TISCO二期扩建工程项目总承包(EPC)合同 中英文
中英文建筑工程合同(Contract of Construction Project)
建设工程合同Contract of Construction Project合同编号：Contract Number:工程名称：Project Name:发包方（甲方）：_________________________Employer (Party A):_________________________承包方（乙方）：_________________________Contractor (Party B): _________________________根据《中华人民共和国合同法》和《建筑安装工程承包合同条例》及有关规定，为明确双方在施工过程中的权利、义务和经济责任，经双方协商同意签订本合同。
In order to make definite of the rights, obligations and economic responsibilities of both parties during the construction, the parties, in accordance with The PRC Contract Law and Construction Engineering Contract Regulations and relevant provisions, agree to sign this contract.第一条工程项目Article 1, Project item1．工程地点：Project site:2. 工程范围：Scope of project3. 工程造价：人民币元整(该造价为包工包料价)Project cost: PMB Yuan only(Cost of this contract is the contract price for labor and materials)第二条施工准备Article 2, Preparation for construction1．甲方协助乙方办理临时水电及垂直运输,提供建筑图纸及有关隐蔽障碍物的资料。
建筑工程合同范本中英
建筑工程合同范本中英CONTRACT AGREEMENTThis Contract Agreement (hereinafter referred to as "Contract") is entered into as of [Date], by and between [Name of Party A], a [Legal Entity Type] with its principal place of business at [Address of Party A] (hereinafter referred to as "Contractor"), and [Name of Party B], a [Legal Entity Type] with its principal place of business at [Address of Party B] (hereinafter referred to as "Client").1. Scope of WorkThe Contractor agrees to perform the construction work as described in the attached Scope of Work document, which is an integral part of this Contract.2. Contract PriceThe total contract price for the work described in the Scope of Work is [Amount], which includes all labor, materials, equipment, and services necessary to complete the work.3. Payment TermsThe Client shall make payments to the Contractor in accordance with the following schedule: [Insert Payment Schedule].4. Commencement and CompletionThe work shall commence on [Commencement Date] and isexpected to be completed by [Completion Date], subject to any extensions of time granted by the Client.5. Warranties and GuaranteesThe Contractor warrants that all work will be performed in a professional and workmanlike manner, in accordance with the highest industry standards and practices.6. Changes and VariationsAny changes or variations to the Scope of Work must be agreed upon in writing by both parties and shall be subject to additional costs and time extensions as appropriate.7. Delays and Extensions of TimeThe Contractor shall not be liable for any delays caused by factors beyond its control. The Client may grant extensions of time at its sole discretion.8. Liability and IndemnificationThe Contractor shall indemnify and hold the Client harmless from any and all claims, damages, or losses arising out of the Contractor's performance of the work.9. Dispute ResolutionAny disputes arising out of or in connection with this Contract shall be resolved through [Insert Dispute Resolution Method, e.g., arbitration, mediation, or litigation].10. TerminationThis Contract may be terminated by either party upon [Insert Conditions for Termination, e.g., breach of contract,insolvency, etc.].11. Force MajeureNeither party shall be liable for any failure or delay in performing its obligations under this Contract to the extent that such failure or delay is caused by events beyond the reasonable control of that party.12. ConfidentialityBoth parties agree to keep all information related to this Contract confidential and not to disclose such information to any third party without the prior written consent of the other party.13. Entire AgreementThis Contract constitutes the entire agreement between the parties and supersedes all prior negotiations, representations, and agreements between them.14. Governing LawThis Contract shall be governed by and construed in accordance with the laws of [Insert Governing Law].15. NoticesAll notices under this Contract shall be in writing and shall be deemed duly given when delivered personally or sent by registered mail to the addresses set forth in this Contract.IN WITNESS WHEREOF, the parties have executed this Contract as of the date first above written.[Name of Party A] [Name of Party B]By: ___________________ By: ___________________ [Title] [Title]Date: ___________________ Date: ____________________ [Signature of Party A] [Signature of Party B]。
越南太原钢铁厂工程项目总承包合同中英文
越南（太原）钢铁厂工程项目总承包合同(中英文第二部分)越南（太原）钢铁厂工程项目总承包合同(中英文第二部分)TECHNICAL ANNEX FOR EPC CONTRACT OF TISCO SECOND STAGE EXPANSION PROJECT（TISCO）VIETNAM4.DESCRIPTION OF GENERAL LAYOUT,TRANSPORTATION,ROADWAY,RAILWAY AND PIPELINE WORKS OF THE WHOLE PLAN(STAGE II)全厂钢铁厂工程之总图运输，公路，铁路，各种管网的概述4.1GENERAL概述TISCO,being a important enterprise in Vietnam,was established in1958. TISCO possesses coke making plant,sinter plant,iron making plant,steel making plant,rolling mill plant as well as corresponding utilities and auxiliary facilities etc.Its annual output of iron and steel is about200,000t and common carbon steel casting billet is about250,000t.TISCO始建于1958年，是越南国有重点企业。
TISCO现有焦化、烧结、炼铁、炼钢、轧钢生产厂和相应的公辅设施等。
年生产钢、铁约20万吨，普碳钢连铸坯约25万吨。
In the plant there are railways and station yard of railway,and total railway length in the whole plant is about60km(including railway of mines). The railway transportation is the main transport means in the plant, complementary with roads,so the transportation in the plant is very convenience.厂内设有铁路及铁路站场，全厂共有铁路约60公里（包括矿山铁路），厂内运输主要以铁路运输为主，并设有厂内道路，交通运输极为便利。
EPC合同条件(中英文对照版)
