技术开发合同(中英对照)
英文技术开发合同6篇
英文技术开发合同6篇篇1Technical Development AgreementThis Technical Development Agreement (the "Agreement") is entered into as of [Date], by and between [Company Name], having its principal place of business at [Address] (the "Company"), and [Developer Name], having its principal place of business at [Address] (the "Developer").BackgroundThe Company is engaged in the business of [Brief description of Company's business], and the Developer possesses certain technical expertise in [Brief description of Developer's technical expertise].The Company wishes to engage the Developer to provide technical development services as described herein, and the Developer wishes to provide such services under the terms and conditions set forth in this Agreement.Agreement1. Scope of Services. The Developer shall provide technical development services to the Company as requested by the Company from time to time. The services to be provided by the Developer may include, but are not limited to, [Description of services to be provided].2. Compensation. The Company shall compensate the Developer for the services provided under this Agreement at the rate of [Rate] per hour. The Developer shall submit invoices to the Company on a [Weekly/Monthly] basis for payment.3. Term. This Agreement shall commence on the date first written above and shall continue until terminated by either party upon [Number] days' written notice.4. Confidentiality. The Developer agrees to keep all information and materials provided by the Company confidential and not to disclose such information to any third party without the Company's prior written consent.5. Intellectual Property. Any intellectual property created by the Developer in connection with the services provided under this Agreement shall belong to the Company, and the Developer hereby assigns all rights, title, and interest in and to such intellectual property to the Company.6. Termination. Either party may terminate this Agreement at any time for any reason upon [Number] days' written notice. Upon termination, the Developer shall cease providing services to the Company, and the Company shall compensate the Developer for services rendered up to the date of termination.7. Governing Law. This Agreement shall be governed by and construed in accordance with the laws of the State of [State].In Witness Whereof, the parties hereto have executed this Agreement as of the date first written above.[Company Name]By: ___________________________ Name: Title:[Developer Name]By: ___________________________ Name: Title:This Agreement constitutes the entire agreement between the parties with respect to the subject matter hereof and supersedes all prior agreements and understandings, whether written or oral, relating to such subject matter. This Agreement may be amended only by a written instrument signed by both parties.IN WITNESS WHEREOF, the parties have executed this Agreement as of the date first written above.[Company Name]By: __________________________ Name: Title:[Developer Name]By: __________________________ Name: Title:篇2Technical Development AgreementThis Technical Development Agreement (the "Agreement") is entered into as of [Date] by and between [Company Name], a [Company Type] organized and existing under the laws of [Jurisdiction], with its principal office located at [Company Address] (hereinafter referred to as "Company") and [Developer Name], an individual residing at [Developer Address] (hereinafter referred to as "Developer").WHEREAS, Company desires to engage Developer for the development of certain technical products and services as further described in Exhibit A attached hereto (the "Project"); andWHEREAS, Developer has the necessary expertise and resources to undertake the development of the Project in accordance with Company's specifications;Now, therefore, in consideration of the premises and mutual covenants contained herein, the parties hereto agree as follows:1. Services. Developer shall perform the development services for the Project as described in Exhibit A in a professional and timely manner, using commercially reasonable efforts to meet the milestones and deadlines set forth therein.2. Compensation. In consideration for the services provided by Developer under this Agreement, Company shall pay Developer a total fee of [Total Fee]. Payment shall be made in installments as set forth in Exhibit B attached hereto.3. Ownership. All intellectual property rights, including but not limited to copyrights, patents, trademarks, and trade secrets, developed by Developer in the course of performing the services under this Agreement shall belong exclusively to Company. Developer hereby assigns to Company all rights, titles, and interests in and to such intellectual property rights.4. Confidentiality. Developer shall keep confidential all information related to the Project and shall not disclose suchinformation to any third parties without the prior written consent of Company. This confidentiality obligation shall survive the termination of this Agreement.5. Term and Termination. This Agreement shall commence on the effective date set forth above and shall continue until the completion of the Project unless terminated earlier by either party upon thirty (30) days' written notice. In the event of termination, Company shall pay Developer for the services performed up to the date of termination.6. Governing Law. This Agreement shall be governed by and construed in accordance with the laws of [Jurisdiction]. Any disputes arising out of or related to this Agreement shall be resolved through arbitration in [Arbitration Location] in accordance with the rules of the American Arbitration Association.7. Entire Agreement. This Agreement constitutes the entire agreement between the parties with respect to the subject matter hereof and supersedes all prior agreements, understandings, and negotiations, whether oral or written.IN WITNESS WHEREOF, the parties hereto have executed this Agreement as of the date first above written.[Company Name] [Developer Name]_________________________ _________________________Company Signature Developer SignatureExhibit A - Project DescriptionExhibit B - Payment ScheduleThis is a sample Technical Development Agreement for reference purposes only. It is recommended that you consult with legal professionals to draft a customized agreement that meets your specific needs and requirements.篇3Technology Development ContractThis Technology Development Contract (the "Contract") is made and entered into as of [Insert Date], (the "Effective Date") by and between [Company Name], a corporation organized and existing under the laws of the [state/country], with its principal place of business located at [Company Address] (the "Developer"), and [Company Name], a corporation organized and existing under the laws of the [state/country], with its principal place of business located at [Company Address] (the "Client").1. Scope of WorkThe Developer agrees to provide technical development services to the Client in accordance with the specifications set forth in the Statement of Work (the "SOW") attached hereto as Exhibit A. The SOW shall include a description of the services to be provided, the timeline for completion, and the compensation to be paid.2. PaymentIn consideration for the services provided by the Developer under this Contract, the Client agrees to pay the Developer a fee of [Insert Amount] (the "Fee"). Payment shall be made in [Insert Payment Terms], with [Insert Percentage] due upon signing of the Contract, [Insert Percentage] due upon delivery of the completed work, and the balance due upon final acceptance by the Client.3. Ownership of Work ProductAll work products created by the Developer under this Contract, including but not limited to software code, designs, and documentation, shall be the exclusive property of the Client. The Developer agrees to assign