建设工程委托设计合同(中英文对照)
建设工程设计合同,中英文
建设工程设计合同,中英文篇一：建设工程设计合同(中英文对照版)建设工程设计合同（二）（专业建设工程设计合同）Engineering Service Contract (Ⅱ)(Professional Engineering Service Contract For Construction Project)工程名称：工程地点:合同编号：（由设计人编填）设计证书等级：发包人：设计人：签订日期:Name of the project:Location of the project:Contract No.:(Filled in by the Designer)Level of the design certificate:Employer:Designer:Date of contract: November 25, XX监制中华人民共和国建设部国家工商行政管理部Supervised by: Jiangsu Provincial Department of ConstructionJiangsu Provincial Administration for Industry and Commerce发包人：设计人:发包人委托设计人承担______________________________工程设计，工程地点为_______________ ，经双方协商一致，签订本合同，共同执行。
Employer: (Party A)Designer: (Party B)The Employer entrust the Designer to undertake the engineering design of the 10/ transformer station and the location for the project is within the plant of After friendly consultation, the Parties hereby sign this Contract as follows：第一条本合同签订论据《中华人民共和国合同法》、《中华人民共和国建筑法》和《建设工程勘察设计市场管理规定》。
设计施工中英合同
设计施工合同（中英对照）合同编号：____________签订日期：____年__月__日甲方（委托方）：____________乙方（受托方）：____________根据《中华人民共和国合同法》、《中华人民共和国建筑法》、《中华人民共和国民法典》以及其他有关法律法规的规定，甲乙双方在平等、自愿、公平、诚信的原则基础上，就甲方委托乙方进行设计施工的事宜，达成如下协议：一、项目概述1.1 项目名称：____________1.2 项目地点：____________1.3 项目内容：____________二、设计施工范围及要求2.1 乙方根据甲方的委托，负责完成项目的初步设计、施工图设计、施工组织设计等工作。
2.2 乙方应按照甲方的要求和相关法律法规的规定，确保设计施工的质量、安全、进度和投资控制等目标的实现。
2.3 乙方应提供设计施工所需的所有技术文件和施工图纸，并保证其真实、完整、准确。
2.4 乙方应按照合同约定的时间和质量要求，完成设计施工任务。
三、合同价格及支付方式3.1 乙方向甲方提供的设计施工服务，合同总价为人民币（大写）：____________元整（小写）：____________元。
3.2 甲方支付乙方设计施工费用的进度，按照双方约定的时间节点进行。
3.3 甲方支付乙方设计施工费用的方式，采取以下第____________种方式：（1）一次性支付：甲方在合同签订后____个工作日内，向乙方支付合同总价。
（2）分期支付：甲方在设计施工进度达到约定的节点后，向乙方支付相应的设计施工费用。
四、合同履行及验收4.1 乙方应按照合同约定的时间节点，向甲方提交设计施工成果。
4.2 甲方应按照合同约定的时间节点，对乙方提交的设计施工成果进行验收。
4.3 甲方对乙方提交的设计施工成果验收不合格的，乙方应按照甲方的要求进行整改，并重新提交。
4.4 甲方对乙方提交的设计施工成果验收合格的，甲方应向乙方支付合同约定的设计施工费用。
工程设计委托合同 (中英文)
工程设计委托合同（中英文）CONTRACT FOR CONSTRUCTION DESIGN客户方：设计方：双方本着公平、自愿和诚信的原则，经友好协商达成如下条款（包括基本条款以及其他条款两个部分）： Under the principles of fairness, free will and good will, IT IS HEREBY AGREED between both parties as follows (the Contract includes two parts, i.e. the General Articles and the Contingent Articles):-1.客户方委托设计方提供的建筑设计服务均以本合同各项条款、附录、附表以及双方为履行本合同相关内容所签订的补充协议等所约定的内容为准，设计方应按照双方的约定和客户方的要求完成― A‖工程设计的各项工作。
本合同的附录、附表、其他条款以及补充协议等附件是本合同不可分割的部分，具有与本协定书同等的法律效力。
The architectural design services that the Client appoints the Designer to provide shall be in compliance with the provisions, appendixes and exhibits of the Contract, as well as with the provisions in the supplementary agreements in conjunction with the execution of the Contract that have entered or may be entered between the parties. The Designer shall carry out the design tasks for ―A‖ Project according to the agreement between both parties as well as the requirements of the Client. Appendixes, exhibits, other articles and supplementary agreements of the Contract are integral part of the Contract, and shall have the same legal binding force with the Contract.2.客户方委托设计方为― A‖工程提供的详细设计服务项目全部列于本合同附表2——《设计服务项目清单》中，同时设计方承诺按照该附表中客户方的要求提供列明的全部服务项目。
2019年建设工程设计合同(中英文)-secret
建设工程设计合同Construction Project Design Contract项目名称：Project Name:项目建设地点：Project Location:合同编号：Contract No.:设计证书等级：Grade of Design License:委托方：Client:承接方：Design Firm:签订日期：Signed on:委托方（甲方）：Client (Party A):承接方（乙方）：Design Firm (Party B):甲方委托乙方承担XX项目（一期）工程设计,经双方协商一致,签订本合同. Party A entrusts Party B to undertake the design for . This Contract is made by the two parties after their mutual agreement.第一条本合同依据下列文件签订Article1. This Contract is made on the basis of the following documents:1.1《中华人民共和国合同法》、《中华人民共和国建筑法》和《建设工程勘察设计市场管理规定》.1.1 The Contract Law of the People’s Republic of Chin, The building regulations of the People’s Republic of China and The developmental Law of the People’s Republic of China.1.2国家及地方有关建设工程勘察设计管理法规和规章.1.2 Relevant Building & Design Codes and Regulations of the State and of the Shanghai Municipality.1.3建设工程的相关批准文件.1.3 The approval documents that are required for this construction project.第二条本合同工程设计项目的名称、地点、规模、投资、内容及标准Article2. The name, location, size, investment sum, function, design contents and standards:2.1工程项目的名称：XX项目（一期）2.1 Project name:2.2工程项目的地点：2.2 Project location:2.3工程项目的规模：总建筑面积约平方米（其中地下面积约平方米）,高度米.2.3 Project size: The total floor area is approximately ㎡(of which the floor area of the underground area is ㎡), the total height is ｍ.2.4工程特征及附注说明：商业办公综合楼2.4 Project features & remarks: A commercial cum office building complex2.5工程项目的投资总额：控制在 亿元人民币以下2.5 Project investment in total: Controlled Within million yuan RMB2.6工程项目的设计内容及标准：红线内的建筑、结构、机电、总体设计（包括3000㎡人防设计,不包括精装修设计、园艺设计和艺术泛光照明等专业设计）,施工图设计约为70000㎡（不包括五层到七层的SOHO 区域）.2.6 Design requirements and scope of work: The scope of work shall include master planning and building design that are located within the boundary line. For building design it shall comprise of the architectural, structural & M/E work. (including 3,000㎡of Air-raid shelter design, but excluding other specialists’ design, such as the Luxurious Interior Design, Landscaping Design and Facade Flood Lighting Design). The total floor area during the working drawing stage is 70,000㎡(excluding the SOHO Area, which is starting from the fifth floor level to the seventh floor level).