室内(办公室)设计装修合同-中英文

合集下载

全面的室内装潢契约英文版

全面的室内装潢契约英文版Comprehensive Interior Decorating ContractWhen it comes to designing or renovating the interior of your home or office, having a detailed and comprehensive contract in place is essential to ensure that both parties are clear on the terms and expectations of the project. This document will outline all the necessary details such as the scope of work, timeline, budget, materials, and any other specific requirements that need to be agreed upon before the project begins.The interior decorating contract should include a detailed description of the work to be done, including the specific rooms or areas that will be decorated, the types of materials and finishes to be used, and any special requests or design preferences. It should also outline the responsibilities of both the client and the decorator, including payment terms, deadlines, and any additional services that may be provided.By having a comprehensive contract in place, both parties can avoid any potential misunderstandings or disputes that may arise during the course of the project. It provides a clear roadmap for the project, ensuring that everyone is on the same page and working towards a common goal.In conclusion, a comprehensive interior decorating contract is a crucial document that should not be overlooked. It serves as a legal and binding agreement between the client and the decorator, outlining all the necessary details to ensure a successful and smooth project completion. Make sure to carefully review and discuss the contract with your decorator before signing to ensure that all parties are in agreement and that the project can proceed as planned.。

办公楼装饰装修工程施工合同(中英文)(20210126030629)

装修装饰工程施工合同CONTRACT OF DECORATION ENGINEERING签署日期Date of工程名称：Project Name:工程地址：Project Place:发包方（甲方）：Owner （Hereinafter referred to as party A）承包方（乙方）：Contractor: （hereinafter called party B）鉴于甲方拟对办公楼进行装修装饰，通过招投标程序，将该工程授予乙方施工并完成；鉴于乙方具备装修装饰施工的资质，并愿意接受招投标规定的条件，同意承担该工程的施工并完成；鉴于双方同意遵照《中华人民共和国合同法》、《建筑装饰装修管理规定》、《住宅室内装饰装修管理办法》及有关法律、法规规定履行本合同；基于本合同之合意、声明、约定及其它约因，双方当事人兹就下列各事项达成协议：WHEREAS party A intends to make decoration of office building, through bidding procedure, award this project hereby to party B for construction and completion thereof.WHEREAS party B is with the qualification of decoration engineering, intends to accept bidding conditions and consent to undertake the project construction and complete.WHEREAS parties hereto agree to execute this contract in accordance with LAW OF CONTRACT, REGULATIONS OF CONSTRUCTION DECORATION MANAGEMENT, ADMINISTRATION RULES FOR INDOOR HOME DECORATION and concerned laws and regulations.NOW THEREFORE in consideration of the mutual promises, assertions and covenants herein and other good and valuable considerations, the receipts of which is acknowledged hereby, the parties hereby agree as follows:第一条工程概况Work Overview1、工程名称：Project Name2、工程地址：Project Place:3、承包方式：总承包（包工包料，包质量，包安全，包工期）Contracting Means: General contracting, including contracting of materials and labor, liabilities of quality, work ' s safety and work's schedule.4、承包内容：包括所有的拆除及改造工程，以附件《工程报价单》为准。

