地铁隧道工程建设承包合同(中英文)
地铁隧道工程建设承包合同（中英文）
地铁隧道工程建设承包合同（中英文）地铁隧道工程建设承包合同CONSTRUCTION CONTRACT OF SUBWAY TUNNEL签约日期：Signature Date of本合同系中译英翻译：张云军Translated from Chinese to Englishby Mr. Chang Yunejune.发包人：城市轨道交通（集团）有限公司Employer: City Railway (Group)., Ltd.承包人：隧道工程建设有限公司Contractor: Tunnel Construction Limited Company鉴于：轨道交通（集团）有限公司（以下简称：发包人）为实施轨道交通六号线隧道土建工程（项目名称），已接受隧道工程建设有限公司（以下简称：承包人）对该项目施工的投标；鉴于：承包方是具有隧道土建工程资质和技术能力的专业工程公司，愿意接受发包方提出的招标条件并中标；发包人和承包人依照招标文件共同达成如下协议。
Whereas: City Railway (Group)., Ltd. ( hereinafter referred to as employer), in the expectation of construction of tunnel earthwork for No. 6 railway traffic, has accept the bid of Contractor: Tunnel Construction Limited Company (hereinafter referred to as contractor ).Whereas: Contractor is a professional engineering company with the quality and technical ability of tunnel civil engineering, willing to accept the bidding conditions which are issued by employer and win the bid;NOW, THEREFORE, Parties of employer and contractor hereby, in accordance with bidding documents, enter into following agreement:第一部分协议书 Part One Agreement1.本协议书与下列文件一起构成合同文件：Contract documentation is constituted by this agreement and following documents: （1）中标通知书；Notice of Acceptance（2）投标函及投标函附录；Bid letter and Appendix therewith （3）专用合同条款及通用合同条款Particular provision and general provision（4）技术标准和要求及图纸；T echnical standard, requirement and drawing（5）已标价工程量清单；Priced list of project amount（8）其他合同文件。
建筑工程承包施工合同中英文版
xxx engineering contract xxx工程合同Contract No.:合同编号：Party A: xxxCompany Limited甲方：xxx有限公司Party B:xxx Company Limited乙方：xxx有限公司Party A: xxx Company Limited,甲方：xxx有限公司，xxx经营的公司，住所地为xxx，（下称“甲方”），法定代表人：xxxParty B:xxx Company Limited,乙方：xxx有限公司，一家xxx经营的公司，注册地址是：xxx，（下称“乙方”），法定代表人：xxxParty A and Party B are called by a joint name of Both Parties under this contract, each of which is called as A Party.甲方和乙方在本合同项下统称为“双方”，单独称为“一方”。
1. Work Content and Requirements1. 工作内容、要求1.1 In accordance with the items stipulated in this Contract, Party B shall conduct the project as per the Projectstandard and quality standard stipulated by Ministry of Engineering of the Union of xx.1.1 依据本合同所限定的条款，乙方应以xx工程部规定的建筑标准和质量要求执行本工程。
2. Contract Period2. 合同期限2.1 Work period for the Road Construction Project: the work shall be completed within 2 month upon signingthe Contract. The condition of handover is that the Project Inspection & Acceptance Team constituted by Party A, shall issue the Inspection & Acceptance Sheet after onsite inspection.2.1 本次工程时间周期：合同签订后14个工作日内完成，并以甲方组成的竣工验收小组现场检验并出具验收单为竣工交接条件。
工程承包类合同中英
工程承包类合同中英---工程承包合同甲方（业主）：___________乙方（承包商）：___________鉴于甲方拟委托乙方进行___________工程项目的建设，经双方协商一致，特订立本合同如下：第一条工程概况1.1 工程名称：___________1.2 工程地点：___________1.3 工程规模：___________1.4 工程内容：___________1.5 工程质量要求：___________第二条合同价格2.1 合同总价为人民币（大写）___________元整（￥___________）。
2.2 价格包含所有材料、人工、机械使用及管理费用等。
第三条工期3.1 开工日期：____年__月__日3.2 竣工日期：____年__月__日3.3 工期延误按每日____元的标准向甲方支付违约金。
第四条支付方式4.1 预付款：甲方需在合同签订后__天内支付合同总价的__%作为预付款。
4.2 进度款：根据工程进度分阶段支付。
4.3 结算款：工程竣工验收合格后__天内支付剩余款项。
第五条质量保证5.1 乙方保证工程质量符合国家及行业标准。
5.2 对存在的质量问题，乙方应在接到通知后__小时内进行无偿修复。
第六条违约责任6.1 双方均应严格履行合同义务，任何一方违约均应承担相应的违约责任。
6.2 如因不可抗力因素导致无法履行合同，应及时通知对方并协商解决。
第七条争议解决7.1 本合同在履行过程中发生争议，双方应友好协商解决；协商不成时，可提交_____仲裁委员会仲裁或依法向人民法院起诉。
第八条其他约定8.1 本合同自双方签字盖章之日起生效。
8.2 本合同一式两份，甲乙双方各执一份，具有同等法律效力。