第三条 甲方向乙方提交的有关资料及文件（见下表）Article3. Relevant documents which shall be issued by Party A to Party B:第四条乙方向甲方交付的设计文件（见下表）Article4. Design documents which shall be submitted by Party B to Party A (listed as follows):注：设计文件深度按照《建筑工程设计文件编制深度规定》（建设部2003年4月版）执行. Notes: The design documents shall be prepared in compliance with the Regulations on detailrequirements of design documents for construction project (issued by Ministry of construction dated in April, 2003).第五条设计费用及支付方法Article 5. Design fee and the mode of payment:5.1甲方应支付本合同项目的设计费为.（含所有乙方应缴纳的税费及其它政府规定应由乙方交纳的款项）5.1 Party A shall pay the design fee of RMB yuan for this project to Party B (this fee shall include taxes and all other duties that should be paid by Party B as required by the government regulations).5.2支付方法（见下表）：5.2 The payment method is (listed as the following):第六条双方责任Article6. Responsibilities of both parties:6.1甲方责任6.1 Responsibilities of Party A:6.1.1甲方按本合同第三条规定的内容,在规定的时间内向乙方提交资料及文件,并对其完整性、正确性及时限负责.甲方提交上述资料及文件超过规定期限15天以内,乙方按本合同第四条规定交付设计文件时间顺延；超过规定期限15天以上时,乙方有权重新确定提交设计文件的时间.6.1.1 According to the contents stated in Article 3 of this Contract, Party A shall submit materials and documents to Party B within the stipulated time as described and shall be responsible for the completeness, correctness and validity of such materials and documents. In the event that Party A has delayed the issuance of such materials and documents, but not exceeding 15 days from the stipulated time, Party B could consequently postpone the submittal of the design documents as stipulated in Article 4 of this Contract. In case that Party A has delayed the issuance of materials and documents for more than 15 days exceeding the stipulated time limit, Party B shall have the right to determine the new date for submitting the design documents.6.1.2甲方变更委托设计项目、规模、条件,或对提交资料作重大修改,以致造成乙方设计需返工时,双方除需另行协商签订补充合同、重新明确有关条款外,甲方应按乙方所耗工作量向乙方支付返工费.6.1.2 If Party A alters greatly the design project, scale, conditions which they have already entrusted to Party B, or the materials provided by Party A is wrong/incompleteor Party A makes major alterations to the approved design and the information given, as a result of which, has caused Party B to redo the design work, or has generated un-necessary abortive works, both parties shall enter into negotiation and to draw up a supplementary contract. Party A shall compensate Party B for the additional work load in accordance to the new agreement.6.1.3在合同履行期间,甲方单方提出解除合同的,乙方已开始设计工作的,甲方应根据乙方已进行的实际工作量支付设计费.6.1.3 Should Party A terminate the Contract during the contractual period, Party A shall pay Party B according to the actual work done.6.1.4甲方在收到乙方付款通知书后30天内,按本合同第五条规定的金额和时间向乙方支付设计费用；在收到付款通知书的60天仍未支付,每逾期支付一天,应承担应支付金额千分之一的逾期违约金.逾期超过30天以上时,乙方有权暂停履行下阶段工作,并书面通知甲方.甲方上级对设计文件部审批或本合同项目停缓建,甲方均应支付应付的设计费.6.1.4 Party A shall pay the design fee to Party B within Thirty (30) days upon receiving the Notice of Payment from Party A according to the amount and the time stipulated in Article 5. In case that such payment is delayed for Sixty (60) days upon receiving the Notice of Payment, then a penalty of 0.1% of the due amount of payment on a daily basis shall be paid by Party A. In case that such payment is delayed for a period over 30 days, Party B shall have the right to suspend their design work for the next phase and shall inform Party A in writing. In case that the management of Party A does not approve the design documents or the construction of the project of this Contract is stopped or.. postponed, Party A shall nevertheless pay the due design fee.6.1.5甲方要求乙方比合同规定时间提前提交设计文件时,甲方应支付赶工费. 6.1.5 If Party A requests Party B to submit the design documents ahead of the stipulated time as mentioned in the Contract, Party A shall make additional payment for fast and immediate service.6.1.6为一方派往现场的工作人员提供工作方便条件.6.1.6 Party A shall provide site office and all relevant office stationary for Party B’s personnel who are being sent to work site during the construction stage.6.1.7甲方应保护乙方的设计版权,未经乙方同意,甲方对乙方交付的设计文件不得复制或向第三方转让或用于本合同外的项目,如发生以上情况,乙方有权索赔.6.1.7 Party A shall protect the design copyright of Party B. Without Party B’s consent, Party A shall not duplicate of transfer to a third party or use the design documents for other projects. If the above-mentioned is happened, Party B shall have the right to claim.6.2乙方责任：6.2 Responsibilities of Party B:6.2.1乙方按本合同第四条规定的内容、时间及份数向甲方交付设计文件.6.2.1 Party B shall submit to Party A the required design documents in right content, time and copies according to the clause of Article 4.6.2.2乙方对设计文件出现的遗漏或错误应在施工前负责修改或补充.