双方书面同意。
变更可能导致合同金额和/或时间表的调整。
七、违约责任违反合同条款的一方需承担相应的违约责任，包括但不限于赔偿对方因此遭受的损失。
八、争议解决双方应通过友好协商解决合同执行过程中的任何争议。
如果协商不成，可提交至[指定仲裁机构]进行仲裁。
九、其他条款包括但不限于保密协议、知识产权保护、不可抗力条款等，双方可根据具体情况协商确定。
十、生效和终止本合同自双方签字盖章之日起生效，直至项目完成并通过甲方验收后终止。
---Contract asic Information- arty A (Client): [Name of arty A]- arty (Contractor): [Name of arty ]- Date of Signing: [Date]- roject Name: [roject Name]- roject Location: [roject Location]urose and Scoe of the ContractThis contract aims to clarify the resonsiilities, rights, and oligations of oth arties regarding the construction, management, and maintenance of the [roject Name] roject. The scoe includes ut is not limited to design, construction, material suly, and roject management.Contract Amount and ayment Method- Total Contract rice: [Total Contract rice]- ayment Terms: ayment shall e made in stages according to the rogress of the roject, with secific ayment ratios and time oints detailed in the annex.Work lan and Timetalearty shall sumit a detailed work lan and timetale within [secific numer of days] after the signing of the contract. arty A shall rovide comments or confirmation within [secific numerof days] uon receit.Quality Assurance and Accetance Criteriaarty shall ensure that all work meets industry standards and arty A's secific requirements. Uon comletion, arty A has the right to conduct accetance and roose necessary modifications efore accetance.Changes and AdjustmentsAny changes or adjustments to the original contract contents require written consent from oth arties. Changes may lead to adjustments in the contract amount and/or timetale. Liaility for reach of ContractThe arty reaching the contract terms shall ear the corresonding liaility for reach, including ut not limited to comensation for losses suffered y the other arty.Disute ResolutionAny disutes arising during the execution of the contract shall e resolved through friendly consultation etween the arties. If consultation fails, the disute may e sumitted to [secified aritration institution] for aritration.Other TermsIncluding ut not limited to confidentiality agreements, intellectual roerty rotection, force majeure clauses, etc., which may e determined through negotiation ased on secific circumstances.Effectiveness and Termination。
工程合同中英双语
工程合同中英双语【合同名称】Contract Name: 建设工程合同Construction Contract【甲方（发包方）】arty A (Emloyer): ______________________【乙方（承包方）】arty (Contractor): ______________________鉴于甲乙双方根据平等自愿的原则，就以下工程项目的施工达成如下协议：Whereas arty A and arty have reached the following agreement ased on the rincile of equality and voluntariness regarding the construction of the roject elow:第一条合同项目及范围Article 1 Scoe of the Contract roject1.1 本合同项目为[具体项目名称]，位于[具体地点]。
The contract roject is [secific roject name], located at [secific location].1.2 工程范围包括[详细描述工程内容和范围]。
The scoe of the roject includes [detailed descrition of the roject content and scoe].第二条合同金额Article 2 Contract Amount2.1 本合同总金额为[金额数额]人民币/美元。