英文装修合同范本模板

英文装修合同范本模板Renovation ContractThis Renovation Contract (the "Contract") is made and entered into on [date] and between [Client's Name] (the "Client") and [Contractor's Name] (the "Contractor").1. Project DescriptionThe Contractor agrees to undertake the renovation project described as follows: [Describe the scope and detls of the renovation work, including rooms, specific tasks, materials to be used, etc.]2. Project TimelineThe renovation work is scheduled to mence on [start date] and be pleted [pletion date]. The Contractor shall make every effort to meet the agreed-upon timeline.3. Project CostThe total cost of the renovation project is agreed to be $[amount]. This includes labor, materials, and any other expenses as specified in the detled estimate provided the Contractor.4. Payment ScheduleThe Client shall make the following payments to the Contractor:A deposit of $[deposit amount] upon signing this Contract.[Interim payment detls and amounts, if applicable]The final payment of $[final payment amount] upon satisfactory pletion of the project and inspection the Client.5. Workmanship and MaterialsThe Contractor warrants that the work will be performed in a professional and workmanlike manner and that all materials used will be of good quality and in accordance with industry standards.6. Changes and AdditionsAny changes or additions to the original project scope must be agreed upon in writing both the Client and the Contractor, and may result in adjustments to the project cost and timeline.7. Inspection and AcceptanceUpon pletion of the work, the Client shall inspect the project within [number of days] days. If the work is found to be satisfactory and in accordance with the Contract, the Client shall accept the project. If there are any deficiencies, the Contractor shall rectify them within a reasonable time.8. Warranties and GuaranteesThe Contractor provides a warranty for the workmanship and materials for a period of [warranty period] from the date of project pletion.9. Dispute ResolutionIn the event of a dispute arising out of or in connection with this Contract, the parties shall attempt to resolve the dispute through amicable negotiation. If negotiation fls, the dispute shall be submitted to arbitration in accordance with the rules of [arbitration institution].10. TerminationEither party may terminate this Contract under the following circumstances: Breach of the Contract the other party.Unforeseen circumstances that make it impossible to plete the project.11. InsuranceThe Contractor shall mntn appropriate liability insurance during the course of the project.12. Governing LawThis Contract shall be governed and construed in accordance with the laws of [jurisdiction].13. Entire AgreementThis Contract constitutes the entire agreement between the parties and supersedes all prior negotiations, understandings, and agreements.IN WITNESS WHEREOF, the parties have executed this Contract as of the date first above written.Client's Signature: [Client's Name]Date: [Client's Signature Date] Contractor's Signature: [Contractor's Name] Date: [Contractor's Signature Date]。

室内(办公室)设计装修合同-中英文

办公室设计合同合同号：________________签订日期：________________签订地点：________________根据《中华人民共和国合同法》以及其他相关法律、法规，结合室内装饰的特点，经甲、乙双方友好协商，甲方委托乙方承担室内装饰设计，并达成如下协议。

一、甲方委托室内设计的地址________________________，房型____________，总面积____________平方米。

二、甲方委托乙方室内设计，且乙方不负责施工，其设计收费标准为每平方米____________美元，收取设计费共计____________美元。

甲方应在合同签署时付首期50% 设计费，并与乙方约定上门测量的时间和地点。

乙方设计师在测量后____天内完成平面布置图及顶面布置图。

三、乙方完成初步设计方案后，甲方与乙方设计师经过沟通同意，填写设计方案进程表。

甲方应支付设计费余款，乙方设计师将在____天内完成全套装潢设计图。

四、图纸完成后，甲方如有更改意见，再与乙方设计师沟通。

乙方根据协商方案，绘制更改图纸，双方再次填写设计方案进程表。

图纸更改确认后，乙方将全套图纸交给甲方使用。

五、施工过程中，乙方设计师应至少有三次去现场指导施工，以达到设计效果。

六、违约责任：1.乙方未在约定时间内完成设计图且延期时间在_____天内的，每延期一天应当支付设计费总价的 3% 违约金给甲方。

2. 乙方延期____天以上未完成设计图的，甲方有权解除合同，乙方应退还甲方的设计费用，并承担设计费总价 50% 的违约金。

3. 乙方无故终止合同，除退还甲方所交的设计费用外，还应按合同规定的设计费总价的 50% 作为违约金付给甲方。

七、设计合同经双方签字认可后，甲方必须按合同约定支付设计费。

如甲方中途取消合同，乙方不再退还已收取的设计费。

八、除本合同外，甲乙双方之间的所有往来函件，乙方给甲方的资料、图纸等均采用英文。

九、本合同中如有未尽事宜，由双方协商解决,协商不成，由甲方所在地人民法院裁决。

中英文对照装饰施工合同

中英文对照装饰施工合同合同编号：__________中英文对照装饰施工合同甲方：Address:Contact Person:Phone:乙方：Address:Contact Person:Phone:鉴于甲方为进行房屋装饰装修，需要乙方提供装饰施工服务，双方本着平等互利的原则，经协商一致，特订立本合同，以便共同遵守。

第一条工程概况1.1 工程名称：____________________1.2 工程地点：____________________1.3 工程内容：包括但不限于____________、____________、____________等。