由于乙方设计错误造成工程质量事故损失,乙方除负责采取补救措施外,应免收损失部分的设计费,并根据损失程度向甲方偿付赔偿金,赔偿金额根据乙方与保险公司签订的设计责任保险合同计算.6.2.2 Party B shall be responsible for correcting any omission or mistake in their design documents before the construction. If the design mistake made by Party B has caused losses to Party A, Party B shall not only be responsible for taking the remedial measures, but also shall remit the design fee for the part of such losses and shall pay compensation to Party A according to the degree of such loss. The amount of the compensation shall be determined by party B and his insurance company and to be in accordance to the professional indemnity insurance coverage.6.2.3由于乙方自身原因,延误了按本合同第四条规定的设计文件交付时间,每延误一天,应减收该项目应收设计费的千分之一.6.2.3 If it is Party B’s own fault to have delayed the submission of the design documents according to the stipulated time as described in Article 4, Party B shalldeduct 0.1% of the due amount of the design fee on a daily basis for the delay period.6.2.4合同生效后,乙方单方提出解除合同的,乙方应当按照有关规定赔偿甲方损失.6.2.4 After the Contract comes into forces, if Party B proposes to terminate the Contract, Party B shall compensate Party A’s losses according to the releva nt regulations.6.2.5乙方交付设计文件后,应参加甲方及相关职能部门的设计审查会议及根据审查结论负责不超出原定计划任务书范围内的必要调整补充；负责向甲方及施工各单位进行设计交底,处理有关的设计问题和参加竣工验收.乙方应派相关人员参加施工期间的例会.乙方应优化设计以帮助业主将造价控制在预算内.6.2.5 After the design documents has been submitted, Party B shall also attend the approval meetings held by Party A and the relevant competent authorities and shall be responsible for making the necessary adjustments, revisions and supplements which does not exceed the scope of the documents of design requirements as originally defined based on the comments of such meetings. Party B shall be responsible for explaining design details to Party A and the main contractor; and shall be responsible for solving all the relevant design problems and to attend the handing over meeting. Party B shall send the relevant personnel to participate in the regular site meetings suring the construction. Party B should optimize the design to assist Party A in meeting the project budget.6.2.6乙方不得向第三方扩散、泄露、转让甲方提交的产品图纸、技术经济资料.如发生以上情况,甲方有权向乙方索赔.6.2.6 Party B is not allowed to disclose and transfer to a third party any product drawing, technical and economic data etc. which are provided by Party A. In case that the above-mentioned is happened, Party A shall have the right to claim.6.2.7未经甲方同意乙方不得将本项目的设计工作全部或部分转包给第三者.6.2.7 Party B is not allowed to subcontract the design work completely or partially to any third party without the permission of Party A.第七条其他约定Article7. Other provisions7.1甲方要求乙方派专人长期驻施工现场进行配合与解决有关问题时,双方应另行签订技术咨询服务合同.7.1 When Party A requires Party B to send site personnel to the construction site for a long period, the two parties shall negotiate for these additional work and sign a supplementary service Contract.7.2乙方为本合同项目所采用的国家或地方标准图,由甲方自费向有关出版部门购买.7.2 Party A shall pay for all the relevant publications and standard collections of drawings issued by the state and local government which are needed by Party B for the purpose of designing the project.7.3本合同第四条规定乙方交付的设计文件份数超过本合同第四条规定的份数,乙方另收工本费.7.3 If Party B is requested to submit design documents, of which, the number of copies are more than those stipulated in Article 4 of this Contract, Party A shall pay for those additional copies.7.4本工程项目中,建筑材料、设备的加工订货,甲方需要乙方设计人员配合时,所需费用由甲方承担.7.4 If Party A requires Party B to provide personnel to assist them for procurement purposes, such as the procurement of building material, equipments, etc.; the expenses needed shall be borne by Party A.7.5甲方委托乙方承担本合同内容之外的工作服务,另行支付费用.7.5 If Party A entrusts Party B to undertake those work and services which are beyond this Contract, Party A shall pay additional fee.7.6由于不可抗拒因素致使合同无法履行时,双方应及时协商解决.7.6 When this Contract can not be executed because of the unforeseeable natural forces, the two parities shall timely negotiate to solve the problem.7.7本建设工程设计合同在履行过程中发生纠纷,双方应及时协商解决.协商不成时,双方同意由上海市仲裁委员会仲裁.7.7 Both parties shall timely discuss each other for the settlement of any dispute arising during the execution of this Contract. In case that such discussion fails, bothparties have agreed appealing to Shanghai Municipal Arbitration Commission can be accepted.7.8甲方聘请为甲方的顾问,协助甲方进行设计管理和建筑设计咨询.费用由甲方另行支付.7.8 Party A has engaged to act as Party A’s consultants to assist Party A to provide the management and design consultation services. The fee will be paid by Party A directly and separately.7.9本合同未尽事宜,双方可签订补充协议,补充协议与本合同具有同等效力.7.9 Supplementary agreement could be made between the two parties in case that any additional clause shall be added. The supplementary agreement shall have the same effect and power as this Contract.7.10本合同一式八份,甲执四份,乙执三份,政府部门一份.7.10 This Contract shall be made in 8 copies. Party A shall hold 4 copies. Party B shall hold 3 copies. The government authority department shall hold one copy.7.11本合同以中英对照书写,如有矛盾,应以中文文本为准.7.11 This Contract is prepared in both Chinese and English languages, in the event of conflicts in any of the provisions between the two versions; provisions specified in the Chinese language version shall take precedence.7.12本合同双方签章后,在30日内报项目所在地建设行政主管部门备案.