甲方代表（签字）：___________乙方代表（签字）：___________签订日期：____年__月__日---Contract for Construction rojectarty A (Owner): ___________arty (Contractor): ___________Whereas arty A intends to entrust arty with the construction of the ___________ roject, the two arties have reached an agreement through consultation and herey estalish this contract as follows:Article 1 General Information of the roject1.1 roject Name: ___________1.2 roject Location: ___________1.3 roject Scale: ___________1.4 roject Content: ___________1.5 Quality Requirements: ___________Article 2 Contract rice2.1 The total contract rice is in Renmini (in words) ___________ Yuan only (￥___________).2.2 The rice includes all materials, laor, machinery usage, and management costs, etc. Article 3 Construction eriod3.1 Start Date: __ year __ month __ day3.2 Comletion Date: __ year __ month __ day3.3 In case of delay in construction eriod, a enalty fee of ____ Yuan er day shall e aid to arty A. Article 4 ayment Method4.1 Advance ayment: arty A shall ay __% of the total contract rice as an advance ayment within __ days after the signing of the contract.4.2 rogress ayment: To e aid in stages according to the rogress of the roject.4.3 Final ayment: The remaining amount shall e aid within __ days after the roject asses the comletion insection.Article 5 Quality Assurance5.1 arty guarantees that the quality of the work meets national and industry standards. 5.2 For any quality issues identified, arty shall reair at no cost within __ hours uon notification.Article 6 Liaility for reach of Contract6.1 oth arties shall strictly fulfill their oligations under the contract, and any reach y either arty shall ear the corresonding liaility for reach of contract.6.2 If it is imossile to erform the contract due to force majeure, the affected arty shall notify the other arty in a timely manner and seek a resolution through negotiation.Article 7 Disute Resolution7.1 In case of any disute during the erformance of this contract, oth arties shall resolve it through friendly negotiation; if negotiation fails, either arty may sumit the disute to the _____ Aritration Commission for aritration or file a lawsuit in accordance with the law.Article 8 Other Agreements8.1 This contract shall ecome effective uon signature and seal y oth arties.8.2 This contract is made in dulicate, with each arty holding one coy, oth having equal legal effect.Reresentative of arty A (Signature): ___________Reresentative of arty (Signature): ___________Date of Signing: __ year __ month __ day---。
工程承包合同中英文
工程承包合同中英文工程承包合同是发包方（甲方）与承包方（乙方）之间就某一建设工程项目的实施所签订的法律文件。
该合同详细规定了工程的范围、质量要求、施工周期、价格条款以及双方的权利与义务等关键信息。
以下是一份简化的工程承包合同中英文范本的核心内容：---工程承包合同Construction Contract甲方（发包方）：__________arty A (Emloyer): __________乙方（承包方）：__________arty (Contractor): __________鉴于甲乙双方就[工程名称]项目达成一致，特此签订本合同。
Whereas arty A and arty have agreed to the [roject Name] roject, this contract is herey signed.第一条工程范围Article 1 Scoe of Work本工程包括但不限于以下内容：__________The work shall include, ut not e limited to: __________第二条工程质量Article 2 Quality of Work乙方须确保工程质量满足甲方要求及相关国家标准。
arty shall ensure that the quality of work meets arty A's requirements and relevant national standards.第三条施工周期Article 3 Construction eriod工程预计开工日期为____年____月____日，竣工日期为____年____月____日。
The exected commencement date of the roject is ____ Year ____ Month ____ Day, and the comletion date is ____ Year ____ Month ____ Day.第四条合同价款Article 4 Contract rice合同总价为人民币____元或其等值美元。
工程建设的合同中英
工程建设的合同中英---Construction Contract甲方（Emloyer）： [Full Name]地址（Address）： [Address]乙方（Contractor）： [Full Name]地址（Address）： [Address]鉴于甲乙双方同意按照以下条款和条件进行合作，现就[roject Name]工程项目达成如下合同：I. roject Details1. 工程名称（Name of the roject）： [roject Name]2. 工程地点（Location of the roject）： [Location]3. 工程范围（Scoe of Work）： [Detailed Descrition]4. 工期（Duration of the roject）： [Start Date] to [End Date]5. 合同金额（Contract Sum）： [Amount in Numer and Currency]II. Resonsiilities of the Emloyer1. 提供必要的工程资料和施工场地。
2. 按合同约定支付工程款项。
3. 协助解决施工过程中的问题。