The total amount of this contract is [amount in RM/USD].2.2 合同金额包含所有施工成本及乙方预期利润。
The contract amount covers all construction costs and arty 's exected rofits.第三条工期要求Article 3 Construction eriod Requirements3.1 工程开工日期为[具体日期]，竣工日期为[具体日期]。
英文版工程合同
英文版工程合同合同标题：ENGINEERING CONTRACT甲方（Emloyer）： [公司名称]乙方（Contractor）： [公司名称]合同编号：[合同编号]签订日期：[签订日期]项目地点：[项目地点]鉴于甲方希望委托乙方进行[具体工程名称]的设计、施工及竣工工作，乙方愿意接受此项工作，双方经协商一致，达成如下合同条款：I. 合同目的本合同旨在规定甲乙双方在[具体工程名称]项目中的权利、义务和责任，以确保工程质量、进度和投资控制符合预期目标。
II. 合同范围1. 设计服务：乙方需根据甲方提供的规范和要求，完成工程设计工作。
2. 施工服务：乙方负责工程项目的施工管理，确保工程按图施工，质量达到行业标准。
3. 竣工验收：乙方需按照约定的标准和程序完成工程竣工，并协助甲方进行验收工作。
III. 合同价格合同总价为[合同金额]美元，包括所有设计、施工、材料、人工和管理费用。
IV. 付款方式1. 预付款：甲方需在合同签订后[天数]天内支付合同总价的[百分比]作为预付款。
2. 进度款：根据工程进度和完成的工作量，乙方可向甲方申请进度款。
3. 竣工款：工程竣工验收合格后，甲方应支付剩余的合同款项。
V. 工期与进度1. 工程开工日期为[开工日期]，竣工日期为[竣工日期]。
2. 乙方需提交详细的工程进度计划，并定期更新进度报告。
VI. 质量保证1. 乙方必须遵守所有相关的建筑法规和标准，确保工程质量。
2. 如发生质量问题，乙方应及时修复并承担相应责任。
VII. 变更与调整任何对工程范围、价格或工期的变更，都需双方书面同意后方可执行。
VIII. 争议解决如双方在合同执行过程中发生争议，应首先通过友好协商解决；协商不成时，可提交至[指定的仲裁机构]进行仲裁。
IX. 法律适用本合同的签订、解释、执行和争议解决均适用[指定国家或地区的法律]。
X. 其他条款1. 保密条款：双方应对合同内容及相关信息保密。
2. 终止条款：在特定条件下，任一方均可提前终止合同。
工程合同英汉版
工程合同英汉版合同编号：[合同编号]合同名称：[工程名称]甲方（业主）：[甲方全称]乙方（承包商）：[乙方全称]鉴于甲乙双方本着平等自愿、诚实信用的原则，就[具体工程项目描述]达成如下协议：一、合同目的本合同旨在规范甲乙双方的权利与义务，确保工程顺利进行，并按照约定完成。
二、工程概况1. 工程地点：[详细地址]2. 工程规模：[具体规模描述]3. 工程内容：[详细内容描述]4. 工程质量：应符合国家相关标准及甲方要求。
三、合同金额合同总价为人民币[金额]元/美元[金额]，包含所有材料费、人工费、管理费等。
四、支付方式1. 预付款：合同签订后，甲方需支付总金额的[百分比]%作为预付款。
2. 进度款：根据工程进度，甲方应按合同约定支付相应款项。
3. 竣工款：工程完工并通过验收后，甲方应在规定时间内支付剩余款项。
五、工期要求工程开工日期为[具体日期]，竣工日期为[具体日期]。
除非双方另有书面约定，或因不可抗力因素影响，否则乙方应按时完成工程。
六、违约责任如一方未能履行合同义务，应承担违约责任，并赔偿对方因此造成的损失。
七、争议解决因执行本合同所发生的一切争议，双方应通过友好协商解决；协商不成时，可提交至甲方所在地人民法院诉讼解决。
八、其他条款1. 保密条款：双方应对合同内容及合作过程中获知的信息保密。
2. 变更和解除：任何一方提出变更或解除合同，应及时通知对方，并经双方协商一致。
3. 附件：本合同的附件是合同不可分割的一部分，与本合同具有同等法律效力。
九、合同生效本合同自双方授权代表签字盖章之日起生效。
十、合同文本本合同一式两份，甲乙双方各执一份，具有同等法律效力。
合同英文版与中文版如有不一致之处，以中文版为准。
甲方代表（签字）：_____________ 日期：____年__月__日乙方代表（签字）：_____________ 日期：____年__月__日。
xxx工程合同中英文版
主合同文本使用说明：1、本合同适用于与业务相关的所有签约事宜；2、本合同书中空白部分由当事人根据实际情况进行填写，当事人使用本合同书时约定无需填写的条款，应在该条款处注明“无”等字样；3、未尽事项，可由当事人附页另行约定，并可作为本合同的组成部分。
This Term Sheet ("TS") is entered into on [DD MMM YYYY] between Party A and Party B (as respectively defined below) and sets out the key terms relating to the Proposed Transaction (as defined below). The key terms set out herein shall form the basis of the definitive agreements("Definitive Agreements') to be negotiated and entered into between the Parties in relation to the Proposed Transaction此协议（以下称“本协议“）于【】年【】月【】日，由甲方与乙方签署 (”甲方”与“乙方”的定义在以下的协议内容明细)，明确相关单位就本协议的具体投资条款清单。
本协议的条款将作为日后双方协商以及签署的投资合同（以下称“合同“）的基础。
xxx engineering contractxxx工程合同Contract No.:合同编号：Party A: xxxCompany Limited甲方：xxx有限公司Party B:xxx Company Limited乙方：xxx有限公司This contract is made and entered into on the day of , 2014 by the following Parties in . 本合同于2014年月日由以下当事方在签署。
中英文版施工合同-xxx工程合同中英文版