双方认为必要时,到项目所在地工商行政管理部门签证.上方履行完合同规定的义务后,本合同即行终止.7.12 This Contract, within 30 days after it has been signed and stamped by both parties, shall be submitted to the local government authority for endorsement. When it is considered necessary, both parties could send this Contract to the local industrial and commercial administration departments for registration. This Contract is to be terminated and expired itself after both parties have performed their duties as stipulated in this Contract.7.13本合同经甲、乙双方盖章签字后自年月日生效.（以下无正文）7.13 This Contract shall come into force beginning from the date when both partieshave stamped it and signed it on month year .委托方单位名称： 承接方单位名称：（盖章） （盖章）Party A: Party B:(Stamp) (Stamp)单位地址： 单位地址：Address: Address:邮政编码： 邮政编码：Post Code: Post Code:电 话：电 话：Tel: Tel:电 传： 电 传：Fax: Fax:开户银行： 开户银行：Name of bank: Name of bank:银行账号： 银行账号：Bank account: Bank account:签订合同代表（签字）： 签订合同代表（签字）： Contract Signing Representative: Contract Signing Representative:本合同于 年 月 日签于上海.This Contract is signed in Shanghai on (date) (month) (year) . 法定代表人： 法定代表人：Legal Representative: Legal Representative:市勘察设计市场管理部门意见： 市勘察设计市场管理部门意见： （盖章） （盖章）备案日期： 签证日期：年 月 日 年 月 日。
建设工程设计合同协议书中英文6篇
建设工程设计合同协议书中英文6篇篇1本合同协议书由XXX（以下简称“委托方”）与YYY（以下简称“设计方”）签订，委托方委托设计方承担[项目名称]建设工程的设计工作，双方本着平等、自愿、公平、诚信的原则，经协商一致，签订本合同，以资信守。
一、工程概况1. 工程名称：[项目名称]2. 工程地点：[项目地点]3. 工程内容及规模：[项目内容及规模]4. 设计服务范围：[设计服务范围]二、合同双方的权利和义务（一）委托方的权利和义务1. 委托方应当向设计方提供必要的设计资料，包括但不限于：工程地质勘察报告、地形测量图、工程规划许可证等。
2. 委托方应当对设计方的工作进行监督，并提出合理的修改意见。
3. 委托方应当按照合同约定支付设计费用。
4. 委托方应当为设计方提供必要的工作条件，包括但不限于：办公场所、通讯设备等。
（二）设计方的权利和义务1. 设计方应当按照合同约定完成设计工作，并保证设计质量。
2. 设计方应当根据委托方的要求进行设计，并确保设计符合相关的规范和标准。
3. 设计方应当对设计成果进行自查，并确保设计成果无误。
4. 设计方应当对委托方提出的合理修改意见进行修改，并确保修改后的设计符合合同要求。
5. 设计方应当保护委托方的知识产权，并不得将设计成果用于其他用途。
三、合同价款及支付方式1. 本合同的设计费用为人民币[设计费用]元。
2. 委托方应当按照以下方式支付设计费用：（1）合同签订后，委托方向设计方支付设计费用的XX%；（2）设计成果经委托方确认后，委托方向设计方支付剩余的设计费用。
3. 委托方逾期支付设计费用的，应当按照逾期支付金额的XX%向设计方支付违约金。
四、违约责任1. 委托方违反本合同约定，未向设计方提供必要的设计资料或者未对设计成果提出合理意见的，应当承担相应的违约责任。
2. 设计方违反本合同约定，未按照合同要求完成设计工作或者设计质量不符合规范的，应当承担相应的违约责任。
3. 违约方应当赔偿因此给对方造成的全部损失。
建设工程合同中英文
建设工程合同中英文首先来看中文版部分：建设工程合同甲方（业主）：__________ 乙方（承包商）：__________鉴于甲方希望建立以下描述的工程项目，并愿意委托乙方进行施工，现双方遵循平等、自愿、公平和诚信的原则，就下列建设工程事宜达成如下协议：一、工程概况工程名称：__________工程地点：__________工程内容：__________工程造价：__________工程期限：自____年____月____日起至____年____月____日止二、工程质量乙方必须按照国家有关质量标准和规范，以及合同约定的技术要求进行施工，确保工程质量达到约定的标准。
三、工程进度乙方应根据合同约定的时间表，合理安排施工进度，确保按期完成工程建设任务。
四、付款方式甲方应按照合同约定，及时支付工程款项。
具体付款方式如下：（详细列出付款时间点、金额及条件）五、违约责任如一方违反合同约定，需承担违约责任，赔偿对方因此遭受的损失。
六、争议解决因履行本合同所产生的任何争议，双方应首先通过友好协商解决；协商不成时，可提交至甲乙双方所在地人民法院诉讼解决。
七、其他事项（根据具体情况约定其他相关事项）本合同一式两份，甲乙双方各执一份，自双方签字盖章之日起生效。
甲方代表（签字）：__________ 乙方代表（签字）：__________签订日期：____年____月____日接下来是英文版部分：Construction Contractarty A (Emloyer): __________ arty (Contractor): __________Whereas arty A wishes to estalish the construction roject descried elow and is willing to entrust arty with the construction work, the two arties, adhering to the rinciles of equality, voluntariness, fairness, and good faith, have reached the following agreement regarding the construction:I. roject Overviewroject Name: __________roject Location: __________roject Descrition: __________roject Cost: __________roject Duration: From ____ Year ____ Month ____ Day to ____ Year ____ Month ____ DayII. roject Qualityarty must construct according to relevant national quality standards and secifications, as well as technical requirements agreed uon in the contract, to ensure the roject quality meets the agreed-uon standards.III. roject Schedulearty shall arrange the construction schedule reasonaly according to the timetale agreed uon in the contract, ensuring the comletion of the construction on time.IV. ayment Methodarty A shall ay for the roject in accordance with the contract terms in a timely manner. The secific ayment methods are as follows:(Detailed listing of ayment milestones, amounts, and conditions)V. Liaility for reachShould one arty reach the contract, it shall ear the liaility for reach and comensate the other arty for any losses incurred as a result.VI. Disute ResolutionAny disutes arising from the erformance of this contract shall e resolved through friendly negotiation etween the arties; if negotiation fails, it may e sumitted to the eole's Court where oth arties are located for litigation.VII. Miscellaneous(Additional rovisions ased on secific circumstances)This contract is made in dulicate, with each arty holding one coy, effective uon signature and seal y oth arties.Reresentative of arty A (Signature): __________ Reresentative of arty (Signature): __________ Date of Signing: ____ Year ____ Month ____ Day。
建设工程设计合同(中英文对照版)示范文本