1.4 工程预算：人民币（大写）：____________元整（小写）：_____________元。

第二条合同价格及支付方式2.1 双方确认，乙方向甲方提供的装饰施工服务价格为人民币（大写）：____________元整（小写）：_____________元。

2.2 甲方支付乙方的款项分三次支付，具体支付时间和比例如下：第一次支付：合同签订后七个工作日内，支付合同价的30%；第二次支付：工程进度达到50%时，支付合同价的30%；第三次支付：工程验收合格后，支付合同价的40%。

2.3 甲方支付款项时，应出具相应的付款凭证。

第三条施工期限3.1 双方确认，乙方应按照本合同约定的施工内容、施工标准和施工期限完成施工。

3.2 乙方承诺，本工程的施工期限为________个月，自甲方支付首期款项之日起计算。

3.3 乙方如因特殊情况需延长施工期限，应提前七个工作日书面通知甲方，并征得甲方同意。

甲方同意延长的期限，乙方应相应顺延。

第四条工程质量4.1 乙方应按照甲方的要求、国家相关标准和规范进行施工，保证工程质量。

4.2 工程验收不合格的，乙方应负责返工、整改，直至验收合格。

4.3 工程验收合格后，乙方应承担保修责任，保修期限自工程验收合格之日起计算，保修期限为________年。

室内装修工程合同书

室内装修工程合同书英文回答：Interior Decoration Construction Contract。

Article 1: Parties to the Contract。

1.1 The Client: [Client's Name], a company incorporated under the laws of [Country] with its registered office at [Registered Address].1.2 The Contractor: [Contractor's Name], a company incorporated under the laws of [Country] with its registered office at [Registered Address].Article 2: Scope of Work。

2.1 The Contractor shall provide all labor, materials, and equipment necessary to complete the interior decoration of the Client's premises located at [Address].2.2 The scope of work includes, but is not limited to:Demolishing existing walls and partitions。

Installing new walls and partitions。

Painting and decorating。

Installing flooring and ceilings。

Installing light fixtures and electrical fittings。

Installing plumbing and sanitary fittings。

5个标准版室内装修设计合同英文版

5个标准版室内装修设计合同英文版Title: 5 Standard Indoor Decoration Design ContractsWhen it comes to interior decoration design contracts, it is crucial to ensure that all parties involved are on the same page. Here are five essential elements that should be included in a standard indoor decoration design contract:1. Scope of Work: This section should clearly outline the specific tasks and responsibilities of both the designer and the client. It should detail the design services to be provided, the timeline for completion, and any additional services that may be required.2. Payment Terms: It is important to clearly define the payment terms in the contract. This should include the total cost of the design services, the payment schedule, and any additional fees that may apply. Both parties should agree on the payment terms before work begins.3. Design Approval Process: The contract should outline the process for design approval. This should include how designs will be presented to the client, how revisions will be handled, and the deadlines for design approval. Clear communication is key to ensuring a successful design process.4. Ownership of Design: This section should address the ownership rights of the design work. It should specify that the designer retains ownership of the design until full payment is received. Once payment is made, the client will have full rights to use the design as outlined in the contract.5. Termination Clause: In the event that either party wishes to terminate the contract, there should be a clear termination clause included. This should outline the steps that need to be taken to terminate the contract, any penalties or fees that may apply, and the process for resolving any disputes that may arise.By including these five elements in a standard indoor decoration design contract, both parties can ensure a smooth and successful designprocess. It is important to review the contract carefully and make any necessary revisions before signing to avoid any misunderstandings or disputes down the line.。