中英文版施工合同-xxx工程合同中英文版甲方（业主）： [Party A (Owner)]乙方（承包商）： [Party B (Contractor)]第一部分：合同条款第一条工程概况1.1 工程名称：[Name of the Project]1.2 工程地点：[Location of the Project]1.3 工程范围：[Scope of the Project]1.4 工程内容：[Content of the Project]第二条合同价格2.1 合同总价：[Total Contract Price]2.2 价格调整：[Price Adjustment]第三条工程质量3.1 质量标准：[Quality Standards]3.2 质量保证：[Quality Assurance]第四条工程进度4.1 开工日期：[Commencement Date]4.2 竣工日期：[Completion Date]4.3 进度计划：[Progress Schedule]第五条工程变更5.1 变更通知：[Change Notification]5.2 变更费用：[Change Costs]第六条工程验收6.1 验收标准：[Acceptance Standards]6.2 验收程序：[Acceptance Procedures]第七条付款方式7.1 预付款：[Advance Payment]7.2 进度款：[Progress Payment]7.3 最终结算：[Final Settlement]第八条违约责任8.1 违约定义：[Definition of Breach]8.2 违约赔偿：[Compensation for Breach]第九条争议解决9.1 争议解决方式：[Dispute Resolution Method]9.2 适用法律：[Applicable Law]第十条其他条款10.1 保密协议：[Confidentiality Agreement]10.2 合同变更：[Contract Modification]10.3 合同终止：[Contract Termination]第二部分：附加条款[Additional Clauses as per the specific requirements of the project]第三部分：签字页甲方（业主）代表签字：[Signature of Party A's Representative]乙方（承包商）代表签字：[Signature of Party B's Representative]日期：[Date]Construction ContractContract No.: [Contract No.]Date of Contract: [Date of Contract]Party A (Owner): [Party A (Owner)]Party B (Contractor): [Party B (Contractor)] Part I: Contract TermsArticle 1: Project Overview1.1 Project Name: [Name of the Project]1.2 Project Location: [Location of the Project] 1.3 Project Scope: [Scope of the Project]1.4 Project Content: [Content of the Project]Article 2: Contract Price2.1 Total Contract Price: [Total Contract Price] 2.2 Price Adjustment: [Price Adjustment]Article 3: Project Quality3.1 Quality Standards: [Quality Standards]3.2 Quality Assurance: [Quality Assurance]Article 4: Project Schedule4.1 Commencement Date: [Commencement Date]4.2 Completion Date: [Completion Date]4.3 Progress Schedule: [Progress Schedule]Article 5: Project Changes5.1 Change Notification: [Change Notification]5.2 Change Costs: [Change Costs]Article 6: Project Acceptance6.1 Acceptance Standards: [Acceptance Standards]6.2 Acceptance Procedures: [Acceptance Procedures]Article 7: Payment Method7.1 Advance Payment: [Advance Payment]7.2 Progress Payment: [Progress Payment]7.3 Final Settlement: [Final Settlement]Article 8: Liability for Breach of Contract8.1 Definition of Breach: [Definition of Breach]8.2 Compensation for Breach: [Compensation for Breach]Article 9: Dispute Resolution9.1 Dispute Resolution Method: [Dispute Resolution Method] 9.2 Applicable Law: [Applicable Law]Article 10: Other Terms10.1 Confidentiality Agreement: [Confidentiality Agreement] 10.2 Contract Modification: [Contract Modification]10.3 Contract Termination: [Contract Termination]Part II: Additional Terms[Additional terms as per the specific requirements of the project]Part III: Signature PageSignature of Party A's Representative: [Signature of Party A's Representative]Signature of Party B's Representative: [。
