工程管理专业英语(5)
工程管理专业英语
2.2 句型
（1）为表达客观态度，常用it作为形式 主语。
专业英语多描述客观事物、现象和规律。这一特点决定了科 技人员在撰写科技文献时，要采用客观和准确的手法陈述被 描述对象的特性、规律，而不需要突出人。
例4、It is important to study the possibility of using SCM to improve the performance of construction enterprises, especially their environmental performance.
应该尽可能简洁，避免不必要的修饰和重复
例2、The yield criterion for a material is a mathematical description of the combinations of stresses which would cause yield of the material.In other words it is a relationship between applied stresses and strength.
其他常用的省略形式：
As already discussed 前已讨论 As explained before 前已解释
If so 倘若如此 As previously mentioned 前已提到 When needed (necessary, feasible)必要
As described above 如上所示
2 Features of Specialized English
专业英语的特点
2.1 措辞
措辞要准确、简洁、清楚 客观性（Objective）、准确性（accuracy）和精练性(conciseness)。
工程管理专业英语第二版第四章课后答案
目录1、本细则编写依据2、专业工程特点3、监理工作的流程如下：4、监理工作的方法5、监理土建质量控制目标、控制要点及措施5.1 钢筋工程监理要点及措施5.2 模板工程监理要点及措施5.3 砼浇筑工程监理要点及措施5.4 大体积砼施工监理要点及措施5.5、深基坑支护监控要点5.6 地下室工程监理工程要点5.7 砌体工程监理要点及措施楼地面工程监理要点及措施5.8 建筑装饰装修工程监控要点5.8.1 材料5.8.2 施工5.8.3 抹灰工程5.8.4 吊顶工程5.8.5 轻质隔墙工程5.8.6 饰面板（砖）工程5.9 屋面工程监控要点土建工程监理实施细则1、本细则编写依据1.1工程建设方面的法律、法规1.1.1《中华人民共和国建筑法》1.1.2《建设工程质量管例条例》1.1.3《建设工程安全生产管理条例》1.1.4《中华人民共和国合同法》1.2 部分有关技术标准1.2.1.1《建设工程监理规范》GB/T50319-2013；1.2.1.2《建筑工程施工质量验收统一标准》GB50300-2001；1.2.1.3《建筑地基基础工程施工质量验收规范》GB50202-2002；1.2.1.4《建筑地面工程施工质量验收规范》GB50209-2002；；1.2.1.5《建筑装饰装修工程质量验收规范》GB50210-2001;1.2.1.6《砌体工程施工质量验收规范》GB50203-2002；1.2.1.7《钢筋焊接及验收规范》JGJ18-2003；1.2.1.8《混凝土结构工程施工质量验收规范》GB50204-2002；1.2.1.9《屋面工程质量验收规范》GB50207-2002；2、专业工程特点1.1建筑层数：本建筑物地下室为两层，地上一栋为20层楼，为18层写字楼，裙房为2层。
1.2.建筑高度：为81.9m；1.3.结构特征：本工程是一个集商业、办公为一体的高层建筑,结构体系为钢筋混凝土框架－剪力墙核心筒基本是剪力墙。
工程管理专业英语词汇
1、Construction industry 建筑业2、High-rise apartments 高层公寓3、Institution and commercial building construction 办公和商业用房建设4、Oligopoly 垄断，供过于求5、Specialized industrial construction 专业化工业项目建设6、Infrastructure and heavy construction 重大基础项目建设7、Residential housing construction 住宅类房屋建设8、Take charge 负责9、Single-family house 独户住宅10、Professional consultant 专业征询人士11、General contractor 总承包商12、Mission-oriented 以目的（任务）为导向的13、Continuity 连续性14、Indispensable 不可或缺的15、Common-place 常见的16、Schedule 进度17、Maximization 最大化18、Communication 沟通19、Certification 认证20、Distinguish 区别，区分21、Predetermined 预定的22、Ingredient 组成部分，成分23、Linear programming 线性规划24、Trade off 均衡，权衡25、Delineation 叙述，说明26、Utilization 使用27、Integration 综合，整合28、Shop drawings 施工图，安装图29、Simultaneously 同时的30、Prebid site 投标前现场31、Nominated subcontractor 指定分包商32、Prequalified 预审合格33、An manual of professional practice 专业人员从业手册34、Risk-reward 风险和回报35、Structural design 结构设计36、Specialized subcontractor 专业分包商37、Work package 工作包38、Construction planning 施工计划39、Technical feasibility 技术可行性40、Construction operations 施工作业41、Structural or foundation details 结构或基础的具体情况42、Ingenuity and creativity 灵活性和发明性43、Construction constractors 施工承包商44、Monitoring and control 监督和控制45、Facility design 设施设计46、Estimate stage 估算阶段47、Evaluation stage 评估阶段48、equity partners 股权伙伴49. 、specifications and drawings 技术规范和图纸50.、Placing concrete on site 现场浇混凝土1、Job-site productivity 工地生产率2、Contractual agreements 协议3、Safety consciousness 安全意识4、Labor productivity 劳动生产率5、Foreign operations 国外施工6、Labor efficiency 劳动效率7、Infrastructure 基础设施8、Linear interpolation 线性内插9、Labor jurisdictions 劳动仲裁10、Non-productive activities 非生产性活动11、On-site 现场12、Labor characteristics 劳动力的特性13、Security sensitivity 安全敏感性14、Recognized strength 公认的实力15、Processing plant 加工厂16、Logistic problems 后勤问题17、Drilling platform 钻井平台18、Building construction 建筑施工19、Material procurement and delivery 材料采购和运送20、Bulk materials 大宗材料21、Overlapping and rehandling 搭接和再解决22、Semi-processed 半加工的，半成品的23、Concrete mix 混凝土拌和物24、Steel beams and columns 钢梁和柱25、. bills of quantity 工程量清单26、. minutes of the conference 会议纪要27、the lowest evaluated cost 经评审的最低造价28、reimbursable expenses 可补偿费用29、.Hierarchical structure 层级结构30、Critical path scheduling 关键线路进度控制程序31、.bonus and penalty clauses 奖励和处罚条款32、lump-sum agreement 总价协议33、.written authorization 书面授权34、unit-price agreement 单价协议35、Bids and quotations 投标和报价36、Off-the-shelf material 现货材料37、Earthwork to be excavated 土方开挖38 .general procurement notice 通用采购公告39、. conditions of contract 协议条件40、Construction supervision 施工监督41、Freight delivery 货品运送44、Slippage or contraction 延误或提前45、.Marginal efficiency of capital 边际资本收益46、.Equivalent uniform annunual net value 等额净年值47、changes clause 变更条款49、prequalification 资格预审49、limited international bidd ing 有限国际招标50、Unit Cost of Estimetion 单位估价1、Cost estimation 成本估算2、Cost engineering 工程估价3、Profitability 赢利4、Production function 生产函数5、Statistical inference 记录推断6、Construction equipment 施工机具7、General office overhead 总部管理费8、The cost engineer or estimator 估算师9、Cost control 成本控制10、Empirical cost inference 经验成本推论法11、Allocation of joint costs 综合成本的分摊12、Bill of quantities 工程量清单2、Cooling system 冷却系统3、Heat exchanger 热互换器4、Slabs and beams 楼板和梁5、Furnaces 锅炉6、Plus ancillary items 辅助设备7、Formwork 模板8、Detailed Estimates 具体估算9、Preliminary Estimates 具体估算10、Subcontractor Quotations 分包报价11、Construction Procedures 施工方法12、Factored Estimate Formula 系数估算公式13、Reinforcing bars 钢筋14、Building foundation 建筑物基础1、Economic evaluation 经济评价2、Sensitivity 灵敏度3、Planning horizon 规划周期4、Project alternative 备择项目5、Opportunity cost 机会成本6、Financial investment 金融投资7、Minium attractive rate of return 最低收益率8、Social rate discount 社会折现率9、Investment consideration 投资分析10、Decision maker 决策者11、Cash flow profile 钞票流分布形态12、Net annual cash flow 年净钞票流13、Capital project 资本项目14、Socially desirable programs 社会公益项目15、The Office of Management and Budget 财政部门16、Government agency 政府部门17、linear programming线性规划18、network analysis 网络分析19、Under ordinary circumstances, 在通常情况下20、best price/performance characteristics最优性价比特性21、an acceptable quality levelallowable可接受的质量水平22、a allowable fraction of defective items.可接受的缺陷比例23、ill structured棘手的24、critical ingredients关键因素25、identified as被看作为26、the rate of return资本回收率 cash flow 净钞票流量28.financing options 融资方式29.project finance 项目融资30.negative cash balance 负钞票结余31.profit measure 利润指标值32.private corporations 私营股份制公司33.Public agencies 公告机构34 instructions to bidders 投标人须知35 . conditions of contract协议条件36.Equivalent uniform annunual net value 等额净年值37.Capital recovory factor 资金回收因子38.Benefit cost ratio 收益费用比39.Profitability index 赚钱指数40. prequalification 资格预审41. bidding documents 招标文献42. domestic contractor 国内承包商43.Marginal efficiency of capital 边际资本收益44.Adjusted internal rate of capital 调整后的内部收益率45.Return on investment 投资收益46. international competitive bidd ing 竞争性国际招标47limited international bidd ing 有限国际招标48.national competitive bidd ing 国内竞争性招标49 .general procurement notice 通用采购公告50 substantially responsive 实质性响应1. changes 工程变更2. contract awards 协议授予3.changes clause 变更条款4.publicly financed priject 公共项目融资5.extra work 附加工作6.the prime contractor 主承包商7. pre-construction sercices 施工前服务8.reimbursable expenses 可补偿费用9. overhead and profit 管理费和利润10.Construction planning 施工计划11. chioce of technology 施工技术的选择12.The definition of work tasks 工作任务的定义13.Normative problem 规范性问题14.Cost control 成本控制15.Schedule control 进度控制16.Critical path scheduling procedure关键线路进度控制程序17.Job shop scheduling procedure 工作现场进度控制程序18.Datebases and information systes m 数据库和信息系统19.The duration of the activity 工作活动的连续时间20.Placing concrete on site 现场浇筑混凝土21 Placing forms 支设模版22. Installing reinforcing steel 绑扎钢筋23. Pouring concrete 浇筑混凝土24.Finishing the concrete 混凝土养护25. Removing forms 模版拆除26.Position forms on the cleanning station 在清理场合码放模版27. Hierarchical structure 层级结构28.fixed fee 固定费用29.overhead and profit 管理费和利润30.job shop scheduling procedure 现场进度控制程序31.change order 变更单32.cost –plus-fee agreement成本加费用协议33.quantity takeoff 工程量清单34. prequalification 资格预审35、decomposed into 分解为36.From the viewpoint of从某个角度看37.responsible for 对某事负责38.superior to 优于。
工程管理专业英语徐勇戈课第二版后答案
专业英语Unit1第一题1.设计/施工过程Design and construction process2.房地产开发商Real estate developer3.投机性住宅市场Speculative housing market4.项目管理Project management5.项目全寿命期Project life cycle6.项目范围Scope of a project/project scope7.专业化服务Professional services8.重大基础项目建设Construction of major infrastructure projects9.住宅类房屋建设Residential housing construction10.办公和商业用房建设office and commercial building construction11.专业化工业项目建设Specialized industrial projects construction12.专业咨询师Professional consultants13.总承包商Original contractor14.价值工程value engineering15.竞争性招标Competitive bidding16.建筑和工程设计公司Architectural and engineering design company17.运营与维护管理operation and maintenance18.设计/施工公司design and construction company19.分包商subcontractor20.设施管理facility management第一章1、从项目管理的角度看，“业主”和“发起方”是同义的，因为两者的基本权力是制定所有重大决策。
2、项目范围界定后，详细的工程设计将提供建设蓝图，最终费用估计将作为控制成本的基准。
工程管理专业英语试题(含答案)
《工程管理专业英语》期末试题1一、词汇汉译英1.Project scheduling：项目企划2.individual project：单项工程3.framed structure：框架结构4.buckling：弯曲、翘曲5.foundation settlement：基础沉降6.line of action and the sense of the force：力的作用线和力的指向7.statically indeterminate structure：超静定结构8.Rate of expansion：伸长率9.Simulation: 仿真10.Relative height：相对高度（高差）11.Pavement：人行道12.Bulldozer：推土机13.Dummy：虚工序14.Withdrawal：撤回二、词汇汉译英1.钢筋混凝土：reinforced concrete2.抗压强度：compression strength3.恒载：dead loads4.总承包商：general contractors5.预算：budget6.承重墙：bearing wall7.规范、说明书：specification8.水平荷载：vertical load9.流动资金：working capital10.合同管理：contract management11.工程量清单：bill of quantities12.垫层砂浆：bedding mortar13.刚度：rigidity三、典型句子英译汉1、All these loads depend largely on the location of the building, have to be taken by the structural system from all points and manners of application and transferred to the foundations.所有这些荷载，在很大程度上取决于建筑物的位置，这些荷载由结构体系从各个点以各种作用方式传递到基础。
工程管理专业英语翻译
passge1project management perspective关键步骤在任何项目的第一步，这是了解项目的目标，和项目团队成员沟通，考虑项目替代办法在投入项目工作之前。
在项目投入工作之前坐下来讨论是非常重要的。
项目经理需要沿学习曲线的项目非常快。
为此本项目经理应争取尽可能多的信息，关于该项目的客户。
客户端可以是高层管理人员也可以是其他职能领域的者.在某些情况下，项目的客户是项目管理本身在确定了项目并获得批准的项目从最高管理。
在建筑公司的客户是一个组织以外的建筑公司.项目管理需要详细讨论具体的项目目标，把它写下来，经工程用户学习一切有了解的项目，特别是在qriteria成功，预计的预算和进度.来，作为关键的决定或出现问题或机会，开发，项目经理需要仔细考虑谁是客户端和检查客户的关键决定.首先，审批进行项目已获批准，项目经理可以通过一个清单和收集项目信息。
项目经理早就被要求作出若干决定的宝贵投入的项目团队成员。
其中有些决定是什么目标完成日期的项目；项目的预算；在资源来；项目团队成员谁会和谁将开发计划的项目或提供系统支持，等等。
项目经理在形成阶段输入所获得的信息，将是有价值的，在作出这些早期决定。
项目经理应确定的复杂性，规模和独特的项目。
所有这些方面的影响，例如，对一些项目团队成员，他们将，预算，和时间表。
过程中的信息收集，转氨酶开始的项目，该项目经理面试关键职能管理人员谁预计贷款项目团队成员对这个项目。