CONTENTS目录1General Provisions一般规定 (6)1.1Definitions定义 (6)1.2Interpretation解释 (11)1.3Communications通信交流 (12)1.4Law and Language法律和语言 (13)1.5Priority of Document文件优先次序 (13)1.6Contract Agreement合同协议书 (13)1.7Assignment权益转让 (14)1.8Care and Supply of Document文件的照管和提供 (14)1.9Confidentiality保密性 (15)1.10Employer’s Use of Contractor’s Documents雇主使用承包商文件 (15)1.11Contractor’s Use of Employer’s Documents承包商使用雇主文件 (16)1.12Confidential Details保密事项 (16)1.13Compliance with Laws遵守法律 (16)1.14Joint and Several Liability共同的和各自的责任 (17)2The Employer雇主 (17)2.1Right of Access to the Site现场进入权 (17)2.2Permits, Licences or Approves许可、执照或批准 (18)2.3Employer’s personnel雇主人员 (19)2.4Employer’s Financial Arrangements雇主的资金安排 (19)2.5Employer’s Claims雇主的索赔 (19)3The Employer’s Administration雇主的管理 (20)3.1The Employer’s Representative雇主代表 (20)3.2The Employer’s personnel其他雇主人员 (21)3.3Delegated Persons受托人员 (21)3.4Instructions指示 (22)3.5Determinations确定 (22)4The Contractor承包商 (22)4.1The Contractor’s General Obligations承包商的一般义务 (23)4.2Performance security履约担保 (23)4.3Contractor’s Representative承包商代表 (24)4.4Subcontractors分包商 (25)4.5Nominated Subcontractors指定的分包商 (26)4.6Co-operation合作 (26)4.7Setting out放线 (27)4.8Safety procedures安全程序 (27)4.9Quality Assurance质量保证 (28)4.10Site Data现场数据 (28)4.11Sufficiency of the Contract Price合同价格 (29)4.12Unforeseeable Difficulties不可预见的困难 (29)4.13Rights of way and Facilities道路通行权于设施 (29)4.14Avoidance of Interference避免干扰 (30)4.15Access Route进场通路 (30)4.16Transport of Goods货物运输 (31)4.17Contractor’s Equipment承包商设备 (31)4.18Protection of the Environment环境保护 (31)4.19Electricity, Water and Gas电、水和燃气 (32)4.20Employer’s Equipment and Free-Issue Material雇主设备和免费供应的材料 (32)4.21Progress Reports进度报告 (33)4.22Security of the Site现场保安 (34)4.23Contractor’s Operations on Site承包商的现场作业 (35)4.24Fossils化石 (35)5Design设计 (36)5.1General Design Obligations设计义务一般要求 (36)5.2Contractor’s Documents承包商文件 (37)5.3Contractor’s Undertaking承包商的承诺 (38)5.4Technical Standards and Regulations技术标准和法规 (38)5.5Training培训 (39)5.6As-Built Documents竣工文件 (39)5.7Operation and Maintenance Manuals操作和维修手册 (40)5.8Design Error设计错误 (40)6Staff and Labour员工 (40)6.1Engagement of Staff and Labour员工的雇用 (41)6.2Rates of Wages and Conditions of Labour工资标准和劳动条件 (41)6.3Persons in the Service of Employer为雇主服务的人员 (41)6.4Labour Laws劳动法 (41)6.5Working Hours工作时间 (42)6.6Facilities for Staff and Labour为员工提供设施 (42)6.7Health and Safety健康和安全 (42)6.8Contractor’s Superintendence承包商的监督 (43)6.9Contractor’s Person nel承包商人员 (43)6.10Records of contractor’s Personnel and Equipment承包商人员和设备的记录 (44)6.11Disorderly Conduct无序行为 (44)7Plant, Materials and Workmanship生产设备、材料和工艺 (44)7.1Manner of Execution实施方法 (44)7.2Samples样品 (45)7.3Inspection检验 (45)7.4Testing试验 (46)7.5Rejection拒收 (47)7.6Remedial Work修补工作 (47)7.7Ownership of Plant and Materials生产设备和材料的所有权 (48)7.8Royalties土地(矿区)使用费 (48)8Commencement,Delays and Suspension开工、延误和暂停 (49)8.1Commencement of Works工程的开工 (49)8.2Time for Completion竣工时间 (49)8.3Programme进度计划 (50)8.4Extension of Time for Completion竣工时间延长 (51)8.5Delays Caused by Authorities当局造成的延误 (51)8.6Rate of Progress工程进度 (52)8.7Delay Damages误期损害赔偿费 (52)8.8Suspension of Work暂时停工 (53)8.9Consequences of Suspension暂停的后果 (53)8.10Payment for Plant and Materials in Event of Suspension暂停时对生产设备和材料的付款 (54)8.11Prolonged Suspension托长的暂停 (54)8.12Resumption of Work复工 (54)9Tests on Completion竣工试验 (55)9.1Contractor’s Obligations承包商的义务 (55)9.2Delayed Tests延误的试验 (56)9.3Retesting重新试验 (56)9.4Failure to Pass Tests on Completion未能通过竣工试验 (57)10Employer’s Taking Over雇主的接收 (57)10.1Taking Over of the Works and Sections工程和分项工程的接收 (57)10.2Taking Over of Parts of the Works部分工程的接收 (58)10.3Interference with Tests on Completion对竣工试验的干扰 (58)11Defects Liability缺陷责任 (59)11.1Completion of Outstanding Work and Remedying Defects完成扫尾工作和修补缺陷 (59)11.2Cost of Remedying Defects修补缺陷的费用 (60)11.3Extension of Defects Notification Period缺陷通知期的延长 (60)11.4Failure to Remedy Defects未能修补的缺陷 (61)11.5Removal of Defective Work移出有缺陷的工程 (61)11.6Further Tests进一步试验 (62)11.7Right of Access进入权 (62)11.8Contractor to Search承包商调查 (62)11.9Performance Certificate履约证书 (63)11.10Unfulfilled Obligations未履行的义务 (63)11.11Clearance of Site现场清理 (63)12Tests after Completion竣工后试验 (64)12.1Procedure for Tests after Completion竣工后试验的程序 (64)12.2Delayed Tests延误的试验 (65)12.3Retesting重新试验 (65)12.4Failure to Pass Tests after Completion未能通过的竣工后试验 (66)13Variations and Adjustments变更和调整 (67)13.1Right to Vary变更权 (67)13.2Value Engineering价值工程 (67)13.3Variation Procedure变更程序 (67)13.4Payment in Applicable Currencies以适用货币支付 (68)13.5Provisional Sums暂列金额 (68)13.6Daywork计日工作 (69)13.7Adjustments for Changes in Legislation因法律改变的调整 (70)13.8Adjustments for Changes in Cost因成本改变的调整 (71)14Contract price and Payment合同价格和支付 (71)14.1The Contract Price合同价格 (71)14.2Advance payment预付款 (71)14.3Application for Interim Payments期中付款的申请 (73)14.4Schedule of Payments付款价格表 (74)14.5Plant and Materials intended for the Works拟用于工程的生产设备和材料 (74)14.6Interim Payments期中付款 (75)14.7Timing of Payments付款的时间安排 (75)14.8Delayed Payment延误的付款 (76)14.9Payment of Retention Money保留金支付 (76)14.10Statement at Completion施工报表 (77)14.11Application for Final Payment最终付款的申请 (77)14.12Discharge结清证明 (78)14.13Final Payment最终付款 (78)14.14Cessation of Employer’s Liability雇主责任的中止 (79)14.15Currencies of Payment支付的货币 (79)15Termination by Employer由雇主终止 (80)15.1Notice to Correct通知改正 (80)15.2Termination by Employer由雇主终止 (80)15.3Valuation at Date of Termination终止日期时的估价 (82)15.4Payment after Termination终止后的付款 (82)15.5Employer’s Entitlement to Termination雇主终止的权利 (83)16Suspension and termination by Contractor由承包商暂停和终止 (83)16.1Contractor’s Entitlement to Suspend Work承包商暂停工作的权利 (83)16.2Termination by Contractor由承包商终止 (84)16.3Cessation of Work and Removal of Contractor’s Equipment停止工作和承包商设备的撤离 (85)16.4Payment on Termination终止时的付款 (85)17Risk and Responsibility风险和职责 (86)17.1Indemnities保障 (86)17.2Contractor’s Care of the Works承包商对工程的照管 (87)17.3Employer’s Risks雇主的风险 (88)17.4Consequence of Employer’s Risks雇主风险的后果 (88)17.5Intellectual and Industrial Property Rights知识产权和工业产权 (89)17.6Limitation of Liability责任限度 (90)18Insurance保险 (90)18.1General Requirements for