III. Resonsiilities of the Contractor1. 按合同要求完成工程建设任务。
2. 保证工程质量符合标准。
3. 及时通报工程进度和存在的问题。
IV. ayment Terms1. 工程款支付方式：[Detailed ayment Method]2. 进度款支付条件：[Detailed rogress ayment Conditions]3. 最终款项结算：[Detailed Final ayment Settlement]V. Default and enalties1. 如甲方违约，应按合同规定承担相应责任。
2. 如乙方违约，应按合同规定承担相应责任。
VI. Disute Resolution任何争议应首先通过友好协商解决，协商不成可提交至[Aritration or Court Name]解决。
建设工程施工合同中英文对照版
建设工程施工合同中英文对照版建设工程施工合同中英文对照版一、合同背景本合同是根据相关法律法规以及双方自愿、平等、公正、诚实信用原则，为确保建设工程施工过程的顺利进行而订立的合同。
由甲方（以下简称“业主”）和乙方（以下简称“承包商”）共同签署并遵守。
二、合同条款1. 项目名称英文：Project Name中文：项目名称2. 承包商信息英文：Contractor Information中文：承包商信息3. 业主信息英文：Owner Information中文：业主信息4. 工程范围英文：Scope of Work中文：工程范围5. 工程质量和标准英文：Quality and Standards中文：工程质量和标准6. 工程价格和支付方式英文：Price and Payment Terms中文：工程价格和支付方式7. 工期和交付时间英文：Timeframe and Delivery Date中文：工期和交付时间8. 变更和补充条款英文：Change and Supplemental Clauses 中文：变更和补充条款9. 保证和担保英文：Warranty and Guarantee中文：保证和担保10. 违约和争议解决英文：Breach and Dispute Resolution中文：违约和争议解决11. 合同解除英文：Termination of the Contract中文：合同解除12. 其他条款英文：Other Provisions中文：其他条款13. 合同生效和效力英文：Effective Date and Validity中文：合同生效和效力三、合同条款解释1. 项目名称：合同中的项目名称应与相关文件一致，准确描述需要施工的建筑或基础设施项目的名称。
2. 承包商信息：列出承包商的名称、注册地址、以及相关资格证书。
3. 业主信息：列出业主的名称、注册地址、等信息。
4. 工程范围：详细描述工程涉及的施工范围、关键任务和必要材料等。
铁路隧道工程施工承包合同(中英文)最新修正版
铁路隧道工程施工承包合同CONTRACT OF RAILW AY TUNNEL ENGINEERING CONSTRUCTION（翻译：张云军）签署日期：Date of Signature甲方：中铁集团（以下简称甲方）Party A: China Railway Group. ( hereinafter referred to as Party A)乙方：隧道工程公司（以下简称乙方）Party B: T unnel Engineering Company (hereinafter referred to as Party B)条款目录CONTENT S一、组成合同的文件：Documents Constitut ed Contract二、工程概况General Review of Project三、工期Work Term四、工程数量的核实和确认Check and Confirmation of Work Quantity五、承包工程造价Project Cost六、工程质量标准与验收Project Quality Standards and Acceptance七、隐蔽工程检查和签证Inspection and Confirmation of Hidden Works八、材料的供应Supply of Material九、工程变更Alteration十、双方责任与权利Responsibilities and Rights of Parties十一、安全施工Safe Construction十二、进度计划Progress Schedule十三、承包工程价款支付和结算Settlement and Payment十四、履约担保Performance Bond ( PB履约金2-5%)十五、保修Maintenance and Repair十六、违约责任Liabilities十七、其它约定Miscellaneous鉴于：甲方系铁路建设工程总承包商，因铁路建设需要并经过业主同意，通过招标将一号隧道工程承包给具有隧道建设资质和能力的专业公司施工；鉴于：乙方系专业从事隧道工程建设的施工公司，具有相应的工程资质和能力，中标承包本合同工程；据此，甲方将一号隧道的洞身钻爆开挖、洞门修建、防排水设施、锚网喷支护、衬砌、洞内沟槽及洞室和相应的隧道施工附属项目承包给乙方施工，经双方协商一致，订立本合同，共同遵守。
铁路工程施工承包合同中英文（范文模版）
铁路工程施工承包合同中英文（范文模版）第一篇：铁路工程施工承包合同中英文（范文模版）铁路工程施工承包合同（中英文）CONTRACT OF RAILWAY CONSTRUCTION签署日期 The date of本合同经下述双方签署：This Contractor Contract is signed between the following parties:老挝铁路总公司（以下简称甲方）；Railway Company of Laos People’s Democratic Public(Hereinafter referred to as Party A)地址：Address Laos Address: House No: 220, Unit 17, Phonsay Village, Say Settha District, Vientaine Capital, Lao PDR.联系电话： Contact T elephone 承包方（以下简称乙方）：Contractor(Hereinafter referred to as Party B)授权项目经理： The authorized project manager is Mr.地址：Address 联系电话： Contact Telephone 鉴于甲方经业主授权为老挝沙湾拿吉—老堡铁路基础建设与附属开发区建设部分第共两个标段进行公开议标，议标后依据老挝国家交通运输部签署的2008年11月10日第MOU号决议，双方缔约于下：With respect to Laos, Savannakhet to Lao Bao Railway infrastructure construction and the affiliated development zone construction for a total of two packages tender: Part----&--, Party A is authorized by the owner to call for bidding, the proposed bid based on the Lao Ministry of Transpo rt’s MOU signed on , the terms and conditions are as follows :-（一）合同内容Content of the contract 乙方要在老挝沙湾拿吉省对沙湾拿吉至老堡电气化铁路基础与附属开发区建设部分的第五、第六共两个标段进行总承包施工。
工程承包合同英文版