项目经理应沟通的事实，最高管理者批准的计划，并获得批准的职能经理谁将提供资源进行项目，特别是那些谁将提供人力资源。
不确定性是一个元素开始，每一个项目的预设。
有时，这是目前在更大的程度比其他人。
它是特别普遍在项目是独一无二的，因为没有类似的东西已完成的项目管理，不确定性也是目前在很大程度上这是第一个项目由项目经理或，更因此，如果它的第一个项目所进行的组织的项目管理部。
前面提到的清单，和额外的努力，该项目获得以信息尽可能早期，可以穿过这个杠杆的不确定性和模糊性。
工程管理专业英语(英文版)一、建设项目的主要类型
The residential housing market is heavily affected by general economic conditions, tax laws, and the monetary and fiscal policies of the government. Often, a slight increase in total demand will cause a substantial investment in construction, since many housing projects can be started at different locations by different individuals and developers at the same time. Because of the relative ease of entry, at least at the lower end of the market, many new builders are attracted to the residential housing construction. Hence, this market is highly competitive, with potentially high risks as well as high rewards.
批注本地保存成功开通会员云端永久保存去开通
Unit one Major Types of Construction
Since most owners are generally interested in acquiring only a specific type of constructed facility, they should be aware of the common industrial practices for the type of construction pertinent to them. Likewise, the construction industry is a conglomeration of quite diverse segments and products. Some owners may procure a constructed facility only once in a long while and tend to look for short term advantages.
工程项目管理专业英语
Engineering projects are complex endeavors that require meticulous planning, execution, and control to ensure successful completion. As the world becomes increasingly globalized, the need for professionals whocan effectively communicate and manage engineering projects in Englishis paramount. This article aims to provide an overview of key terms, concepts, and practices in engineering project management, translatedinto professional English, to help professionals navigate this fieldwith confidence.Key Terms and Definitions:1. Project Management (PM): The application of knowledge, skills, tools, and techniques to project activities to meet the project requirements.It involves the integration of all project elements to achieve theproject objectives within the agreed constraints.2. Project Manager (PM): The individual responsible for leading the project team and ensuring the successful completion of the projectwithin the defined scope, schedule, and budget.3. Project Scope: The defined and documented deliverables of the project, including the work to be performed and the results to be achieved.4. Project Schedule: A document that defines the project's timeline, including start and end dates for activities, milestones, and thecritical path.5. Project Budget: The financial resources allocated to the project, including costs for labor, materials, equipment, and other expenses.Key Concepts and Practices:1. Project Planning: The process of defining the project's objectives, scope, and deliverables, and developing a detailed plan to achieve them. This includes identifying project stakeholders, defining project tasks, estimating resources, and establishing a project schedule.2. Risk Management: The process of identifying, analyzing, and responding to risks that may affect the project. This involvesidentifying potential risks, assessing their impact and likelihood, and developing strategies to mitigate or avoid them.3. Quality Management: The process of ensuring that the project deliverables meet the required quality standards. This includes establishing quality policies, planning quality activities, and implementing quality control measures.4. Change Management: The process of managing changes to the project scope, schedule, or budget. This involves assessing the impact of changes, obtaining approval for changes, and updating project documentation accordingly.5. Configuration Management (CM): The process of identifying, organizing, and controlling modifications made to the project deliverables. CM ensures that the project's configuration items are properly documented, tracked, and managed throughout the project lifecycle.Practical Examples:1. Project Change Request (PCR): A formal document submitted by aproject stakeholder requesting a change to the project scope, schedule, or budget. The project manager must assess the impact of the change and obtain approval from relevant stakeholders before implementing it.2. Feasibility Analysis: A study conducted to determine whether aproject is technically, economically, and operationally feasible. This analysis helps project managers make informed decisions about whether to proceed with the project.3. Project Management Office (PMO): A centralized office within an organization responsible for overseeing the management of projects. The PMO provides support to project managers and ensures that projects are aligned with the organization's strategic objectives.In conclusion, engineering project management is a dynamic and challenging field that requires a strong command of professional English. By understanding key terms, concepts, and practices, professionals caneffectively communicate and manage engineering projects, contributing to their success and the success of their organizations.。
(完整版)工程管理专业英语词汇短语
Part1market demand 市场需求facility 设施the speculative housing market 投机性住宅市场the real estate developer 房地产开发商government agency 政府机构public project 公共项目project management 项目管理the conceptual planning stage 概念规划阶段feasibility 可行性in-house 内部的，内业的the project life cycle 项目生命周期from cradle to grave 从开始到结束knowledge domain 知识领域construction industry 建筑业spectrum 波普，光谱，范围residential housing construction 房屋住宅建设subcontractor 分包商institutional and commercial building construction 办公与商业用房建设specialized industrial construction 专业化工业项目建设infrastructure and heavy construction 重大基础项目建设architectural and engineering(A/E)firm 建筑与工程设计公司consortium 财团，株式会社preliminary design 初步设计general contractor 总承包商on site quality inspection 现场质量监督litigation 法律诉讼shop drawings 施工图constructability 可建造性，可施工性value engineering 价值工程construction contract 施工合同design/construct firm 设计、施工公司turnkey 交钥匙（承发包）模式facility maintenance 设施维护Part2project integration management 项目综合管project scope management 项目范围管理project time management 项目时间管理project cost management 项目成本管理project quality management 项目质量管理project human resource management 项目人力资源管理project communications management 项目沟通管理project risk management 项目风险管理project procurement management 项目采购管理contractual relationships 合同关系changes 工程变更claims 施工索赔mega-projects 巨型项目“functional”organization “职能式”组织“project”organization “项目式”组织suborganizations 次级组织strong matrix-type suborganization 强矩阵式次级组织interpersonal influence 人际间影响力formal authority 正式的授权reward and/or penalty power 奖励和/或惩罚的权利matrix organization 矩阵式组织hierarchical structure 层级结构Part3job-site productivity 工作现场生产率non-productive activities 非生产性工作temporary work stoppage 临时性工作暂停union activities 工作活动performance analysis 绩效分析base labor productivity 基准劳动生产率labor productivity index 劳动力生产指数non-local labor 非当地用工productive labor yield 劳动力产出requisitions 询价purchase orders 订购单subcontracts 分包合同shipping and receiving documents 装船与接收文件invoices 发票bulk materials 大众材料standard off-the-shelf materials 现货材料fabricated members or units 预制构件或单元semi-processed state 半成品状态pre-processed 预加工的pressure vessels 压力容器field assembly 现场装配skilled craftsmen 熟练技工crawler mounting 履带式底盘claim shell 抓铲挖土机`dragline 拉铲挖土机backhoe 反铲挖土机shovel 正铲挖土机bulldozer 推土机rotary-percussion drills 旋转冲击钻bituminous 沥青Part4economic evaluation 经济评价the planning horizon 规划期cash flow profile 现金流量图minimum attractive rate of return(MARR) 最低收益率sensitivity or uncertainty analysis 敏感性或不确定性分析annual benefit 年收益annual cost 年费用net annual cash flow 年净现金流量opportunity cost 机会成本social rate of discount 社会贴现率profit measure利润指标值private corporations 私营股份制公司public agencies 公共机构net future value(NFV) /净终值net present value(NPV) 净现值equivalent uniform annual net value (NUV)等额净年值capital recovery factor 资金回收因子benefit-cost ratio(BCR) 收益-费用比profitability index 盈利指数saving-to-investment ratio(SIR) 存款投资比率absolute numerical measure 绝对指数internal rate of return(IRR) 内部收益率marginal efficiency of capital 边际资本收益return on investment(ROI) 投资收益payback period(PBP) 投资回收期profit maximization利润最大化public sector 公共领域basic principle 基本原理nonnegative 非负的budget constraint 预算限制incremental analysis 追加分析internal rate of return method 内部收益率法Part5Word Bank-financed projects 世界银行融资贷款项目foreign bidders 海外投标人civil works 土木工程I nternational Competitive Bidding(ICB) 竞争性国际招标Limited International Bidding 有限国际招标National Competitive Bidding 国内竞争性招标International Shopping 国际订购Direct Contracting 直接签约General Procurement Notice 通用采购公告prequalification 资格预审bidding documents 招标文件domestic contractors 国内承包商instructions to bidders 投标人须知conditions of contract 合同条件specifications of drawings 技术规范与图纸bill of quantities 工程量清单payment terms 支付条件minutes of the conference 会议纪要pre-bid conferences 标前会议site visits 现场踏勘substantially responsive 实质性响应the lowest evaluated cost 经评审的最低造价Part6the sealed bids 密封的投标报价construction company 建筑公司marketing strategy 市场营销策略long-term goals 长期目标client relationships 客户关系short-term goal 短期目标direct costs estimate 直接费估算mark-up 涨价溢价company or head office overheads 公司或总部管理费unrealistic bids 不切实际的报价owner-contractor agreement 业主与承包商之间订立的合同standard form of agreement 标准合同形式American Institute of Architects(AIA) 美国建筑师协会bonus and penalty clauses 奖励与惩罚条款lump-sum agreement 总价合同changer order 变更单written authorization 书面授权unit-price agreement 单价合同quantity takeoff 工程量清单cost-plus-fee agreements 成本加酬金合同equity partners 股权伙伴rental rates 出租比例percentage fee 百分百酬金合同fixed fee 固定酬金合同changes 工程变更contract award 合同授予changes clause 变更条款publicly financed project 公共融资项目extra work 附加工作the prime contractor 主承包商Part7the International Federation of Consulting Engineering 国际咨询师联合会the FIDIC Conditions of Contract for Constructions FIDIC施工合同条件the General Conditions （FIDIC）通用条件the Particular Conditions （FIDIC）专业条件the Appendix to Tender （FIDIC）投标附录arbitration 仲裁，裁决Dispute Adjudication Board（DBA）争议仲裁委员会Conditions of Contract for Works of Civil Engineering Construction 土木工程施工合同条件Conditions of Contract for Electrical and Mechanical Work 机电安装工程合同条件Conditions of Contract for Design-Build and Turnkey设计-建造于交钥匙合同条件Client/Consultant