工程建设合同范本,英文
英文建筑合同模板
英文建筑合同模板Building Contract Template。
This Building Contract ("Contract") is made and entered into as of [Date], by and between [Builder Name], with a principal place of business at [Address] ("Builder"), and [Owner Name], with a principal place of residence at [Address] ("Owner").1. Scope of Work。
Builder agrees to provide all labor, materials, equipment, and services necessary for the construction of [Description of Project] ("Project") in accordance with the plans and specifications attached hereto as Exhibit A. Builder shall complete the Project in a good and workmanlike manner, in compliance with all applicable laws, regulations, and codes.2. Payment。
Owner agrees to pay Builder the total contract price of [Total Contract Price] for the completion of the Project. The payment shall be made in installments as follows:a. [Percentage]% of the total contract price upon the execution of this Contract;b. [Percentage]% of the total contract price upon completion of [Milestone 1];c. [Percentage]% of the total contract price upon completion of [Milestone 2];d. [Percentage]% of the total contract price upon substantial completion of the Project; and。
建设工程施工合同(GF-2013-0201)中英文翻译件范本
资料可以编辑修改使用资料可以编辑修改使用资料可以编辑修改使用致力于数据挖掘，合同简历、论文写作、PPT设计、计划书、策划案、学习课件、各类模板等方方面面，打造全网一站式需求主要经营：网络软件设计、图文设计制作、发布广告等，公司秉着以优质的服务对待每一位客户，做到让客户满意工程编号：__________________Project No.:合同编号：__________________Contract No.:建设工程施工合同Construction Contract for Construction Projects（GF-2013-0201）工程名称：Name of project:工程地点：Location of project:发包人：Client:承包人：Contractor:住房和城乡建设部制定国家工商行政管理总局Made byMinistry of Housing Urban-Rural DevelopmentState Administration for Industry & Commerce of the P. R.C目录Table of Contents第一部分合同协议书……………………………………………………......................…...错误！未定义书签。
Part I Contract Agreement ………………………………………......................…...错误！未定义书签。
一、工程概况 (17)I. Project Overview (17)二、合同工期 (20)II. Project Duration under Contract (18)三、质量标准 (18)III. Quality Standard (18)四、签约合同价与合同价格形式 (20)IV. Contract Price and Form of Contract Price (18)五、项目经理 ..........…..........…..........…..........…..........…..........…..........…..........…错误！未定义书签。
工程建设合同范本英文
工程建设合同范本英文Contract for Construction rojectThis Contract for Construction roject (the "Contract") is made and entered into on [Date], y and etween [Owner's Name], with its registered office at [Owner's Address] ("Owner"), and [Contractor's Name], with its registered office at [Contractor's Address] ("Contractor").Whereas, the Owner wishes to construct a roject known as [roject Name] located at [roject Location], andWhereas, the Contractor has agreed to erform the construction services in accordance with the terms and conditions set forth herein.NOW, THEREFORE, in consideration of the mutual romises, covenants, and agreements contained herein, the arties agree as follows:1. SCOE OF WORKThe Contractor shall rovide all laor, materials, equiment, and services necessary for the comletion of the construction roject descried in the [roject Documents], which include the lans, secifications, drawings, and other related documents aroved y the Owner.2. CONTRACT SUM AND AYMENTThe total contract sum for the roject is [Contract Sum in currency]. The ayment shall e made in accordance with the schedule outlined in the ayment lan annexed to this Contract.3. SCHEDULEThe Contractor shall commence work on [Commencement Date] and comlete the roject y [Comletion Date]. Any delay in the comletion date shall e suject to liquidated damages as secified herein.4. QUALITY ASSURANCEThe Contractor warrants that all works shall e erformed in a good and workmanlike manner, in accordance with the standards and requirements secified in the [roject Documents].5. CHANGE ORDERSAny changes to the scoe of work or the roject Documents shall e made ursuant to a written change order, which shall e inding uon oth arties once signed.6. INDEMNITY AND INSURANCEThe Contractor shall indemnify and defend the Owner against any claims, losses, or exenses related to the Contractor's negligence or reach of contract. The Contractor shall carry insurance olicies as required y law and as secified in this Contract.7. TERMINATIONEither arty may terminate this Contract in the event of a material reach y the other arty, which remains uncured after notice.8. GOVERNING LAWThis Contract shall e governed y and construed in accordance with the laws of [Governing Law Country].9. DISUTE RESOLUTIONAny disute arising out of or in connection with this Contract shall e resolved through mediation. If mediation fails, the disute shall e finally settled y aritration in accordance with the rules of [Aritration Association].10. ENTIRE AGREEMENTThis Contract constitutes the entire agreement etween the arties and suersedes all rior negotiations, reresentations, and understandings. This Contract may only e amended y a written document duly executed y oth arties.IN WITNESS WHEREOF, the arties have executed this Contract as of the date first aove written.[Owner's Name]y: _______________ [Titleosition][Name], [Signature][Contractor's Name]y: _______________ [Titleosition][Name], [Signature]。
英文承揽工程合同范本
英文承揽工程合同范本PARTIES TO THE CONTRACT:The following contract is entered into between [Contractor Name], hereinafter referred to as the "Contractor", and [Client Name], hereinafter referred to as the "Client".SCOPE OF WORK:The Contractor agrees to perform the following services as part of this contract:1. Supplying all necessary materials, equipment, and labor for the completion of the construction project located at [Project Address].2. Adhering to all local building codes and regulations throughout the duration of the project.3. Completing the project within the agreed-upon timeline of [Start Date] to [Completion Date].4. Keeping the worksite clean and safe at all times.PAYMENT TERMS:The Client agrees to pay the Contractor a total of [Total Contract Amount] for the completion of the project. Payment will be made in installments as follows:1. A deposit of [Deposit Amount] is due upon signing of this contract.2. Progress payments of [Progress Payment Amount] will be due on the 1st and 15th of each month.3. The final payment of [Final Payment Amount] will be due upon completion and approval of the project.CHANGES TO THE SCOPE OF WORK:Any changes to the scope of work must be agreed upon in writing by both parties. Any additional work requested by the Client will incur extra charges as determined by the Contractor.TERMINATION OF CONTRACT:Either party may terminate this contract with written notice if the other party fails to fulfill their obligations under the agreement. In the event of termination, the Client will be responsible for payment of all work completed up to the date of termination.DISPUTE RESOLUTION:Any disputes arising out of this contract will be resolved through mediation by a neutral third party. If mediation is unsuccessful, the parties agree to resolve the dispute through binding arbitration.IN WITNESS WHEREOF, the parties have executed this contract as of the date first above written.CONTRACTOR: [Contractor Name] Date: [Date]CLIENT: [Client Name] Date: [Date]This contract represents the entire agreement between the Contractor and the Client and supersedes any prior agreements or understandings, whether written or oral.。