xxx工程合同中英文版 (2)
xxx engineering contract xxx工程合同Contract No.:合同编号：Party A: xxxCompany Limited甲方：xxx有限公司Party B:xxx Company Limited乙方：xxx有限公司This contract is made and entered into on the day of , 2014 by the following Parties in .本合同于2014年月日由以下当事方在签署。
Party A: xxx Company Limited,甲方：xxx有限公司，xxx经营的公司，住所地为xxx，（下称“甲方”），法定代表人：xxxParty B:xxx Company Limited,乙方：xxx有限公司，一家xxx经营的公司，注册地址是：xxx，（下称“乙方”），法定代表人：xxxParty A and Party B are called by a joint name of Both Parties under this contract, each of which is called as A Party.甲方和乙方在本合同项下统称为“双方”，单独称为“一方”。
1. Work Content and Requirements1. 工作内容、要求1.1 In accordance with the items stipulated in this Contract, Party B shall conduct the project as per the Projectstandard and quality standard stipulated by Ministry of Engineering of the Union of xx.1.1 依据本合同所限定的条款，乙方应以xx工程部规定的建筑标准和质量要求执行本工程。
中英文工程合同模板
中英文工程合同模板---工程合同（中英文对照）Engineering Contract (Chinese-English ilingual)甲方（客户）：___________arty A (Client): ___________乙方（承包商）：___________arty (Contractor): ___________鉴于甲乙双方同意按照以下条款和条件进行合作，特此签订本合同：Whereas arty A and arty agree to collaorate under the terms and conditions set forth elow, this contract is herey estalished:第一条：合同目的Article 1: urose of the Contract本合同旨在规定甲乙双方就_________工程项目（以下简称“本工程”）的权利、义务与责任。
This contract is made for the urose of stiulating the rights, oligations, and liailities of oth arties concerning the engineering roject named _________ (hereinafter referred to as "the roject").第二条：工程描述Article 2: Descrition of the roject乙方应按照甲方提供的技术规格和要求，完成本工程的设计、施工及相关服务。
arty shall comlete the design, construction, and related services for the roject in accordance with the technical secifications and requirements rovided y arty A.第三条：合同价格Article 3: Contract rice本工程的总合同价为___________元人民币（或美元），具体支付方式如下所述。
xxx工程合同中英文版
xxx engineering contract xxx工程合同Contract No.:合同编号：Party A: xxxCompany Limited甲方：xxx有限公司Party B:xxx Company Limited乙方：xxx有限公司This contract is made and entered into on the day of , 2014 by the following Parties in .本合同于2014年月日由以下当事方在签署。
Party A: xxx Company Limited,甲方：xxx有限公司，xxx经营的公司，住所地为xxx，（下称“甲方”），法定代表人：xxxParty B:xxx Company Limited,乙方：xxx有限公司，一家xxx经营的公司，注册地址是：xxx，（下称“乙方”），法定代表人：xxxParty A and Party B are called by a joint name of Both Parties under this contract, each of which is called as A Party.甲方和乙方在本合同项下统称为“双方”，单独称为“一方”。
1. Work Content and Requirements1. 工作内容、要求1.1 In accordance with the items stipulated in this Contract, Party B shall conduct the project as per the Projectstandard and quality standard stipulated by Ministry of Engineering of the Union of xx.1.1 根据本合同所限定的条款，乙方应以xx工程部规定的建筑标准和质量要求实行本工程。
xxx工程合同中英文版
xxx engineering contract xxx工程合同Contract No.:合同编号：Party A: xxxCompany Limited甲方：xxx有限公司Party B:xxx Company Limited乙方：xxx有限公司This contract is made and entered into on the day of , 2014 by the following Parties in .本合同于2014年月日由以下当事方在签署。