Model Services Agreement 客户/咨询师服务协议Conditions of Subcontract for Works of Civil Engineering Construction 土木工程分包合同条件Guides to the Use of the Different FIDIC Conditions of Contract 各种FIDIC合同条件应用指南Amicable Settlement of Construction Disputes 施工争端友好解决方式Insurance of Large Civil Engineering Projects 大型土木工程保险The Conditions of Contract for Plant and Design-Build （FIDIC）安装与设计-建造合同The Conditions of Contract for EPC/Turnkey Projects （FIDIC）EPC/交钥匙项目合同条件The Short Form of Contract （FIDIC）简短格式合同The Form of Contract for Dredging and Reclamation Works （FIDIC）疏浚与防洪工程合同格式priced contract with activity schedule 总价合同priced contract with bill of quantities 单价合同target contract with activity schedule 目标总价合同target contract with bill of quantities 目标单价合同cost reimbursable contract 成本补偿合同performance bond 履约保函parent company guarantee 母公司担保advance payment 预付款retention （工程)留置权bonus for early completion 工期提前奖delays damages 误期损害surety 担保financial loan 商业贷款insurance policy 保险政策in breach of contract 合同违约bid bond 投标担保justification （正当的）理由labor and material bond 劳动力与原材料担保lien bond 留置权担保comprehensive general liability insurance 综合责任险professional liability insurance职业责任险workers’compensation insurance 工人补偿险builder’s risk fire insurance 施工方火灾险Part8construction planning 施工计划the choice of technology 施工技术的选择the definition of work tasks 工作任务的定义the estimation of the required resources and durations for individual tasks 所需资源和各项工作持续时间的估算reasoning backward 逆向推理normative problem 规范性问题cost control 成本控制schedule control 进度控制critical path scheduling procedures 关键线路进度控制程序job shop scheduling procedures 工作现场进度控制程序work breakdown 工作分解manufacturing terminology加工制造业术语resource allocations 资源分配fore-runner 先行者laborious and tedious process 复杂和枯燥的过程general models 通用模型databases and information systems 数据库和信息系统the storage and recall of the activities工作活动的存储于记忆manpower 人力，劳动力the duration of the activity 工作活动的持续时间placing concrete on site 现场浇筑混凝土placing forms 支设模板installing reinforcing steel 绑扎钢筋pouring concrete 浇筑混凝土finishing the concrete 混凝土养护removing forms 模板拆除position forms on the cleaning station 在清理场所码放的模板hierarchical structure 层级结构work breakdown structure 工作结构分解precedence relations 先导顺序关系structural integrity结构整体性design drawings 设计图纸milestone events 里程碑事件lag 时间间隔computer based simulation 基于计算机的模拟excavation equipment 开挖机械\Part9critical path method(CPM) 关键路线发predecessor/successor activities先导/后续工作resource constraint 资源约束artificial precedence constraint 人为先导关系约束activity-branch network 双代号网络图dummy activity 虚工作earliest time schedule 最早时间进度latest time schedule 最迟时间进度float 时差，机动时间maneuvering room 可调整的余地free float 自由时差independent float 独立时差total float 总时差inter-relationships 相互关系graphical presentations of project schedules 项目进度的图形表达network diagrams 网络图time-scaled network 时标网络bar or Gantt chart 横道或甘特图horizontal axis 横轴，横坐标vertical axis 纵轴，纵坐标S-curves S型曲线resource graphs 资源图uncertainty associated with the actual durations与实际持续时间相关的不确定性regulatory approval 行政许可adverse weather 不利的天气contingency allowance 应急准备probabilistic perspective概率的角度independent random variables 相互独立的随机变量random fluctuations 随机波动positive correlations正相关over-optimistic 过于乐观的Part10e-construction 工程返工personal injuries 人身伤害conformance 遵守，服从re-evaluation of design decisions设计决策的重要评估tunneling methods 隧道开掘方法actual site conditions 现场的实际状况roadway rehabilitation 公路路面返修quality assurance 质量保证n-site inspections 现场监督检查US Occupational Safety and Health Administration（OSHA）美国职业安全与健康署violation of existing standard 违反现行规范标准employee participation in quality control 质量控制的员工参与statistical methods 统计方法batches of materials 材料批implicit assumption 隐含的假设total quality control 全面质量控制zero defects goal 零缺陷目标quality circles 质量环“optimum”proportion “最佳”的比例non-destructive techniques 非破坏性技术x-ray inspection of welds 焊接的X光检测exhaustive or 100% testing 全数或100%检测lot 母体，总体sampling by attributes 特征抽样sampling by variables 变量抽样direct costs 直接成本indirect costs 间接成本construction accidents 工程事故insurance premiums 保险赔偿unsecured railings 未经保护的围栏on-board electronics面板电子元器件asbestosis 矽肺，石棉肺sewer line 排污管道four lane street 四车道道路Part11construction yard and warehouse management information 施工仓储管理信息concrete pumps 混凝土泵warehouse clerks 仓储管理员daily rental charge 日租金tedious manual task 繁琐的手工作业application programs 应用程序duplicate 复制verbal description 文字描述warehouse inventory database 仓储清单数据库relational data model 关系数据模型data dictionary 数据字典numerical code 数据编码redundancy 冗余aggregate 集料，骨料external models of the information 外部信息模型algebraic theory 代数理论projection 映射advantages of distributed processing 分散式处理的优点dynamic changes in information needs 信息需求的动态变化untidy information 凌乱的信息information flow 信息流preprocessor system 预处理系统independent systems 独立系统geometric information 图形信息。
工程管理专业英语宁欣 吴春林课后题答案
工程管理专业英语宁欣吴春林课后题答案1、In 2019 we moved to Boston,（）my grandparents are living. [单选题] *A. whoB. whenC. where(正确答案)D. for which2、Last week they _______ in climbing the Yuelu Mountain. [单选题] *A. succeeded(正确答案)B. succeedC. successD. successful3、Jim, we have _______ important to tell you right now . [单选题] *A. someB. something(正确答案)C. anyD. anything4、--Henry treats his secretary badly.--Yes. He seems to think that she is the _______ important person in the office. [单选题] *A. littleB. least(正确答案)C. lessD. most5、Don’t talk _______. Your grandmother is sleeping now. [单选题] *A. happilyB. nearlyC. loudly(正确答案)D. hardly6、John will go home as soon as he _______ his work. [单选题] *A. finishB. will finishC. finishedD. finishes(正确答案)7、If you want to be successful one day, you have to seize every _______ to realize your dream. [单选题] *A. changeB. chance(正确答案)C. chairD. check8、He usually ________ at 6:30 a.m. [单选题] *A. gets toB. gets up(正确答案)C. gets overD. gets in9、—_____ will the bus arrive? —In four minutes. [单选题] *A. How longB. How oftenC. How soon(正确答案)D. How far10、The huntsman caught only a（）of the deer before it ran into the woods. [单选题] *A. gazeB. glareC. glimpse(正确答案)D. stare11、Two（）in our school were sent to a remote village to teach for a month. [单选题] *A. women teachers(正确答案)B. woman teachersC. women teacherD. woman teacher12、I don’t know how to improve my English. Can I ask you for some _______? [单选题] *A. answersB. advice(正确答案)C. questionsD. words13、The commander said that two _____ would be sent to the Iraqi front line the next day. [单选题] *A. women's doctorB. women doctorsC. women's doctorsD. women doctor(正确答案)14、The manager was quite satisfied with his job. [单选题] *A. 担心的B. 满意的(正确答案)C. 高兴的D. 放心的15、12．Who will ________ the Palace Museum after Shan Jixiang retires? [单选题] * A．in chargeB．in charge ofC．be in charge of (正确答案)D．be in the charge of16、Medicines are to be taken according to the doctor’s advice. [单选题] *A. 发放B. 提取C. 配方D. 服用(正确答案)17、Whatever difficulties you have, you should not _______ your hope. [单选题] *A. give inB. give outC. give up(正确答案)D. give back18、He doesn’t feel well. He has a _______ nose. [单选题] *A. runingB. rainingC. runny(正确答案)D. rainy19、If by any chance someone comes to see me, ask him to leave a _____. [单选题] *A. message(正确答案)B. letterC. sentenceD. notice20、The scenery is so beautiful. Let’s _______. [单选题] *A. take photos(正确答案)B. take mapsC. take busD. take exams21、Every morning John takes a（）to his office. [单选题] *A. 20-minutes' walkB. 20 minute ' walkC. 20-minutes walkD. 20-minute walk(正确答案)22、They might have found a better hotel if they _________ a few more kilometers. [单选题]*A. droveB. would driveC. were to driveD. had driven(正确答案)23、( ) .Would you please ______me the gifts from your friends? [单选题] *A.to showB. showingC. show(正确答案)D. shown24、58．—How much is Lucy's skirt?—She________320 yuan for it. I think it's a little dear. [单选题] *A．tookB．paid(正确答案)C．spentD．bought25、They will hold the party if they _____ the project on time. [单选题] *A. will completeB. complete(正确答案)C．completedD. had completed26、The bookshop is far away. You’d better _______. [单选题] *A. by the busB. by busC. take busD. take?the bus(正确答案)27、While they were in discussion, their manager came in by chance. [单选题] *A. 抓住时机C. 碰巧(正确答案)D. 及时28、My father?is _______ flowers. [单选题] *A. busy watering(正确答案)B. busy waterC. busy with wateringD. busy with water29、_________ we don't stop climate change, many animals and plants in the world will be gone. [单选题] *A.AlthoughB.WhileC.If(正确答案)D.Until30、21 In a few years' time, there ________ thousands of trees on the hill. [单选题] *A．will haveB．will be(正确答案)C．are have。
工程管理专业英语相关翻译
1.1T he Project Life Cycle1段：Project managers or the organization can divide projects into phases to provide better management control with appropriate links to the ongoing operations of the performing organization. Collectively, these phases are known as the project life cycle. Many organizations identify a specific set of life cycles for use on all of their projects.项目经理或组织可以把每一个项目划分成若干个阶段，以便有效地进行管理控制，并与实施该项目组织的日常运作联系起来。
这些项目阶段合在一起称为项目生命期。
许多组织识别出一套具体的生命期供其所有的项目使用。
2段：For example, from the perspective of an owner, the project life cycle for a constructed facility may be illustrated schematically in Figure1-1.从业主的角度来看，建设项目的生命周期可用图1-1表示。
Essentially, a project is conceived to meet market demands or needs in a timely fashion.从本质上讲，一个项目试图及时满足市场需求。
in a timely fashion. 及时meet market demands or needs 满足市场需求Various possibilities may be considered in the conceptual planning stage, and the technological and economic feasibility of each alternative will be assessed and compared in order to select the best possible project.在项目规划阶段，很多不同的方案都可能被考虑，同事每一天备选方案的技术可行性都经过评估和比较，以选出最优方案。
工程管理专业英语
《工程管理专业英语》教学大纲开课学院：建筑工程学院Begin College:Construction Engineering College适用专业：工程管理Applicable to Professional:Engineering Management课程编号：Course Number:课程英文名称：Engineering ManagementEnglish Course Title：Engineering Management课程性质：学科基础课Course property：Discipline Basic Courses课程总课时：32Course Total Class：32学分：2Credit：2课程教学目标与基本要求：通过本课程的学习，使学生了解土木工程专业的培养目标、行业发展、主要的科学问题和解决的方法、课程之间的联系、专业学习的特点、毕业后的去向等情况。
能够为学生选修课程和将来的工作提供参考。