all rights, title, and interest in andto the work product to the Client upon completion of the services.4. ConfidentialityThe Developer agrees to keep confidential all information provided by the Client in connection with the services, including but not limited to proprietary information, trade secrets, and intellectual property. The Developer shall not disclose such information to any third party without the Client's prior written consent.5. Term and TerminationThis Contract shall commence on the Effective Date and shall continue until the services described in the SOW are completed. Either party may terminate this Contract upon written notice to the other party if the other party materially breaches any provision of the Contract and fails to cure such breach within [Insert Cure Period] days of receiving written notice.6. Independent ContractorThe Developer is an independent contractor and not an employee of the Client. The Developer shall have sole control over the manner and means by which the services are performed,provided that the work is completed in accordance with the specifications set forth in the SOW.7. Governing LawThis Contract shall be governed by and construed in accordance with the laws of the [state/country] without regard to conflicts of law principles. Any disputes arising out of or relating to this Contract shall be resolved by binding arbitration in accordance with the rules of the American Arbitration Association.IN WITNESS WHEREOF, the parties hereto have executed this Contract as of the Effective Date.[Signature Page Follows]IN WITNESS WHEREOF, the parties hereto have executed this Contract as of the Effective Date.Developer: [Developer Name]Client: [Client Name]By: _________________ By: __________________Name: Name:Title: Title:Date: Date:篇4Technical Development ContractThis Technical Development Contract (the "Contract") is entered into on this __________ day of __________, 20__, by and between _______________________ (the "Client") and_______________________ (the "Developer").1. Scope of WorkThe Developer agrees to provide technical development services to the Client for the project described as_______________________ (the "Project"). The scope of work includes but is not limited to:- Designing and developing software or applications according to Client's specifications.- Testing and debugging the software to ensure proper functionality.- Providing ongoing technical support and maintenance for the software post-launch.- Meeting all deadlines and milestones as outlined in the project plan.2. PaymentThe Client agrees to pay the Developer a total fee of$__________ for the completion of the Project. Payment will be made in installments as follows:- 25% upon signing of the Contract.- 25% upon completion of the design phase.- 25% upon completion of the development phase.- 25% upon final delivery and acceptance of the Project.Payment can be made via check, wire transfer, or credit card, as agreed upon by both parties.3. Intellectual Property RightsAll intellectual property rights, including but not limited to copyrights, patents, and trademarks, related to the software developed under this Contract shall belong to the Client. The Developer agrees to transfer all such rights to the Client upon completion of the Project.4. ConfidentialityBoth parties agree to keep all information exchanged during the course of the Project confidential. This includes but is notlimited to source code, design documents, and any other proprietary information related to the software.5. TerminationEither party may terminate this Contract with written notice if the other party breaches any of the terms outlined herein. In the event of termination, the Developer shall be entitled to payment for services rendered up to the date of termination.6. Governing LawThis Contract shall be governed by the laws of the state of __________. Any disputes arising under this Contract shall be resolved through arbitration in accordance with the rules of the American Arbitration Association.In witness whereof, the parties have executed this Contract as of the date first written above.___________________________Client Name___________________________Developer NameThis document constitutes the entire agreement between the Client and the Developer and supersedes any prior agreements or understandings, whether written or oral.篇5Technical Development AgreementThis Technical Development Agreement (“Agreement”) is entered into on this [insert date] by and between [Company Name], having its principal place of business at [insert address] (“Developer”) and [Client Name], having its principal place of business at [insert address] (“Client”).WHEREAS, Client desires to engage Developer to provide technical development services for the purpose of [insert description of project]; andWHEREAS, Developer is willing to perform such services for Client on the terms and conditions set forth herein.NOW, THEREFORE, in consideration of the mutual covenants and agreements contained herein, the parties agree as follows:1. Services. Developer shall provide technical development services for Client in accordance with the specifications outlined in Exhibit A attached hereto.2. Compensation. Client shall pay Developer a fee of [insert amount] for the services to be provided under this Agreement. Payment shall be made in [insert payment terms], as outlined in Exhibit B attached hereto.3. Term. This Agreement shall commence on [insert start date] and shall continue until the completion of the project or termination by either party.4. Confidentiality. Developer acknowledges that in the course of performing services for Client, Developer may have access to confidential information belonging to Client. Developer agrees to keep such information confidential and shall not disclose it to any third party without the prior written consent of Client.5. Ownership of Work Product. All work product created by Developer in connection with the services provided under this Agreement shall be the exclusive property of Client. Developer agrees to assign all rights, title, and interest in such work product to Client.6. Warranties. Developer warrants that the services provided under this Agreement shall be performed in a professional and workmanlike manner and shall conform to the specifications outlined in Exhibit A. Developer further warrants that it has theright to enter into this Agreement and that the services provided do not infringe upon the intellectual property rights of any third party.7. Indemnification. Developer shall indemnify and hold harmless Client from any claims, damages, losses, or expenses arising out of Developer's breach of this Agreement or negligence in the performance of its services.8. Termination. Either party may terminate this Agreement upon written notice if the other party materially breaches any provision of this Agreement and fails to cure such breach within [insert number] days of receiving written notice.9. General Provisions. This Agreement constitutes the entire understanding between the parties with respect to the subject matter hereof and supersedes all prior agreements and understandings, whether written or oral. This Agreement may not be amended except by written agreement signed by both parties.IN WITNESS WHEREOF, the parties have executed this Agreement as of the date first set forth above.