Contract for Engineering ConstructionThis Contract for Engineering Construction (the "Contract") is made and entered into as of [Date], by and between [Contractor's Name], a corporation organized and existing under the laws of [Country/State] ("Contractor"), and [Owner's Name], a individual/corporation organized and existing under the laws of [Country/State] ("Owner").1. Scope of WorkThe Contractor agrees to perform all the engineering construction services (the "Work") as described in the attached Scope of Work document (the "Scope of Work") and as further detailed in the Contract Documents. The Work shall be performed at the project site located at [Project Location].2. TermThe term of this Contract shall commence on the date hereof and shall continue until the completion of the Work, subject to the terms and conditions set forth herein. The Contractor agrees to complete the Work within [Number] days from the commencement date, unless the time for completion is extended in writing by the Owner.3. PaymentThe Contractor shall be paid for the Work performed under this Contract in accordance with the payment terms set forth in the Scope of Work. The Contractor shall submit invoices to the Owner for payment of the Work performed, and the Owner shall make payments to the Contractor within [Number] days after receipt of such invoices.4. Changes to the WorkThe Owner may, at any time during the performance of the Work, order changes to the Work. The Contractor agrees to promptly comply with any such changes, and to make any necessary adjustments to the schedule, budget, and other terms of the Contract to reflect such changes. Any changes to the Work shall be documented in writing and signed by both parties.5. Default and TerminationIf either party defaults in the performance of any obligation under this Contract, the non-defaulting party may terminate this Contract upon written notice to the defaulting party. In the event of termination, the Contractor shall be entitled to payment for the Work performed up to the date of termination, less any amounts owed to the Contractor by the Owner.6. Dispute ResolutionAny disputes arising out of or in connection with this Contract shall be resolved by arbitration in accordance with the rules of the [Arbitration Institution]. The decision of the arbitrator(s) shall be final and binding upon the parties.7. Governing Law and JurisdictionThis Contract shall be governed by and construed in accordance with the laws of [Country/State]. Any legal action or proceeding arising out ofor in connection with this Contract shall be brought exclusively in the courts of [Country/State].8. Entire AgreementThis Contract constitutes the entire agreement between the parties with respect to the subject matter hereof and supersedes all prior agreements, understandings, negotiations, and discussions, whether oral or written, of the parties.IN WITNESS WHEREOF, the parties have executed this Contract as of the date first above written.[Contractor's Name] [Owner's Name]By: \_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_ By:\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_Name: \_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_ Name: \_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_Title: \_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_ Title: \_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_Address: \_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_ Address: \_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_Date:\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_ \_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\。
建设工程施工合同中英
合同编号：_______甲方（发包方）：_______乙方（承包方）：_______根据《中华人民共和国合同法》及相关法律法规的规定，甲乙双方在平等、自愿、公平、诚实信用的原则基础上，就甲方发包，乙方承包的建设工程项目，达成如下协议：一、工程概况1.1 工程名称：_______1.2 工程地点：_______1.3 工程内容：_______1.4 工程面积：_______1.5 工程质量：_______1.6工程造价：人民币（大写）：_______元整（小写）：￥_______元。