建设工程设计合同Construction Project Design Contract项目名称：Project Name:项目建设地点：Project Location:合同编号：Contract No.:设计证书等级：Grade of Design License:委托方：Client:承接方：Design Firm:签订日期：Signed on:委托方（甲方）：Client (Party A):承接方（乙方）：Design Firm (Party B):甲方委托乙方承担XX项目（一期）工程设计，经双方协商一致，签订本合同。
Party A entrusts Party B to undertake the design for . This Contract is made by the two parties after their mutual agreement.第一条本合同依据下列文件签订Article1. This Contract is made on the basis of the following documents:1.1《中华人民共和国合同法》、《中华人民共和国建筑法》和《建设工程勘察设计市场管理规定》。
1.1 The Contract Law of the People’s Republic of Chin, The building regulations of the People’s Republic of China and The devel o pmental Law of the People’s Republic of China.1.2国家及地方有关建设工程勘察设计管理法规和规章。
1.2 Relevant Building & Design Codes and Regulations of the State and of the Shanghai Municipality.1.3建设工程的相关批准文件。
建设工程设计合同(中英文)-secret(最新)
建设工程设计合同Construction Project Design Contract项目名称：Project Name:项目建设地点：Project Locatio n:合同编号：Con tract No.:设计证书等级：Grade of Desig n Lice nse:委托方：Clie nt:承接方：Desig n Firm:签订日期：Sig ned on:委托方(甲方)：Client (Party A):承接方(乙方)：Design Firm (Party B):築池網fhulong.Gom築池網fhulong.Gom 甲方委托乙方承担XX项目(一期)工程设计，经双方协商一致，签订本合同。
Party A en trusts Party B to un dertake the desig n for . This Con tractis madeby the two parties after their mutual agreeme nt.第一条本合同依据下列文件签订Articled This Con tract is made on the basis of the followi ng docume nts:1.1《中华人民共和国合同法》、《中华人民共和国建筑法》和《建设工程勘察设计市场管理规定》。
1.1 The Con tract Law of the Peoples Republic of Chin, The build ingregulati ons of the Peoples Republic of China and The developmental Law ofthe Peoples Republic of Chi na.1.2国家及地方有关建设工程勘察设计管理法规和规章。
1.2 Releva nt Build ing & Desig n Codes and Regulati ons of the State and ofthe Shan ghai Muni cipality.1.3建设工程的相关批准文件。
工程设计合同(中英文)6篇
工程设计合同(中英文)6篇篇1工程设计合同中文版甲方（客户）：_________乙方（设计单位）：_________根据《中华人民共和国合同法》及相关法律法规，甲乙双方在平等、自愿、协商一致的基础上，就甲方委托乙方进行工程设计事宜，达成如下协议：一、工程名称及地点工程名称：_________地点：_________二、设计内容1. 乙方需根据甲方需求，对_________工程进行设计。
2. 设计范围包括但不限于_________。
三、设计费用及支付方式1. 设计费用为人民币_________元整。
2. 甲方需在合同签订后_________日内支付设计费用的_________%作为预付款。
3. 乙方在收到预付款后开始进行设计工作。
4. 设计完成后，甲方需支付剩余的设计费用。
四、设计期限1. 乙方需在收到预付款后_________日内完成设计。
2. 如因甲方原因导致设计无法按时完成，乙方不承担任何责任。
五、违约责任1. 甲方如未按合同约定支付设计费用，需向乙方支付违约金，违约金为设计费用的_________%。
2. 乙方如未按合同约定完成设计，需向甲方支付违约金，违约金为设计费用的_________%。
六、争议解决1. 如双方在执行合同过程中发生争议，应首先通过友好协商解决。
2. 协商不成的，任何一方均可向有管辖权的人民法院提起诉讼。
七、其他约定事项1. 甲方如需对设计内容进行变更，需提前书面通知乙方，乙方根据变更内容调整设计。
2. 本合同一式两份，甲乙双方各执一份。
本合同自双方签字盖章之日起生效。
3.未尽事宜，由双方协商补充。
甲方（签字/盖章）：_________日期：_________年_________月_________日乙方（签字/盖章）：_________日期：_________年_________月_________日英文版Party A (Client): _________Party B (Design Unit): ___________According to the Contract Law of the People's Republic of China and relevant laws and regulations, both parties, on the basis of equality, voluntariness, and mutual consent, have reached the following agreement on Party A entrusting Party B to carry out engineering design:I. Project Name and LocationProject Name: _________Location: _________II. Design Content1. Party B needs to design the _________ project according to Party A's needs.2. The design scope includes but is not limited to ___________.III. Design Fee and Payment Method1. The design fee is RMB _________ yuan.篇2工程设计合同中文版甲方（委托人）：乙方（受托人）：根据《中华人民共和国合同法》及相关法律法规的规定，甲乙双方在平等、自愿、协商一致的基础上，就甲方委托乙方进行工程设计事宜，达成如下协议：一、工程概况1. 工程名称：2. 工程地点：3. 工程规模：二、设计内容1. 乙方需按照甲方的需求，提供工程的设计方案。
工程建设的合同中英
工程建设的合同中英---Construction Contract甲方（Emloyer）： [Full Name]地址（Address）： [Address]乙方（Contractor）： [Full Name]地址（Address）： [Address]鉴于甲乙双方同意按照以下条款和条件进行合作，现就[roject Name]工程项目达成如下合同：I. roject Details1. 工程名称（Name of the roject）： [roject Name]2. 工程地点（Location of the roject）： [Location]3. 工程范围（Scoe of Work）： [Detailed Descrition]4. 工期（Duration of the roject）： [Start Date] to [End Date]5. 合同金额（Contract Sum）： [Amount in Numer and Currency]II. Resonsiilities of the Emloyer1. 提供必要的工程资料和施工场地。
2. 按合同约定支付工程款项。
3. 协助解决施工过程中的问题。
III. Resonsiilities of the Contractor1. 按合同要求完成工程建设任务。
2. 保证工程质量符合标准。
3. 及时通报工程进度和存在的问题。
IV. ayment Terms1. 工程款支付方式：[Detailed ayment Method]2. 进度款支付条件：[Detailed rogress ayment Conditions]3. 最终款项结算：[Detailed Final ayment Settlement]V. Default and enalties1. 如甲方违约，应按合同规定承担相应责任。
2. 如乙方违约，应按合同规定承担相应责任。
VI. Disute Resolution任何争议应首先通过友好协商解决，协商不成可提交至[Aritration or Court Name]解决。
建设工程设计合同文本中英文对照
建设工程设计合同文本中英文对照一、合同目的与范围Ojective and Scoe of the Contract:本合同的目的是明确甲乙双方在建设工程设计项目中的权利、义务和责任。
合同范围涵盖了从初步设计到施工图纸的所有阶段。
The urose of this contract is to clarify the rights, oligations, and resonsiilities of oth arties in the construction engineering design roject. The scoe of the contract covers all stages from reliminary design to construction drawings.二、设计要求与标准Design Requirements and Standards:乙方需根据甲方提供的要求和相关法规标准，完成工程设计任务。
设计成果应满足功能需求、安全规范和审美标准。
arty shall comlete the engineering design tasks in accordance with the requirements rovided y arty A and relevant regulatory standards. The design results should meet functional needs, safety secifications, and aesthetic standards.三、设计周期与阶段Design eriod and hases:工程设计将分为三个主要阶段：概念设计、初步设计和施工图设计。
每个阶段的完成时间应在合同中明确规定。