The teaching goal and the basic requirements：Through learning of this course, make students understand the civil engineering professional training target, industry development, the main scientific problems and the solution method, the connection between the course and the characteristics of professional learning, go after graduation, and so on and so forth.Courses for students and working to provide the reference for the future.教学内容Content of courses 教学要求Teaching requirement教学模式Modelteaching课时分配（建议）Teachinghours第一部分工程概述1.工程的概念2.工程的作用3.我国古代工程4.我国现代工程The first part Project overview1.The concept of the engineering;2.The role of engineering;3. Ancient China engineering ;4.Modern engineering in our country. 了解工程的概念；了解工程的作用；了解我国古代工程。
工程管理专业英语
目录Unit One About Engineering Economy第一单元关于工程经济Unit Two The Principles of Engineering Economy第二单元工程经济原理Unit Three Cost Concept第三单元成本概念Unit Four Time Value of Money第四单元金钱的时间价值Unit Five The Basic Methods of Engineering Economy 第五单元工程经济的基本方法Unit Six The Definition of a “Project”第六单元项目的定义Unit Seven Why Project Management?第七单元为什么要对项目进行管理？Unit Eight The Project Life Cycle第八单元项目的寿命周期Unit Nine The Project Manager第九单元项目经理Unit Ten Project Planning第十单元制订项目计划Unit Eleven Initial Project Coordination第十一单元开始的项目协调Unit Twelve Budgeting and Cost Estimation第十二单元预算和成本估算Unit Thirteen The Monitoring System of Project第十三单元项目监测系统Unit Fourteen Project Control第十四单元项目控制Unit Fifteen Conditions of Contract for Construction(Excerpts)第十五单元施工合同条件（节选）Unit One About Engineering EconomyEngineering economy——what is it, and why is it important? The initial reaction of many engineering students to these questions is “Money matters will be handled by someone else. It is not something I need to worry about.” In reality, any engineering project must be not only physically realizable, but also economically affordable. For example, a child's tricycle could be built with an aluminum frame or a composite frame. Some may argue that because the composite frame will be stronger and lighter, it is a better choice. However, there is not much of a market for thousand dollar tricycles! One might suggest that this argument is ridiculously simplistic and that common sense would dictate choosing aluminum for the framing material. Although the scenario is an exaggeration, it reinforces the idea that the economic factors of a design weigh heavily in the design process, and that engineering economy is an integral part of that process, regardless of the engineering discipline. Engineering, without economy, makes no sense at all.In broad terms, for an engineering design to be successful, it must be technically sound and produce benefits. These benefits must exceed the costs associated with the design in order for the design to enhance net value. The field of engineering economy is concerned with the systematic evaluation of the benefits and costs of projects involving engineering design and analysis. In other words, engineering economy quantifies the benefits and costs associated with engineering projects to determine whether they make (or save) enough money to warrant their capital investments. Thus, engineering economy requires the application of engineering design and analysis principles to provide goods and services that satisfy the consumer at an affordable cost. As we shall see, engineering economy is as relevant to the design engineer who considers material selection as it is to the chief executive officer whoapproves capital expenditures for new ventures.The technological and social environments in which we live continue to change at a rapid rate. In recent decades, advances in science and engineering have made space travel possible, transformed our transportation systems, revolutionized the practice of medicine, and miniaturized electronic circuits so that a computer can be placed on a semiconductor chip. The list of such achievements seems almost endless. In your science and engineering courses, you will learn about some of the physical laws that underlie these accomplishments.The utilization of scientific and engineering knowledge for our benefit is achieved through the design of things we use, such as machines, structures, products, and services. However, these achievements don't occur without a price, monetary or otherwise. Therefore, the purpose of this book is to develop and illustrate the principles and methodology required to answer the basic economic question of any design: Do its benefits exceed its costs?The Accreditation Board for Engineering and Technology states that engineering “is the profession in which a knowledge of the mathematical and natural sciences gained by study, experience, and practice is applied with judgment to develop ways to utilize, economically, the materials and forces of nature for the benefit of mankind.”*In this definition, the economic aspects of engineering are emphasized, as well as the physical aspects. Clearly, it is essential that the economic part of engineering practice be accomplished well.Therefore，engineering economy is the dollars-and-cents side of the decisions that engineers make or recommend as they work to position a firm to be profitable in a highly competitive marketplace．Inherent to these decisions are trade-offs among different types of costs and the performance(response time，safety, weight, reliability, etc.) provided by the proposed design or problem solution．The mission of engineering economy is to balance thesetrade-offs in the most economical manner. For instance, if an engineer at Ford Motor Company invents a new transmission lubricant that increases fuel mileage by 10% and extend s the life of the transmission by 30,000 miles，how much can the company afford to spend to implement this invention? Engineering economy can provide an answer.A few more of the myriad situations in which engineering economy plays a cruclal role come to mind：1. Choosing the best design for a high-efficiency gas furnace.2. Selecting the most suitable robot for a welding operation on an automotive assembly line.3. Making a recommendation about whether jet airplanes for an overnight delivery service should be purchased or leased.4. Determining the optimal staffing plan for a computer help desk.From these illustrations，it should be obvious that engineering economy includes significant technical considerations．Thus，engineering economy involves technical analysis with emphasis on the economic aspects, and has the objective of assisting decisions．This is true whether the decision maker is an engineer interactively analyzing alternatives at a computer-aided design workstation or the Chief Executive Officer(CEO)considering a new project．A n engineer who is unprepared to excel at engineering economy is not properly equipped for，his or her job.Cost considerations and comparisons are fundamental aspects of engineering practice．This basic point was emphasized in Section 1.1. However, the development of engineering economy methodology, which is now used in nearly all engineering work，is relatively recent．This does not mean that，historically, costs were usually overlooked in engineering decisions. However, the perspective that ultimate economy is a primary concern to the engineer and the availability of sound techniques to address this concern differentiate this aspect of modern engineering practicefrom that of the past.A pioneer in the field was Arthur M．Wellington, a civil engineer, who in the latter part of the nineteenth century specifically addressed the role of economic analysis in engineering projects. His particular area of interest was railroad building in the United States．This early work was followed by other contributions in which the emphasis was on techniques that depended primarily on financial and actuarial mathematics．In 1930. Eugene Grant published the first edition of his textbook.+ This was a milestone in the development of engineering economy as we know it today. He placed emphasis on developing an economic point of view in engineering，and(as he stated in the preface) “this point of view involves a realization that quite as definite a body of principles governs the economic aspects of an engineering decision as governs its physical aspects.” In 1942，Woods and DeGarmo wrote the first edition of this book，later titled Engineering Economy.Unit Two The Principles of Engineering EconomyThe development, study, and application of any discipline must begin with a basic foundation．We define the foundation for engineering economy to be a set of principles，or fundamental concepts，that provide a comprehensive doctrine for developing the methodology, These principles will be mastered by students as they progress through this book. However, in engineering economic analysis, experience has shown that most errors can be traced to some violation of or lack of adherence to the basic principles．Once aproblem or need has been clearly defined, the foundation of the discipline can be discussed in terms of seven principles.PRINCIPLE1－DEVELOP THE ALTERNATIVES:The choice(decision) is among alternatives. The alternatives need to be identified and then defined for subsequent analysisA decision situation involves making a choice among two or more alternatives. Developing and defining the alternatives for detailed evaluation is important because of the resulting impact on the quality of the decision．Engineers and managers should place a high priority on this responsibility．Creativity and innovation are essential to the process.One alternative that may be feasible in a decision situation is making no change to the current operation or set of conditions(i.e., doing nothing). If you judge this option feasible，make sure it is considered in the analysis. However, do not focus on the status quo to the detriment of innovative or necessary change.PRINCIPLE2-FOCUS ON THE DIFFERENCES:Only the differences in expected future outcomes among the alternatives are relevant to their comparison and should be considered in the decision.If all prospective outcomes of the feasible alternatives were exactly the same，there would be no basis or need for comparison．We would be indifferent among the alternatives and could make a decision using a random selection.Obviously, only the differences in the future outcomes of the alternatives are important．Outcomes that are common to all alternatives can be disregarded in the comparison and decision．