Insurances有关保险的一般要求 (90)18.2Insurance for Works and Contractor’s Equipment工程和承包商设备的保险 (92)18.3Insurance against Injury to Persons and Damage to Property人身伤害和财产损害险 (94)18.4Insurance for Contractor’s Personnel承包商人员的保险 (95)19Force Majeure不可抗力 (95)19.1Definition of Force Majeure不可抗力的定义 (96)19.2Notice of Force Majeure不可抗力的通知 (97)19.3Duty to Minimise Delay将延误减至最小的义务 (97)19.4Consequences of Force Majeure不可抗力的后果 (97)19.5Force Majeure Affecting Subcontractor不可抗力影响分包商 (98)19.6Optional Termination, Payment and Release自主选择终止、支付和解除 (98)19.7Release from Performance under the Law根据法律解除履约 (99)20Claims, Disputes and Arbitration索赔、争端和仲裁 (99)20.1Contractor’s Claims承包商的索赔 (100)20.2Appointment of the Dispute Adjudication Board争端裁决委员会的任命 (101)20.3Failure to Agreement Dispute Adjudication Board对争端裁决委员会未能取得一致时 (103)20.4Obtaining Dispute Adjudication Board’s Decision取得争端裁决委员会的决定 (103)20.5Amicable Settlement友好解决 (104)20.6Arbitration仲裁 (105)20.7Failure to Comply with Dispute Adjudication Board’s Decision未能遵守争端裁决委员会的决定 (106)20.8Expiry of Dispute Adjudication Board’s Appointment争端裁决委员会任命期满 (106)1General Provisions一般规定1.1Definitions定义In the Conditions of Contract (“these Conditions”), which include Particular Conditions and these General Conditions, the following words and expressions shall have the meaning stated. Words indicating persons or parties include corporation and other legal entities, except where the context requires otherwise.在合同条件（“本条件”），包括专用条件和通用条件中，下列词语和措辞应具有以下所述的含义.除上下文另有要求外，文中人员或当事各方等词语包括公司和其他合法实体.1.1.1The Contract consignee合同1.1.1.1“Contract” means the Contract Agreement, these Conditions, the Employer’s Requirement,the Tender, and further document (if any) which are listed in the Contract Agreement.“合同”系指合同协议书、本条件、雇主要求、投标书和合同协议书列出的其他文件（如果有）.1.1.1.2“Contract Agreement”means the contract agreement referred to in Sub-Clause 1.6[Contract Agreement], including any annexed memoranda.“合同协议书”系指第1.6款[合同协议书]中所述的合同协议书及所附各项备忘录.1.1.1.3“Employer’s requirements”means the document entitled employer’s requirements, asincluded in the Contract, and any additions and modifications to such document in accordance with the Contract. Such document specifies the purpose, scope, and/or design and/or other technical criteria, for the Works.“雇主要求”系指合同中包括的，题为雇主要求的文件，其中列明工程的目标、范围、和（或）设计和（或）其他技术标准，以及按合同对此项文件所作的任何补充和修改.1.1.1.4“Tender” means the Contractor’s signed offer for the Works and all other documents whichthe Contractor submitted therewith (other than these Conditions and Employer’s Requirements, if so submitted), as included in the Contract.“投标书”系指包含在合同中的由承包商提交的为完成工程签署的报价，以及随同提交的所有其他文件（本条件和雇主要求除外，如同时提交）.1.1.1.5“Performance Guarantees” and “Schedule of payments” mean the documents so named(if any), as included in the Contract.“履约保证”和“付款计划表”系指合同中包括的具有上述名称的文件（如果有）.1.1.2Parties and Persons各方和人员1.1.2.1“Party” means the Employer or the Contractor, as the context requires.“当事方（或一方）”根据上下文需要，或指雇主，或指承包商。
工程建设的合同中英
工程建设的合同中英---Construction Contract甲方（Emloyer）： [Full Name]地址（Address）： [Address]乙方（Contractor）： [Full Name]地址（Address）： [Address]鉴于甲乙双方同意按照以下条款和条件进行合作，现就[roject Name]工程项目达成如下合同：I. roject Details1. 工程名称（Name of the roject）： [roject Name]2. 工程地点（Location of the roject）： [Location]3. 工程范围（Scoe of Work）： [Detailed Descrition]4. 工期（Duration of the roject）： [Start Date] to [End Date]5. 合同金额（Contract Sum）： [Amount in Numer and Currency]II. Resonsiilities of the Emloyer1. 提供必要的工程资料和施工场地。
2. 按合同约定支付工程款项。
3. 协助解决施工过程中的问题。
III. Resonsiilities of the Contractor1. 按合同要求完成工程建设任务。
2. 保证工程质量符合标准。
3. 及时通报工程进度和存在的问题。
IV. ayment Terms1. 工程款支付方式：[Detailed ayment Method]2. 进度款支付条件：[Detailed rogress ayment Conditions]3. 最终款项结算：[Detailed Final ayment Settlement]V. Default and enalties1. 如甲方违约，应按合同规定承担相应责任。
2. 如乙方违约，应按合同规定承担相应责任。
VI. Disute Resolution任何争议应首先通过友好协商解决，协商不成可提交至[Aritration or Court Name]解决。
工程合同中英双语
工程合同中英双语【合同名称】Contract Name: 建设工程合同Construction Contract【甲方（发包方）】arty A (Emloyer): ______________________【乙方（承包方）】arty (Contractor): ______________________鉴于甲乙双方根据平等自愿的原则，就以下工程项目的施工达成如下协议：Whereas arty A and arty have reached the following agreement ased on the rincile of equality and voluntariness regarding the construction of the roject elow:第一条合同项目及范围Article 1 Scoe of the Contract roject1.1 本合同项目为[具体项目名称]，位于[具体地点]。
The contract roject is [secific roject name], located at [secific location].1.2 工程范围包括[详细描述工程内容和范围]。
The scoe of the roject includes [detailed descrition of the roject content and scoe].第二条合同金额Article 2 Contract Amount2.1 本合同总金额为[金额数额]人民币/美元。
The total amount of this contract is [amount in RM/USD].2.2 合同金额包含所有施工成本及乙方预期利润。
The contract amount covers all construction costs and arty 's exected rofits.第三条工期要求Article 3 Construction eriod Requirements3.1 工程开工日期为[具体日期]，竣工日期为[具体日期]。
2017建设项目工程总承包合同（中英文）
13.1变更权 Right of amendment 13.2 变更范围Scope of amendment 13.3变更程序Procedure of amendment 13.4 紧急性变更程序Emergency amendment procedure 13.5 变更价款确定 Determination of amendment price 13.6 建议变更的利益分享Benefit-sharing of proposed amendment 13.7 合同价格调整Contract price adjustment
第 9 条 工程接收Engineering taking-over 9.1 工程接收Engineering taking-over 9.2 接收证书Taking-over certificate 9.3 接收工程的责任Responsibility for receiving works 9.4 未能接收工程Failure to receive work
第 2 条 发包人 Article Two Employer 2.1 发包人的主要权利和义务Main rights and obligations of employer 2.2 发包人代表 Employer’s representative 2.3 监理人Supervisor 2.4 安全保证 Safety guarantee 2.5 保安责任Security responsibility
10.8 丧失了生产价值和使用价值Lost value of production and use
第11 条 质量保修责任 Article Eleven Quality warranty liability 11.1 质量保修责任书Warranty of quality liability 11.2 缺陷责任保修金 Warranty premium on defects liability
中英文建筑工程合同(ContractofConstructionProject)