[Developer Name][Client Name]Exhibit A: Project SpecificationsExhibit B: Payment Terms_______________________________[Signature] [Date]篇6Technical Development AgreementThis Technical Development Agreement ("Agreement") is entered into by and between [Company Name], a company organized and existing under the laws of [Country], having its principal place of business at [Address] ("Company"), and [Developer Name], an individual residing at [Address] ("Developer").1. Scope of ServicesDeveloper agrees to provide technical development services to Company. The services to be provided by Developer shall include but not be limited to designing, coding, testing, and implementing software solutions in accordance with Company's specifications. Developer shall perform the services in a timely and professional manner and in accordance with best industry practices.2. PaymentCompany agrees to pay Developer for the services rendered in accordance with the fee schedule attached as Schedule A to this Agreement. Payment shall be made [payment terms]. Developer shall invoice Company for the services rendered on a [payment frequency] basis.3. Ownership of Intellectual PropertyAny intellectual property developed by Developer in the course of providing the services under this Agreement shall be the exclusive property of Company. Developer hereby assigns to Company all right, title, and interest in and to any intellectual property developed herein.4. ConfidentialityDeveloper acknowledges that in the course of providing the services under this Agreement, Developer may have access to confidential information of Company, including but not limited to Company's proprietary software, technical data, and business strategies. Developer agrees to keep all confidential information confidential and not to disclose it to any third party without Company's prior written consent.5. Term and TerminationThis Agreement shall commence on [Commencement Date] and continue until [Termination Date], unless earlier terminated as provided herein. Either party may terminate this Agreement upon [notice period] written notice to the other party. Upon termination of this Agreement, Developer shall deliver to Company all materials and property belonging to Company and cease using Company's confidential information.6. IndemnificationDeveloper agrees to indemnify and hold harmless Company against all claims, damages, and liabilities arising out of Developer's breach of this Agreement or negligence in providing the services hereunder.7. Governing LawThis Agreement shall be governed by and construed in accordance with the laws of [Country]. Any dispute arising out of or in connection with this Agreement shall be resolved by arbitration in [City], [Country], in accordance with the rules of the [Arbitration Institution].IN WITNESS WHEREOF, the parties hereto have executed this Agreement as of the date first above written.[Company Name]By:Name:Title: [Developer Name] By:Name:。
技术开发委托合同中英文
技术开发委托合同中英文TECHNICAL DEVELOPMENT AGREEMENT技术开发委托合同This Technical Development Agreement (the "Agreement") is made and entered into on this ___ day of __________, 20___ (the "Effective Date") by and between:本技术开发委托合同（以下称“本协议”）由以下双方于_______年_______月_______日（下称“生效日期”）签署：Party A:[Name of Company A][Company Address][City, State, Zip Code][Country]甲方：[公司名称A][公司地址][城市，省/州，邮编][国家]Party B:[Name of Company B][Company Address][City, State, Zip Code][Country]乙方：[公司名称B][公司地址][城市，省/州，邮编][国家]Collectively referred to as the "Parties."以上统称为“双方”。
WHEREAS Party A possesses certain technical expertise and resources to develop new technologies;鉴于甲方拥有某些技术专长和资源以开发新的技术；WHEREAS Party B desires to engage the services of Party A to develop a specific technology;鉴于乙方希望聘请甲方开发一项具体技术；NOW, THEREFORE, in consideration of the mutual promises and covenants contained herein, the Parties agree as follows:故双方根据本合同的互相承诺和约定，达成如下协议：1. Scope of Work1. 工作范围1.1 Party B hereby engages Party A to provide technical development services for the purpose of developing the following technology (the "Technology"):1.1 乙方特此聘请甲方提供技术开发服务，目的是开发以下技术（以下称“技术”）：[Description of the Technology][技术描述]1.2 Party A shall perform all necessary work in order to develop the Technology, including, but not limited to:1.2 甲方应执行所有必要的工作以开发技术，包括但不限于：- Conducting research and analysis related to the Technology;- 进行与技术相关的研究和分析；- Designing and developing prototypes or models;- 设计和开发原型或模型；- Conducting testing and evaluation of the Technology;- 进行技术的测试和评估；- Providing technical support and assistance during the implementation of the Technology.- 在技术实施过程中提供技术支持和协助。
技术开发(委托)合同 中英文
合同编号/ Contract Number:技术开发（委托）合同Contract of technical development(entrustment)项目名称：Project Name:委托方（甲方）：Entrusting Party (Party A):受托方（乙方）：Entrusted Party (Party B):签订时间/ Signing Date:签订地点/ Signing Address:中华人民共和国科学技术部印制Made by Ministry of Science and Technology of the People's Republicof China填写说明Filling Notes一、本合同为中华人民共和国科学技术部印制的技术开发（委托）合同示范文本，各技术合同认定登记机构可推介技术合同当事人参照使用。
1. This contract is the model contract of technical development (entrustment), which is made by Ministry of Science and Technology of the People's Republic of China. The institute of certificating and registering technical contract can recommend the party involved to use it.二、本合同书适用于一方当事人委托另一方当事人进行新技术、新产品、新工艺或者新材料及其系统的研究开发所订立的技术开发合同。
2. This contract is suitable for the contract of technical development, made by one party entrusts the other party to develop new technology, new product or new material and do systematic research for it.三、签约一方为多个当事人的，可按各自在合同关系中的作用等，在“委托方”、“受托方”项下（增页）分别排列为共同委托人或共同受托人。
技术开发合同(中英对照)
技术开发合同书Tech no logy Developme nt Con tract鉴于：本合同签约各方就本合同书中所描述项目的研究开发、投资融资、成果权属、收益分配、风险责任以及与之相关的技术和法律问题经过平等协商，在真实、充分地表达各自意愿的基础上，根据《中华人民共和国合同法》之规定，达成如下协议，由签约各方共同恪守。
WHEREAS:The Parties hereto have carried out mutual consultation on an equal basis with respect to theresearch and developme nt, i nvestme nt financing, deliverables ' own ership, profit distributio n, risliabilities and any related technical and legal issues concerning the project contemplated herein, theParties have en tered into this Con tract on the basis of good faith, pursua nt to the Con tract Law of thePeople ' s Republic of China, and agree to be bound hereby:第一条签约方Article 1 The Parties:甲方：何氏眼科医院Part A: He Eye Hospital地址：Address:乙方：Party B:地址：Address:第二条合同性质Article 2 Con tract Type:本合同属于：1、委托开发合同口2、合作开发合同口This Con tract is a:1. Authorized Developme nt Con tract; or2. Joint Developme nt Con tract第三条签约时间和地点Article 3 Date and Place of Executi on本合同由上述签约方于年月日在签订。
英文技术开发合同5篇
英文技术开发合同5篇篇1Contract for Technical Development甲方（客户）：__________________乙方（开发方）：__________________签订日期：____________________一、合同背景及目的本合同由甲方和乙方共同签署，目的在于明确双方在技术开领域的合作关系及具体事务处理细节。
甲方委托乙方进行特定的技术开发工作，乙方同意接受委托并按照本合同的要求完成相关任务。
二、开发内容与技术要求1. 开发内容：具体描述开发的系统名称、功能及目标。
（例如：开发一套智能物流管理系统，实现货物追踪、数据分析及优化物流路径等功能。
）2. 技术要求：明确开发的软件应满足的技术标准和规范，包括但不限于系统稳定性、兼容性、安全性等方面的要求。
三、开发周期与进度安排1. 开发周期：自合同签订之日起至完成所有开发任务并交付验收的总时长。
2. 进度安排：详细列明开发各阶段的时间节点及主要任务，包括需求分析、设计、编码、测试等阶段的具体时间安排。
四、知识产权与保密条款1. 知识产权归属：明确开发成果的知识产权归属，是归属于甲方还是双方共同拥有。
如归属甲方，则乙方不得擅自将相关技术用于其他用途或转让给第三方。
2. 保密条款：双方应对在合作过程中获知的对方商业秘密和技术秘密承担保密义务，未经对方书面同意，不得向任何第三方泄露。
五、费用与支付方式1. 开发费用：详细列明本次技术开发的费用总额及构成，包括各个阶段的工作费用。
费用的确定应遵循公平合理原则。
2. 支付方式：约定支付的时间节点（如预付款、进度款、尾款等）及支付条件。
同时明确如发生变更时双方应如何调整费用。
六、验收与交付1. 验收标准：根据开发内容和技术要求制定详细的验收标准。
2. 交付物：明确开发完成后应交付的文档、软件等物品及其格式和存储方式。
七、风险承担与违约责任1. 风险承担：明确在开发过程中可能遇到的风险及责任承担方式，包括但不限于技术风险、市场风险及不可抗力等因素。
技术开发的英文合同5篇