For example，if your feasible housing alternatives were two residences with the same purchase(or rental)price，price would be inconsequential to your final choice．Instead，the decision would depend on other factors, such as location and annual operating and maintenance expenses. This example illustrates，in a simple way, Principle 2，which emphasizes the basic purpose of an engineeringeconomic analysis：to recommend a future course of action based on the differences among feasible alternatives.PRINCIPLE 3-USE A CONSISTENT VIEWPOINT:The prospective outcomes of the alternatives, economic and other, should be consistently developed from a defined viewpoint (perspective).The perspective of the decision maker, which is often that of the owners of the firm，would normally be used．However, it is important that the viewpoint for the particular decision be first defined and then used consistently in the description analysis，and comparison of the alternatives.As an example，consider a public organization operating for the purpose of developing a river basin，including the generation and wholesale distribution of electricity from dams on the river system．A program is being planned to upgrade and increase the capacity of the power generators at two sites. What perspective should be used in defining the technical alternatives for the program? The “owners of the firm” in this example means the segment of the public that will pay the cost of the program and their viewpoint should be adopted in this situation.Now let us look at an example where the viewpoint may not be that of the owners of the firm．Suppose that the company in this example is a private firm and that the problem deals with providing a flexible benefits package for the employees. Also, assume that the feasible alternatives for operating the plan all have the same future costs to the company．The alternatives，however, have differences from the perspective of the employees，and their satisfaction is an important decision criterion. The viewpoint for this analysis and decision should be that of the employees of the company as a group, and the feasible alternatives should be defined from their perspective.PRINCIPLE 4-USE A COMMON UNIT OF MEASURE:Using a common unit of measurement to enumerate asmany of the prospective outcomes as possible will simplify the analysis and comparison of the alternatives.It is desirable to make as many prospective outcomes as possible commensurable (directly comparable)．For economic consequences，a monetary unit such as dollars is the common measure．You should also try to translate other outcomes(which do not initially appear to be economic) into the monetary unit．This translation，of course, will not be feasible with some of the outcomes, but the additional effort toward this goal will enhance commensurabilitv and make the subsequent analysis and comparison of alternatives easier.What should you do with the outcomes that are not economic(i.e., the expected consequences that cannot be translated (and estimated) using the monetary unit)? First, if possible, quantify the expected future results using an appropriate unit of measurement for each outcome．If this is not feasible for one or more outcomes，describe these consequences explicitly so that the information is useful to the decision maker in the comparison of the alternatives．PRINCIPLE 5-CONSIDER ALL RELEV ANT CRITERIASelection of a preferred alternative (decision making) requires the use of a criterion (or several criteria). The decision process should consider both the outcomes enumerated in the monetary unit and those expressed in some other unit of measurement or made explicit in a descriptive manner.The decision maker will normally select the alternative that will best serve the long-term interests of the owners of the organization. In engineering economic analysis, the primary criterion relates to the long-term financial interests of the owners. This is based on the assumption that available capital will be allocated to provide maximum monetary return to the owners. Often, though, there are other organizational objectives you would like to achieve with your decision, and these should be considered and given weight in the selection of an alternative. These nonmonetarv attributes andmultiple objectives become the basis for additional criteria in the decision-making process.PRINCIPLE6-MAKE UNCERTAINTY EXPLICIT:Uncertainty is inherent in projecting (or estimating) the future outcomes of the alternatives and should be recognized in their analysis and comparison.The analysis of the alternatives involves projecting or estimating the future consequences associated with each of them．The magnitude and the impact of future outcomes of any course of action are uncertain．Even if the alternative involves no change from current operations, the probability is high that today‟s estimates of, for example，future cash receipts and expenses will not be what eventually occurs. Thus, dealing with uncertainty is an important aspect of engineering economic analysis and is the subject of Chapters 10 and 13.PRINCIPLE 7- REVISIT YOUR DECISIONS:Improved decision making results from an adaptive process, to the extent practicable, the initial projected outcomes of the selected alternative should be subsequently compared with actual results achieved.A good decision-making process can result in a decision that has an undesirable outcome. Other decisions, even though relatively successful，will have results significantly different from the initial estimates of the consequences. Learning from and adapting based on our experience are essential and are indicators of a good organization.The evaluation of results versus the initial estimate of outcomes for the selected alternative is often considered impracticable or not worth the effort. Too often, no feedback to the decision-making process occurs. Organizational discipline is needed to ensure tha t implemented decisions are routinely postevaluated and that the results used to improve future analyses of alternatives and the quality of decision making．The percentage of important decisions inan organization that are not postevaluated should be small．For example，a common mistake made in the comparison of alternatives is the failure to examine adequately the impact of uncertainty in the estimates for selected factors on the decision．Only postevaluations will highlight this type of weakness in the engineering economy studies being done in an organization.Unit Three Cost Concept3.1 Fixed, Variable, and Incremental CostsFixed costs are those unaffected by changes in activity level over a feasible range of operations for the capacity or capability available. Typical fixed costs include insurance and taxes on facilities, general management and administrative salaries, license fees, and interest costs on borrowed capital.Of course, any cost is subject to change, but fixed costs tend to remain constant over a specific range of operating conditions. When large changes in usage of resources occur, or when plant expansion or shutdown is involved, fixed costs will be affected.Variable costs are those associated with an operation that vary in total with the quantity of output or other measures of activity level. If you were making an engineering economic analysis of a proposed change to an existing operation, the variable costs would be the primary part of the prospective differences between the present andchanged operations as long as the range of activities is not significantly changed. For example, the costs of material and labor used in a product or service are variable costs, because they vary in total with the number of output units, even though the costs per unit stay the same.An incremental cost (or incremental revenue) is the additional cost (or revenue) that results from increasing the output of a system by one (or more) units. Incremental cost is often associated with “go-no go” decisions that involve a limited change in output or activity level.③For instance, the incremental cost per mile for driving an automobile may be. $0.27, but this cost depends on considerations such as total mileage driven during the year (normal operating range), mileage expected for the next major trip, and the age of the automobile. Also, it is common to read of the “incremental cost of producing a barrel of oil” and “incremental cost to the state for educating a student.” As these examples indicate, the incremental cost (or revenue) is often quite difficult to determine in practice.3.2 Recurring and Nonrecurring CostsThese two general cost terms are often used to describe various types of expenditures. Recurring costs are those that are repetitive and occur when an organization produces similar goods or services on a continuing basis. Variable costs are also recurring costs, because they repeat with each unit of output. But recurring costs are not limited to variable costs. A fixed cost that is paid on a repeatable basis is a recurring cost. For example, in an organization providing architectural and engineering services, office space rental, which is a fixed cost, is also a recurring cost.Nonrecurring costs, then, are those which are not repetitive, even though the total expenditure may be cumulative over a relatively short period of time. Typically, nonrecurring costs involve developing or establishing a capability or capacity to operate. For example, the purchase cost for real estate upon which a plant will bebuilt is a nonrecurring cost, as is the cost of constructing the plant itself.3.3 Direct, Indirect, and Standard CostsThese frequently encountered cost terms involve most of the cost elements that also fit into the previous overlapping categories of fixed and variable costs, and recurring and nonrecurring costs. Direct costs are costs that can be reasonably measured and allocated to a specific output or work activity. The labor and material costs directly associated with a product, service, or construction activity are direct costs. For example, the materials needed to make a pair of scissors