家装设计合同书英文

家装设计合同书英文Home Renovation Design ContractThis Home Renovation Design Contract ("Contract") is made and entered into on the date of [Insert Date] between [Insert Client Name] ("Client"), and [Insert Designer Name] ("Designer"), with the address of [Insert Client Address] and [Insert Designer Address] respectively.1. Scope of Work: The Designer is hired to provideprofessional design services for the renovation of theClient's home located at [Insert Property Address]. The services include, but are not limited to, space planning, selection of materials, color schemes, and furniture layout.2. Design Fee: The total design fee for the services rendered is [Insert Total Fee]. This fee is non-refundable and is tobe paid in [Insert Number of Installments] installments as follows: [Insert Payment Schedule].3. Payment Terms: The Client agrees to pay the design fee in accordance with the payment schedule outlined above. Anydelay in payment may result in a delay of the design services.4. Designer’s Res ponsibilities: The Designer shall:- Provide initial design concepts within [Insert Time Frame] after the signing of this contract.- Present revised designs based on Client feedback within[Insert Revision Time Frame].- Coordinate with any third-party contractors or suppliers as necessary for the execution of the design.- Ensure that the design adheres to all relevant building codes and regulations.5. Client’s Responsibilities: The Client shall:- Provide the Designer with access to the property for measurements and design purposes.- Offer timely feedback on design proposals.- Approve design concepts and revisions within the agreed time frame to avoid project delays.- Obtain all necessary permits and approvals for the renovation work.6. Intellectual Property: All design materials, including sketches, drawings, and digital files, are the property of the Designer. The Client is granted a limited license to use these materials for the sole purpose of the renovation project.7. Termination: Either party may terminate this Contract by providing written notice to the other party. In the event of termination, the Client shall be responsible for payment for all services rendered up to the date of termination.8. Confidentiality: The Designer agrees to keep all information regarding the Client’s project confidential and not to disclose such information to any third party without the Client’s prior written consent.9. Liability: The Designer’s liability for any claim, loss, damage, or expense related to this Contract shall be limitedto the total amount of the design fee paid by the Client.10. Force Majeure: Neither party shall be liable for anyfailure or delay in performing its obligations under this Contract to the extent that such failure or delay is causedby circumstances beyond the reasonable control of that party.11. Governing Law: This Contract shall be governed by and construed in accordance with the laws of [Insert Governing Law].12. Entire Agreement: This Contract constitutes the entire agreement between the parties concerning the subject matter hereof and supersedes all prior and contemporaneous agreements, whether oral or written.IN WITNESS WHEREOF, the parties have executed this Contractas of the date first above written.[Insert Client Name] [Insert Designer Name]Client Signature: ________________________ Designer Signature: _______________________Date: ________________________ Date: _______________________ Print Name: ________________________ Print Name:_______________________[Insert Client Address] [Insert Designer Address]。

全面版房屋装修合同书英文版

全面版房屋装修合同书英文版Comprehensive House Renovation ContractThis contract is entered into between the homeowner, referred to as the "Client," and the renovation contractor, referred to as the "Contractor," on [date].1. Scope of Work:The Contractor agrees to provide all labor, materials, and equipment necessary to complete the renovation of the Client's house located at [address]. This includes but is not limited to painting, flooring, plumbing, electrical work, and carpentry.2. Schedule:The renovation work is expected to begin on [start date] and be completed by [end date]. The Contractor shall provide a detailed schedule of work to the Client prior to the start date.3. Payment:The total cost of the renovation project is agreed upon as [total amount]. The Client agrees to make payments according to the following schedule:- 50% deposit due prior to the start of work- 25% payment due at the halfway point of the project- 25% final payment due upon completion of the project4. Changes and Extras:Any changes or additional work requested by the Client must be agreed upon in writing and may result in additional costs and extended completion time.5. Quality of Work:The Contractor agrees to perform all work in a professional and workmanlike manner, using materials of good quality and in accordance with industry standards.6. Warranty:The Contractor warrants all workmanship and materials for a period of [warranty period] from the date of completion. Any defects that arise during this period will be repaired by the Contractor at no additional cost to the Client.7. Termination:Either party may terminate this contract with written notice if the other party fails to fulfill their obligations. In the event of termination, the Client will pay for all work completed up to that point.8. Disputes:Any disputes arising from this contract will be resolved through mediation. If mediation is unsuccessful, the parties agree to arbitration in accordance with [arbitration rules].9. Governing Law:This contract shall be governed by the laws of [state/country] and any disputes shall be resolved in the courts of [jurisdiction].10. Signatures:Both parties acknowledge that they have read and understood the terms of this contract and agree to be bound by them.Client Signature: ________________________ Date:_______________Contractor Signature: _____________________ Date:_______________。