技术开发的英文合同5篇篇1TECHNOLOGY DEVELOPMENT CONTRACTContract No.: [Insert Contract Number]Date: [Insert Date]1. Scope of Work:The Developer agrees to undertake the development of [describe the technology to be developed in detail] (hereinafter referred to as the "Technology") for the Principal. The Technology shall be developed in accordance with the specifications and requirements provided by the Principal.2. Development Period:The period of development shall commence on [Start Date] and continue until [End Date], unless extended by mutual agreement in writing.3. Project Milestones:The Developer shall achieve the following milestones within the specified timeframes:* Milestone 1: [Describe milestone 1 with timeline]* Milestone 2: [Describe milestone 2 with timeline]* ... (as per the requirements of the project)4. Intellectual Property Rights:All intellectual property rights arising out of or in connection with the Technology shall be owned by the Principal. The Developer shall assign all such rights to the Principal upon completion of the project.5. Payments:The Principal shall pay the Developer the following fees for the development work:* Development Fee: [Amount]* Milestone Payments: [Describe milestone payments with amounts and conditions]* Any other fees or expenses: [Specify other fees/expenses, if any, with amounts]All payments shall be made within [specified timeframes] from the date of invoice.6. Confidentiality:Both parties shall maintain confidentiality of all information disclosed to each other during the course of this Contract. Neither party shall disclose any confidential information to third parties without the prior written consent of the other party.7. Warranty and Liability:The Developer shall ensure that the Technology developed is free from defects in material and workmanship for a period of [Warranty Period]. The Developer shall indemnify and hold harmless the Principal from any claims, losses, or damages arising out of any defects in the Technology.8. Termination:9. Force Majeure:Neither party shall be liable for any failure to perform its obligations due to events beyond its reasonable control, such as acts of war, riots, natural disasters, etc. The affected party shall notify the other party of such events and provide evidence to support its claim.10. General Terms:* This Contract constitutes the entire agreement between the parties and no modifications shall be made except by a written agreement signed by both parties.* The laws of [Country/State] shall apply to this Contract.* Any disputes arising out of or in connection with this Contract shall be settled through friendly negotiations. If no settlement is reached, the dispute shall be referred to [specify dispute resolution mechanism, e.g., arbitration].* This Contract shall be governed by and construed in accordance with the laws of [Country/State].* This Contract may be executed in [number of counterparts] counterparts, each of which shall be deemed an original and all of which shall constitute one and the same instrument.In witness whereof, the parties have executed this Contract on the dates indicated below.Developer:Principal:(Authorized Representative) (Authorized Representative)Date: Date:Place: Place:------------------------------------------------------------------------ 签名与印章应分别在上述打印日期下方占据指定空间位置的位置上对齐插入以加强正式感与合法性表达。
英文技术开发合同7篇
英文技术开发合同7篇篇1Development Contract for Technology in English甲方（委托方）：____________________（Name of Client）地址：____________________（Address）联系方式：____________________（Contact Information）乙方（开发方）：____________________（Name of Developer）地址：____________________（Address）联系方式：____________________（Contact Information）鉴于甲方需要对特定技术进行开发，而乙方具备相关技术开发的实力和经验，双方在平等、自愿、公平的基础上，经过友好协商，达成以下技术开发合同协议：一、合同目的和背景本合同旨在明确甲、乙双方在技术开发项目中的权利与义务，确保双方合作顺利进行，共同实现技术开发的成功。
二、开发内容和目标（详细说明开发项目的名称、内容、目标、预期成果等）三、开发时间和进度安排（明确开发项目的起始日期、预计完成日期、各个阶段的时间节点和主要任务等）四、知识产权归属1. 乙方在本合同期间所完成的技术成果及其知识产权归甲方所有。
2. 未经甲方书面同意，乙方不得将本合同约定的技术成果转让给第三方。
3. 双方共同保守本合同约定的技术秘密和商业秘密。
五、费用支付和结算方式1. 甲方应按照约定的时间和金额支付乙方的开发费用。
2. 开发费用包括研发费用、材料费、差旅费等，具体金额和支付方式由双方另行约定。
3. 若因甲方原因导致开发进度延误，甲方应相应调整支付时间。
六、质量保证和技术支持1. 乙方应保证开发的技术成果符合约定的质量要求。
2. 甲方在开发过程中遇到技术问题，乙方应提供必要的技术支持。
3. 乙方应确保所提供的技术成果不侵犯第三方的知识产权。
技术开发合同(中英对照)
技术开发合同书Technology Development Contract鉴于：本合同签约各方就本合同书中所描述项目的研究开发、投资融资、成果权属、收益分配、风险责任以及与之相关的技术和法律问题经过平等协商，在真实、充分地表达各自意愿的基础上，根据《中华人民共和国合同法》之规定，达成如下协议，由签约各方共同恪守。
WHEREAS:The Parties hereto have carried out mutual consultation on an equal basis with respect to the research and development, investment financing, deliverables’ ownership, profit distribution, risk liabilities and any related technical and legal issues concerning the project contemplated herein, the Parties have entered into this Contract on the basis of good faith, pursuant to the Contract Law of the People’s Republic of China, and agree to be bound hereby:第一条签约方Article 1 The Parties:2. Joint Development Contract第三条签约时间和地点Article 3 Date and Place of Execution本合同由上述签约方于年月日在签订。
This Contract is made and entered into as of ______ by and between the foregoing Parties in ___________.第四条项目名称（用简明规范的专业术语概括技术特征）Article 4 Project Name第五条技术内容Article 5 Technology Description5.1 技术主要组成部分：5.1 Major Technology Components:5.2 研究方法和技术路线：5.2 Research Method and Technology Roadmap5.3 技术开发手段：5.3 Technology Development Methods5.4 技术目标（包括技术指标和参数）：5.4 Technological Target (including technical specifications and parameters):第六条研究开发计划Article 6 Research and Development Plan6.1 阶段进度：6.1 Project Milestones6.2 总体计划：6.2 Overall Plan:第七条转委托Article 7 Transfer7.1 开发方/合作双方是否可以将部分开发工作转委托给第三方：（1）是□（2）否□7.1 The Contractor/Cooperation Parties may/may not transfer part of the development work to a third party:7.2 转委托的具体内容包括：7.2 The specific work to be transferred includes:第八条保密要求Article 8 Confidentiality8.1 保密范围：8.1 Confidential Information:8.2 保密期限：8.2 Term of the Confidentiality Obligation:第九条权利保障Article 9 Warranty签约方保证本合同涉及的全部技术内容具有自主性和真实性，并不因本合同的履行而侵犯他人的合法权益。
技术开发与许可合同中英文
技术开发与许可合同中英文Technical Development and License AgreementThis Technical Development and License Agreement (the "Agreement") is entered into as of [Date] (the "Effective Date") by and between [Party A], with its principal place of business at [Address] (hereinafter referred to as "Licensor"), and [Party B], with its principal place of business at [Address] (hereinafter referred to as "Licensee").1. PurposeLicensor is the owner of certain intellectual property rights and possesses technical expertise in the field of [Field], and Licensee desires to obtain a license to use Licensor's technology for the purpose of [Purpose] (the "Project").2. Grant of License2.1 Licensor hereby grants Licensee a non-exclusive, non-transferable license to use Licensor's technology, patents, trademarks, copyrights, and know-how, as necessary for the development, manufacture, and commercialization of the Project.2.2 The license granted under this Agreement shall be limited to the territory of [Territory] and shall be valid for a period of [Duration], unless terminated earlier in accordance with Section 9 of this Agreement.3. Development of the Project3.1 Licensee shall be solely responsible for the development, manufacturing, marketing, and sales of the Project.3.2 Licensee shall diligently work towards achieving the milestones and objectives set forth in the accompanying development plan (the "Development Plan").3.3 Licensor shall provide technical assistance and support to Licensee during the development of the Project, as mutually agreed upon by the Parties.4. Compensation and Royalties4.1 In consideration of the license granted herein, Licensee shall pay Licensor a one-time upfront fee of [Amount] within [Timeframe].4.2 Licensee shall also pay royalties to Licensor based on the net sales of the Project, as follows: [Royalty Structure].4.3 Royalty payments shall be made [Frequency] and shall be accompanied by a statement detailing the calculation of the royalties.4.4 All payments to Licensor shall be made in [Currency] and shall be deemed received upon receipt into Licensor's designated bank account.5. Confidentiality5.1 Both Parties agree to keep any confidential information received from the other Party confidential and not to disclose it to any third party, except as required by law or with the prior written consent of the disclosing Party.5.2 The confidentiality obligations under this Agreement shall survive the termination or expiration of this Agreement for a period of [Period].6. Intellectual Property6.1 Licensee acknowledges that all intellectual property rights in the technology provided by Licensor shall remain the sole property of Licensor.6.2 Licensee shall not take any action that may infringe or adversely affect the intellectual property rights of Licensor.6.3 Licensee shall promptly notify Licensor of any unauthorized use or infringement of Licensor's intellectual property rights that comes to its attention.7. Term and Termination7.1 This Agreement shall commence on the Effective Date and shall continue until the completion