would be a direct cost.Indirect costs are costs that are difficult to attribute or allocate to a specific output or work activity. The term normally refers to types of costs that would involve too much effort to allocate directly to a specific output. In this usage, they are costs allocated through a selected formula (such as, proportional to direct labor hours, direct labor dollars, or direct material dollars) to the outputs or work activities. For example, the costs of common tools, general supplies, and equipment maintenance in a plant are treated as indirect costs.Overhead consists of plant operating costs that are not direct labor or direct material costs. In this book, the terms indirect costs, overhead, and burden are used interchangeably. Examples of overhead include electricity, general repairs, property taxes, and supervision. Administrative and selling expenses are usually added to direct costs and overhead costs to arrive at a unit selling price for a product or service. (Appendix A provides a more detailed discussion of cost accounting principles.)Various methods are used to allocate overhead costs among products, services, and activities. The most commonly used methods involve allocation in proportion to direct labor costs, direct labor hours, direct materials costs, the sum of direct labor and direct materials costs (referred to as prime cost in a manufacturing operation), or machine hours. In each of these methods, it isnecessary to know what the total overhead costs have been or are estimated to be for a time period (typically a year) to allocate them to the production (or service delivery) outputs.Standard costs are representative costs per unit of output that are established in advance of actual production or service delivery. They are developed from anticipated direct labor hours, materials, and overhead categories (with their established costs per unit). Because total overhead costs are associated with a certain level of production, this is an important condition that should be remembered when dealing with standard cost data (for example, see Section 2.5.3). Standard costs play an important role in cost control and other management functions. Some typical uses are the following:1. Estimating future manufacturing costs.2. Measuring operating performance by comparing actual cost per unit with the standard unit cost.3. Preparing bids on products or services requested by customers.4. Establishing the value of work in process and finished inventories.3.4 Cash Cost versus Book CostA cost that involves payment of cash is called a cash cost (and results in a cash flow) to distinguish it from one that does not involve a cash transaction and is reflected in the accounting system as a noncash cost. This noncash cost is often referred to as a book cost. Cash costs are estimated from the perspective established for the analysis (Principle 3, Section 1.3) and are the future expenses incurred for the alternatives being analyzed. Book costs are costs that do not involve cash payments, but rather represent the recovery of past expenditures over a fixed period of time. The most common example of book cost is the depreciation charged for the use of assets such as plant and equipment. In engineering economic analysis, only those costs that are cash flows or potential cash flows from the defined perspective for the analysis need to be considered.Depreciation, for example, is not a cash flow and is important in an analysis only because it affects income taxes, which are cash flows. We discuss the topics of depreciation and income taxes in Chapter 6.3.5 Sunk CostA sunk cost is one that has occurred in the past and has no relevance to estimates of future costs and revenues related to an alternative course of action. Thus, a sunk cost is common to all alternatives, is not part of the future (prospective) cash flows, and can be disregarded in an engineering economic analysis. For instance, sunk costs are nonrefundable cash outlays, such as earnest money on a house or money spent on a passport.We need to be able to recognize sunk costs and then handle them properly in an analysis. Specifically, we need to be alert for the possible existence of sunk costs in any situation that involves a past expenditure that cannot be recovered, or capital that has already been invested and cannot be retrieved.The concept of sunk cost is illustrated in the next simple example. Suppose that Joe College finds a motorcycle he likes and pays $40 as a down payment, which will be applied to the $1,300 purchase price, but which must be forfeited if he decides not to take the cycle. Over the weekend, Joe finds another motorcycle he considers equally desirable for a purchase price of $1,230. For the purpose of deciding which cycle to purchase, the $40 is a sunk cost and thus, would not enter into the decision, except that it lowers the remaining cost of the first cycle. The decision then is between paying $1,260 ($1,300～$40) for the first motorcycle versus $1,230 for the second motorcycle.In summary, sunk costs result from past decisions and therefore are irrelevant in the analysis and comparison of alternatives that affect the future. Even though it is sometimes emotionally difficult to do, sunk costs should be ignored, except possibly to the extent that their existence assists you to anticipate better what will happen in the future.3.6 Opportunity CostAn opportunity cost is incurred because of the use of limited resources, such that the opportunity to use those resources to monetary advantage in an alternative use is foregone. Thus, it is the cost of the best rejected (i.e., foregone) opportunity and is often hidden or implied.For example, suppose that a project involves the use of vacant warehouse space presently owned by a company. The cost for that space to the project should be the income or savings that possible alternative uses of the space may bring to the firm. In other words, the opportunity cost for the warehouse space should be the income derived from the best alternative use of the space. This may be more than or less than the average cost of that space obtained from the accounting records of the company.Consider also a student who could earn $20,000 for working during a year, but chooses instead to go to school for a year and spend $5,000 to do so. The opportunity cost of going to school for that year is $25,000:$5,000 cash outlay and $20,000 for income foregone. (This figure neglects the influence of income taxes and assumes that the student has no earning capability while in school.)3.7 Life-Cycle CostIn engineering practice, the term life-cycle cost is often encountered. This term refers to a summation of all the costs, both recurring and nonrecurring, related to a product, structure, system, or service during its life span, The life cycle is illustrated in Figure 2-2. The life cycle begins with identification of the economic need or want (the requirement) and ends with retirement and disposal activities. It is a time horizon that must be defined in the context of the specific situation-whether it is a highway bridge, a jet engine for commercial aircraft, or an automated flexible manufacturing cell for a factory. The end of the life cycle may be projected on a functional or an economic basis. For example, the amount of time that a structure or piece of equipment is able to perform economically maybe shorter than that permitted by its physical capability. Changes in the design efficiency of a boiler illustrate this situation. The old boiler may be able to produce the steam required, but not economically enough for the intended use.Unit Four Time Value of Money4.1 IntroductionThe term capital refers to wealth in the form of money or property that can be used to produce more wealth. The majority of engineering economy studies involve commitment of capital for extended periods of time, so the effect of time must be considered. In this regard, it is recognized that a dollar today is worth more than a dollar one or more years from now because of the interest (or profit) it can earn. Therefore, money has a time value.4.2 Why Consider Return to Capital?Capital in the form of money for the people, machines, materials, energy, and other things needed in the operation of an。
工程管理专业英语教案
统一编号_____________ (共1 册)
常州大学怀德学院教案簿
（第 1 册）
课程名称《工程管理专业英语》
教学单位建筑与环境工程系
主讲教师翁鹏职称助教
课程性质B3 总学时32 总学分 2
授课班级工程16级总人数61
课程授课学期 5 起止时间2018.9 至2019.1
本教案用于第 5 学期
所用教材及编者《工程管理专业英语》柳立生主编；武汉理工大学出版社
主要参考书及编者：
《工程管理专业英语》徐勇戈主编
《工程管理专业英语》王竹芳主编
《建筑施工技术》古栋列主编
教学事务部（教务）制
本册教案目录
常州大学怀德学院教案
学生反馈。
Unit 1 Types of construction project(工程管理专业英语)
Exordium
Contents
Vocabulary
Key Structures
Questions
English for Construction Project Management
Unit One Types of Construction Project
……and typically all phase of the project are handled by the same firm on a negotiated designconstruct or “turnkey” contractual arrangement, with considerable overlap between design, procurement, and construction. 此外，（工业建筑）项目各阶段的工作一般依据设计建 造或交钥匙合同由同一家企业来承担，因而其设计、采 购与施工等各阶段工作之间存在相当大的工作联系。 “turnkey” contractual arrangement，交钥匙合同方式， 即工程项目建设的全过程，包括设计、采购、施工、运 行试验等都由同一家企业承包，最后它将一个随时可以 使用的工程交给合同另一方的方式。
虽然它们和住宅类建设一样，也是劳动力与材料 密集型，但此类项目范围更广，所包含的技术更复 杂。 句中的labor-and-materials-intensive 为 “劳动力与材料密集型”的意思。much larger 与 more complex 分别对应其前的the scope 与technology.
精炼厂，炼制厂
Vocabulary
high-rise
Key Structures
n
高楼，大厦；a 高层的
工程管理专业英语unit
3
谈判英语的应用场景
谈判英语广泛应用于工程项目合作、国际贸易、 商务交流等领域，是工程管理专业人员必备的技 能之一。
04
Engineering Management Professional English Practice
Case Analysis
Case preparation
Provide background information and prepare necessary documents for students to understand the case.
Engineering Management Professional English Unit
contents
目录
• introduction • Fundamentals of English in
Engineering Management • Application of English in
Simulation monitoring
Monitor the progress of the simulation and provide guidance and assistance when needed.
ABCD
Simulation implementation
Provide necessary tools and resources for students to carry out the simulation.
English-written technical documents
and reports in the field of engineering
management.