二、施工期限2.1 工程开工日期：_______2.2 工程竣工日期：_______2.3 工程总日历天数：_______天。
三、合同价款及支付方式3.1合同价款：人民币（大写）：_______元整（小写）：￥_______元。
3.2 支付方式：（1）预付款：合同签订后_______日内，甲方支付乙方合同价款的_______%作为预付款；（2）进度款：乙方按照工程进度，分阶段向甲方申请支付进度款，甲方应在收到乙方申请后_______日内支付；（3）结算款：工程竣工验收合格后，乙方提交结算资料，甲方应在收到乙方提交的结算资料后_______日内支付至合同价款的____ ___%；（4）质保金：工程竣工验收合格满_______年后，甲方支付乙方剩余的_______%合同价款作为质保金。
四、工程变更4.1 工程变更范围：合同范围内的工程变更；4.2工程变更程序：乙方提出工程变更申请，经甲方审核同意后，按照变更后的设计方案进行施工；4.3工程变更费用：按照实际发生的费用，由甲乙双方另行协商确定。
五、违约责任5.1甲方违约：甲方未能按照合同约定支付合同价款，每逾期一日，应支付逾期付款金额的_______%作为违约金；逾期超过_______日的，乙方有权解除合同，并要求甲方支付合同总价款的_______%作为违约金；5.2乙方违约：乙方未能按照合同约定完成工程，每逾期一日，应支付逾期竣工金额的_______%作为违约金；逾期超过_______日的，甲方有权解除合同，并要求乙方支付合同总价款的_______%作为违约金。
建设工程施工合同中英(3篇)
第1篇Contract No.: [Contract Number]Date: [Contract Date]Parties Involved:1. Contractor:- Name: [Contractor's Name]- Address: [Contractor's Address]- Contact Person: [Contractor's Contact Person]- Contact Information: [Contractor's Contact Information]2. Client:- Name: [Client's Name]- Address: [Client's Address]- Contact Person: [Client's Contact Person]- Contact Information: [Client's Contact Information]Scope of Work:1. Project Description: [Detailed description of the construction project, including type of project, location, and main objectives.]2. Work to be Performed: [List of all the specific tasks and activities to be carried out by the Contractor, including design, construction, and any other related services.]3. Deliverables: [Detailed list of all deliverables, including but not limited to drawings, specifications, progress reports, and final certificates of completion.]Contract Price and Payment Terms:1. Contract Price: [Total contract price including all costs, fees, and expenses.]2. Payment Schedule:- Progress Payments: [Details of progress payments, including payment milestones, percentage of work completed, and payment schedule.]- Final Payment: [Conditions and terms for the final payment, including completion and final inspection requirements.]3. Retention: [Percentage of the contract price to be retained until the project is completed and all conditions are met.]Duration of the Contract:1. Start Date: [Date when the work is to begin.]2. Completion Date: [Estimated completion date based on the project scope and schedule.]3. Extension of Time: [Conditions under which the completion date may be extended and the process for requesting an extension.]Quality Standards:1. Quality Requirements: [Specific quality standards to be adhered to during the construction process, including materials, workmanship, and compliance with relevant codes and regulations.]2. Inspection and Testing: [Provisions for regular inspections and testing to ensure compliance with quality standards.]Warranties and Liabilities:1. Warranties: [Details of warranties provided by the Contractor, including duration and scope of warranty coverage.]2. Liabilities: [Responsibilities and liabilities of the Contractor in the event of any defects, damages, or claims arising from the work performed under the contract.]Force Majeure:1. Definition: [Definition of force majeure events, including acts of God, war, strikes, labor disputes, and any other events beyond the reasonable control of the Contractor.]2. Effect: [Provisions regarding the suspension of the contract and the obligations of the parties in the event of a force majeure event.]Dispute Resolution:1. Arbitration: [Provisions for resolving disputes, including the procedure for arbitration and the appointment of an arbitrator.]2. Legal Actions: [Conditions under which legal actions may be taken and the jurisdiction of any disputes.]General Provisions:1. Governing Law: [The laws of the jurisdiction that will govern the interpretation and enforcement of the contract.]2. Amendments: [Provisions regarding the process for making amendments to the contract.]3. Termination: [Conditions under which the contract may be terminated and the consequences of termination.]Acknowledgment:The parties hereto acknowledge that they have read, understand, and agree to be bound by the terms and conditions of this Construction Engineering Contract.