英文工程合同模板
英文工程合同模板Engineering Contract Template。
This Engineering Contract ("Contract") is entered into as of [Date], by and between [Client Name] ("Client") and [Engineering Firm Name] ("Firm").1. Scope of Work。
The Firm agrees to provide engineering services for the following project:[Project Description]2. Services。
The Firm shall provide the following services:[List of Services]3. Schedule。
The Firm shall commence work on the project on [Start Date] and shall complete the work by [End Date].4. Compensation。
The Client agrees to pay the Firm a total fee of [Total Fee] for the services provided under this Contract. The fee shall be paid in [Number of Installments] installments as follows:[Payment Schedule]5. Changes。
Any changes to the scope of work or services to be provided under this Contract must be agreed upon in writing by both parties.6. Termination。
建设工程英文合同范本
建设工程英文合同范本Construction Engineering ContractParty A: [Name of Party A]Party B: [Name of Party B]This Construction Engineering Contract (hereinafter referred to as the "Contract") is entered into by and between Party A and Party B on [Date].Article 1 Scope of Work1. Party A agrees to engage Party B to complete the construction of [Project Name] located at [Project Address]. The scope of work includes but is not limited to [Details of Work to be Completed].2. Party B shall provide all labor, materials, equipment, and services necessary to complete the construction in accordance with the plans and specifications provided by Party A.Article 2 Contract Price1. The total contract price for the construction project shall be [Total Amount in Words] ([Total Amount in Numbers]) payable as follows:- [Amount] upon signing of the Contract- [Amount] upon completion of [Specific Milestone]- [Amount] upon final completion and acceptance of the construction project2. Any additional work requested by Party A shall be subject to written change orders and may result in adjustments to the contract price.Article 3 Time of Completion1. The construction project shall commence on [Start Date] and shall be completed no later than [End Date] unless extended in writing by both parties.2. Party B shall provide a construction schedule outlining the sequenceof work and the anticipated completion dates for each phase of the project.Article 4 Quality and Performance1. Party B agrees to perform all work in a professional and workmanlike manner and in accordance with industry standards.2. All materials and equipment used in the construction shall be new, unless otherwise agreed upon in writing by both parties.3. Party B shall be responsible for any defects or deficiencies in the workmanship or materials for a period of [Warranty Period] from the date of final completion.Article 5 Inspection and Acceptance1. Upon completion of the construction project, Party A shall have the right to inspect the work and may request any necessary corrections or repairs.2. Party A shall issue a certificate of acceptance within [Number of Days] days of satisfactory completion of the construction project.Article 6 Payment Terms1. Progress payments shall be made by Party A to Party B in accordance with the following schedule:- [Payment Schedule]2. Invoices for progress payments must be submitted by Party B to PartyA in a timely manner and shall include detailed documentation of work completed.Article 7 Termination1. Either party may terminate this Contract by providing written notice to the other party in the event of a material breach of the terms and conditions of the Contract.2. In the event of termination, Party B shall be entitled to payment for work performed up to the date of termination and any costs incurred as a result of the termination.Article 8 Dispute Resolution1. Any disputes arising out of or relating to this Contract shall be resolved through negotiations between the parties.2. If the parties are unable to reach a resolution through negotiations, the dispute shall be referred to binding arbitration in accordance with the laws of [Jurisdiction].Article 9 Governing LawThis Contract shall be governed by and construed in accordance with the laws of [Jurisdiction].Article 10 Entire AgreementThis Contract constitutes the entire agreement between the parties with respect to the construction project and supersedes all prior agreements, whether written or oral.IN WITNESS WHEREOF, the parties hereto have executed this Contract as of the date first above written.Party A: ________________________ Date: ___________Party B: ________________________ Date: ___________[Signatures of Parties]。
工程合同模板英文
工程合同模板英文This Engineering Contract (“Contract”) is entered into by and between [Client Name], with a mailing address at [Client Address] (“Client”) and [Engineering Company Name], with a mailing address at [Engineering Company Address] (“Engineer”), collectively referred to as the “Parties.”1. Scope of WorkEngineer agrees to provide engineering services to Client for the project located at [Project Location]. The scope of work shall include but not be limited to [Description of Services]. 2. Time FrameThe services shall commence on [Start Date] and be completed by [Completion Date]. The Parties agree to adhere to the agreed-upon schedule and milestones outlined in the Project Plan.3. CompensationClient agrees to pay Engineer a total fee of [Total Fee] for the services rendered. Payment shall be made in installments as follows: [Payment Schedule]. Payment shall be made within [Number] days of receipt of an invoice from Engineer.4. Change OrdersAny changes to the scope of work or project schedule must be agreed to in writing by both Parties. Additional fees may apply for any changes requested by Client.5. ResponsibilitiesClient agrees to provide Engineer with all necessary information, access, and resources required to complete the project. Engineer shall perform the services in a professional and timely manner, adhering to industry standards and best practices.6. Ownership of WorkAll work product created by Engineer in connection with the project shall belong to Client upon payment of the total fee. Engineer retains the right to use project information for marketing and promotional purposes.7. TerminationEither Party may terminate this Contract by providing written notice to the other Party. In the event of termination, Client agrees to pay Engineer for all services rendered up to the date of termination.8. ConfidentialityBoth Parties agree to keep all project-related information confidential and not disclose it to any third parties without prior written consent.9. InsuranceEngineer shall maintain professional liability insurance coverage for the duration of the project. Client agrees to maintain general liability insurance coverage.10. Governing LawThis Contract shall be governed by and construed in accordance with the laws of [State]. Any disputes arising from this Contract shall be resolved through arbitration.In witness whereof, the Parties have executed this Contract as of the date first above written. Client:______________________________[Client Name]Engineer:______________________________[Engineering Company Name]This Contract is effective as of the date of signing by both Parties.。