of the Project or the termination of this Agreement as provided herein.7.2 Either Party may terminate this Agreement in the event of a material breach by the other Party, subject to a [Notice Period] prior written notice regarding such breach.8. Governing Law and Dispute Resolution8.1 This Agreement shall be governed by and construed in accordance with the laws of [Jurisdiction].8.2 Any dispute arising out of or in connection with this Agreement shall be resolved through amicable negotiations between the Parties. In the event the dispute cannot be resolved amicably, the Parties agree to submit the dispute to arbitration in accordance with the rules of [Arbitration Institution].9. Miscellaneous9.1 This Agreement represents the entire agreement between the Parties and supersedes any prior agreements, understandings, or representations, whether oral or written.9.2 No modification or amendment to this Agreement shall be valid unless made in writing and signed by both Parties.9.3 This Agreement may be executed in counterparts, each of which shall be deemed an original but both of which, taken together, shall constitute one and the same instrument.In witness whereof, the parties hereto have executed this Technical Development and License Agreement as of the Effective Date.[Party A]By: _______________________Name: _____________________Title: ______________________[Party B]By: _______________________Name: _____________________Title: ______________________Date: ______________________。
技术开发合同英文 示范文本
技术开发合同英文示范文本I. Parties Involved.Party A (The Entrusting Party):Full name: [Company/Individual Name of Party A]Address: [Address of Party A]Contact person: [Name of Contact Person]Phone number: [Phone Number]Email: [Email Address]Party B (The Contractor):Full name: [Company/Individual Name of Party B]Address: [Address of Party B]Contact person: [Name of Contact Person]Phone number: [Phone Number]Email: [Email Address]II. Background and Purpose.Party A has some specific technological needs in [describe the general area, like "mobile app development" or "new manufacturing process improvement"]. Party B is an expert in relevant technology fields and has the ability to carry out the development work. So, the two parties reach this contract to jointly promote the development of this technology.III. Technical Development Content.1. Project Name.The name of this technology development project is: [Project Name]2. Specific Technical Requirements.Party A hopes that Party B can develop a system/technology/product with the following functions:[Function 1, describe it in detail, e.g., "A user friendly interfacethat allows users to easily input their personal information."][Function 2][Function 3]...The technology should meet the following performance standards:[Performance Standard 1, such as "The response time should be within 2 seconds."][Performance Standard 2][Performance Standard 3]...3. Development Plan and Milestones.Party B will follow the following development plan:In the first [number] weeks/months, complete the basic framework design. This includes [describe what is included in the basic framework].By the end of [specific time period], finish the key function development. For example, [mention the key functions to be completed].In the final [number] weeks/months, conduct comprehensive testing and debugging to ensure that all functions work properly and meet the performance standards.Party A has the right to check the progress at each milestone. If Party B fails to meet the milestone requirements on time, Party B should take immediate remedial measures and inform Party A in advance.IV. Intellectual Property Rights.1. Ownership of Intellectual Property.All intellectual property rights related to the developed technology, including but not limited to patents, copyrights, and trade secrets, shall belong to Party A. Party B agrees to transfer all relevant rights to PartyA upon completion of the project.However, Party B can use the relevant technology for internal research and improvement purposes, but not for any commercial use without thewritten permission of Party A.2. Confidentiality.Both parties shall keep the technical information, business secrets,and any other confidential information related to this project confidential.The confidentiality period is [number] years from the date of signing this contract.V. Consideration and Payment Terms.1. Total Consideration.Party A shall pay Party B a total of [amount in currency] for this technology development project.2. Payment Schedule.An initial payment of [amount] shall be made within [number] days after signing this contract. This payment is to cover Party B's initial research and preparation costs.After Party B completes the key milestone [describe the milestone], Party A shall pay [amount].The final payment of [amount] will be made upon successful completion of the project and acceptance by Party A.VI. Project Acceptance.1. Acceptance Criteria.Party A will accept the project based on the technical requirements and performance standards specified in this contract.Party B shall submit all relevant technical documents, including design documents, test reports, and user manuals, to Party A for review.2. Acceptance Procedure.Party B shall notify Party A in writing when the project is ready for acceptance.Party A shall organize relevant personnel to conduct acceptance tests within [number] days after receiving the notice.If the project fails to pass the acceptance test, Party B shall make necessary modifications and re submit for acceptance within [number] days.VII. Liability for Breach of Contract.1. By Party A.If Party A fails to make payments on time according to the payment schedule, Party A shall pay a late fee of [percentage] of the overdue amount per day.If Party A unilaterally terminates the contract without justifiable reasons, Party A shall compensate Party B for all losses already incurred and the expected profit of the unfinished part of the project.2. By Party B.If Party B fails to complete the project on time or fails to meet the technical requirements and performance standards, Party B shall refund all payments already received from Party A and compensate Party A for any losses caused thereby.If Party B discloses confidential information of Party A, Party B shall bear all legal liabilities and compensate Party A for all losses.VIII. Governing Law and Dispute Resolution.1. Governing Law.This contract shall be governed by the laws of [specific jurisdiction, like "the laws of the State of California" or "the laws of the People's Republic of China"].2. Dispute Resolution.In case of any disputes arising from this contract, the two parties shall first try to resolve them through friendly negotiation.If the negotiation fails, either party can submit the dispute to [specific arbitration body or court] for arbitration or litigation.IX. Miscellaneous.1. Amendments and Supplements.Any amendments or supplements to this contract shall be made in writing and signed by both parties.2. Entire Agreement.This contract constitutes the entire agreement between the two parties with respect to the subject matter hereof and supersedes all prior oral or written agreements and understandings relating to the same.3. Severability.If any provision of this contract is held to be invalid or unenforceable, the validity and enforceability of the remaining provisions shall not in any way be affected.This contract is made in duplicate, with each party holding one copy. The contract shall come into force as of the date of signing by both parties.Party A (Signature): [Authorized Signature of Party A]Date: [Date of Signing]Party B (Signature): [Authorized Signature of Party B]Date: [Date of Signing]。
技术开发(委托)合同 中英文