室内装修改造合同

室内装修改造合同（中英文实用版）Title: Interior Renovation Contract1.Parties involved:Contractor: XYZ Construction Co., Ltd.Client: Mr.John Smith1.Scope of Work:The contractor shall be responsible for the following renovation works:- Remodeling of the living room, bedroom, and kitchen- Installation of new flooring, tiles, and paint- Installation of new electrical and plumbing systems- Installation of new kitchen cabinets and countertops1.Timeframe:The renovation works shall commence on March 1, 2022, and be completed by May 1, 2022.1.Payment Terms:The client shall pay the contractor a 50% deposit upon signing of the contract.The remaining 50% shall be paid upon completion of the renovation works.1.Dispute Resolution:Any disputes arising out of or in connection with this contract shallbe resolved by arbitration in accordance with the rules of the International Chamber of Commerce.erning Law:This contract shall be governed by and construed in accordance with the laws of the People"s Republic of China.2.Amendments:This contract may be amended or modified only by a written instrument executed by both parties.2.Entire Agreement:This contract constitutes the entire agreement between the parties and supersedes all prior agreements and understandings, whether written or oral, between the parties.甲方（业主）：约翰·史密斯先生乙方（施工方）：XYZ建筑有限公司1.工程范围：乙方应负责以下装修工作：- 客厅、卧室和厨房的改造- 铺设新地板、瓷砖和油漆- 安装新的电气和给排水系统- 安装新的厨房橱柜和台面1.工程期限：装修工程应自2022年3月1日起开始，至2022年5月1日完成。

全方位的室内设计合同英文版

全方位的室内设计合同英文版Comprehensive Interior Design ContractThis document serves as a comprehensive agreement between the client and the interior designer for the design and execution of interior spaces. It outlines the responsibilities, timelines, and payment terms for both parties involved.Scope of WorkThe interior designer will provide design services including conceptualization, space planning, material selection, and project management. The client will provide necessary information, approvals, and access to the space for design and installation.TimelineThe project timeline will be outlined in a detailed schedule provided by the designer. Any delays or changes in schedule must be communicated and agreed upon by both parties in writing.Payment TermsPayments for design services will be made in installments as outlined in the contract. Additional fees for changes or additional services requested by the client will be agreed upon in writing before proceeding.ResponsibilitiesThe client is responsible for providing accurate information about the space, budget, and design preferences. The designer is responsible for delivering high-quality design services within the agreed timeline and budget.TerminationEither party has the right to terminate the contract in writing if the other party fails to fulfill their obligations. Termination may result in additional fees or penalties as outlined in the contract.ConfidentialityBoth parties agree to keep all project details and information confidential. Any disclosure of sensitive information may result in legal action.Dispute ResolutionAny disputes arising from this contract will be resolved through negotiation and mediation. If a resolution cannot be reached, legal action may be pursued.Governing LawThis contract is governed by the laws of the state in which the project is located. Any legal proceedings will take place in the jurisdiction specified in the contract.SignaturesBoth parties acknowledge their understanding and acceptance of the terms outlined in this contract by signing below.Client Signature: ______________________Date: _______________Designer Signature: ____________________ Date: _______________。

装修合同协议书英文

装修合同协议书英文这是小编精心编写的合同文档，其中清晰明确的阐述了合同的各项重要内容与条款，请基于您自己的需求，在此基础上再修改以得到最终合同版本，谢谢！装修合同协议书英文Contract Agreement for Home Renovation甲方（以下简称“甲方”）：地址：联系方式：乙方（以下简称“乙方”）：地址：联系方式：鉴于甲方希望对自有房屋进行装修，乙方具备相关装修资质和经验，双方本着平等、自愿、互利的原则，经友好协商，就甲方房屋装修事宜达成以下协议：1. 装修项目及要求1.1 乙方根据甲方的要求，对甲方房屋进行装修，包括（但不限于）以下项目：- 墙面翻新- 地面铺设- 卫生间改造- 厨房改造- 水电改造- 室内布局调整- 家具选购与摆放1.2 乙方应按照甲方的要求及相关装修标准，保证装修质量，确保装修工程安全、环保。

2. 装修费用及支付方式2.1 乙方向甲方提供的装修报价为人民币（大写）：________元整（小写）：________元。

如有增项，双方协商确定增项费用。

2.2 甲方支付装修款项分三个阶段：- 合同签订后三天内支付装修总价的30%作为预付款；- 装修工程进度达到50%时支付装修总价的30%；- 装修工程验收合格后支付装修总价的40%。