The engineering design will e divided into three main hases: concetual design, reliminary design, and construction drawing design. The comletion time for each hase should e clearly defined in the contract.四、费用支付与结算ayment and Settlement:甲方应按合同约定向乙方支付设计费用。
建设工程施工合同中英文对照版
建设工程施工合同中英文对照版1.总则1.1 背景本合同是由甲方（委托方）和乙方（承包方）之间就特定建设工程的施工相关事宜达成的法律协议。
1.2 定义在本合同中，以下术语的定义分别如下：●“甲方”指委托方。
●“乙方”指承包方。
●“建设工程”指在本合同中具体描述的工程项目。
●…2.合同的设立2.1 合同的效力本合同自双方当事人双方签署后生效，并对双方具有法律约束力。
2.2 合同的变更双方当事人可以通过书面协议对本合同进行变更。
变更协议应明确记录变更的具体内容、生效日期等相关信息。
3.工程范围3.1 工程描述本合同的工程范围涵盖但不限于以下内容：●工程名称、地点、规模等基本信息。
●工程实施的时间和期限。
●工程的任务和目标。
●…3.2 工程图纸和设计文件乙方应在工程施工之前，获得甲方提供的工程图纸和设计文件，并确认其具备实施工程的必要条件。
4.工程进度4.1 工期甲方和乙方应在合同中明确约定工程的开始和结束日期，并在履行合同过程中确保工程按时完成。
4.2 进度计划在工期约定的前提下，乙方应根据工程的具体情况制定详细的工程进度计划，并在实施过程中及时进行更新和调整。
5.质量控制5.1 质量标准甲方应在合同中明确规定工程的质量标准，并要求乙方按照相关法规和行业标准进行施工。
5.2 质量保证乙方应确保施工过程中的所有工作符合甲方要求，并对施工结果承担相应的质量责任。
6.工程支付6.1 付款方式双方应在合同中明确约定工程支付的方式和时间。
甲方应按照约定的比例或时间节点支付工程款项。
6.2 工程结算工程的结算方式和程序应在合同中详细阐明。
乙方应向甲方提供相关的工程进度报告和结算申请。
7.违约责任7.1 甲方违约如果甲方未按照合同约定的方式支付工程款项或未提供必要的配合和支持，甲方应承担相应的违约责任。
7.2 乙方违约如果乙方未按照合同约定的方式完成工程，并导致严重延误或质量问题，乙方应承担相应的违约责任。
8.法律适用和争议解决8.1 法律适用本合同受相关法律法规的约束，并在合同中明确适用的法律法规。
建设工程设计合同中英文
建设工程设计合同中英文合同编号：[填写合同编号]签订日期：[填写签订日期]甲方（业主）：[业主全称]乙方（设计单位）：[设计单位全称]鉴于甲方拟建设的项目需要专业的工程设计服务，经双方协商一致，特订立本合同，以便共同遵守执行。
第一条合同目的本合同旨在规定甲乙双方在[具体工程项目名称]的设计工作中的权利、义务及责任，确保工程设计满足相关法律法规和技术标准要求，保障工程质量和安全。
第二条设计范围与内容1. 乙方根据甲方提供的项目需求和技术参数，负责项目的初步设计、施工图设计及后续设计变更等工作。
2. 设计工作包括但不限于建筑设计、结构设计、给排水设计、电气设计、暖通设计等专业领域。
3. 乙方应确保设计文件符合国家及地方的建设规范、标准和法规。
第三条设计周期与提交1. 设计工作自合同签订之日起开始，至工程竣工验收合格之日结束。
2. 乙方应在约定的时间内完成各阶段设计工作，并按照甲方要求提交相应的设计文件。
第四条费用支付1. 设计费用总额为[具体金额]元人民币，分为预付款、进度款和尾款三个阶段支付。
2. 甲方应在合同签订后[具体天数]天内支付预付款，金额为设计费用总额的[具体比例]%。
3. 随着设计工作的进展，甲方将根据乙方提交的设计文件支付相应的进度款。
4. 最终尾款将在工程竣工验收合格后的[具体天数]天内结清。
第五条违约责任1. 如乙方未能按合同约定时间提交设计文件，应按未提交部分设计费用的[具体比例]%向甲方支付违约金。
2. 如因乙方设计错误导致工程质量问题或安全事故，乙方应承担相应的法律责任和经济赔偿。
第六条争议解决合同执行过程中发生的任何争议，双方应首先通过友好协商解决；协商不成时，可提交至甲方所在地人民法院诉讼解决。
第七条其他事项1. 本合同的修改和补充应以书面形式进行，经双方授权代表签字盖章后生效。
2. 本合同一式两份，甲乙双方各执一份，具有同等法律效力。
甲方（盖章）：_________________ 日期：____年__月__日乙方（盖章）：_________________ 日期：____年__月__日。
建设工程委托设计合同中英文对照
建设工程设计合同Construction Project Design Contract项目名称：Project Name:项目建设地点：Project Location:合同编号：Contract No.:设计证书等级：Grade of Design License:委托方：Client:承接方：Design Firm:签订日期：Signed on:委托方：（甲方）Client (Party A):承接方：（乙方）Design Firm (Party B):甲方委托乙方承担XX 项目（一期）工程设计，经双方协商一致，签订本合同。
Party A entrusts Party B to undertake the design for This Contract is made by the two parties after their mutual agreement.第一条本合同依据下列文件签订Article 1. This Contract is made on the basis of the following documents:1.1 《中华人民共和国合同法》、《中华人民共和国建筑法》和《建设工程勘察设计市场管理规定》。
1.1 《The Contract Law of the People’s Republic of China》,《The building regulations of thePeople’s Republic of China》and 《The developmental Law of the People’s Republic ofChina.1.2 国家及地方有关建设工程勘察设计管理法规和规章。
1.2 Relevant Building & Design Codes and Regulations of the State and of the Shanghai Municipality.1.3 建设工程的相关批准文件。
建设工程设计合同英文版
建设工程设计合同英文版Construction Engineering Design ContractWHEREAS, the Client intends to construct a [Description of the Project] (the "Project"); and1. Scope of Services:2. Design Fees:2.2 The Design Fee shall be payable in installments as follows: [Payment Schedule]. The Client shall make all payments within [Number] days from the date of receipt of an invoice.3. Ownership of Documents:4. Project Changes:4.2 Any changes requested by the Client must be agreed upon in writing by both parties before implementation.5. Delays and Force Majeure:6. Confidentiality:6.1 Both parties shall maintain the confidentiality of all proprietary information, trade secrets, and other confidential information received from the other party in connection with the Project.6.2 This obligation of confidentiality shall continue even after the termination of this Contract.7. Termination:7.1 Either party may terminate this Contract for a material breach by the other party, provided that a written notice is given specifying the nature of the breach and a reasonable opportunity is given to cure such breach.8. Governing Law and Jurisdiction:This Contract shall be governed by and construed in accordance with the laws of [Country/State]. Any disputes arising under or in connection with this Contract shall be subject to the exclusive jurisdiction of the courts in[City/Region].IN WITNESS WHEREOF, the parties hereto have executed this Construction Engineering Design Contract as of the date first above written.[Client Name]By:______________________Name: ____________________Title: _____________________By:______________________Name: ____________________。
建设工程设计英文合同
建设工程设计英文合同我们需要明确合同的主体部分。
在合同中，甲方通常指的是业主或发包方，而乙方则是指承包方或设计方。
在撰写合同时，应确保双方的名称、地址、联系方式等信息准确无误。