Party A: xxx Company Limited,甲方：xxx有限公司，xxx经营的公司，住所地为xxx，（下称“甲方”），法定代表人：xxxParty B:xxx Company Limited,乙方：xxx有限公司，一家xxx经营的公司，注册地址是：xxx，（下称“乙方”），法定代表人：xxxParty A and Party B are called by a joint name of Both Parties under this contract, each of which is called as A Party.甲方和乙方在本合同项下统称为“双方”，单独称为“一方”。
1. Work Content and Requirements1. 工作内容、要求1.1 In accordance with the items stipulated in this Contract, Party B shall conduct the project as per the Projectstandard and quality standard stipulated by Ministry of Engineering of the Union of xx.1.1 依据本合同所限定的条款，乙方应以xx工程部规定的建筑标准和质量要求执行本工程。
xxx工程合同中英文版最新修正版
xxx engineering contract xxx工程合同Contract No.:合同编号：Party A: xxxCompany Limited甲方：xxx有限公司Party B:xxx Company Limited乙方：xxx有限公司This contract is made and entered into on the day of , 2014 by the following Parties in .本合同于2014年月日由以下当事方在签署。
Party A: xxx Company Limited,甲方：xxx有限公司，xxx经营的公司，住所地为xxx，（下称“甲方”），法定代表人：xxxParty B:xxx Company Limited,乙方：xxx有限公司，一家xxx经营的公司，注册地址是：xxx，（下称“乙方”），法定代表人：xxxParty A and Party B are called by a joint name of Both Parties under this contract, each of which is called as A Party.甲方和乙方在本合同项下统称为“双方”，单独称为“一方”。
1. Work Content and Requirements1. 工作内容、要求1.1 In accordance with the items stipulated in this Contract, Party B shall conduct the project as per the Projectstandard and quality standard stipulated by Ministry of Engineering of the Union of xx.1.1 依据本合同所限定的条款，乙方应以xx工程部规定的建筑标准和质量要求执行本工程。
xxx工程合同中英文版-推荐
xxx engineering contract xxx工程合同Contract No.:合同编号：Party A: xxxCompany Limited甲方：xxx有限公司Party B:xxx Company Limited乙方：xxx有限公司This contract is made and entered into on the day of , 2014 by the following Parties in .本合同于2014年月日由以下当事方在签署。
Party A: xxx Company Limited,甲方：xxx有限公司，xxx经营的公司，住所地为xxx，（下称“甲方”），法定代表人：xxxParty B:xxx Company Limited,乙方：xxx有限公司，一家xxx经营的公司，注册地址是：xxx，（下称“乙方”），法定代表人：xxxParty A and Party B are called by a joint name of Both Parties under this contract, each of which is called as A Party.甲方和乙方在本合同项下统称为“双方”，单独称为“一方”。
1. Work Content and Requirements1. 工作内容、要求1.1 In accordance with the items stipulated in this Contract, Party B shall conduct the project as per the Projectstandard and quality standard stipulated by Ministry of Engineering of the Union of xx.1.1 依据本合同所限定的条款，乙方应以xx工程部规定的建筑标准和质量要求执行本工程。
xxx工程合同中英文版-精编.docx
xxx engineering contract xxx工程合同Contract No.:合同编号：Party A: xxxCompany Limited甲方：xxx有限公司Party B:xxx Company Limited乙方：xxx有限公司This contract is made and entered into on the day of , 2014 by the following Parties in .本合同于2014年月日由以下当事方在签署。
Party A: xxx Company Limited,甲方：xxx有限公司，xxx经营的公司，住所地为xxx，（下称“甲方”），法定代表人：xxxParty B:xxx Company Limited,乙方：xxx有限公司，一家xxx经营的公司，注册地址是：xxx，（下称“乙方”），法定代表人：xxxParty A and Party B are called by a joint name of Both Parties under this contract, each of which is called as A Party.甲方和乙方在本合同项下统称为“双方”，单独称为“一方”。