工程投标合同范本英文
工程投标合同范本英文Engineering Tendering ContractThis Engineering Tendering Contract (hereinafter referred to as the "Contract") is made and entered into and between [Bidder's Name] (hereinafter referred to as the "Bidder") and [Tenderer's Name] (hereinafter referred to as the "Tenderer") on [date of contract].1. Subject Matter of TenderingThe Bidder agrees to submit a tender for the [description of the project] in accordance with the requirements and specifications provided the Tenderer.2. Bidder's ObligationsThe Bidder shall prepare and submit a plete and accurate tender proposal, including but not limited to technical plans, price quotations, and other relevant information, within the stipulated time.3. Tenderer's ObligationsThe Tenderer shall provide all necessary information and documents to the Bidder to facilitate the tendering process. The Tenderer shall also evaluate the tenders received in a fr and transparent manner.4. Evaluation and AwardThe Tenderer shall evaluate the tenders based on pre-determined criteria and shall award the contract to the most suitable Bidder.5. ConfidentialityBoth the Bidder and the Tenderer shall mntn the confidentiality of all information and documents exchanged during the tendering process.6. Dispute ResolutionIn the event of any disputes or differences arising between the parties in connection with this Contract, the parties shall attempt to resolve them through amicable negotiations. If such negotiations fl, the disputes shall be submitted to arbitration in accordance with the applicable arbitration rules.7. TerminationEither party may terminate this Contract in the event of a material breach the other party.8. MiscellaneousThis Contract contns the entire agreement between the parties and supersedes all prior negotiations and understandings. Any amendments or modifications to this Contract shall be in writing and signed both parties.IN WITNESS WHEREOF, the parties have signed this Contract as of the date first above written.Bidder: [Bidder's Name]Signature: [Bidder's Signature]Tenderer: [Tenderer's Name]Signature: [Tenderer's Signature]Please note that this is just a basic template and may need to be customized and adapted based on the specific requirements and circumstances of your project. It is always advisable to consult a legal professional for accurate and prehensive contract drafting.。
建设工程合同 英文
建设工程合同英文Title: Construction Engineering Contracts。
Construction engineering contracts are essential documents that outline the terms and conditions of a construction project. These contracts are crucial for ensuring that all parties involved in the project understand their responsibilities and obligations.The construction engineering contract typically includes details such as the scope of work, project timeline, payment terms, and dispute resolution procedures. It also outlines the roles and responsibilities of the owner, contractor, and any other parties involved in the project.One of the key elements of a construction engineering contract is the scope of work. This section clearly defines the work to be performed, including the specific tasks, materials, and equipment required for the project. By clearly outlining the scope of work, the contract helps to prevent misunderstandings and disputes during the construction process.The project timeline is another important aspect of a construction engineering contract. This section outlines the start and completion dates of the project, as well as any milestones or deadlines that need to be met. Having a clear timeline in the contract helps to ensure that the project stays on track and is completed in a timely manner.Payment terms are also a critical component of construction engineering contracts. This section specifies the payment schedule, including the amount and timing of payments to be made to the contractor. It also outlines any penalties or incentives related to meeting project deadlines or milestones.In addition to these key elements, construction engineering contracts also include provisions for dispute resolution. This section outlines the procedures to be followed in the event of a dispute between the parties involved in the project. By including these provisions in the contract, potential conflicts can be resolved in a fair and efficient manner.In conclusion, construction engineering contracts play a vital role in ensuring the success of construction projects. By clearly outlining the scope of work, project timeline, payment terms, and dispute resolution procedures, these contracts provide a solid foundation for the successful completion of construction projects. It is essential for all parties involved in a construction project to carefully review and understand the terms of the contract before signing, in order to avoid any potential issues or disputes down the line.。
epc英文合同范本
epc英文合同范本EPC英文合同范本名称：____________________地址：____________________名称：____________________地址：____________________鉴于雇主希望乙方按照本协议规定的条款和条件，为雇主提供工程、采购和建设（EPC）服务，双方达成如下协议：一、定义1. 工程服务（Engineering Services）：指乙方根据本协议规定，为雇主提供的工程设计、技术支持、项目管理等服务。
2. 采购服务（Procurement Services）：指乙方根据本协议规定，为雇主采购所需的设备、材料、技术等。
3. 建设服务（Construction Services）：指乙方根据本协议规定，为雇主进行的土建、安装、调试、试运行等服务。
4. EPC服务：指乙方根据本协议规定，为雇主提供的工程、采购和建设服务。
5. 合同价格（Contract Price）：指本协议中双方商定的EPC服务的总价格。
6. 工程进度计划（Project Schedule）：指乙方根据本协议规定，制定的工程实施计划。
二、合同内容1. 工程服务a. 工程设计；b. 技术支持；c. 项目管理。
2. 采购服务a. 采购所需的设备、材料、技术等；b. 负责与供应商的沟通、协调、谈判；c. 负责采购合同的签订和履行。
3. 建设服务a. 土建工程；b. 设备安装；c. 调试、试运行；d. 工程验收。
4. EPC服务的履行（4）乙方应按照本协议规定的工程进度计划，履行EPC服务。
三、合同价格与支付1. 合同价格（1）本协议的合同价格为______（币种及金额），包括工程服务、采购服务和建设服务的全部费用。
2. 支付a. 工程服务费用：按工程进度计划支付；b. 采购服务费用：按采购合同支付；c. 建设服务费用：按建设进度支付。
四、合同期限本协议的有效期为______个月，自双方签订之日起计算。
国际工程合同范本英文