---Contract No.: [Contract Number]Date: [Contract Date]Contractor:[Signature of Contractor] ___________________________[Name of Contractor] ___________________________Client:[Signature of Client] ___________________________[Name of Client] ___________________________---Note: This is a general template for a construction engineering contract. Specific contracts may require additional details or clauses based onthe nature of the project and the requirements of the parties involved.It is recommended that legal advice be sought when drafting or entering into a construction contract.第2篇Contract No. __________Contract Date: __________Contractor: __________Client: __________1. IntroductionThis Construction Engineering Contract (hereinafter referred to as "the Contract") is entered into between __________ (hereinafter referred toas "the Contractor") and __________ (hereinafter referred to as "the Client") on the basis of mutual consultation, agreement, and mutual benefit. The Contractor agrees to construct and complete theconstruction project as specified in the Contract, and the Client agrees to pay the agreed contract price for the completed construction project. The Contract is binding on both parties and shall be strictly observed.2. Project Description2.1 Project Name: __________2.2 Project Location: __________2.3 Project Scope: The construction project includes the following scopes:a. Civil engineering works: __________b. Electrical engineering works: __________c. Mechanical engineering works: __________d. Other relevant works: __________3. Contract Price3.1 The total contract price for the construction project is __________ Yuan, which is subject to the following terms:a. The Contractor shall provide detailed project estimates and invoices for the Client's approval.b. The Client shall make payment in accordance with the agreed payment schedule.c. Any additional costs due to changes in the project scope or unforeseen circumstances shall be agreed upon by both parties in writing.4. Performance and Quality4.1 The Contractor shall ensure that the construction project is completed within the agreed time frame and meets the quality standards specified in the Contract.4.2 The Contractor shall adhere to the relevant national standards,local regulations, and industry practices during the construction process.4.3 The Client shall have the right to inspect and accept the construction project at any time during the construction process.5. Payment Schedule5.1 The payment schedule is as follows:a. Upon the signing of the Contract, the Client shall pay the Contractor a deposit of __________ Yuan.b. Upon the completion of each phase of the project, the Contractor shall submit an invoice to the Client for payment.c. The Client shall pay the invoice within __________ days upon receipt.6. Insurance6.1 The Contractor shall obtain and maintain all necessary insurance policies to cover the risks associated with the construction project, including but not limited to:a. Public liability insuranceb. Workers' compensation insurancec. Property insurance7. Termination of the Contract7.1 Either party may terminate the Contract in writing if the other party fails to comply with the terms