编号：_______________本资料为word版本，可以直接编辑和打印，感谢您的下载中英文建筑工程合同(ContractofConstructionProject)甲方：___________________乙方：___________________日期：___________________Contract of Construction Project合同编号：Contract Number:工程名称：Project Name:发包方(甲方)： ______________________________Employer (Party A): ________________________承包方(乙方)： ______________________________Contractor (Party B): ________________________根据《中华人民共和国合同法》和《建筑安装工程承包合同条例》及有关规定，为明确双方在施工过程中的权利、义务和经济责任，经双方协商同意签订本合同。
In order to make definite of the rights, obligations and economic responsibilities of both parties during the construction, the parties, in accordance with The PRC Contract Law and Construction Engineering Contract Regulations and relevant provisions, agree to sign this contract.第一条工程项目Article 1, Project item1 .工程地点：Project site:2. 工程范围：Scope of project3. 工程造价：人民币元整(该造价为包工包料价)Project cost: PMB Yuan only(Cost of this contract is the contract price for labor and materials)第二条施工准备Article 2, Preparation for construction1 .甲方协助乙方办理临时水电及垂直运输，提供建筑图纸及有关隐蔽障碍物的资料。
中英文 工程总承包合同 示范文本
中英文工程总承包合同示范文本The construction industry has witnessed significant growth and development in recent decades, driven by rapid urbanization, infrastructure development, and the increasing demand for commercial and residential properties worldwide. As the global economy becomes more interconnected, cross-border construction projects have become more prevalent, involving collaboration between companies and individuals from different countries and cultures. To facilitate these international construction projects, awell-designed and comprehensive contract is essential to ensure the successful execution of the project and to mitigate potential risks and disputes.One such contract is the Model Contract for General Contracting of Construction Projects between China and Foreign Countries. This standardized contract template serves as a guide for parties involved in construction projects between Chinese and foreign entities, providing a framework for the rights, obligations, and responsibilities of each party. The contract covers a wide range of essential elements, including project scope, contract price, payment terms, projectmanagement, quality control, and dispute resolution mechanisms.The primary purpose of this model contract is to establish a clear and mutually understood set of rules and procedures that govern the construction project, thereby promoting transparency, fairness, and efficiency in the collaboration between Chinese and foreign stakeholders. By using this standardized contract, parties can avoid potential misunderstandings, minimize the risk of disputes, and ensure that the project is completed in accordance with the agreed-upon terms and conditions.One of the key features of the Model Contract for General Contracting of Construction Projects between China and Foreign Countries is its comprehensive coverage of the construction process. The contract outlines the responsibilities of the general contractor, including project management, quality control, and safety measures. It also addresses the role of the owner, including their obligations in terms of providing necessary information, approvals, and timely payments.The contract also includes provisions for handling changes and variations to the project scope, as well as mechanisms for resolving disputes that may arise during the course of the construction project. These dispute resolution mechanisms often involve a combination of negotiation, mediation, and, if necessary, arbitration, ensuring thatany conflicts are addressed in a fair and efficient manner.Another important aspect of this model contract is its emphasis on the protection of intellectual property rights. The contract includes clauses that define the ownership and usage rights of any designs, drawings, or other intellectual property generated during the project. This is particularly relevant in cross-border construction projects, where the exchange of technical information and know-how is a critical component of the collaboration.The Model Contract for General Contracting of Construction Projects between China and Foreign Countries also addresses the issue of force majeure, which refers to unforeseeable circumstances that may disrupt the project's progress. The contract outlines the rights and obligations of the parties in the event of such occurrences, providing a framework for addressing the impact on the project schedule, costs, and performance.One of the key benefits of using this standardized contract is the increased efficiency and predictability it brings to the construction process. By having a pre-established set of terms and conditions, parties can streamline the negotiation and contracting phase, allowing them to focus more on the successful execution of the project. Additionally, the use of a widely recognized and accepted contract template can help to build trust and confidence betweenthe Chinese and foreign stakeholders, as it demonstrates a shared understanding of the project's requirements and expectations.Moreover, the adoption of this model contract can contribute to the harmonization of construction practices and standards between China and other countries. By establishing a common framework for international construction projects, the model contract can help to facilitate the exchange of best practices, technological advancements, and industry expertise, ultimately leading to the improvement of construction quality and efficiency on a global scale.In conclusion, the Model Contract for General Contracting of Construction Projects between China and Foreign Countries is a valuable tool for parties engaged in cross-border construction projects. By providing a comprehensive and standardized contract template, it helps to promote transparency, fairness, and efficiency in the collaboration between Chinese and foreign stakeholders. The contract's thorough coverage of various aspects of the construction process, as well as its dispute resolution mechanisms and intellectual property protection provisions, make it a crucial instrument for ensuring the successful execution of international construction projects. As the global construction industry continues to evolve, the adoption and continued refinement of this model contract can contribute to the strengthening of international cooperation and the advancement of the construction industry as a whole.。