Objective 4
工程管理英文翻译英语翻译
On improving the quality of project cost managementAbstractProject cost is an important part of project construction management, it can take effective measures in the whole process of engineering construction, the construction of full cost control within the approved limit, and correct the deviation at any time, to ensure that completed the investment estimate, design budget and final accounts, etc, to achieve the goal of management to achieve the rational use of manpower, material resources, financial resources, the purpose of the largest investment benefit. Is the core content of the project cost estimates of investment estimation, design, modification and construction drawing budget, engineering settlement, completion final accounts, and so on. The task of the project cost is according to the drawings, norm and listing standards, calculate the project included in the direct fee (all the branch of engineering, subdivisional work of labor, materials, mechanical stage class expense, etc.), indirect fees, fees and taxes, and so on.Engaged in engineering cost personnel mainly involves the ability should include: the project has a strong ability of calculation of quantities, to prepare the accounting settlement of construction cost control, the bill of quantities, prices, bid price quotations, engineering settlement, skilled application software cost, have certain ability of data management and so on.Keywords: construction cost; The status of the construction project cost management; The project cost; Benefits.Project cost is a pay all the expenses of construction projects completed and put into operation combined. Engineering cost in addition to the related to project content, it also with the construction of regional economic development level, the management of builders, and technical level, national and local government policies, laws and other external conditions is intimately involved. The uniqueness of the project determines the project cost also has uniqueness. Preparation of project cost correctly for the government and the owner's decision has an irreplaceable role. In our country has been under the situation of "WTO", study how to improve the level of project cost establishment, scientifically reflect the engineering actual expense, is already in front of our construction cost professionals has become a major topic. Combined with practical work and thinking about the problem now, talk about the following experience and advice.1. the current situation of engineering cost management in our countryOur country the current engineering cost management system is formed in the 50 s, eighty s perfect. Due to historical reasons, the former Soviet union's basically overall introduction of the basic construction of budget system. The system is the product of highly centralized planned economic system. Directly involved in the form of country and management of economic activities. Regulation in different design stage must prepare the estimate or budget and shall be responsible for the government; Relevant departments to formulate the budget compilation principle, content, methods and measures for examination and approval, the cost budget quota, quota and equipment material budget price establishment, examination and approval, management authority, etc. Along with the historical process, after recovery, reform and development, formed a relatively complete system of budget quota management. But with the development of the socialist market economy, many of the problems in the system has been exposed.In recent years, the developed countries in the world is predicted in advance, matter to the requirement of engineering investment control. And the practice of our country traditional decision objectively cause light, heavy, light the economy and technology, after construction, first get the consequences. Due to the engineering technical personnel's technical and economic ideas and weak consciousness of costcontrol, cost management personnel's quality is difficult to improve. The project cost control goal difficult to achieve for a long time.According to the above situation, our country academic circles in the eighty s first puts forward the concept of whole process cost management and control, relevant departments are the feasibility study of construction projects and the budget to the relevant requirements of both ends to extension, the our country cost management ideas and methods mentioned a new height. We should now the task is the modern cost management and target market economic system which accords with the situation of China, draw lessons from the advanced experience of developed countries, to establish a set of perfect market economy law system of engineering cost management, efforts to improve the level of project cost of.2. change the backward idea, establish consciousness of the whole process of investment controlProject cost control and management, it is in the project decision-making stage, design stage and construction stage of project implementation, the study of project cost, the construction project cost control in the range of scientific and reasonable, according to the project progress at any time the deviation correction, to ensure the implementation of project management investment objectives, strive for in every stage of the construction of the project reasonable use of manpower and material resources, financial resources, in order to obtain better investment benefit and social benefit. According to the scientific connotation of engineering construction, and cost control problems in each stage. Interconnected each stage of cost control, this requires that we should establish a scientific and perfect engineering cost management system, make the project valuation, review, determine, settlement and final accounts of standardization institutionalization, establish a set of powerful supervision and inspection mechanism and rewards and punishments measures. At the same time, how to reasonably determine the cost and make full and reasonable match of the various resources, in order to obtain better investment benefit and social benefit, is also need to study the problem.Because the project construction period is longer, usually influenced by a variety of external factors and constraints, the beginning of the project is difficult to determine the correct cost. With the development of the project and the thorough,understanding of the project is more comprehensive, thus cost estimate is more reasonable. Such as estimation, budget, budget and final accounts of compilation is done in different stages of the construction, its precision is becoming more and more deep. Therefore, reasonable and effective control of engineering cost, should consider the following issues:(1) because of the large scale of construction projects, construction cycle is long, complex technology, financial and material resources is used up big, considering the factors such as economic benefits after put into use, once decision-making error, will cause huge economic loss beyond retrieve, in order to reasonable cost, must be in the whole construction process, according to the characteristics of different stages of multiple valuation, namely according to construction procedure reasonable accuracy of the various stages of construction cost, to fully embody the rationality of the cost. Historical experience tells us that the sequencing of construction project is the basic premise for reasonable cost.(2) over the years, our country the construction of the project is generally ignored the importance of prophase project construction stage, the cost control mainly focus on the project of the construction of the late stage and even in the final stage, so often appear the phenomenon of investment overrun. Some programs even in after the completion of investment has more than plan, bad engineering so as to build a lot of benefits. , so we must renew the idea, summed up a complete set of engineering cost control and management methods.(3) the project cost control should run through the whole process of construction projects, but in the early period of the control key should be transferred to the project construction, is transferred to the project decision-making and design stage, but once the investment decision, the control should focus on the design stage.(4) all construction project implementation stage is subject to supervision and engineering cost control system, all can obtain satisfactory economic benefits and social benefits, but at present our country construction project prophase stage has not yet adopted this system. Because on the premise of meet the specifications, designs the cost will be because of the influence of the experience, level, or other factors, the difference is bigger, conservative design thought, and makes the project cost is high, so, the whole process of construction project management and cost control system is very necessary.3, to effectively control the project costEffectively control the project cost, it is necessary to do the following: first, at the early stage of the project construction phase must be carried out on the supervision system of supervision (including cost). It should be said that this is a relatively objective and fair way. Through the supervision of the design process, make a design more reasonable, the construction cost control within the scope of the limit, but also can make design units to improve management, optimize structure, improve the design level, truly with minimal funds for maximum output. On the other hand is actively promoting "limit design method, which is proved an effective way, it is not just an economic problem, more accurately, a technical and economic problems. Will not assimilation of the whole project by facilities sites or function is divided into several units, design personnel according to the limited quota for selection and design. The limitation of "design" can effectively control the project cost of the project. For the aim of "design" the limit to, should be involved in the designer must be experienced designers understand the technical and economic. The results of their design must be practical, advanced and reasonable cost. To control the engineering cost on the other hand is a must for scheme comparison, because design achievements is a process of gradually improve, not can determine down at the beginning, so much more is to measure the practicality, advancement and economy.Effectively control the project cost, should be measures in many aspects: from the organizational measures is clear project organization structure, clear cost controller and its mission to make the cost of each part is responsible for personnel; Take measures from the technology's strict inspection supervise each stage of design, design review, in terms of technical and economic research may save investment; Take measures is to dynamically from the economic comparative cost plan value and the actual value, audit strictly the expense, adjust the design according to the design progress.Engineering design field in China for a long time do not do the optimization combination of technology and economy. Technical personnel lack of economic idea, conservative design, make the design results of economy get fully embody. And budget personnel because of not familiar with engineering technology, also less understanding of the project progress in various relations, difficult to effectively control the project cost. Therefore, we should solve the problem now is to enhance economic efficiency as the goal, in the heart of the project construction process organically organization, technology and economy. Through economic analysis, the comparison of the technology, and the effect evaluation, correctly handle the unity ofopposites between the economic and reasonable and advanced technology, strive to advanced technology under the condition of economic and reasonable, in the economic and reasonable on the basis of advanced technology.In the process of project cost control is very important. Cost engineer should comprehensively to master and apply the bidding documents, the contract agreement and the relevant design, construction documents. Was based on reasonable of the bill of quantities, grasp measurement pay this key link, carefully examine and verify the payment application, so that each of the funds to jindu can get reasonable control and payment. Cost engineer except for what had happened in the process of project implementation of cost control, also need to know the national related aspects of the project cost in the laws and regulations, collect all kinds of price information, understand price is dynamic, after analyzing all kinds of cost data, etc. Obviously, there is no solid knowledge of economic and technical strength is difficult to finish the work. It puts forward higher requirements on cost engineer.The core content of the project cost control is based on the market as the center of cost dynamic control and management. The complexity of construction project determines its valuation for many times, and the construction process in different stages of the corresponding cost is dynamically reflect the total cost of the project. Especially in the project implementation stage, due to the changes of external conditions, the design phase is not considered factors are often exposed, lead to design changes, the cost changes. This will require a cost engineer for timely research and analysis of problems in the operation of the construction project, and take timely corrective measures, to achieve the target. This stage is the most concentrated cost dynamic control process. Cost engineer is the large amount of work should be done at this time.4, develop a team having both ability and political integrity of the project costProject cost management is a comprehensive discipline. It to the relevant national guidelines and policies as the norms of engineering construction, and other technical and economic disciplines, it is a policy, technical, economy and practicality are very strong work. Cost engineer in addition to our professional knowledge, therefore, have a deep understanding and the understanding, also deal with design content, design process, construction technology, project management, economic lawsand regulations, computer application, construction of the external environment and so on, have a comprehensive understanding. Shall also have rich practical experience, with its technical and economic knowledge. Cost engineer is a multi-level talent of knowledge. In market economic system gradually perfected, investment increasingly diverse today, urgent need a large number of provide scientific decision basis for project investment cost engineer. To meet the above requirements, should begin from the following aspects:(1) to establish a truly independent of engineering cost consulting agencies, intermediary role between the owner and the contractor. In the management of government investment project, consultancy activities that the government need not go directly to the project management, and to rely on indirect means to achieve the purpose of regulating the management. In the process, cost engineers and other professional engineers have the same status and restrict and influence each other and play a positive role in engineering construction; This not only can let the government officials from multifarious economic activity, can give full play to the project cost professional work initiatives and creativity. They both for the owners to provide quality, convenient, comprehensive cost management services, and provide professional engineering cost consultation service for government departments.