1. Work Content and Requirements1. 工作内容、要求1.1 In accordance with the items stipulated in this Contract, Party B shall conduct the project as per the Projectstandard and quality standard stipulated by Ministry of Engineering of the Union of xx.1.1 依据本合同所限定的条款，乙方应以xx工程部规定的建筑标准和质量要求执行本工程。
合同模板-中英文工程合同
Contract of Construction Project合约编号：Contract Number:工程名称：Project Name:发包方（合约甲方）：工程设计顾问（北京）Employer (Party A): International Consulting Engineers ( Beijing) Limited承包方（合约乙方）：中寰艺高建筑装饰工程有限责任公司Contractor (Party B): Zhong Huanyigao Building Decoration Engineering Co. , Ltd根据《中华人民共和国合约法》和《建筑安装工程承包合约条例》及有关规定，为明确双方在施工过程中的权利、义务和经济责任，经双方协商同意签订本合约。
In order to make definite of the rights, obligations and economic responsibilities of both parties during the construction, the parties, in accordance with The PRC Contract Law and Construction Engineering Contract Regulations and relevant provisions, agree to sign this contract.第一条工程项目Article 1, Project item1．工程地点：Project site:2. 工程范围：Scope of project3. 工程造价：人民币元整(该造价为包工包料价)Project cost: PMB Yuan only(Cost of this contract is the contract price for labor and materials)第二条施工准备Article 2, Preparation for construction1．合约甲方协助合约乙方办理临时水电及垂直运输,提供建筑图纸及有关隐蔽障碍物的资料。
工程施工合同中英文版
编号：_______________本资料为word版本，可以直接编辑和打印，感谢您的下载工程施工合同中英文版甲方：___________________乙方：___________________日期：___________________Construction ContractPO No.: XXXXXXXBuyer:. Date of signature:甲方：签约日期：Seller:乙方：This Purchase Order is made by and between the Buyer and the Seller: Whereby the Buyer agrees to buy and the Seller agrees to sell the under mentioned commodity according to the terms and conditions stipulated below: 甲乙双方经友好协商，一致就供应下列产品，达成如下条款：1. Scope of Supply and Price工作范围及价格明细2. Technical Requirement, Quality Requirement, Standard & Warranty Period:Seller shall carried out the construction in strict accordance with the National Standard andthe requirements stipulated in the Technical Agreement No.which both party signed (see attached documents). The warranty period shall be 1 year after placement of Goods in service.技术要求、质量要求、技术标准和质保期限：按国家标准和双方签定的技术协议(编号：附件)施工，质保期为投产后1年。
- 1、下载文档前请自行甄别文档内容的完整性，平台不提供额外的编辑、内容补充、找答案等附加服务。
- 2、"仅部分预览"的文档,不可在线预览部分如存在完整性等问题,可反馈申请退款(可完整预览的文档不适用该条件!)。
- 3、如文档侵犯您的权益，请联系客服反馈,我们会尽快为您处理(人工客服工作时间：9:00-18:30)。
xxx engineering contract XXX工程合同
Contract No.:
合同编号：
Party A: xxxCompany Limited
甲方：xxx有限公司
Party B:xxx Company Limited
乙方：xxx有限公司
本合同于2014年月日由以下当事方在签署。
Party A: xxx Compa ny Limited,
甲方：xxx有限公司，xxx经营的公司，住所地为xxx，（下称“甲方”），法定代表人：xxx
Party B: xxx Company Limited ,
乙方：xxx有限公司，一家 xxx经营的公司，注册地址是：xxx，（下称“乙方”），法定代表人：xxx Party A and Party B are called by a joint n ame of Both Parties un der this con tract, each of which is called as A Party.
甲方和乙方在本合同项下统称为“双方”，单独称为“一方”。
1. Work Content and Requirements
1. 工作内容、要求
1.1 In accorda nce with the items stipulated in this Con tract, Party B shall con duct the project as per the Project
sta ndard and quality sta ndard stipulated by Mini stry of Engin eeri ng of the Union of xx.