国际工程合同范本英文International Engineering ContractThis International Engineering Contract (hereinafter referred to as the "Contract") is made and entered into on [date] and between [Party A name], a pany incorporated and existing under the laws of [Party A's country], with its registered address at [Party A's address] (hereinafter referred to as "Party A"), and [Party B name], a pany incorporated and existing under the laws of [Party B's country], with its registered address at [Party B's address] (hereinafter referred to as "Party B").1. Project DescriptionParty A here engages Party B to undertake the [project name] project (hereinafter referred to as the "Project") at the location of [project location]. The scope of the Project includes but is not limited to [detled project scope].2. Contract Price and Payment TermsThe total contract price for the Project is [contract price] (inclusive of all taxes and fees). Party A shall make the following payments to Party B:An advance payment of [advance payment amount] within [number of days] days after the signing of this Contract.Progress payments based on the pletion of milestones as mutually agreed and specified in the Contract.3. Project ScheduleThe Project is expected to be pleted within [project duration] days from the effective date of this Contract. The detled project schedule shall be provided Party B and approved Party A within [number of days] days after the signing of this Contract.4. Quality Assurance and WarrantyParty B shall ensure that the Project is pleted in accordance with the applicable industry standards and the requirements specified in this Contract. Party B shall provide a warranty for the Project for a period of [warranty period] after the pletion and acceptance of the Project.5. Force MajeureIf either party is unable to perform its obligations under this Contract due to force majeure events such as natural disasters, wars, or government actions, the affected party shall notify the other party in writing within a reasonable time and provide relevant evidence. The performance of the Contract shall be suspended during the period of force majeure, and the parties shall negotiate in good fth to find an appropriate solution.6. Dispute ResolutionAny disputes arising from or in connection with this Contract shall be resolved through friendly negotiation between the parties. If the negotiation fls, the dispute shall be submitted to arbitration in accordance with the rules of [arbitration institution].7. Governing LawThis Contract shall be governed and construed in accordance with the laws of [applicable law jurisdiction].8. Other Terms and ConditionsThis Contract contns all the terms and conditions agreed upon the parties regarding the Project. Any amendments or additions to this Contract shall be made in writing and signed both parties.IN WITNESS WHEREOF, the parties have executed this Contract as of the date first above written.Party A: [Party A's signature and name]Party B: [Party B's signature and name]Date: [date]Please note that the above is just a basic template and may need to be customized based on the specific nature and requirements of the international engineering project. It is remended to consult with legal professionals for a prehensive and legally binding contract.。
工程英文合同范本
工程英文合同范本Engineering ContractThis Engineering Contract (the "Contract") is made and entered into as of [date] (the "Effective Date"), and between [Client Name], a [Client Entity Type] with its principal place of business at [Client Address] (the "Client"), and [Contractor Name], a [Contractor Entity Type] with its principal place of business at [Contractor Address] (the "Contractor").1. Project DescriptionThe Contractor shall undertake the [Project Name] project (the "Project") as described in the attached Exhibit A. The Project shall include, but not be limited to, the following scope of work: [Describe the scope of work in detl].2. Contract Price and Payment Terms2.1 The total contract price for the Project is [Total Contract Price] (the "Contract Price"), which is inclusive of all taxes, duties, and other charges.2.2 The Client shall make the following payments to the Contractor:[Payment Schedule and Amounts]2.3 Payments shall be made within [Number of Days] days after the Contractor submits an invoice and the Client receives and approves the same.3. Project Schedule3.1 The Contractor shall mence the Project on or before [Commencement Date] and shall plete the Project [Completion Date].3.2 The Project schedule is attached as Exhibit B. The Contractor shall adhere to the schedule and notify the Client in writing of any anticipated delays or deviations from the schedule.4. DeliverablesThe Contractor shall deliver to the Client the following deliverables: [List the deliverables and their specifications]. The deliverables shall be delivered to the Client at the address specified in this Contract.5. Quality Assurance and Inspection5.1 The Contractor shall perform the Project in a professional and workmanlike manner and in accordance with the industry standards and best practices.5.2 The Client shall have the right to inspect the work in progress and the pleted deliverables. The Contractor shall provide reasonable access to the work site and cooperate with the Client's inspection.5.3 If the Client finds any defects or deficiencies in the work or the deliverables, the Contractor shall rectify the same at its own cost within a reasonable time.6. Intellectual Property Rights6.1 All intellectual property rights arising out of or in connection with the Project shall belong to the Client, unless otherwise agreed in writing.6.2 The Contractor shall not use or disclose any of the Client's intellectual property rights without the prior written consent of the Client.7. Confidentiality7.1 Both parties agree to keep the terms and conditions of this Contract and all information related to the Project confidential and not to disclose the same to any third party without the prior written consent of the other party.7.2 This confidentiality obligation shall survive the termination of this Contract.8. Termination8.1 Either party may terminate this Contract in the event of a material breach the other party. The terminating party shall give written notice of the breach to the other party and allow the other party a reasonable time to cure the breach. If the breach is not cured within the specified time, the Contract shall be terminated.8.2 In the event of termination, the Contractor shall stop work immediately and shall deliver to the Client all work in progress and pleted deliverables. The Client shall pay the Contractor for the work performed up to the date of termination, less any damages or losses suffered the Client as a result of the Contractor's breach.9. Force MajeureNeither party shall be liable for any flure or delay in performing its obligations under this Contract if such flure or delay is