EPCheteong合同中英对照
APPENDIX 3 (GC) - INSURANCE REQUIREMENTS附件3 (GC) –保险要求Insurance to be taken out by the Contractor.承包商承担保险：In accordance with the provisions of GC34, the Contractor shall at its expense take out and maintain in effect, or cause to be taken out and maintained in effect, during the performance of the Contract, the insurance set forth below in the sums and with the deductibles and other conditions as specified. The identity of the insurers and the form of the policies shall be subject to the approval of YY. The costs for insurance to be included in Bid price依照第GC34部分之规定，在合同履行期间，承包商负责投保或促成投保以保持该保险有效，保险金额、扣除条款及其他条件规定如下。
保险公司和保险单形式均须获得YY集团正式批准。
标价含保险费。
1. Construction and Erection Insurance施工和安装保险The following insurance shall be taken out and maintained by the Contractor during the period of delivery/installation/ construction/ field testing/commission-ing/trial operation at the Site of the Works covered under the Contract:依照合同规定，承包商须在现场工程交付/安装/施工/现场测试/调试/试运行期间投保和保持以下保险：(a) Erection All Risks Insurance to cover the entire Works (permanent and/ortemporary) from any and all kinds of damages which it is standard international practice for a contractor to insure under such a policy;“安装一切险”：范围含全部工程保险（永久和/或临时性工程保险），即承包商依照保险单规定按标准国际惯例投保的所有损害保险；(b) "Third-Party Liability Insurance" to cover injury or death to persons ordamages to property caused by the Works or by the Contractor's vehicles, tools and/or equipment or personnel;“第三方责任险”：范围包括由于工程施工或承包商的车辆、工具和/或设备或工作人员造成的人员伤亡或财产损害；(c) "Workman's Compensation Insurance". This type of insurance is requiredunder Vietnamese Law to be secured by the Contractor for his employees. The Contractor shall, therefore, faithfully comply with the requirements of said law.依照某国的法律规定，承包商须保证为其雇员提供“职工赔偿保险”。
epc总承包合同示范文本
epc总承包合同示范文本英文回答：An EPC (Engineering, Procurement and Construction) contract is a type of contract that covers the entire scope of a project, from design and engineering to procurement of materials and equipment, to construction and commissioning of the project.EPC contracts are typically used for large, complex projects that require a high level of coordination and expertise. For example, EPC contracts are often used for the construction of power plants, industrial facilities, and offshore oil and gas platforms.The scope of an EPC contract will vary depending on the specific project, but will typically include the following:Design and engineering of the project.Procurement of all materials and equipment requiredfor the project.Construction of the project.Commissioning of the project.Training of the owner's personnel in the operation and maintenance of the project.EPC contracts can be either lump-sum or unit-price contracts. Lump-sum contracts are fixed-price contracts, in which the contractor agrees to complete the project for a set price. Unit-price contracts are contracts in which the contractor agrees to perform the work for a specified unit price, such as per square foot or per ton.EPC contracts typically include a number of contractual provisions that allocate risk between the owner and the contractor. These provisions may include:Warranties and guarantees.Performance bonds.Insurance requirements.Dispute resolution mechanisms.EPC contracts can be a complex and challenging type of contract. However, when properly drafted and executed, EPC contracts can help to ensure the successful completion of large, complex projects.中文回答：总承包合同是一种涵盖项目全部范围的合同，从设计和工程到材料和设备的采购，再到项目的施工和调试。
TISCO二期扩建工程项目总承包(EPC)合同 中英文
TECHNICAL ANNEXFOREPC CONTRACTOFTISCO SECOND STAGE EXPANSION PROJECTVIETNAMTISCO二期扩建工程项目总承包（EPC）合同技术附件TECHNICAL ANNEX (VIII)(GENERAL LAYOUT AND TRANSPORTATION, ROADS, RAILWAYS, ALL KINDS OF PIPING NETWORK FOR TISCO’S SECOND STAGE REVANPING AND EXPANSION PROJECT) TISCO二期扩建工程之总图运输，公路，铁路，各种管网2007.7CONTENTS INDEX附件目录1.GENERAL DISCRIPTION OF TISCO’S STAGE II EXPANSIONPROJECT( EPC)TISCO二期扩建工程概述2.WORKING SCOPE OF CONTRACTOR承包商工作范围3.ADOPTED STANDARDS AND CODES FOR THE PROJECT项目规范和标准4.DESCRIPTION OF GENERAL LAYOUT, TRANSPORTATION,ROADWAY, RAILWAY AND PIPELINE WORKS OF THE WHOLE PLAN (STAGE II)全厂TISCO二期扩建工程之总图运输，公路，铁路，各种管网的概述5. EQUIPMENT LIST AND GENERAL LAYOUT ARRANGEMENT设备清单与布置图6. SOLUTIONS FOR IMPLEMENTATION ARRANGEMENT进度计划1.GENERAL DISCRIPTION OF TISCO’S STAGE II EXPANSIONPROJECT (EPC)TISCO二期扩建工程概述2.According to the requirements of sold bidding document 01#EPC, datedon March. 10, 2007, for the second stage revamping and expansionproject of TISCO, the long process of steel making production line withcapacity of 500,000t/a casting billet will be newly built up in the mainplant areas of LUU XA.3.根据在2007年3月10日卖出的01#EPC—TISO二期扩建项目投标文件的要求，在LUU XA.主厂区新建500.000t/a连铸坯生产能力的钢铁冶炼长流程工程。
epc英文合同范本