2.3 乙方开具正规发票，甲方按约定时间支付装修款项。

3. 装修工期3.1 乙方承诺在甲方同意的情况下，按照双方约定的工期完成装修工程。

如因乙方原因导致工期延误，乙方应承担相应的违约责任。

4. 质量保证4.1 乙方对装修工程的质量负责，自验收合格之日起提供____年的质保服务。

质保期内，如出现质量问题，乙方负责免费维修或更换。

5. 验收及争议解决5.1 装修工程完成后，甲方应按照双方约定的标准进行验收。

如甲方对工程质量有异议，应在验收合格后三天内提出，并由乙方负责整改。

5.2 如在验收过程中发生争议，双方应友好协商解决；协商不成的，可向合同签订地人民法院提起诉讼。

装修工程合同中英文版

装修工程合同中英文版装修工程合同Decoration Project Contract甲方：_______________（公司或个人名称），注册地址：_______________，法定代表人：_______________，联系电话：_______________。

Party A: _______________ (company or individual name), registered address: _______________, legal representative: _______________, contact number: _______________.乙方：_______________（公司或个人名称），注册地址：_______________，法定代表人：_______________，联系电话：_______________。

Party B: _______________ (company or individual name), registered address: _______________, legal representative: _______________, contact number: _______________.鉴于甲方有一处房产需要装修，现甲乙双方经友好协商，达成如下合同，共同遵守。

Whereas Party A requires decoration for their property, Party A and Party B negotiate in a friendly manner and reach the following contract, to be jointly observed.一、装修的内容范围包括如下：The scope of the decoration includes but is not limited to:1、电路改造、水路改造、墙面装饰、地面铺装、吊顶、阳台封闭及窗户翻新。

全面版的室内设计合同英文版

全面版的室内设计合同英文版Comprehensive Interior Design ContractThis document serves as a comprehensive agreement between the client and the interior designer for the design and implementation of interior spaces. The contract outlines the rights and responsibilities of both parties to ensure a smooth and successful design process.Services ProvidedThe interior designer agrees to provide the following services:- Initial consultation to discuss client needs and preferences- Development of design concepts and mood boards- Selection of furnishings, materials, and accessories- Coordination with contractors and vendors- Installation and styling of final designClient ResponsibilitiesThe client agrees to:- Provide accurate information about their needs and budget- Make timely decisions on design options- Approve final design plans and budget- Provide access to the space for measurements and installations- Communicate any concerns or changes promptlyPayment TermsThe client agrees to pay the interior designer a fee of [insert amount] for the design services provided. Payment will be made in installments as outlined in the contract. Additional fees for materials, furnishings, and contractor services will be the responsibility of the client.TimelineThe interior designer will provide a timeline for the design process, including key milestones and deadlines. The client agrees to adhere to the timeline and provide any necessary approvals or feedback in a timely manner to avoid delays.TerminationEither party may terminate the contract with written notice if there is a breach of contract or if the project cannot be completed forunforeseen reasons. In the event of termination, the client will be responsible for payment of any services rendered up to the termination date.ConfidentialityBoth parties agree to keep all project-related information confidential, including design plans, budgets, and client preferences. Any disclosure of confidential information without consent may result in legal action.Governing LawThis contract shall be governed by the laws of [insert jurisdiction] and any disputes shall be resolved through arbitration. Both parties agree to comply with all legal requirements and regulations in the execution of this contract.By signing below, both parties acknowledge and agree to the terms and conditions outlined in this comprehensive interior design contract._______________________ _______________________Client Signature Designer Signature Date: _______________ Date: _______________。