caused an event of force majeure, which shall include, but not be limited to, natural disasters, wars, strikes, lockouts, and government actions. The affected party shall notify the other party in writing of the force majeure event as soon as possible and shall provide evidence of the same. The parties shall then discuss and agree on a reasonable course of action to minimize the impact of the force majeure event.10. Dispute ResolutionIn the event of a dispute or controversy arising out of or in connection with this Contract, the parties shall first attempt to resolve the same through amicable negotiations. If the negotiations fl, the dispute shall be submitted to arbitration in accordance with the rules of [Arbitration Institution]. The arbitration shall take place in [Arbitration Location] and the language of the arbitration shall be English. The decision of the arbitrator shall be final and binding on both parties.11. Governing LawThis Contract shall be governed and construed in accordance with the laws of [Jurisdiction].12. Entire AgreementThis Contract constitutes the entire agreement between the parties with respect to the subject matter hereof and supersedes all prior agreements, negotiations, and understandings, whether written or oral.IN WITNESS WHEREOF, the parties have executed this Contract as of the Effective Date.CLIENT: [Client Name]By: [Authorized Signature]Name: [Authorized Signatory Name]Title: [Authorized Signatory Title]Date: [Date]CONTRACTOR: [Contractor Name]By: [Authorized Signature]Name: [Authorized Signatory Name] Title: [Authorized Signatory Title] Date: [Date]Exhibit A: Project Description Exhibit B: Project Schedule。
全面版建设工程协议书英文版
全面版建设工程协议书英文版Comprehensive Construction AgreementThis agreement outlines the terms and conditions for a construction project between the parties involved. The document covers the scope of work, timelines, payment terms, and responsibilities of each party. It is essential to have a detailed agreement in place to ensure that all aspects of the project are clearly defined and agreed upon.The agreement will include details such as the project description, location, start date, completion date, and any specific requirements or specifications. It will also outline the payment schedule, including the total project cost, payment milestones, and any penalties for delays or non-compliance.Additionally, the agreement will address the responsibilities of each party, including the contractor's obligations to provide materials, labor, and equipment, as well as the client's responsibilities such as providing access to the site and ensuring a safe working environment.It is crucial to have a comprehensive construction agreement in place to protect the interests of both parties and avoid any potential disputes or misunderstandings. By clearly outlining all terms and conditions upfront, the project can proceed smoothly and efficiently, leading to a successful outcome for all involved.。
epc英文合同范本
epc英文合同范本EPC ContractContract No.: [Contract Number]Date: [Date of Contract Execution]Parties1. Employer: [Employer's Name and Address]2. Contractor: [Contractor's Name and Address]1. Project DescriptionThe Employer intends to undertake a project for the [Project Name] and here engages the Contractor to provide engineering, procurement and construction services on an EPC basis. The project scope and requirements are detled in the attached Appendix [Appendix Number].2. Contract Price and Payment Terms2.1 The total contract price for the pletion of the project is [Contract Price] (inclusive of all taxes and duties).2.2 The Employer shall make the following payments to the Contractor:An advance payment of [Advance Payment Amount] within [Number of Days] days after the effective date of this contract.Interim payments based on the progress of the work as certified the Engineer. The Contractor shall submit progress reports and payment requests at regular intervals as specified in the contract.The final payment of [Final Payment Amount] shall be made within [Number of Days] days after the successful pletion and acceptance of the project.3. Time for Completion3.1 The Contractor shall plete the project within [Number of Days/Months] from the effective date of this contract.3.2 In the event of delay in pletion, the Contractor shall be liable to pay liquidated damages as stipulated in the contract.4. Engineering and Design4.1 The Contractor shall be responsible for the engineering and design of the project in accordance with the applicable standards and specifications.4.2 The designs and drawings shall be submitted to the Employer for review and approval. The Employer shall provide ments and approvals within [Number of Days] days of receipt.5. Procurement5.1 The Contractor shall procure all materials, equipment and services required for the project in a timely manner and in accordance with the approved specifications.5.2 All procurements shall be subject to the Employer's inspection and acceptance.6. Construction6.1 The Contractor shall carry out the construction works in a diligent and petent manner, adhering to the approved construction plans and safety standards.6.2 The Contractor shall provide regular updates on the construction progress to the Employer.7. Quality Assurance and Control7.1 The Contractor shall establish and mntn a quality management system to ensure the quality of the project.7.2 The Employer or its representatives shall have the right to inspect and test the works at any stage of the project.8. Risk and Insurance8.1 The Contractor shall assume the risks associated with the project until the pletion and acceptance of the works.8.2 The Contractor shall obtn and mntn insurance coverage as required the contract and provide evidence of such insurance to the Employer.9. Force Majeure9.1 If either party is prevented from performing its obligations under this contract due to force majeure events, such as natural disasters, war, etc., theaffected party shall notify the other party promptly and provide relevant evidence.9.2 The performance of the contract shall be suspended during the period of force majeure, and the parties shall negotiate a reasonable extension of time or other appropriate measures.10. Dispute Resolution10.1 Any disputes arising out of or in connection with this contract shall be resolved through amicable negotiations between the parties.10.2 If the negotiations fl, the dispute shall be submitted to arbitration in accordance with the rules of [Arbitration Institution].11. Governing LawThis contract shall be governed and construed in accordance with the laws of [Jurisdiction].12. Other Terms and ConditionsThe parties may include other terms and conditions as deemed necessary for the successful execution of the project.IN WITNESS WHEREOF, the parties hereto have executed this contract as of the date first above written.Employer: [Employer's Signature and Name]Contractor: [Contractor's Signature and Name]。