合同编号/ Contract Number:技术开发（委托）合同Contract of technical development(entrustment)项目名称：Project Name:委托方（甲方）：Entrusting Party (Party A):受托方（乙方）：Entrusted Party (Party B):签订时间/ Signing Date:签订地点/ Signing Address:中华人民共和国科学技术部印制Made by Ministry of Science and Technology of the People's Republicof China填写说明Filling Notes一、本合同为中华人民共和国科学技术部印制的技术开发（委托）合同示范文本，各技术合同认定登记机构可推介技术合同当事人参照使用。
1. This contract is the model contract of technical development (entrustment), which is made by Ministry of Science and Technology of the People's Republic of China. The institute of certificating and registering technical contract can recommend the party involved to use it.二、本合同书适用于一方当事人委托另一方当事人进行新技术、新产品、新工艺或者新材料及其系统的研究开发所订立的技术开发合同。
2. This contract is suitable for the contract of technical development, made by one party entrusts the other party to develop new technology, new product or new material and do systematic research for it.三、签约一方为多个当事人的，可按各自在合同关系中的作用等，在“委托方”、“受托方”项下（增页）分别排列为共同委托人或共同受托人。
技术开发合同英文版示范文本
技术开发合同英语示范文本1Technology development contracts play a crucial role in modern business, especially in the fields of software and hardware. A well-structured technology development contract clearly defines the rights and obligations of both parties, minimizing potential disputes and ensuring the smooth progress of the project.Let's take a software technology development contract as an example. Intellectual property rights are a key element. It should be clearly stipulated who owns the rights to the software developed, whether it's the developer or the client. For instance, if the client commissions a software for internal use only, the contract might state that the client has exclusive rights to use the software within their organization, but the developer retains the right to reuse certain components for other projects.In the case of hardware technology development, detailed specifications for product performance indicators are of great significance. The contract might specify parameters such as processing speed, power consumption, and durability. For example, in the development of a new type of mobile phone chip, the contract could require that the chip must achieve a certain benchmark in processing speed and energy efficiency to meet market expectations.Another important aspect is the timeline for the project. The contract should clearly outline the milestones and deadlines for each stage of the development process. This helps to ensure that the project stays on track and is delivered on time.In conclusion, a comprehensive and precise technology development contract is essential for the success of any technology-related project. It not only protects the interests of both parties but also lays a solid foundation for efficient collaboration and the achievement of common goals.2Technology development contracts play a crucial role in modern business and research scenarios. They serve as legal bindings that safeguard the interests of all parties involved. Let's take an example of a company collaborating with a scientific research institution to develop a new technology. In such a contract, the rights and obligations of both sides are clearly stipulated. The company might commit to providing financial resources and marketing support, while the research institution is responsible for conducting the technical research and development work. The contract would detail the timeline for each stage of the project, the ownership of intellectual property rights, and the mechanisms for resolving disputes.Another instance could be a startup team signing a technology development contract with an investor. This contract would clearly definethe investment amount and the usage of funds. The startup team might be obligated to achieve certain milestones within a specified time frame. At the same time, the investor would have the right to monitor the progress and have a say in major decisions. The contract would also address issues such as the exit strategy for the investor and the consequences of non-compliance by either party.In conclusion, technology development contracts are not just pieces of paper; they are powerful tools that ensure fairness, clarity, and protection. They provide a solid foundation for successful collaborations and innovations, allowing both parties to focus on achieving their common goals with confidence and security.3Technology development contracts play a crucial role in modern business transactions. However, they often come with hidden traps that one must be aware of. One common pitfall is the ambiguity in the technical standards stipulated in the contract. For instance, if the contract merely states that the developed technology should be "advanced" without clearly defining what constitutes "advanced", it can lead to significant disputes later on. The parties might have different understandings of this term, resulting in delays, extra costs, and even legal battles.Another potential risk lies in unreasonable confidentiality clauses. Say a contract demands an overly broad and long-term confidentialityobligation, which could severely restrict the developer's ability to collaborate with others or use similar technologies in future projects. This might prevent the developer from making legitimate advancements and limit their business opportunities.To prevent such issues, it is essential to have a detailed and precise contract. All technical standards should be clearly defined using measurable and objective criteria. When it comes to confidentiality, the scope and duration should be reasonable and balanced, taking into account the nature of the technology and the industry norms.In conclusion, a well-drafted technology development contract that anticipates and mitigates these potential traps is crucial for the success of the project and the protection of the interests of all parties involved.4Technology development contracts play a crucial role in driving innovation and progress in various industries. Different types of these contracts exhibit distinct characteristics and disparities.Take the contrast between internet technology development contracts and those in traditional manufacturing. In terms of delivery standards, for internet technology, the focus might be on seamless user experience, high performance, and scalability. The software or applications need to be compatible with a wide range of devices and operating systems. On the contrary, in traditional manufacturing, the delivery standard often lies inthe physical product meeting precise specifications, quality benchmarks, and functional requirements. Regarding the acceptance methods, for internet technology, it usually involves extensive testing of the software's functionality, security, and performance through automated tools and user feedback. However, in traditional manufacturing, physical inspections, quality checks, and performance evaluations of the manufactured products are common.Another example is the comparison between multinational and domestic technology development contracts. When it comes to legal application, multinational contracts have to navigate through the complex web of different legal systems and international laws. Cultural differences also pose significant considerations. Language barriers, diverse business practices, and different expectations regarding project timelines and communication styles can all impact the success of the contract. In domestic contracts, the legal framework is relatively uniform, and cultural understanding is typically more straightforward.In conclusion, understanding the unique features and differences of various types of technology development contracts is essential for achieving successful technological advancements and business collaborations in today's globalized and diverse marketplace.5Technology development contracts play a crucial role in both the legaland business domains. They serve as the foundation for successful collaborations and innovations in the technological landscape.Consider a case where a well-structured and comprehensive technology development contract was in place. A