epc英文合同范本EPC ContractThis EPC Contract (the "Contract") is made and entered into as of [Insert Date], by and between [Insert Company Name], a [Insert Jurisdiction] corporation, with its principal place of business at [Insert Company Address] (hereinafter referred to as "Employer"), and [Insert Contractor Name], a [Insert Jurisdiction] corporation, with its principal place of business at [Insert Contractor Address] (hereinafter referred to as "Contractor").RecitalsWHEREAS, the Employer desires to engage the Contractor to provide engineering, procurement, and construction services ("EPC Services") for the project known as [Insert Project Name] (the "Project");WHEREAS, the Contractor has the necessary expertise and resources to provide the EPC Services and agrees to do so on the terms and conditions set forth herein;NOW, THEREFORE, in consideration of the mutual covenants and agreements contained herein and for other good and valuable consideration, the receipt and sufficiency of which are hereby acknowledged, the parties agree as follows:Article 1: Definitions1.1 "Commencement Date" shall mean the date on which the Contractor begins the EPC Services.1.2 "Completion Date" shall mean the date on which the Contractor completes the EPC Services in accordance with the requirements of the Contract.1.3 "Project Site" shall mean the location specified in Exhibit A, where the EPC Services are to be performed.1.4 "Contract Price" shall mean the total amount to be paid by the Employer to the Contractor for the EPC Services as specified in Exhibit B.Article 2: Scope of Work2.1 The Contractor shall provide all necessary EPC Services to design, procure, construct, and commission the Project in accordance with the specifications and requirements set forth in Exhibit C.2.2 The Contractor shall be responsible for obtaining all necessary permits, approvals, and licenses required for the performance of the EPC Services.Article 3: Contract Price and Payment3.1 The Employer shall pay the Contractor the Contract Price for the EPC Services, as detailed in Exhibit B.3.2 Payment shall be made in accordance with the payment schedule set forth in Exhibit D, which shall be based on the achievement of certain milestones and the submission of invoices by the Contractor.Article 4: Performance and Completion4.1 The Contractor shall commence the EPC Services on the Commencement Date and shall use its best efforts to complete the EPC Services by the Completion Date.4.2 The Contractor shall notify the Employer in writing if it anticipates that the Completion Date will not be met, and shall provide a revised schedule and the reasons for the delay.Article 5: Warranties and Representations5.1 The Contractor represents and warrants that it has the necessary qualifications, experience, and resources to perform the EPC Services.5.2 The Contractor shall provide the Employer with a warranty for the EPC Services, the terms of which are set forth in Exhibit E.Article 6: Termination6.1 Either party may terminate this Contract for cause upon written notice to the other party if the other party breachesany material provision of this Contract and fails to curesuch breach within [Insert Number] days after receipt of written notice.6.2 Upon termination, the Contractor shall be entitled to payment for work performed up to the date of termination,less any amounts owed by the Contractor to the Employer.Article 7: Indemnification7.1 The Contractor shall indemnify and hold harmless the Employer from and against any and all claims, damages, losses, and expenses arising out of or in connection with the performance of the EPC Services, except to the extent causedby the Employer's negligence or willful misconduct.Article 8: Force Majeure8.1 Neither party shall be liable for any failure or delay in performing its obligations under this Contract to the extent that such failure or delay is caused by events beyond the reasonable control of that party, including but not limitedto acts of God, war, terrorism, civil unrest, labor disputes, or changes in applicable laws.Article 9: Dispute Resolution9.1 Any disputes arising out of or in connection with this Contract shall be resolved through mediation, followed by arbitration, in accordance with the rules of the [Insert Arbitration Institution] then in effect.Article 10: Notices10.1 All notices required or permitted under this Contract shall be in writing and shall be deemed given when delivered personally or by overnight courier service, or three (3) days after being sent by registered or certified mail, postage prepaid, to the addresses set forth in Exhibit F.Article 11: Entire Agreement11.1 This Contract, including the Exhibits and any attachments hereto, constitutes the entire agreement between the parties with respect to the subject matter hereof and supersedes all prior negotiations, understanding。
epc合同范本英文
epc合同范本英文EPC CONTRACT TEMPLATEPARTIESThis Engineering, Procurement and Construction ("EPC") Contract (the "Contract") is made and entered into as of [date] (the "Effective Date") and between:Party A: [Party A's name], a [Party A's legal form] organized and existing under the laws of [Party A's jurisdiction], with its registered office at [Party A's registered address] (hereinafter referred to as "Owner"); andParty B: [Party B's name], a [Party B's legal form] organized and existing under the laws of [Party B's jurisdiction], with its registered office at [Party B's registered address] (hereinafter referred to as "Contractor").1. PROJECT DESCRIPTION1.1 The Owner intends to undertake a project (the "Project") for [project purpose].1.2 The Project shall consist of [describe the scope and nature of the project in detl].2. CONTRACT SCOPE2.1 The Contractor shall be responsible for the engineering, procurement and construction of the Project on a turnkey basis in accordance with the requirements and specifications set forth in this Contract.2.2 The Contractor's scope of work shall include, but not be limited to:2.2.1 Engineering design and related services.2.2.2 Procurement of all equipment, materials and supplies necessary for the Project.2.2.3 Construction and installation works.2.2.4 Commissioning and testing of the Project.2.2.5 Trning of the Owner's personnel.3. CONTRACT PRICE AND PAYMENT TERMS3.1 The total contract price for the Project (the "Contract Price") is [amount in words and figures].3.2 