2024年房屋装修合同样板英文版

2024年房屋装修合同样板英文版2024 House Renovation Contract TemplateThis document serves as a template for a house renovation contract to be used in 2024. It outlines the terms and conditions that both parties must adhere to during the renovation process.1. Parties Involved- This contract is entered into between the homeowner, referred to as the "Client," and the renovation contractor, referred to as the "Contractor."2. Scope of Work- The Contractor agrees to provide renovation services for the Client's house as outlined in the project proposal. This includes but is not limited to, demolition, construction, plumbing, electrical work, and finishing.3. Timeline- The renovation project is expected to commence on [start date] and be completed by [end date]. Any delays in the schedule must be communicated and agreed upon by both parties.4. Payment Terms- The total cost of the renovation project is [total amount], to be paid in installments as follows:- 25% of the total amount is due upon signing of the contract.- 50% of the total amount is due at the midway point of the project.- The remaining 25% is due upon completion and final inspection of the renovation.5. Change Orders- Any changes to the scope of work must be agreed upon in writing by both parties. Additional costs resulting from change orders will be documented and added to the final invoice.6. Warranty- The Contractor warrants that all work performed will be of good quality and free from defects for a period of [warranty period] from the completion date. Any issues arising during this period will be rectified by the Contractor at no additional cost to the Client.7. Termination- Either party may terminate the contract with written notice if the other party breaches any of the terms outlined in this agreement. In the event of termination, the Client will be responsible for payment of any work completed up to the termination date.8. Governing Law- This contract shall be governed by the laws of [state/country], and any disputes arising from this agreement shall be resolved through arbitration.9. Signatures- Both parties hereby acknowledge their acceptance of the terms and conditions outlined in this contract by signing below.Client Signature: ________________________ Date:______________Contractor Signature: ___________________ Date:______________This contract is effective as of the date of the last signature and supersedes any prior agreements between the parties.。

装修合同格式英文范文

Contract for Home RenovationThis Contract for Home Renovation (the "Contract") is made and entered into as of [Date], by and between [Homeowner's Name], hereinafter referred to as the "Homeowner," and [Contractor's Name], hereinafter referred to as the "Contractor."1. Scope of WorkThe Contractor agrees to perform the following renovation services for the Homeowner (the "Project"):[List the specific renovation services, including but not limited to, kitchen remodeling, bathroom renovation, painting, flooring, etc.]2. Project TimelineThe Contractor agrees to complete the Project within [Number] weeks from the start date, which shall be [Start Date]. The Contractor will make every effort to complete the Project within this timeframe, however, unforeseen circumstances may require adjustments to the timeline. In such cases, the Contractor will notify the Homeowner in advance and make necessary adjustments to the schedule.3. Payment TermsThe total cost of the Project shall be [Total Cost], which shall be paid by the Homeowner to the Contractor in accordance with the following payment schedule:[List the payment schedule, including down payment, milestone payments, and final payment upon project completion]The Homeowner agrees to make timely payments as specified in the payment schedule. Failure to make any payment by the specified deadline shall result in interest charges of [Interest Rate]% per annum on the outstanding balance, and the Contractor may suspend work until the outstanding payment is received.4. Change OrdersIf the Homeowner requests changes to the scope of work or specifications during the course of the Project, the Contractor will provide a written estimate of the additional costs or savings resulting from such changes. The Homeowner must approve any change orders in writing. Once approved, the change orders will become part of this Contract, and the payment schedule may be adjusted accordingly.5. WarrantyThe Contractor warrants that all work performed under this Contractshall be free from defects in materials and workmanship for a period of [Warranty Period]. If any defects are discovered during the warranty period, the Contractor shall repair or replace the defective materials or work at no additional cost to the Homeowner.6. Dispute ResolutionAny disputes arising out of or in connection with this Contract shall be resolved by arbitration in accordance with the rules of the [Arbitration Association]. The decision of the arbitrator(s) shall be final and binding upon the parties.7. IndemnificationThe Contractor shall indemnify and hold harmless the Homeowner against any claims, suits, losses, damages, or expenses (including attorney's fees) arising out of or resulting from the performance of theContractor's work under this Contract.8. Governing LawThis Contract shall be governed by and construed in accordance with the laws of [Jurisdiction].9. Entire AgreementThis Contract constitutes the entire agreement between the parties and supersedes all prior agreements and understandings, both written and oral, relating to the subject matter of this Contract. This Contract maybe amended or modified only by a written instrument executed by both parties.IN WITNESS WHEREOF, the parties have executed this Contract as of the date first above written.Homeowner:[Homeowner's Signature][Homeowner's Name]Contractor:[Contractor's Signature][Contractor's Name]。