leading tech company joined forces with a research institution to develop a revolutionary software. The contract clearly defined the rights and obligations of each party, including the scope of the project, timelines, intellectual property rights, and financial arrangements. As a result, the project progressed smoothly, and the new software not only met but exceeded expectations. It led to a significant increase in market share for the company and established it as an industry leader.On the contrary, imagine a situation where a technology development contract had loopholes and ambiguous terms. A startup entered into a partnership with a larger firm to create a cutting-edge hardware device. However, due to the lack of clear provisions regarding the sharing of profits and the ownership of patents, disputes arose during the development process. This led to delays, increased costs, and ultimately, the failure of the project. The startup suffered substantial financial losses and lost valuable time and opportunities.In conclusion, a well-drafted technology development contract is not just a piece of paper; it is the blueprint for success. It ensures that all parties involved have a clear understanding of their roles and responsibilities,mitigates risks, and protects the interests of both sides. Only through careful consideration and precise drafting can these contracts drive technological advancements and business growth.。
技术合同范本中英文版
技术合同范本中英文版甲方（委托方）：Party A (Client):地址：Address:乙方（受托方）：Party B (Contractor):地址：Address:鉴于甲方需要就以下技术项目委托乙方进行研究、开发，双方本着平等互利的原则，经友好协商，达成如下协议：WHEREAS, Party A requires the research and development of the following technology project to be entrusted to Party B, and the Parties, in the spirit of equality and mutual benefit, have reached the following agreement through friendly negotiation:1. 技术项目名称：1. Name of Technology Project:2. 技术目标：2. Technical Objectives:3. 技术内容、范围和要求：3. Technical Content, Scope, and Requirements:4. 研究开发期限：4. Research and Development Period:5. 甲方的责任和义务：5. Party A’s Responsibilities and Obligations:6. 乙方的责任和义务：6. Party B’s Responsibilities and Obligations:7. 技术成果的归属和分享：7. Ownership and Sharing of Technical Achievements:8. 技术成果的验收：8. Acceptance of Technical Achievements:9. 付款方式和时间：9. Payment Method and Timing:10. 违约责任：10. Liability for Breach of Contract:11. 保密条款：11. Confidentiality Clause:12. 合同变更和解除：12. Contract Modification and Termination:13. 争议解决：13. Dispute Resolution:14. 其他约定：14. Other Agreements:本合同自双方授权代表签字盖章之日起生效。
技术开发合同协议书范本中英文对照
技术开发合同协议书范本中英文对照Technical Development Contract Agreement Sample (English-Chinese Comparison)This Technical Development Contract Agreement ("Agreement") is made and entered into this [date] (the "Effective Date") by and between [Company A], with its principal place of business at [address] (hereinafter referred to as "Party A"), and [Company B], with its principal place of business at [address] (hereinafter referred to as "Party B").WHEREAS, Party A is engaged in the business of technical development and has the expertise and resources required for software development;WHEREAS, Party B desires to engage Party A for the development of a customized software solution;NOW, THEREFORE, in consideration of the promises and mutual covenants contained herein, the Parties hereby agree as follows:1. Scope of Work1.1 Party B engages Party A to develop a customized software solution (the "Project") in accordance with the specifications outlined in Exhibit A.1.2 Party B shall provide Party A with all necessary information and resources to complete the Project. Party A shall use its best efforts to develop the Project in a timely and professional manner.2. Project Timeline2.1 The Project shall commence on the Effective Date and is estimated to be completed within [number] months.2.2 Party A shall provide Party B with regular updates on the progress of the Project.3. Payment Terms3.1 Party B shall pay Party A a total sum of [amount] for the development of the Project. The payment shall be made in [number] installments as follows:- X% of the total sum upon execution of this Agreement;- Y% of the total sum upon successful completion of [milestone];- Z% of the total sum upon delivery and acceptance of the finalized software solution.4. Intellectual Property4.1 Party A acknowledges that all intellectual property rights, including but not limited to copyrights, patents, and trade secrets, arising from the Project shall be the sole property of Party B.4.2 Party A agrees to promptly disclose and assign to Party B any inventions, improvements, or developments made in connection with the Project.5. Confidentiality5.1 Both Parties agree to treat any information disclosed during the course of this Agreement as confidential. Such information shall not bedisclosed to any third party without the prior written consent of the disclosing Party.6. Termination6.1 Either Party may terminate this Agreement upon written notice if the other Party fails to fulfill its obligations under this Agreement, provided that a cure period of [number] days is given for the defaulting Party to rectify the breach.7. Governing Law and Jurisdiction7.1 This Agreement shall be governed by and construed in accordance with the laws of [jurisdiction]. Any disputes arising out of or in connection with this Agreement shall be subject to the exclusive jurisdiction of the courts of [jurisdiction].IN WITNESS WHEREOF, the Parties have executed this Technical Development Contract Agreement as of the Effective Date first above written.[Company A][Authorized Signatory][Company B][Authorized Signatory]技术开发合同协议书范本（中英文对照）本技术开发合同协议书（以下简称“协议”）由以下双方于【日期】签署并生效。
英文技术开发合同7篇
英文技术开发合同7篇篇1This Technology Development Contract (hereinafter referred to as the "Contract") is made and executed on the basis of mutual respect and mutual trust between the parties, in accordance with the laws of the People's Republic of China.Party A: ________________ (hereinafter referred to as "the Company")Party B: ________________ (hereinafter referred to as "the Developer")I. Contract ObjectiveThe purpose of this Contract is to set out the terms and conditions under which Party B shall undertake the development of a technology project for Party A, with specific focus on the development of ________________ (describe the technology or project in detail).II. Scope of Work1. Party B shall develop the technology project in accordance with the specifications and requirements provided by Party A.2. Party B shall provide technical support and consultation services related to the project.3. The scope of work also includes ________________ (please add other relevant items).III. Contract Term and Commencement Date1. This Contract shall be effective from ________________ (Effective Date) and shall continue until ________________ (Expiration Date).2. The period of performance for the project shall be________________ (development timeframe).IV. Rights and Obligations of the Parties1. Party A has the right to request Party B to carry out the development work in accordance with this Contract.2. Party B has the obligation to complete the development work in a timely and professional manner.3. Party B shall ensure the quality of the developed technology meets the standards set by Party A.4. Party A shall provide necessary materials, information, and support to Party B during the development process.5. Both parties shall keep confidential all information related to this Contract that is not intended for public disclosure.V. Payment Terms1. Party A shall pay Party B a total amount of ________________ (Total Contract Amount) for the development work.2. Payment shall be made in accordance with the payment schedule attached to this Contract.3. In case of any delay in payment by Party A, Party B shall be entitled to claim compensation for any losses incurred.VI. Intellectual Property Rights1. All intellectual property rights arising from the development