The Contract Price shall be pd the Owner to the Contractor in accordance with the following payment schedule:3.2.1 [Describe the initial payment and its conditions].3.2.2 [Describe subsequent milestone payments and their conditions].3.2.3 Final payment shall be made upon successful pletion and acceptance of the Project.4. PROJECT SCHEDULE4.1 The Contractor shall plete the Project in accordance with the following schedule:4.1.1 Commencement date: [date].4.1.2 Substantial pletion date: [date].4.1.3 Final pletion and handover date: [date].4.2 The Contractor shall provide progress reports to the Owner on a regular basis and promptly notify the Owner of any potential delays or deviations from the schedule.5. WARRANTY AND GUARANTEE5.1 The Contractor warrants that the Project shall be pleted in accordance with the applicable standards and specifications and shall be free from defects in materials and workmanship for a period of [warranty period] from the date of final acceptance.5.2 The Contractor shall provide a performance guarantee to ensure the satisfactory operation of the Project during the guarantee period.6. RISK ALLOCATION6.1 The Contractor shall assume the risks associated with the engineering, procurement and construction of the Project, including but not limited to risks of design errors, material shortages, construction delays and cost overruns.6.2 The Owner shall assume the risks related to changes in laws and regulations, force majeure events and unforeseen site conditions.7. DISPUTE RESOLUTION7.1 Any disputes arising out of or in connection with this Contract shall be resolved through amicable negotiations between the parties.7.2 If the negotiations fl, the dispute shall be submitted to arbitration in accordance with the rules of [arbitration institution].8. MISCELLANEOUS PROVISIONS8.1 This Contract constitutes the entire agreement between the parties with respect to the Project and supersedes all prior negotiations, representations and agreements.8.2 Any amendments or modifications to this Contract shall be in writing and signed both parties.8.3 This Contract shall be governed and construed in accordance with the laws of [jurisdiction].IN WITNESS WHEREOF, the parties have executed this Contract as of the date first above written.Party A: [Party A's name and signature]Party B: [Party B's name and signature]Please note that this is just a basic template and should be tlored to the specific circumstances and requirements of the particular EPC project.。
全面工程承包合同英文版
全面工程承包合同英文版Comprehensive Engineering ContractThis document serves as a comprehensive engineering contract between the parties involved in the construction project. The purpose of this contract is to clearly outline the responsibilities, scope of work, and terms of agreement for all parties involved.Parties InvolvedThis contract is entered into between the Owner, represented by [Owner's Name], and the Contractor, represented by [Contractor's Name]. Both parties agree to the terms and conditions outlined in this agreement.Scope of WorkThe Contractor agrees to provide all labor, materials, equipment, and services necessary to complete the engineering project in accordance with the plans and specifications provided by the Owner. The scope of work includes but is not limited to site preparation, excavation,foundation work, structural construction, mechanical, electrical, and plumbing installations, finishing work, and all other tasks necessary for the successful completion of the project.Terms of Agreement1. Payment: The Owner agrees to pay the Contractor the agreed-upon amount in a timely manner as outlined in the payment schedule.2. Change Orders: Any changes to the scope of work must be approved in writing by both parties and may result in additional costs or time extensions.3. Insurance: The Contractor is responsible for maintaining adequate insurance coverage throughout the duration of the project.4. Warranty: The Contractor agrees to provide a warranty for the completed work for a period of [number] years from the date of substantial completion.5. Termination: Either party may terminate this contract for cause by providing written notice to the other party. In the event of termination, the parties agree to resolve any outstanding issues in good faith.ConclusionThis comprehensive engineering contract is a binding agreement between the Owner and the Contractor. Both parties acknowledge that they have read, understood, and agreed to the terms and conditions outlined in this document. Any disputes arising from this contract will be resolved through mediation or arbitration.Signed on [Date] in the presence of witnesses:Owner: [Owner's Signature]Contractor: [Contractor's Signature]。
EPC合同条件(中英文对照版)(DOC106页)
CONTENTS目录1 General Provisions 一般规定 (55)1.1 Definitions 定义 (55)1.2 Interpretation 解释 (1010)1.3 Communications 通信交流 (1111)1.4 Law and Language 法律和语言 (1212)1.5 Priority of Document 文件优先次序 (1212)1.6 Contract Agreement 合同协议书 (1212)1.7 Assignment 权益转让 (1313)1.8 Care and Supply of Document 文件的照管和提供 (1313)1.9 Confidentiality 保密性 (1414)1.10 Employer’s Use of Contractor’s Documents雇主使用承包商文件 (1414)1.11 Contractor’s Use of Employer’s Documents承包商使用雇主文件 (1515)1.12 Confidential Details 保密事项 (1515)1.13 Compliance with Laws 遵守法律 (1515)1.14 Joint and Several Liability 共同的和各自的责任 (1616)2 The Employer 雇主 (1616)2.1 Right of Access to the Site 现场进入权 (1616)2.2 Permits, Licences or Approves 许可、执照或批准 (1717)2.3 Employer’s personnel雇主人员 (1818)2.4 Employer’s Financial Arrangements雇主的资金安排 (1818)2.5 Employer’s Claims雇主的索赔 (1818)3 The Employer’s Administration雇主的管理 (1919)3.1 The Employer’s Representative雇主代表 (1919)3.2 The Employer’s personnel其他雇主人员 (2020)3.3 Delegated Persons 受托人员 (2020)3.4 Instructions 指示...................................... 错误!未定义书签。