and conditions of the Contract.7.2 Upon termination of the Contract, the Contractor shall immediately cease all construction activities and the Client shall pay the Contractor for the work completed up to the date of termination.8. Dispute Resolution8.1 Any disputes arising from the execution of the Contract shall be settled through friendly negotiations between the parties.8.2 If the parties fail to reach an agreement through negotiations, the dispute shall be submitted to the relevant arbitration commission for resolution.9. Governing LawThis Contract shall be governed by the laws of __________.10. Final Provisions10.1 This Contract constitutes the entire agreement between the parties and supersedes all prior agreements and understandings, whether written or oral.10.2 Any amendment or modification of this Contract shall be effective only if it is in writing and signed by both parties.Contractor Signature: ___________________________Client Signature: ___________________________Date: ___________________________---Construction Engineering ContractContract No. __________Contract Date: __________Contractor: __________Client: __________1. Introduction本建筑工程合同（以下简称“本合同”）由__________（以下简称“承包商”）与__________（以下简称“业主”）在相互协商、一致同意和互惠互利的基础上签订。
铁路隧道工程施工承包合同（中英文对照版）
铁路隧道工程施工承包合同（中英文对照版）铁路隧道工程施工承包合同CONTRACT OF RAILWAY TUNNEL ENGINEERING CONSTRUCTION签署日期： Date of Signature甲方：中铁集团（以下简称甲方）Party A: China Railway Group. ( hereinafter referred to as Party A)乙方：隧道工程公司（以下简称乙方）Party B: T unnel Engineering Company (hereinafter referred to as Party B)条款目录 CONTENT S一、组成合同的文件： Documents Constitut ed Contract二、工程概况 General Review of Project三、工期 Work Term四、工程数量的核实和确认 Check and Confirmation of Work Quantity五、承包工程造价 Project Cost六、工程质量标准与验收Project Quality Standards and Acceptance七、隐蔽工程检查和签证Inspection and Confirmation of Hidden Works八、材料的供应 Supply of Material九、工程变更 Alteration十、双方责任与权利 Responsibilities and Rights of Parties十一、安全施工 Safe Construction十二、进度计划 Progress Schedule十三、承包工程价款支付和结算 Settlement and Payment十四、履约担保 Performance Bond ( PB履约金 2-5%)十五、保修 Maintenance and Repair十六、违约责任 Liabilities十七、其它约定 Miscellaneous鉴于：甲方系铁路建设工程总承包商，因铁路建设需要并经过业主同意，通过招标将一号隧道工程承包给具有隧道建设资质和能力的专业公司施工；鉴于：乙方系专业从事隧道工程建设的施工公司，具有相应的工程资质和能力，中标承包本合同工程；据此，甲方将一号隧道的洞身钻爆开挖、洞门修建、防排水设施、锚网喷支护、衬砌、洞内沟槽及洞室和相应的隧道施工附属项目承包给乙方施工，经双方协商一致，订立本合同，共同遵守。
工程承包合同中英文
工程承包合同中英文甲方（发包方）：[甲方名称]乙方（承包方）：[乙方名称]第一条工程概况1.1 工程名称：[工程名称]1.2 工程地点：[工程地点]1.3 工程内容：[工程内容]1.4 工程期限：自[开始日期]至[结束日期]Article 1 Project Overview1.1 Project Name: [Name of the Project]1.2 Project Location: [Location of the Project]1.3 Project Content: [Content of the Project]1.4 Project Duration: From [Start Date] to [End Date]第二条工程价款2.1 工程总价款为[金额]，包括但不限于材料费、人工费、管理费等。
2.2 工程价款的支付方式为：[支付方式描述]。
Article 2 Project Price2.1 The total project price is [Amount], including but not limited to material costs, labor costs, management fees, etc.2.2 The payment method for the project price is: [Descriptionof Payment Method].第三条工程质量3.1 乙方应按照国家及行业标准进行施工，确保工程质量。
3.2 工程验收标准按照[验收标准]执行。
Article 3 Project Quality3.1 The Contractor shall carry out construction in accordance with national and industry standards to ensure project quality.3.2 The project acceptance standards shall be implemented according to [Acceptance Standards].第四条双方责任4.1 甲方负责提供工程所需的场地、水电等条件。
铁路工程施工承包合同中英文(2024版)