施工合同_英文版
Contract for ConstructionThis Contract for Construction (the "Contract") is made and entered into as of [Date], by and between [Contractor's Name], a [Contractor's Jurisdiction] corporation ("Contractor"), and [Owner's Name], a [Owner's Jurisdiction] individual ("Owner").1. Scope of Work1.1 The Contractor agrees to perform all labor and services necessary to complete the construction of the residential building located at [Project Address] (the "Project") in accordance with the plans and specifications provided by the Owner.1.2 The Contractor shall perform the work in a workmanlike manner and in accordance with all applicable laws, regulations, and industry standards.1.3 The Contractor shall be responsible for the procurement and installation of all materials, fixtures, and equipment necessary for the completion of the Project, unless otherwise specified by the Owner.2. Term and Commencement2.1 The term of this Contract shall commence on the date of execution and shall continue until the Project is completed, unless otherwise terminated in accordance with this Contract.2.2 The Contractor agrees to commence work on the Project within [number of days] after the execution of this Contract, and to complete the work within [number of days] after the commencement of work.3. Payment3.1 The Owner agrees to pay the Contractor the sum of [total contract price] for the completion of the Project, as set forth in the attached Schedule A.3.2 Payment shall be made by the Owner to the Contractor in accordance with the payment schedule set forth in the attached Schedule B.3.3 The Contractor shall be entitled to interest on any late payments at the rate of [interest rate] per annum, calculated from the date that the payment was due until the date of payment.3.4 The Contractor shall provide the Owner with a detailed account ofall payments made to the Contractor, which shall be submitted to the Owner on a monthly basis.4. Changes to the Scope of Work4.1 The Owner may request changes to the scope of work defined in this Contract. Any such changes must be submitted in writing to the Contractor and agreed upon by both parties prior to implementation.4.2 The Contractor shall provide the Owner with a written estimate of the additional costs and time required to complete the changes, and the Owner shall be responsible for the payment of such additional costs and the extension of the project timeline, as applicable.5. Termination5.1 either party may terminate this Contract upon written notice to the other party if the other party breaches any material provision of this Contract and fails to cure such breach within [number of days] after receipt of written notice from the other party.5.2 either party may terminate this Contract upon written notice to the other party if the Project is not completed within the timeframe specified in this Contract.6. Dispute Resolution6.1 Any disputes arising out of or in connection with this Contractshall be resolved by binding arbitration in accordance with the rules of the [arbitration association], and the decision of the arbitrator(s) shall be final and binding upon the parties.7. Governing Law and Jurisdiction7.1 This Contract shall be governed by and construed in accordance with the laws of the [governing jurisdiction].7.2 Any legal actions or proceedings arising out of or in connection with this Contract shall be brought exclusively in the courts of the [governing jurisdiction].8. Entire Agreement8.1 This Contract constitutes the entire agreement between the parties with respect to the subject matter hereof and supersedes all prior agreements, understandings, negotiations, and discussions, whether oral or written, of the parties.8.2 This Contract may be amended or modified only by a written instrument executed by both parties.IN WITNESS WHEREOF, the parties have executed this Contract as of the date first above written.[Contractor's Name] [Owner's Name]。
工程建设合同范本 英文
工程建设合同范本英文Engineering Construction Contract TemplateThis Engineering Construction Contract (the “Contract”) is entered into this ___ day of _______, 20__, by and between [Name of Contractor], with its principal place of business at [Address of Contractor], and [Name of Client], with its principal place of business at [Address of Client].RECITALS1. Contractor is a duly licensed and experienced engineering construction company capable of providing the services hereunder.2. Client desires to engage Contractor to perform certain engineering construction services, as set forth herein.NOW, THEREFORE, in consideration of the mutual covenants contained herein and for other good and valuable consideration, the receipt and sufficiency of which are hereby acknowledged, the parties hereto agree as follows:1. Scope of WorkContractor shall provide engineering construction services in accordance with the plans and specifications provided by Client. Contractor shall perform all work in a timely and professional manner, in accordance with industry standards.2. Payment TermsClient shall pay Contractor the total contract price of $____________ for the services provided under this Contract. Payment shall be made in installments as follows: ______% due upon signing of the Contract, ______% due upon completion of [milestone], and ______% due upon final completion.3. Changes and ModificationsAny changes or modifications to the scope of work must be mutually agreed upon in writing by both parties. Any additional costs incurred as a result of such changes shall be the responsibility of Client.4. WarrantiesContractor warrants that all work performed under this Contract shall be free from defects in workmanship and materials for a period of one yearfrom the date o f final completion. Contractor’s liability under this warranty shall be limited to the cost of remedying any such defects.5. IndemnificationContractor agrees to indemnify and hold harmless Client from any claims or damages arising out of Contractor’s per formance under this Contract, except to the extent caused by Client’s negligence.6. TerminationEither party may terminate this Contract upon written notice to the other party in the event of a material breach that is not cured within thirty (30)days of written notice.IN WITNESS WHEREOF, the parties hereto have executed this Contract as of the date first above written.[Name of Contractor]By: _______________________Title: _______________________[Name of Client]By: _______________________Title: _______________________[End of Contract]。
工程合同范本英文版