work shall be owned by Party A, unless otherwise agreed by both parties.2. Party B shall not use any intellectual property belonging to Party A for any purpose other than the development work under this Contract.VII. Termination and Suspension of Contract1. This Contract may be terminated by either party in the case of breach of contract by the other party.2. In case of force majeure circumstances, either party may suspend performance of this Contract until such circumstances are resolved.VIII. Liability and Indemnification1. Either party shall be liable for any losses incurred to the other party due to breach of contract.2. In case of any third-party claims or lawsuits arising from this Contract, both parties shall jointly and severally indemnify each other.IX. Miscellaneous1. This Contract constitutes the entire agreement between the parties and no modifications shall be made except by mutual consent in writing.2. Any disputes arising from or in connection with this Contract shall be resolved through friendly negotiation. If no settlement is reached, such disputes shall be submitted to the jurisdiction of ________________ (specify the court or arbitration institution).3. This Contract shall be governed by and construed in accordance with the laws of the People's Republic of China.4. This Contract is made in ________________ (specify language) and is binding upon both parties equally.Party A:Name:Signature:篇2Development Contract for Technology in English甲方（委托方）：____________________（Name of Client）地址：____________________（Address）联系方式：____________________（Contact Information）乙方（开发方）：____________________（Name of Developer）地址：____________________（Address）联系方式：____________________（Contact Information）鉴于甲方需要对特定技术进行开发，而乙方具备相关技术开发的实力和经验，双方在平等、自愿、公平的基础上，经过友好协商，达成以下技术开发合同协议：一、合同目的和背景本合同旨在明确甲、乙双方在技术开发项目中的权利与义务，确保双方合作顺利进行，共同实现技术开发的成功。
技术开发合同协议书范本中英文对照
技术开发合同协议书范本中英文对照编号：_____________NO: _____________技术开发合同书T echnology Development Contract甲方：________________________________________________Part A: ________________________________________________乙方：___________________________Part B: ________________________________________________签订日期：_______年______月______日DATE: ____________/__________________/__________________Entrusting Party (Party A):委托方（甲方）：Address:地址：Tel: Fax:Entrusted Party (Party B):受托方（乙方）：Address:地址:Tel: Fax:Party A entrust Party B to research and develop Technique Proposal Of Smart T/R Verification System. Party B will develop key circuits verification for the Solution and will be in charge of general thought plan. The following articles are reached and abided by the both parties.甲方委托乙方设计智能收发验证系统技术方案，乙方将设计开发方案的验证电路及负责整体思路的建立，为此订立以下协议，并由双方共同恪守。
- 1、下载文档前请自行甄别文档内容的完整性，平台不提供额外的编辑、内容补充、找答案等附加服务。
- 2、"仅部分预览"的文档,不可在线预览部分如存在完整性等问题,可反馈申请退款(可完整预览的文档不适用该条件!)。
- 3、如文档侵犯您的权益，请联系客服反馈,我们会尽快为您处理(人工客服工作时间：9:00-18:30)。
技术开发合同书Technology Development Contract鉴于：本合同签约各方就本合同书中所描述项目的研究开发、投资融资、成果权属、收益分配、风险责任以及与之相关的技术和法律问题经过平等协商，在真实、充分地表达各自意愿的基础上，根据《中华人民共和国合同法》之规定，达成如下协议，由签约各方共同恪守。
WHEREAS:The Parties hereto have carried out mutual consultation on an equal basis with respect to the research and development, investment financing, deliverables’ ownership, profit distribution, risk liabilities and any related technical and legal issues concerning the project contemplated herein, the Parties have entered into this Contract on the basis of good faith, pursuant to the Contract Law of the People’s Republic of China, and agree to be bound hereby:第一条签约方Article 1 The Parties:本合同属于：1、委托开发合同□2、合作开发合同□This Contract is a:1. Authorized Development Contract; or2. Joint Development Contract第三条签约时间和地点Article 3 Date and Place of Execution本合同由上述签约方于年月日在签订。
This Contract is made and entered into as of ______ by and between the foregoing Parties in ___________.第四条项目名称（用简明规范的专业术语概括技术特征）Article 4 Project Name第五条技术内容Article 5 Technology Description5.1 技术主要组成部分：5.1 Major Technology Components:5.2 研究方法和技术路线：5.2 Research Method and Technology Roadmap5.3 技术开发手段：5.3 Technology Development Methods5.4 技术目标（包括技术指标和参数）：5.4 Technological Target (including technical specifications and parameters):第六条研究开发计划Article 6 Research and Development Plan6.1 阶段进度：6.1 Project Milestones6.2 总体计划：6.2 Overall Plan:第七条转委托Article 7 Transfer7.1 开发方/合作双方是否可以将部分开发工作转委托给第三方：（1）是□（2）否□7.1 The Contractor/Cooperation Parties may/may not transfer part of the development work to a third party:7.2 转委托的具体内容包括：7.2 The specific work to be transferred includes:第八条保密要求Article 8 Confidentiality8.1 保密范围：8.1 Confidential Information:8.2 保密期限：8.2 Term of the Confidentiality Obligation:第九条权利保障Article 9 Warranty签约方保证本合同涉及的全部技术内容具有自主性和真实性，并不因本合同的履行而侵犯他人的合法权益。
The Parties warrant that all the technologies under this Contract are proprietary and authentic, and will not infringe upon others’ legitimate rights and interests due to the performance of this Contract.第十条风险承担Article 10 Risks10.1 在本合同履行过程中，因现有技术水平和客观条件下难以克服的技术困难造成的损失，风险责任按如下约定承担：10.1 During the performance of this Contract, the Parties shall assume any risks and liabilities arising from any technical difficulties that cannot be overcome under the current technical level and objective conditions, as follows:10.2 因不可抗力因素造成的损失，双方按如下约定承担：10.2 The Parties shall bear any losses arising from any force majeure event as follows:10.3 本合同所指不可抗力因素，除法律规定情形之外，还包括以下情形：10.3 Unless otherwise provided for in law, the force majeure event as mentioned herein shall include the following events:第十一条技术成果权益的归属和分享Article 11 Ownership and Sharing of Intellectual Property Rights11.1 履行本合同产生的技术成果申请专利的权利归方所有；11.1 The right to apply for intellectual property rights arising from the performance of this Contract shall vest in Party ______;11.2 履行本合同产生的技术秘密成果有关权益约定如下：1、使用权归属：甲方□乙方□甲乙双方□2、转让权归属：甲方□乙方□甲乙双方□3、使用、转让所产生利益的分配办法：11.2 The ownership of any confidential intellectual property rights arising from the performance of this Contract shall vest in:1. Use rights: Party A □ Party B □ Party A & Party B □2. Transfe r rights: Party A □ Party B □ Party A & Party B □3. Method of distribution of earnings from right use and transfer:11.3 其他需要约定的内容：11.3 Other provisions that need be specified:第十二条成果验收Article 12 Acceptance of Deliverables12.1 技术成果交付载体：12.1 Deliverables:12.2 技术成果交付时间、地点：12.2 Date and Place of the Provision of Deliverables:12.3 技术成果验收标准、方式：12.3 Standards and Methods of the Acceptance of Deliverables:第十三条相关技术服务Article 13 Relevant Technical Services13.1 签约方确认，履行本合同是否需要相关技术服务：（1）是□（2）否□13.1 The Parties acknowledge that the performance of this Contract will / will not need any relevant technical services.13.2 相关技术服务的内容、方式：13.2 Description of relevant technical services and method of provision thereof:第十四条费用及支付方式Article 14 Expenses and Payment Method14.1 本合同费用总额为元。
其中：（1）技术开发经费为元；（2）购置相关设备等费用为元；（3）相关技术服务费为元。
14.1 The total expenses under this Contract shall be RMB_____, including:(1) technical development expenses: RMB_____;(2) expenses for the purchase of relevant equipment: RMB____; and(3) relevant technical service fees: RMB_______.14.2 委托开发合同委托方费用，按以下第种方式支付：（1）一次总付，支付时间和方式：（2）分期支付，支付时间和方式：（3）其他方式约定如下：14.2 The expenses payable by the Employer under the Authorized Development Contract shall be paid by the following ___ method:(1) In one lump sum; date and method of payment:(2) In installments; date and method of payment:(3) Other agreed-upon method:14.3 合作开发合同签约各方确认按以下比例承担费用：14.3 The parties to the Joint Development Contract acknowledge that relevant expenses shall be borne as set forth below:（1）技术开发费：(1) Technical Development Fee:甲方元，支付时间和方式：Party A: RMB________; date and method of payment:14.3 乙方元，支付时间和方式：Party B: RMB______; date and method of payment:（2）设备等其他费用：(2) Equipment and other expenses:甲方元，支付时间和方式：Party A: RMB____; date and method of payment:乙方元，支付时间和方式：Party B: RMB_____; date and method of payment:（3）相关技术服务费的约定：(3) Other provisions on relevant technical service fees:第十五条违约责任Article 15 Liability for Breach15.1 如果一方不能按照本协议执行而给另一方造成了损失，受害方有权利要求对方给予相应的赔偿。