epc中英文合同范本
epc中英文合同范本合同编号：[合同编号]项目名称：[项目名称]甲方（业主）：[甲方名称]地址：[甲方地址]联系电话：[甲方联系电话][甲方]乙方（总承包商）：[乙方名称]地址：[乙方地址]联系电话：[乙方联系电话][乙方]鉴于甲方拟建设[项目名称]，并通过招标选择乙方作为该项目的总承包商，乙方愿意承担该项目的设计、采购、施工等工作，双方经友好协商，达成如下协议：一、工程概况1. 工程名称：[项目名称]2. 工程地点：[项目地点]3. 工程内容：[详细工程内容]4. 工程规模：[工程规模描述]二、合同价格及支付方式1. 合同总价：人民币[大写金额]元（小写：￥[小写金额]元）2. 支付方式：[具体支付方式和时间节点]三、工期1. 开工日期：[预计开工日期]2. 竣工日期：[预计竣工日期]3. 工期延误：如因乙方原因导致工期延误，乙方应承担相应的违约责任。
四、质量标准1. 工程质量标准：[质量标准描述]2. 验收：工程竣工后，甲方应及时组织验收。
如验收不合格，乙方应在规定的时间内整改直至合格。
五、双方责任1. 甲方责任：提供项目所需的相关资料和文件；按时支付合同款项；协助乙方解决施工过程中遇到的问题。
2. 乙方责任：按照合同要求完成工程的设计、采购、施工等工作；确保工程质量符合合同要求；遵守施工现场的管理规定，做好安全防护工作。
六、违约责任1. 若一方违反本合同约定，应承担违约责任，向对方支付违约金[违约金金额]元。
2. 如因一方违约给对方造成损失，违约方应承担相应的赔偿责任。
七、争议解决本合同履行过程中如发生争议，双方应通过友好协商解决；协商不成的，可向有管辖权的人民法院提起诉讼。
八、其他条款1. 本合同自双方签字（盖章）之日起生效。
2. 本合同一式两份，双方各执一份，具有同等法律效力。
3. 本合同未尽事宜，可由双方另行签订补充协议。
甲方（业主）：[甲方名称]（签章）法定代表人或授权代表：[签字人姓名]签订日期：[签订日期]乙方（总承包商）：[乙方名称]（签章）法定代表人或授权代表：[签字人姓名]签订日期：[签订日期]。
- 1、下载文档前请自行甄别文档内容的完整性，平台不提供额外的编辑、内容补充、找答案等附加服务。
- 2、"仅部分预览"的文档,不可在线预览部分如存在完整性等问题,可反馈申请退款(可完整预览的文档不适用该条件!)。
- 3、如文档侵犯您的权益，请联系客服反馈,我们会尽快为您处理(人工客服工作时间：9:00-18:30)。
TECHNICAL ANNEXFOREPC CONTRACTOFTISCO SECOND STAGE EXPANSION PROJECTVIETNAMTISCO二期扩建工程项目总承包（EPC）合同技术附件TECHNICAL ANNEX (VIII)(GENERAL LAYOUT AND TRANSPORTATION, ROADS, RAILWAYS, ALL KINDS OF PIPING NETWORK FOR TISCO’S SECOND STAGE REVANPING AND EXPANSION PROJECT) TISCO二期扩建工程之总图运输，公路，铁路，各种管网2007.7CONTENTS INDEX附件目录1.GENERAL DISCRIPTION OF TISCO’S STAGE II EXPANSIONPROJECT( EPC)TISCO二期扩建工程概述2.WORKING SCOPE OF CONTRACTOR承包商工作范围3.ADOPTED STANDARDS AND CODES FOR THE PROJECT项目规范和标准4.DESCRIPTION OF GENERAL LAYOUT, TRANSPORTATION,ROADWAY, RAILWAY AND PIPELINE WORKS OF THE WHOLE PLAN (STAGE II)全厂TISCO二期扩建工程之总图运输，公路，铁路，各种管网的概述5. EQUIPMENT LIST AND GENERAL LAYOUT ARRANGEMENT设备清单与布置图6. SOLUTIONS FOR IMPLEMENTATION ARRANGEMENT进度计划1.GENERAL DISCRIPTION OF TISCO’S STAGE II EXPANSIONPROJECT (EPC)TISCO二期扩建工程概述2.According to the requirements of sold bidding document 01#EPC, datedon March. 10, 2007, for the second stage revamping and expansionproject of TISCO, the long process of steel making production line withcapacity of 500,000t/a casting billet will be newly built up in the mainplant areas of LUU XA.3.根据在2007年3月10日卖出的01#EPC—TISO二期扩建项目投标文件的要求，在LUU XA.主厂区新建500.000t/a连铸坯生产能力的钢铁冶炼长流程工程。
According to the requirements of bidding document, Fe metal balance forproducing 543,200 t/a hot metal is shown as following calculation blockdiagram:根据投标文件要求，年产543,200 t铁水中金属铁的比例如计算框图1.1MAIN TECHNICAL PROCESS FLOW CHART主要工艺流程LUU XA main plant will adopt a long process production line, namelycoke oven, sintering machine, blast furnace, converter, and continuouscasting production line.LUU XA主厂区采用长流程炼焦、烧结、高炉、转炉连铸生产工艺01# EPC package mainly includes raw material yard project, coke makingproject (coke oven), sintering project, iron making project, steel makingproject, and oxygen generating project, whole plant utilities (water,electricity and natural gas) at the second stage and general layout andtransportation.EPC工程包括的主车间：原料场；炼焦（焦炉）工程；烧结工程；炼铁工程；炼钢工程；制氧工程；二期全厂公辅设施（水、电、燃气）；总图布置及运输。
1.2CONTENTS OF CONTRACTING1.3合同内容The Employer uses the EPC bidding method. The bidding scope includesmain plant area geological exploration for the second stage project,engineering design, equipment supply, staff training, project construction,equipment installation, test-run, trial production, start up of production,acceptance test and hand over.雇主采用EPC方式招标，其内容包括：主厂区二期的地质勘探；工程设计；设备供货；人员培训；施工；设备安装；试车；试生产；投产；验收交付。
1.4ADOPTED STANDARDS AND CODES项目规范和标准According to the requirements of the bidding documents, Vietnam orChina standards and codes shall be adopted.按照招标文件的要求，采用TISCO提供的越南标准和规范，如果TISCO不能提供相关的越南标准和规范，在工程设计、设备制造中将采用中国相应的标准和规范。
1.5PROJECT CONSTRUCTION SHCEDULE项目实施进度表The EPC’s contractor shall complete their work within 30 months.The project construction schedule is arranged based on the actualsituations of all the main production lines of second stage revamping andexpansion project to meet the requirements of whole project startingproduction.承包商应在30个月内完成EPC合同中规定的工作。
项目实施进度是根据二期扩建工程各主要生产线在项目整体投产过程中的需要来进行安排。
1.4.1 Individual Package Schedule of Various Main Workshops各主要生产车间分标段包工程进度时间：1) The raw material yard project shall be put into production at 18months.原料场要求工程进度安排是18个月投产；2) The sintering project shall be put into production at 20 months.烧结工程要求工程进度安排是20个月投产3) The coke making project shall be put into production at 20 months.炼焦工程要求工程进度安排是20个月投产4)The iron making project shall be put into production at 23 months.炼铁工程要求工程进度安排是23个月投产；5) The steel making project shall be put into production at 28 months.炼钢工程要求工程进度安排是28个月投产6) The oxygen generating project shall be put into production at 22months.制氧工程要求工程进度安排是22个月投产；7) The utilities project of plant area for second stage revamping andexpansion project shall be put into production at 18 - 22 monthsprogressively.二期厂区公辅设施要求工程进度安排是18～28个月分期投产；8) The roads, railways, power piping network for second stagerevamping and expansion project shall be put into production at 18 - 22months progressively.二期厂区道路、铁路及动力管网工程要求工程进度安排是18～28个月分期投产1.4.2 For the details of the individual package schedule of various mainproduction workshops, please see the technical appendixes.各主要生产车间分标段包工程实施进度表，见各技术附件。
1.4.3 EPC project construction schedule.EPC实施进度计划表1.5 CONTRACTOR’S SERVICE CONTENTS AND SCHEDULE承包商提供的技术服务的内容及时间The Contractor shall provide the site geological survey report, technicaldesign, shop drawing design, equipment purchasing, equipment supply,construction for plant building, equipment foundation as well as pipingnetwork, equipment installation, staff training, test run and trialproduction for main production lines, start up of the production,acceptance test and hand over.承包商根据各分标段的项目实施进度表，分别提供场地的地质勘探；工程的基本设计、设备采购、供货；厂房、设备基础、管网的施工；设备的安装、调试；人员培训；各主生产线的试车、试生产；投产；验收交付。