工程合同范本英文版[Title]ENGINEERING CONTRACT TEMLATEThis Engineering Contract (the "Contract") is made and entered into on [Date] y and etween [Comany A], with its registered office at [Address], hereinafter referred to as "Emloyer," and [Comany ], with its registered office at [Address], hereinafter referred to as "Contractor" (together the "arties").[Transition]The arties, recognizing the need for a clear and comrehensive agreement to govern their collaoration on the [roject Name] roject, have agreed to the following terms and conditions: 1. SCOE OF WORK1.1 The Contractor shall rovide engineering services for the design, construction, and commissioning of [Detailed roject Descrition]. The secific scoe of work is detailed in Exhiit A attached hereto.1.2 The Emloyer shall rovide all necessary information and access to facilitate the comletion of the work according to the agreed-uon secifications and schedule.2. QUALITY AND STANDARDS2.1 The Contractor guarantees that all work erformed under this Contract shall conform to the standards set forth in Exhiit and any alicale laws and regulations.2.2 The Emloyer shall have the right to insect and audit the Contractor's work to ensure comliance with the stated quality and standards.3. TIMELINE3.1 The Contractor shall commence the work on [Start Date] and comlete it y [End Date], unless otherwise agreed in writing y the arties.3.2 In case of delays caused y the Emloyer or external factors eyond the Contractor's control, the timeline may e adjusted accordingly after mutual consultation.4. COMENSATION AND AYMENT4.1 The total comensation for the work erformed under this Contract shall e [Sum in Words and Numerals], ayale in accordance with the ayment schedule outlined in Exhiit C.4.2 The Emloyer shall make ayments to the Contractor uon the sumission of valid invoices and comletion of milestones as defined in Exhiit C.5. CHANGES AND AMENDMENTS5.1 Any changes to the scoe of work, timeline, or comensation shall e made ursuant to a written amendment to this Contract, which requires the mutual agreement of oth arties.5.2 The Contractor shall romtly notify the Emloyer of any issues that could affect the work's quality, cost, or schedule.6. RISK ALLOCATION6.1 The arties shall allocate risks associated with the roject as detailed in Exhiit D. The Contractor shall take all reasonale recautions to mitigate identified risks.6.2 Insurance requirements for oth arties are secified in Exhiit E, including liaility insurance and insurance against otential damages or losses.7. GOVERNING LAW AND DISUTE RESOLUTION7.1 This Contract shall e governed y and construed in accordance with the laws of [Jurisdiction Name].7.2 Any disute arising out of or related to this Contract shall first e addressed through negotiation etween the arties. If negotiation fails, the disute shall e resolved y [Method of Disute Resolution], as detailed in Exhiit F.8. TERMINATION8.1 Either arty may terminate this Contract uon written notice to the other arty in the event of a material reach of the Contract terms or if the other arty ecomes insolvent or ankrut. 8.2 Uon termination, the arties shall settle any outstanding ayments and return any confidential information to each other.9. MISCELLANEOUS9.1 This Contract reresents the entire agreement etween the arties and suersedes all rior negotiations, reresentations, and agreements. Any amendments must e in writing and signed y oth arties.9.2 No waiver y either arty of any rights under this Contract shall e effective unless in writing and signed y the arty intended to e ound.9.3 This Contract may not e assigned y the Contractor without the rior written consent of the Emloyer.IN WITNESS WHEREOF, the arties have executed this Contract as of the date first aove written.[Emloyer Comany Name]y: ___________________________Name: [Authorized Reresentative Name] Title: [Authorized Reresentative Title] [Contractor Comany Name]y: ___________________________Name: [Authorized Reresentative Name] Title: [Authorized Reresentative Title] [Conclusion]。
工程合同的英文
工程合同的英文h2工程合同/h2strong合同编号：[Contract Numer]/strongstrong日期：[Date]/strongstrong甲方（业主）：[Client Name]/strongstrong乙方（承包商）：[Contractor Name]/strongstrong一、合同目的/strong本合同由甲方与乙方根据相互协商一致的原则订立，目的在于规定双方在[roject Name]项目中的权利、义务和责任。
strong二、工程描述/strong1. 工程名称：[roject Name]2. 工程地点：[roject Location]3. 工程范围：包括[Scoe of Work Descrition]。
详细内容见附件A（工程规范）。
strong三、合同金额/strong总合同价为[Contract Sum]美元，包含所有材料、劳动力、设备及其他必需的费用。
strong四、付款条件/strong1. 预付款：[Down ayment ercentage]%，于工程开工前支付。
2. 进度款：根据实际完成的工作量及进度按月支付。
3. 最终付款：在工程竣工并经甲方验收合格后支付剩余款项。
strong五、工期/strong工程预计开始日期为[Start Date]，完成日期为[Comletion Date]。
除非因不可抗力或双方书面同意外，乙方应确保按期完成工程。
strong六、质量保证/strong乙方保证提供的服务和材料符合本合同规定的标准及附件A中的工程规范。
strong七、变更和调整/strong任何对工程范围的变更需得到双方的书面同意，并可能导致合同金额和/或工期的调整。
strong八、争议解决/strong因本合同引起的任何争议，首先应通过友好协商解决。
若协商不成，则提交至[Jurisdiction or Aritration Clause]进行裁决。
strong九、法律适用/strong本合同的签订、解释、执行和争议解决均适用[Governing Law]法律。
建设工程勘察合同英文版
建设工程勘察合同英文版在工程建设领域，勘察工作是项目成功的重要前提。
一个详尽的勘察可以为后续建设提供准确的地质数据和工程建议。
因此，签订一份全面的建设工程勘察合同至关重要。
以下是一份英文版的建设工程勘察合同范本，旨在为工程项目双方提供一个标准的合作框架。
---Construction roject Survey ContractThis Construction roject Survey Contract (the "Contract") is made and entered into as of [Date] y and etween [Surveyor's Name], with its registered office at [Address] ("Surveyor"), and [Client's Name], with its registered office at [Address] ("Client").Article 1: Scoe of WorkThe Surveyor shall rovide comrehensive survey services for the construction roject located at [roject Address]. The services shall include, ut are not limited to, toograhic surveying, geotechnical investigation, susurface exloration, environmental assessment, and rearation of detailed survey reorts.Article 2: Survey eriodThe Surveyor shall commence the survey work on [Start Date] and comlete all services in accordance with this Contract y [End Date]. The Client may request additional surveys or modifications to the work scoe, which will e suject to a mutually agreed uon addendum to this Contract.Article 3: ComensationIn consideration of the services rovided under this Contract, the Client shall ay the Surveyor the total sum of [Amount in words and figures]. The ayment shall e made in [Numer] installments as follows:- [ercentage]% uon signing of this Contract;- [ercentage]% uon comletion of the reliminary survey reort;- [ercentage]% uon delivery of the final survey reort.Article 4: Quality AssuranceThe Surveyor guarantees that all works erformed under this Contract shall conform to the standards of the relevant industry and regulations. The Surveyor shall use reasonale efforts to ensure accuracy and reliaility of the survey results.Article 5: Liaility and IndemnityNeither arty shall e liale for secial, incidental, indirect, or consequential damages arising out of or in connection with this Contract. The Surveyor shall indemnify and hold harmless the Client from any loss or damage