(2) to set up for the general association of engineering cost personnel of the service organization or academic organizations. These institutions: is the main task of the use of education and the scientific method, cost engineering science. To cultivate new engineering cost to provide convenient conditions; Research project cost management problems, promote the development of engineering cost engineering science and technology; Provide academic BBS and communication tool, to project cost practice () personnel to provide the field of communication, publishing of cost engineering theory and technology journal, published for relevant personnel research experiences and exchange work experience; This industry and promote the social concern; Advance the project cost professional terminology standardization process, applicable standard methods: encourage add people cost engineering course in engineering college and university education is to train the professional senior talents, promote our main goal; To promote the cooperation with other related organizations, promote the development of the public interest.(3) strengthen the accumulation of engineering cost data analysis. Engineering cost is a practical major. If there is no experience but only control method, the work is carried out. Therefore, to improve the level of project cost for both organizations andindividuals, must attach great importance to data accumulation and analysis. Simple data accumulation is just a pile of data. Can only be called after finishing analysis data. In developed countries, all kinds of cost of basic data, including the consumption of labor, materials, machines and prices, and even the land price, raise interest rates, the benefit is generally not make uniform or norm, completely determined by markets or actual needs, by cost management professionals and professional organizations to manage. However, the country has to go through a series of all aspects of the law to regulate market behavior, protect the legitimate interests of all parties, achieve the goal of macroeconomic regulation and control. The engineering cost consultation company has its own years of accumulation, the full cost data. They put the cost data collection, and the analysis in the archives. If necessary, to bring up from the computer at any time, and then adjusted according to the concrete situation, can be used for new project. Many engineering cost consulting company or institute and academic groups also insisted on for many years to the cost of public offering all the latest information and price information, achieve cost social sharing of information resources. The main content in addition to the purpose of people, material, machine, consumption and price, rate, the profits thereof, and all kinds of engineering of annual price index and price index between the cities. These after decades of experience in developed countries proved to be effective methods, we should draw lessons from and fully developed the data collecting and anally sing system suitable for China's national conditions.(4) improve the project cost professional senior education and on-the-job personnel's continuing education activities. Due to the engineering cost management in construction projects and closely related to the economic interests of the parties, and to the economic activities of the whole society plays a very important guiding role, we should according to the market to the quality requirement of the cost management talent, prompting courses in project cost professional education institutions, formal training project cost professional senior talents. The professional curriculum setting, should also be completely according to the requirement of the market needs and talent quality to decide. Both due and structures, machinery and other engineering, should also be open economy, finance, cost, probability and mathematical statistics and other basic courses. At the same time should also open systems engineering, value engineering, technology, economy, econometrics, computer, management science, such as expanding knowledge and enlightenment thinking emerging course. As industry management, engineering cost society should periodically on-the-jobpersonnel to continue education. In academic exchanges, short-term training, and other areas of the form of the cost of the latest theory, technology promotion and reference case. Two aspects of education institutions and industry management institutions constitute a complete education system. To engineering to create conditions for the growth of senior talents.(5) construction cost professionals to learn and improve. Overall, at present we are engineering cost industry personnel quality and distance from the social demands. Therefore, we should take learning and keep up with the pace of The Times. In addition to our professional knowledge is updated to improve, work should also be combined with extensive understanding and preliminary master relevant knowledge of engineering. Only has a comprehensive grasp of project content, in order to increase the project cost control work. Just think, if we don't know for the preparation of the cost of engineering, the professional knowledge is very fuzzy, how can invest control? Construction cost professionals should be the first professional experts, at the same time, it should be an expert in the field of engineering. Only a high level of talent to develop the high levels of the project cost. The role of the professional status and professional is proportional to the. We should improve the level of individual manpower from, and gradually raise the level of the industry's work, for our country modernization play our role.In short, the project cost control is a whole process control, it should be said that each link cannot be ignored, and every link is very important also. With China's accession to the WTO, China's investment must be diversified, investors to reduce the cost, control costs, improve the investment benefit is becoming more and more attention. So, change the original project cost estimation, budget, budget, and the contract price settlement price, the final accounts of the traditional mode, improve the control level, investment projects for the development of comprehensive control system, can promote the development of the socialist market economy in our country, and adapt to the global economic integration process improve the level of project cost establishment is a systems engineering. It not only needs a high quality team of experts, must have the form a complete set of government policy and social environment. In this paper, combined with the author's working practice, made some Suggestions on relevant issues. In view of the author's theoretical level and practical experience is insufficient, Hard to avoid some negligence . Here is only for reference.。
工程项目管理的专业英语
Engineering project management is a comprehensive discipline that involves planning, executing, and closing projects. It is an essential part of the construction, manufacturing, and technology industries. This article will provide an overview of engineering project management, highlighting key concepts, processes, and tools.1. DefinitionEngineering project management is the application of knowledge, skills, tools, and techniques to project activities to meet the project requirements. It encompasses various activities, such as planning, executing, monitoring, controlling, and closing projects.2. Key Conceptsa. Project Scope: The defined deliverables and tasks that must be accomplished to deliver a complete and successful project.b. Project Schedule: The timeline for completing project activities and deliverables.c. Project Cost: The total amount of money required to complete the project.d. Quality: The degree of excellence of the project deliverables.e. Risk: The potential for an event to have a positive or negative impact on the project.3. Processesa. Initiating: Identifying and defining the project, including its objectives, scope, and stakeholders.b. Planning: Developing a detailed plan for executing, monitoring, and controlling the project activities.c. Executing: Implementing the project plan, including coordinating resources, managing stakeholders, and executing project activities.d. Monitoring and Controlling: Tracking, reviewing, and adjusting the project activities to ensure that the project objectives are met.e. Closing: Formalizing the completion of the project, including documentation, handover, and post-project evaluation.4. Tools and Techniquesa. Project Management Software: Tools like Microsoft Project, Oracle Primavera, and Atlassian Jira help in planning, scheduling, and tracking project activities.b. Critical Path Method (CPM): A project management technique that helps in identifying the sequence of activities and their dependencies.c. Agile Methodology: An iterative and incremental approach to project management that focuses on flexibility and collaboration.d. Risk Management: Identifying, analyzing, and mitigating risks to minimize their impact on the project.5. Professional Certificationsa. Project Management Professional (PMP): A certification offered by the Project Management Institute (PMI) that validates a professional's knowledge and skills in project management.b. Certified Project Manager (IAPM): A certification offered by the International Association of Project Managers (IAPM) that focuses on project management skills and knowledge.6. Challenges in Engineering Project Managementa. Complexity: Engineering projects are often complex, involving various stakeholders, activities, and technologies.b. Cost Control: Managing the project budget and ensuring that the project remains within the allocated budget.c. Time Management: Meeting project deadlines and delivering project deliverables on time.d. Communication: Ensuring effective communication among stakeholders, team members, and project managers.In conclusion, engineering project management is a crucial discipline that helps organizations successfully complete projects. By understanding the key concepts, processes, and tools, project managers can ensure that projects are completed on time, within budget, and to the required quality standards.。
- 1、下载文档前请自行甄别文档内容的完整性，平台不提供额外的编辑、内容补充、找答案等附加服务。
- 2、"仅部分预览"的文档,不可在线预览部分如存在完整性等问题,可反馈申请退款(可完整预览的文档不适用该条件!)。
- 3、如文档侵犯您的权益，请联系客服反馈,我们会尽快为您处理(人工客服工作时间：9:00-18:30)。
•
承包人通知发包人检查而发包人未能及时进 行检查的，承包人有权暂停施工。承包人可以顺 延工期，并要求发包人赔偿因此造成的停工、窝 工、材料和构件积压等损失。 • 如果承包人未通知发包人检查而自行进行隐 蔽工程的，事后发包人有权要求对已隐蔽的工程 进行检查，承包人应当按照要求进行剥露，并在 检查后重新隐蔽。如果经检查隐蔽工程不符合要 求的，承包人应当返工。检查隐蔽工程所发生的 费用如检查费用、返工费用、材料费用等由承包 人负担，承包人还应承担工期延误的违约责任。
• The Contractor shall give notice to the Engineer whenever any work is ready and before it is covered up, put out of sight, or packaged for storage or transport. The Engineer shall then either carry out the examination, inspection, measurement or testing without unreasonable delay or promptly give notice to the Contractor that the Engineer does not require to do so. If the Contractor fails to give the notice, he shall, if and when required by the Engineer, uncover the work and thereafter reinstate and make good, all at the Contractor's cost.
ห้องสมุดไป่ตู้
• 隐蔽工程是指地基、电气管线、供水供热管线等需要覆盖、 掩盖的工程。 • 房建工程的隐蔽工程包括以下内容： • （1）给排水工程； • （2）电气管线工程； • （3）地板基层； • （4）护墙基层； • （5）门窗套基层； • （6）吊顶基层； • （7）强电线缆； • （8）网络综合布线线缆（网线,电话线,监控线,电梯 通话线）。
Issue of tender documents Submission of the tender Issue of the letter of acceptance ?d Commencement date
Base date
?d
?d
Tender period Issue of performance security
3. The Engineer shall give the Contractor not less than 24 hours' notice of the Engineer’s intention to attend the tests. If the Engineer does not attend at the time and place agreed, the Contractor may proceed with the tests, unless otherwise instructed by the Engineer, and the tests shall then be deemed to have been made in the Engineer’s presence.
Inspection[7.3]
The Employer’s Personnel shall at all reasonable times: • (a) have full access to all parts of the Site and to all places from which natural Materials are being obtained, and
• (b) during production, manufacture and construction (at the Site and elsewhere), be entitled to examine, inspect, measure and test the materials and workmanship, and to check the progress of manufacture of Plant and production and manufacture of Materials.
Chapter 5 Plant Materials and Commencement, Completion
Clause7-9
5.1 Plant Materials and Workmanship
Definition of Plant: means the apparatus, machinery and vehicles intended to form or forming part of the Permanent Works.[1.1.5.5] Definition of Materials: means things of all kinds (other than Plant) intended to form or forming part of the Permanent Works, including the supply-only materials (if any) to be supplied by the Contractor under the Contract.[1.1.5.3]
• Commencement of Works [8.1] • The Engineer shall give the Contractor not less than 7
days’ notice of the Commencement Date. The Commencement Date shall be within 42 days after the Contractor receives the Letter of Acceptance.
Testing[7.4] 1. The Contractor shall provide all……, as are necessary to carry out the specified tests efficiently. The Contractor shall agree, with the Engineer, the time and place for the specified testing .
• The Contractor shall give the Employer's Personnel full opportunity to carry out these activities, including providing access, facilities, permissions and safety equipment. No such activity shall relieve the Contractor from any obligation or responsibility.
attend （+to）:出席,参加；致力于，献身于；侍候， 照顾；关注 proceed with:继续做…… presence:出席；仪表
4. The Contractor shall promptly forward to the Engineer duly certified reports of the tests. When the specified tests have been passed, the Engineer shall endorse the Contractor’s test certificate, or issue a certificate to him, to that effect. If the Engineer has not attended the tests, he shall be deemed to have accepted the readings as accurate. duly：充分地；适当地；及时
我国《施工合同示范文本》规定： • 承包人在隐蔽工程隐蔽以前，应当通知发包人检 查，发包人检查合格的，方可进行隐蔽工程。 • 实践中，当工程具备覆盖、掩盖条件的，承包人 应当先进行自检，自检合格后，及时通知发包人 对隐蔽工程的条件进行检查。通知包括承包人的 自检记录、隐蔽的内容、检查时间和地点。 • 发包人接到通知后，应当在要求的时间内到达隐 蔽现场，对隐蔽工程的条件进行检查，检查合格 的，发包人或者其派驻的工地代表在检查记录上 签字，承包人检查合格后方可进行隐蔽施工。若 检查不合格，有权要求承包人在一定期限内修改 后重新验收。
endorse：签名，签署；批准 reading:阅读；读物；读数
Rejection[7.5]
• If, as a result of an examination, inspection, measurement or testing, any Plant, Materials or workmanship is found to be defective or otherwise not in accordance with the Contract, the Engineer may reject the Plant, Materials or workmanship.