1.1 依据本合同所限定的条款，乙方应以xx工程部规定的建筑标准和质量要求执行本工程。
2. Contract Period
2. 合同期限
2.1 Work period for the Road Con struct ion Project: the work shall be completed with in 2 month upon sig
ning the Con tract. The con diti on of han dover is that the Project In specti on &Accepta nce Team con stituted by Party A, shall issue the In spect ion &Accepta nce Sheet after on site in spect ion.
2.1 本次工程时间周期：合同签订后14个工作日内完成，并以甲方组成的竣工验收小组现场检验并出具
验收单为竣工交接条件。
2.2 This con tract shall be impleme nted after this is duly sig ned by the legal represe ntatives or authorized
represe ntatives of the Parties and stamped with the seals of the Parties, and closed after the on site accepta nce of the Project and Con tract payme nt.
2.2 本合同自双方法定代表人或授权代表人签字盖章后生效，现场验收合格、款项支付完毕后关闭。
3. Health, Safety and En viro nment Prin ciples （HSE）
3. 健康、安全和环境原则（HSE）
3.1 The staff from Party B shall follow the arrangement of Local government and Party A （or its represe
ntatives）, and comply with the laws and regulatio ns of Myanmar as well as rules and regulati ons on Health, Safety and Environmen t （HSE） of Party A.
3.1 乙方工作人员必须听从地方政府、甲方人员（或代表）的安排，遵守缅甸法律、法规和甲方的安全环境健康规章
制度等。
3.2 Before or duri ng the impleme ntati on of this Project, Party B shall ack no wledge, avoid and preve
nt the possible damage of the Project to the surrounding environment and other affiliated facilities, and the result ing losses shall be borne by Party B.
3.2 在工程实施之前或进行当中，乙方应识别工程可能对周边环境及原有设施造成的危害，应进行规避和防护，对由此带来
的损失，应由乙方承担。
3.3 During the performa nee of this Con tract, Party B shall bear the pers onal and property losses of Party B
or Party B 's personnel injury bself, if the losses are not caused by Party A.
3.3 在合同履行过程中，若发生非甲方原因导致的乙方或乙方人员人身或财产损失的，由乙方自行承担。
4. Contract Price, Payment and Taxes
4. 合同价格、付款事宜及税费
4.1 As per the stipulated con structi on conten ts, both Parties agree that this Con tract is a lump sum con tract. The con tract payme nt in cludes all con struct ion costs and related cost for con struct ion preparatio n and con struct ion impleme ntatio n .Please refer to the follow ing table for the details
4.1 按照本合同所确定的工程内容，甲方与乙方确定本次马德岛岗亭工程为费用总包合同，合同费用包
含全部工程施工费用及其他与工程准备、工程执行相关的费用。
详见下表
The total amount:
费用合计：XXX美金
4.2 The Con tract shall be valued in USD, and the payme nt shall be settled in equivale nt value of KYAT. The
excha nge rate shall be at the spot excha nge rate from USD to KYAT on the day of payme nt by the han dli ng bank of Party A. Un less otherwise specified by Party B and agreed by Party A, Party A shall only con duct payment in accordance with the bank account of Party B agreed in this contract.Party B shall be responsible for the authe nticity, safety and accuracy of its desig nated acco unt in formati on. If Party A fails to pay or
delays payment due to the causes of Party B 's account, all responsibilities and consequences hereof shall b
undertaken by Party B itself. The account information assigned by Party B is as follows:
4.2 本合同以美金计价，以美元或等值缅币结算。
汇率为付款银行付款当天美元兑缅币的即时汇率。
除
非乙方有特别说明并经甲方同意，甲方仅按本合同约定的乙方银行帐号付款，乙方应对其指定的账户信息真实性、安全性、准确性负责。
因乙方账户的原因造成甲方不能付款或付款迟延的，由此引起的一切责任及后果由乙方自己承担。
乙方指定的账户信息如下：。