caused y the Surveyor's negligence or failure to comly with the contractual oligations.Article 6: Confidentialityoth arties agree to maintain confidentiality regarding all information disclosed under this Contract. The oligation of confidentiality shall survive the termination or exiration of this Contract.Article 7: TerminationEither arty may terminate this Contract uon written notice to the other arty in the event of a material reach of this Contract that remains uncured for a eriod of [Numer] days after receit of written notice.Article 8: Governing Law and Disute ResolutionThis Contract shall e governed y and construed in accordance with the laws of [Jurisdiction]. Any disute arising out of or in connection with this Contract shall first e attemted to e resolved through friendly negotiation. If negotiation fails, the disute shall e sumitted to [Method of Disute Resolution].Article 9: Final rovisionsThis Contract constitutes the entire agreement etween the arties and suersedes all rior negotiations, understandings, and agreements. This Contract may only e modified y a written instrument signed y oth arties.IN WITNESS WHEREOF, the arties have executed this Contract as of the date first aove written.[Surveyor's Name]y: ___________________________Name: [Surveyor's Reresentative Name]Title: [Surveyor's Reresentative Title][Client's Name]y: ___________________________Name: [Client's Reresentative Name]Title: [Client's Reresentative Title]---。
- 1、下载文档前请自行甄别文档内容的完整性，平台不提供额外的编辑、内容补充、找答案等附加服务。
- 2、"仅部分预览"的文档,不可在线预览部分如存在完整性等问题,可反馈申请退款(可完整预览的文档不适用该条件!)。
- 3、如文档侵犯您的权益，请联系客服反馈,我们会尽快为您处理(人工客服工作时间：9:00-18:30)。
篇一:中英文对照-工程施工合同范本工程施工合同contract合同编号( contract no、 ): 签订日期( date ):发包方(简称甲方)party a:承包方(简称乙方):party b:根据《中华人民共与国合同法》以及其她有关法律法规规定得原则,结合本工程得具体情况,甲、乙双方在平等、自愿、协商一致得基础上达成如下协议,共同遵守。
according to “p、r、c contract law”, and other relevant laws and regulations to the specific circumstances of this project, parties a and b have hereby equally and voluntarily entered into the following agreement executed on the basis of mutual respect、1.工程概况project overview1.1.工程名称:project name:1.2.工程地点:project location:1.3.工程范围:a.新研发中心与新厂房得网络综合布线系统得施工;b.数据中心得建设,主要包含:数据中心得装饰工程、电气系统、空调系统、机房闭路监控系统、机房门禁系统、消防系统改造、机柜系统等。
project contents:a.the new r & d and new plant construction of network cablingsystems;b.data center, mainly includes: data center decoration andelectrical systems, air-conditioning systems, cctv systems,access control systems, firefighting system reform, server rack systems、1、4 开工条件:合同生效后,甲方预付款到位与现场具备开工条件。
1、5 工程造价:合同工程总造价为￥cny),人民币大写 project cost:total project cost is yuan ( cny )、详细合同价格表见附件报价清单。
detailed contract price list see attached quotation list、在详细设计与施工过程中,若工程量发生变化,按合同单价相应调整工程造价;若材质发生变化,按双方商定得补充协议调整工程造价。
in the detailed design and construction process, if the project quantity changes, according to the contract price adjustment project cost; if the material is changed, the supplemental agreement agreed by both parties for adjustment of engineering cost、2、付款方式terms of payment2、1 由乙方向甲方提供指定帐户、甲方以支票方式或银行转账方式向乙方结算合同款; party b shall provide the designated account to party a, party a by check or bank transfer to pay the contract payment to party b、2、2 本合同生效后,甲方付给乙方合同总价得40%作为工程预付款,即￥元; after the signing of this contract, party a shall pay to party b 40% of the total contract price as the project advance payment;2、3 数据中心及网络布线系统工程完工并且双方签订工程验收报告后7天以内,甲方付给乙方合同总价得55%,即￥元;2、4 工程竣工后3个月内,甲方支付给乙方剩余得合同款,即￥3、双方职责responsibilities of the parties3、1 甲方职责:responsibilities of party a:a.及时以书面形式通知乙方本工程具备开工条件得时间;timely written notice to party b the conditions of this project have the time to start;b.协助乙方办理进驻施工现场所需人员证件、批件等有关手续;to assist party b to enter the construction site personnel required documents, approval documents and other relevant procedures;c.为乙方提供现场工程办公室与足够得现场仓库;to provide on-site engineering office and sufficient field warehouse;d.积极协助乙方施工,协调施工时与各部门得配合,并负责提供工程所需得现场平面图及建筑结构图。
actively assist party b construction, coordination with various departments, and responsible for providing the needed for theproject site plans and architectural drawings、e.及时按合同规定之付款进度向乙方支付工程款项。
timely according to the terms of the contract payment schedule topay party b project funds、3、2 乙方职责:responsibilities of party b:a.乙方在工程开始前应组织有关人员研究与熟悉图纸,参与设计交底,安排施工总进度计划并提交给甲方;party b before the project begins shall organize relevant personnelto study and be familiar with drawings, involved in the design work, arrangement of construction general schedule plan and submit toparty a;b.向甲方或项目监理提供所购各种产品、设备得技术资料,接受进场检验;to the party a or project supervision to provide the purchase avariety of products, equipment, technical information, accept entry inspection;c.遵守甲方或监理方对施工现场得有关规定;abide by the party or the supervision on construction site of the relevant provisions;d.按时完成乙方所承担得施工任务,保证工程施工质量。
4、施工与工程设计变更construction and engineering design change4、1 乙方在施工中要根据国家颁发得施工验收规范与质量检验标准,以及设计要求进行,要求全部工程达到合格标准。
on the construction of party b according to the country issued construction acceptance norms and quality inspection standards, aswell as the design requirements, all project achieve the qualified standard、4、2 在施工中,要坚持按照设计文件与施工图纸施工,任何一方不得随意变更设计,如出现窝工、返工与材料损失,以及增加劳动力成本等,由于甲方得原因造成得,损失由甲方承担,由于乙方得原因造成得,损失由乙方承担。
during construction, to adhere to the design documents and construction drawings of the construction, any party shall not be arbitrarily changed design, such as the emergence of idleness, rework and loss of material, as well as an increase in labor cost, as the party a s cause, loss borne by the party a, the party b causes, losses shall be borne by party b、4、3 在施工中,若甲方a有变更设计文件得要求,应书面通知乙方;若乙方发现设计文件有错误或严重不合理得地方,也应书面通知甲方,双方商定并修改设计文件与图纸后方可继续施工。
during the construction, if the party a to change the design document, shall give a written notice to party b; if party b is found the design documents are wrong or serious ueasonable place, should also be written notice to party a, both sides agreed and modify design drawings and documents before it can continue to construction、4、4 在施工过程中,如遇下列情况,需顺延工期,双方应及时进行协商,并通过书面形式确定顺延期限:in the process of construction, in case of the following circumstances, be extended period, both parties shall timely consultations, and through the written form to determine the extension of the time limit:a.因天灾或人力不能抗拒得原因被迫停工得;because of natural disaster or the manpower irresistible reasons forced shutdown;b.因甲方提出变更计划或变更施工图而不能继续施工得;because party a proposed changes to the plan or change the construction graph therefore cannot continue construction;c.乙方不能按期供设备或所供材料或者设备不合规格要求,被迫停工或不能顺利施工得;party b fails to supply equipment or for the materials orequipment of different specifications, was forced to shut down or not smooth construction;5、竣工验收与售后服务final acceptance and after-sales service5、1 乙方必须严格执行隐蔽工程验收制度,凡隐蔽工程完成后,必须经过验收并作好记录(隐蔽工程指墙内、吊顶内得管线施工等)。