以下是一份建设工程设计英文合同范本的主要条款：1. Contract artiesarty A (Owner): [Owner's Name and Address]arty (Designer): [Designer's Name and Address]2. roject OverviewThe roject involves the design of a [tye of construction roject, such as commercial uilding, residential area, or industrial facility]. The design shall e comleted in accordance with the secifications and requirements set forth y arty A.3. Design ScoeThe design scoe includes, ut is not limited to, architectural design, structural design, electrical and mechanical design, fire rotection system design, and environmental imact assessment. arty shall rovide detailed design drawings, technical secifications, and related documents.4. Design FeeThe total design fee for this roject is [amount in words and figures]. The ayment shall e made in accordance with the following schedule: [ayment terms and conditions].5. Design ScheduleThe design work shall e comleted within [numer] days from the date of contract signing. arty shall sumit the design documents to arty A for review and aroval. Any revisions required y arty A shall e comleted within [numer] days.6. Quality Assurancearty shall ensure that the design comlies with all alicale laws, regulations, and industry standards. arty shall also rovide necessary suort and assistance during the construction hase to ensure the quality of the roject.7. Intellectual roertyAll design documents, drawings, and related materials roduced y arty shall e the roerty of arty A. arty shall have no right to use or disclose any of these materials without the rior written consent of arty A.8. Liaility and IndemnityIn the event of any reach of contract or negligence on the art of arty , arty shall e resonsile for any damages incurred y arty A. arty shall also indemnify arty A against any claims, losses, or exenses arising from such reach or negligence.9. Governing Law and Disute ResolutionThis contract shall e governed y and construed in accordance with the laws of [jurisdiction]. Any disute arising from or related to this contract shall e resolved through negotiation or mediation. If no resolution can e reached, the arties agree to sumit the disute to aritration or litigation.10. TerminationEither arty may terminate this contract uon written notice to the other arty in case of material reach or failure to erform any oligation under this contract. The termination shall not affect any rights or oligations accrued rior to the termination.11. MiscellaneousThis contract contains the entire agreement etween the arties and suersedes all rior negotiations, understandings, and agreements. Any amendment or modification to this contract must e in writing and signed y oth arties.。
建设工程施工合同中英文翻译件范本8篇
建设工程施工合同中英文翻译件范本8篇篇1建设工程施工合同Contract of Construction Engineering一、合同当事人The Parties to the Contract1. 发包方（甲方）：- 单位名称：江苏某某建设集团有限公司- 地址：南京市某某区某某街某某号- 法定代表人：张先生- 电话：+86-12345678901- 电子邮箱：[*****************](mailto:*****************)2. 承包方（乙方）：- 单位名称：南京某某建筑有限公司- 地址：南京市某某区某某街某某号- 法定代表人：李女士- 电话：+86-10987654321- 电子邮箱：[**************](mailto:**************)二、合同标的The Subject of the Contract本合同标的为江苏某某建设集团有限公司委托南京某某建筑有限公司承建的“某某花园”住宅楼建设项目。
项目位于南京市某某区，合同总价为人民币壹亿元整（￥1,000,000,000元）。
三、工程范围和内容Scope and Content of the Works1. 土建工程：包括基础工程、主体结构、屋面工程等。
2. 装饰工程：包括内外装饰、门窗安装等。
3. 水电安装：包括给水、排水、电气照明等。
4. 其他附属设施：包括道路、绿化、景观等。
四、工期和进度Time Limit and Progress of the Works1. 开工日期：本合同自签订之日起生效，工期为36个月。
2. 进度要求：乙方需按照甲方提供的施工进度计划表执行，确保每月完成计划工程量。
3. 延期处理：如因乙方原因造成工期延误，乙方需承担相应的违约责任和赔偿责任。
五、质量与验收Quality and Acceptance1. 质量标准：乙方必须按照国家和地方现行施工规范及标准施工，确保工程质量达到合格标准。
建设工程设计合同中英文版本
编号：_______________本资料为word版本，可以直接编辑和打印，感谢您的下载建设工程设计合同中英文版本甲方：___________________乙方：___________________日期：___________________Construction Project Design Contract项目名称：Project Name:项目建设地点：Project Location:合同编号：Contract No.:设计证书等级：Grade of Design License:委托方：Client:承接方：Design Firm:签订日期：Signed on:委托方（甲方）：Client （Party A）:承接方（乙方）：Design Firm （Party B）:甲方委托乙方承担XX项目（一期）工程设计，经双方协商一致，签订本合同。
Party A entrusts Party B to undertake the design for . This Contract is made by the two parties after their mutual agreement.第一条本合同依据下列文件签订Article1. This Contract is made on the basis of the following documents:1.1〈〈中华人民共和国合同法》、〈〈中华人民共和国建筑法》和〈〈建设工程勘察设计市场管理规定》。
1.1 The Contract Law of the People ' s Republic of Chin, The building regulations of thePeople ' s Republic of China and The developmental Law of the People ' s Republic of China.1.2国家及地方有关建设工程勘察设计管理法规和规章。
施工设计合同中英
施工设计合同（中英）合同编号：____________甲方（发包方）：____________乙方（承包方）：____________根据《中华人民共和国合同法》、《中华人民共和国建筑法》及其他有关法律法规的规定，经双方友好协商，本着平等、自愿、公平、诚信的原则，就甲方委托乙方进行施工设计的事宜，达成如下协议：一、工程概况1.1 工程名称：____________1.2 工程地点：____________1.3 工程规模：____________1.4 工程内容：____________1.5 工程预算：____________1.6 工程周期：____________二、设计要求2.1 乙方应按照甲方的要求，结合工程实际情况，按照相关法律法规、规范标准进行施工设计，确保设计方案的科学性、合理性和可行性。
2.2 乙方应提供完整的设计文件，包括施工图纸、设计说明书、施工技术要求等，并负责对甲方人员进行设计交底。
2.3 乙方应根据工程进度，及时提供设计变更，确保工程的顺利进行。
2.4 乙方应确保设计质量，对设计过程中出现的失误负责并及时更正。
三、合同价格3.1 本合同的设计费为：____________元（大写：_________________________元整）。
3.2 乙方在合同签订后，向甲方开具正规发票。
四、合同履行4.1 甲方应按照合同约定，及时向乙方支付设计费。
4.2 甲方应提供乙方所需的设计资料，并对提供的资料的真实性、准确性负责。
4.3 甲方应按照乙方提供的施工图纸、设计说明书等文件进行施工，不得擅自修改。
4.4 甲方应按照合同约定，对乙方进行评价。
五、违约责任5.1 乙方未按照约定时间完成设计的，应当按照逾期天数向甲方支付违约金，违约金计算方式为：设计费的千分之五。