室内装修设计协议（中英文）_合同范本

室内装修设计协议(中英文)室内装修设计协议AGREEMENT OF HOUSE INTERIOR DESIGNThis AGREEMENT OF INTERIOR DESIGN made this date of between A (hereinafter called "the Client" which expression includes their legal representatives, successors in title an assigns) of the one part and B practicing as design consultant at C (hereinafter ca lled “the Designer" which expression includes his/legal representatives, successors in titles and permitted assigns) of the other part.WHEREAS the Client intends to construct and complete. (hereinafter called 'the project');AND WHEREAS the Client is desirous of appointing the Designer to provide professional design services for the Project on the terms and conditions hereinafter appearingIT IS HEREBY AGREED BETWEEN THE PARTIES HERETO AS FOLLOWS:本设计协议由甲方(客户)和乙方(设计顾问)及丙方(设计公司)于日签订。

中英文装修施工合同范本

中英文装修施工合同范本Contract for Interior Decoration Project合同日期： ________________Contract Date:甲方(委托方)：______________Party A (Client):乙方(承包方)：______________Party B (Contractor):鉴于甲方委托乙方进行装修施工，双方经友好协商达成如下协议：Whereas Party A entrusts Party B to carry out the interior decoration project, both parties have reached the following agreement through friendly negotiations:一、工程内容及标准：1. Project Details and Standards:1.1 甲方委托乙方进行_________（具体工程内容）装修施工，包括但不限于房屋结构改造、墙面装饰、地面铺设、水电安装等。

Party A entrusts Party B to carry out the interior decoration project, including but not limited to structural modification, wall decoration, flooring, plumbing and electrical installation.1.2 装修工程应符合国家相关标准和规定，保证工程质量。

The decoration project shall comply with the relevant national standards and regulations, and ensure the quality of the project.二、施工期限：2. Construction Period:2.1 本合同自签订之日起生效，工程施工期限为_______天。

装修设计合同模板简单英语

装修设计合同模板简单英语Contract for Interior Design ServicesThis contract ("Agreement") is made and entered into on [Date] between [Client Name] ("Client"), and [Designer Name] ("Designer"), a professional interior designer.1. Scope of WorkThe Designer agrees to provide interior design services forthe Client's property located at [Property Address],according to the specifications and requirements outlined in the design proposal dated [Proposal Date].2. Services ProvidedThe services provided by the Designer include, but are not limited to:- Space planning and layout design.- Selection of materials, finishes, and furnishings.- Coordination with contractors and suppliers.- Project management and supervision.3. Fees and PaymentThe total fee for the services provided by the Designer is [Total Fee]. The payment schedule is as follows:- A non-refundable deposit of [Deposit Amount] is due upon signing this Agreement.- [Milestone 1 Amount] upon completion of [Milestone 1 Description].- [Milestone 2 Amount] upon completion of [Milestone 2 Description].- The balance is due upon final completion and acceptance of the project.4. Client ResponsibilitiesThe Client agrees to:- Provide access to the property for the Designer and any necessary contractors.- Make timely payments as per the schedule outlined in this Agreement.- Provide clear and timely communication regarding design preferences and decisions.5. Designer ResponsibilitiesThe Designer agrees to:- Provide professional and timely services as outlined inthis Agreement.- Communicate regularly with the Client regarding the progress of the project.- Ensure all design elements meet the Client's requirements and preferences.6. ConfidentialityBoth parties agree to keep all information related to this Agreement and the project confidential and not disclose it to any third party without the written consent of the other party.7. TerminationEither party may terminate this Agreement by giving [NoticePeriod] days written notice to the other party. In the eventof termination, the Client shall pay for all servicesrendered up to the date of termination.8. Dispute ResolutionAny disputes arising out of or related to this Agreementshall be resolved through mediation or arbitration, as agreed upon by both parties.9. Governing LawThis Agreement shall be governed by and construed in accordance with the laws of [Jurisdiction].10. Entire AgreementThis Agreement constitutes the entire agreement between the parties and supersedes all prior negotiations, understandings, or agreements, whether oral or written.IN WITNESS WHEREOF, the parties have executed this Agreementas of the date first above written.[Client Name] [Designer Name]Signature SignatureDate: [Date] Date: [Date]。