5.2 乙方设计质量不符合约定的，乙方应负责无偿整改，直至达到甲方要求。
5.3 甲方未按照约定时间支付设计费的，应当按照逾期天数向乙方支付违约金，违约金计算方式为：设计费的千分之五。
- 1、下载文档前请自行甄别文档内容的完整性，平台不提供额外的编辑、内容补充、找答案等附加服务。
- 2、"仅部分预览"的文档,不可在线预览部分如存在完整性等问题,可反馈申请退款(可完整预览的文档不适用该条件!)。
- 3、如文档侵犯您的权益，请联系客服反馈,我们会尽快为您处理(人工客服工作时间：9:00-18:30)。
建设工程设计合同Construction Project Design Contract项目名称：Project Name:项目建设地点：Project Location:合同编号：Contract No.:设计证书等级：Grade of Design License:委托方：Client:承接方：Design Firm:签订日期：Signed on:委托方：（甲方）Client (Party A):承接方：（乙方）Design Firm (Party B):甲方委托乙方承担XX 项目（一期）工程设计，经双方协商一致，签订本合同。
Party A entrusts Party B to undertake the design for This Contract is made by the twoparties after their mutual agreement.第一条本合同依据下列文件签订Article 1. This Contract is made on the basis of the following documents:1.1 《中华人民共和国合同法》、《中华人民共和国建筑法》和《建设工程勘察设计市场管理规定》。
1.1 《The Contract Law of the People’s Republic of China》,《The building regulations of thePeople’s Republic of China》 and 《The developmental Law of the People’s Republic ofChina.1.2 国家及地方有关建设工程勘察设计管理法规和规章。
1.2 Relevant Building & Design Codes and Regulations of the State and of the ShanghaiMunicipality.1.3 建设工程的相关批准文件。
1.3 The approval documents that are required for this construction project.第二条本合同工程设计项目的名称、地点、规模、投资、内容及标准Article 2. The name, location, size, investment sum, function, design contents and standards :2.1 工程项目的名称： XX 项目（一期）2.1 Project name:2.2 工程项目的地点：2.2 Project location:2.3 工程项目的规模：总建筑面积约平方米（其中地下面积约平方米），高度米。
2.3 Project size：The total floor area is approximately m2(of which the floor area ofthe underground area is m2),the total height is m.2.4 工程特征及附注说明：商业办公综合楼2.4 Project features & remarks： A commercial cum office building complex2.5 工程项目的投资总额：控制在亿元人民币以下2.5 Project investment in total: Controlled Within RMB million yuan RMB2.6 工程项目的设计内容及标准：红线内的建筑、结构、机电、总体设计（包括3000m2 人防设计，不包括精装修设计、园艺设计和艺术泛光照明等专业设计），施工图设计约为70000 m2（不包括五层到七层的SOHO 区域2.6 Design requirements and scope of work: The scope of work shall include master planningand building design that are located within the boundary line . For building design it shallcomprise of the architectural, structural & M/E work . (including 3,000 m2of Air-raid shelterdesign, but excluding other specialists’ design, such as the Luxurious Interior Design,Landscaping Design and Fa.ade Flood Lighting Design). The total floor area during theworking drawing stage is 70,000 m2 (excluding the SOHO Area, which is starting from thefifth floor level to the seventh floor level ).第三条甲方向乙方提交的有关资料及文件（见下表）Article 3. Relevant documents which shall be issued by Party A to Party B:序号S/N资料及文件名称Name of documents份数copies提交时间Submission Date备注Remarks政府批文Government Approval Documents全套Full set设计任务书Design Instructions规划红线图 Plan of Property Line 1水、电、气源落实情况说明Design Information of Utilities (water,electricity, & gas supply etc.)规划设计要求Requirements from the Government地质勘探报告Soil Investigation Report原打入桩的资料Dsign Information of As Built pilings概念方案Concept Design Information第四条乙方向甲方交付的设计文件（见下表）Article 4. Design documents which shall be submitted by Party B to Party A (listed as follows):序号S/N设计文件名称Design Documents阶段Phase份数Copies提交时间Submission Date备注Remarks方案设计文件Schematic Design Documents 方案Schematic10 30天内Within 30 days初步设计文件D.D. Documents扩初E.P.D.15 30天内Within 30 days初步概算文件Preliminary Estimate扩初E.P.D2 7 天内Within 7 days施工图设计Working Drawings施工图ConstructionDocuments15 桩位图扩初批准后15 天The piling drawings will besubmitted within 15 days afterthe D.D. Approval其余扩初批准后60 天The rest of the drawings will besubmitted within 60 days after theD.D. Approval光盘文件CD files施工图C.D.待定To Be Decided注：设计文件深度按照《建筑工程设计文件编制深度规定》（建设部2003 年4 月版）执行。
Notes: The design documents shall be prepared in compliance with the <Regulations on detailrequirements of design documents for construction projects> (issued by Ministry of Constructiondated in April, 2003).第五条设计费用及支付方法Article 5. Design fee and the mode of payment:5.1 甲方应支付本合同项目的设计费为。
(含所有乙方应缴纳的税费及其它政府规定应由乙方缴纳的款项）5.1 Party A shall pay the design fee of RMB yuan for this project to Party B ( thisfee shall include taxes and all other duties that should be paid by Party B as required bythe government regulations).5.2 支付方法（见下表）：5.2 The payment method is (listed as the following):序号S/N阶段Phase金额（元）Amount(yuan)说明Remarks1 方案阶段Schematic design合同签订后30 日内30 days after Contract is signed2 扩初阶段Design Development扩初批准后30 日内30 days after the D.D. Approval3 施工图阶段Construction Documen施工图提交审图后30 日内30 days after the C.D. Approvalby the Authority.总包施工合同签订后30 日内30 days after the main contractorhas been awarded施工配合Constructioncoordination工程开工后，按季度分五期支付每次支付70,000.00 元5 installment payment shall be madequarterly throughout the entireconstruction period. Each installmentamounting to 70,000.00 yuan施工配合585,000.00 元竣工验收阶段The Completion &Handing over stage竣工验收后After the completion and handingover of the project第六条双方责任Article 6. Responsibilities of both parties:6.1 甲方责任6.1 Responsibilities of Party A:6.1.1 甲方按本合同第三条规定的内容，在规定的时间内向乙方提交资料及文件，并对其完整性、正确性及时限负责。