20XX 专业合同封面COUNTRACT COVER甲方：XXX乙方：XXX铁路工程施工承包合同中英文(2024版)本合同目录一览1. 合同主体及定义1.1 发包方1.2 承包方1.3 工程1.4 施工期1.5 工程质量1.6 工程量1.7 工程款项1.8 违约1.9 争议解决1.10 合同的生效、变更和终止2. 合同条款2.1 承包方的义务2.1.1 施工准备2.1.2 施工进度2.1.3 工程质量与安全2.1.4 材料和设备2.1.5 人员配备2.2 发包方的义务2.2.1 付款条件2.2.2 施工现场提供2.2.3 施工许可2.2.4 保护承包方合法权益2.3 合同的履行与监督2.3.1 工程进度报告2.3.2 工程质量检查2.3.3 工程变更2.3.4 合同监督与协调3. 工程款项3.1 工程预付款3.2 工程进度款3.3 工程竣工款3.4 工程质量保证金3.5 工程款项的支付方式3.6 工程款项的支付时间4. 违约责任4.1 承包方的违约4.1.1 施工进度延误4.1.2 工程质量不合格4.1.3 材料和设备不合格4.1.4 人员不符合要求4.2 发包方的违约4.2.1 付款延误4.2.2 施工现场不符合约定4.2.3 施工许可延误4.2.4 保护承包方合法权益不当5. 争议解决5.1 协商解决5.2 调解解决5.3 仲裁解决5.4 法律途径解决6. 合同的生效、变更和终止6.1 合同的生效6.2 合同的变更6.3 合同的终止7. 其他条款7.1 保密条款7.2 不可抗力7.3 合同的转让7.4 法律法规的适用7.5 合同语言7.6 合同的签署日期和地点8. 附件8.1 工程量清单8.2 施工图纸8.3 技术规范8.4 工程款项支付明细表8.5 履约担保8.6 保险证明8.7 其他相关文件第一部分：合同如下：第一条合同主体及定义1.1 发包方发包方是指根据本合同约定，负责委托和监督工程实施的单位或个人。
中英文版建设工程施工合同
中英文版建设工程施工合同Construction Engineering Contract合同编号： [Contract No.]合同日期： [Date of Contract]甲方（业主）： [Party A (Owner)]乙方（承包商）： [Party B (Contractor)]第一部分通用条款Part I General Provisions第1条定义Article 1 Definitions本合同中使用的术语和表达，除非另有明确说明，应按照本合同的规定解释。
The terms and expressions used in this contract shall be interpreted in accordance with the provisions of this contract, unless otherwise expressly stated.第2条合同文件Article 2 Contract Documents构成本合同的文件包括但不限于：本合同协议书、中标通知书、投标书及其附件、本合同专用条款、本合同通用条款、标准、规范及有关技术文件、图纸、工程量清单和工程报价单或预算书。
The documents constituting this contract include, but are not limited to: this contract agreement, the notice of award, the tender and its attachments, the special provisions of this contract, the general provisions of this contract, standards, specifications and relevant technical documents, drawings,bill of quantities, and the engineering quotation or budget.第3条语言和法律Article 3 Language and Law本合同使用中文和英文两种语言，两种文本具有同等法律效力。
建筑工程承包合同(中英文)
建筑工程承包合同(中英文)建筑工程承包合同 (中英文)合同编号: [合同编号]本合同由以下几方共同签署并遵守：1. 承包商名称: [承包商名称]2. 业主名称: [业主名称]3. 监理单位名称: [监理单位名称]1. 范围和目的1.1 本合同的目的是确保在双方协商一致的情况下，承包商将按照合同规定的要求和条款对建筑工程进行承包，并按时完工交付。
1.2 本合同适用于以下建筑工程项目：[建筑工程项目名称]，位于[工程项目地址]。
2. 工程描述2.1 承包商将按照业主提供的图纸和说明书执行以下工程任务：- [工程任务1]- [工程任务2]- ...2.2 详细的工程细节和要求将在合同签订后通过工程图纸和设计说明书提供。
3. 价格和支付方式3.1 总价格: [总价]。
支付方式如下：- 预付款: [预付款金额]，于合同签署后的[预付款付款日期]前支付承包商账户。
- 进度款: [进度款比例]的工程完成后，根据工程进度进行支付。
- 完工款: 工程完成后的[完工验收日期]前支付承包商账户。
4. 工期4.1 工程开始日期: [工程开始日期]4.2 工程完成日期: [工程完成日期]4.3 若承包商不能按时完成工程，每延迟一天将面临相应的违约金。
5. 質量控制与保证5.1 承包商在施工过程中应遵守施工规范，保证工程的质量符合相关法律法规和标准。
5.2 承包商应为工程提供保修期限，任何非人为因素引起的质量问题承包商负责修复。
6. 变更和解除合同6.1 任何一方在变更合同或解除合同时，应提前书面通知对方，并经过双方协商达成一致。
6.2 变更合同时，双方应重新商定价格、工期等相关条款。
7. 纠纷解决7.1 本合同为中英文对照合同，若在合同解释上发生争议，应以中文为准。
7.2 对于因本合同引起的争议，双方应首先通过友好协商解决，如仍无法解决，则提交有管辖权的仲裁机构进行仲裁，其仲裁裁决是终局的。
本合同自双方签署之日起生效，并在工程完工后终止。
铁路隧道工程施工承包合同(中英文)
铁路隧道工程施工承包合同(中英文)合同封面甲方（发包方）：XXX铁路公司乙方（承包方）：XXX建筑公司工程名称：XXX铁路隧道工程合同编号：XXX签订日期：XXX合同正文一、合同双方1. 甲方（发包方）：XXX铁路公司2. 乙方（承包方）：XXX建筑公司二、工程内容及规模1. 工程名称：XXX铁路隧道工程2. 工程规模：隧道长度XXX米，宽度XXX米，高度XXX米。
三、工程地点及施工期限1. 工程地点：XXX市XXX县2. 施工期限：自签订合同之日起XXX个月。
四、工程价款及支付方式1. 工程价款：人民币XXX万元整。
2. 支付方式：甲方按照合同约定，分阶段向乙方支付工程款。
乙方需提供合法有效的发票。
五、工程质量标准及技术要求1. 工程质量标准：符合国家和地方相关规定。
2. 技术要求：按照施工图纸和甲方提供的技术资料进行施工。
六、双方责任和义务1. 甲方责任和义务：提供施工场地、水、电、路等基本施工条件，协调解决相关问题，对工程质量、安全、进度进行监督和管理。
2. 乙方责任和义务：按照工程设计图纸和甲方提供的技术资料进行施工，保证工程质量、安全、进度，协助甲方解决施工中出现的问题。
七、安全生产和环境保护1. 乙方应遵守国家和地方有关安全生产和环境保护的法律法规，确保施工安全和环境保护。
2. 甲方有权监督乙方执行安全生产和环境保护措施，如发现安全隐患或环保问题，有权要求乙方立即整改。
八、违约责任和争议解决方式1. 违约责任：如因乙方原因导致工程不能按期完工或工程质量不符合国家和地方相关规定，乙方应承担违约责任，并赔偿甲方的经济损失。
2. 争议解决方式：双方在合同履行过程中发生争议，应通过友好协商解决；如协商不成，任何一方均可向工程所在地人民法院提起诉讼。
九、合同生效与份数1. 本合同自双方签字盖章之日起生效。
2. 本合同一式四份，甲、乙双方各执二份。
十、其他约定事项1. 本合同未尽事宜，双方可另行协商解决。
承包地铁隧道工程合同范本
承包地铁隧道工程合同范本甲方（发包方）：______________乙方（承包方）：______________签订日期：______________签订地点：______________鉴于甲方需要进行地铁隧道工程的建设，乙方具有相应的资质和能力，双方本着平等、自愿、公平和诚实信用的原则，就乙方承包甲方地铁隧道工程的相关事宜，经协商一致，订立本合同，以资共同遵守。
第一条工程概况1.1 工程名称：______________1.2 工程地点：______________1.3 工程内容：______________1.4 工程规模：______________1.5 工程质量标准：按照国家及行业相关标准执行。
第二条工程期限2.1 工程开工日期：______________2.2 工程竣工日期：______________2.3 工程总日历天数：______________第三条合同价款3.1 合同总价为人民币（大写）：______________（￥______________元）。
3.2 合同价款的支付方式、时间和条件：______________第四条工程质量与验收4.1 乙方必须严格按照设计图纸、施工规范和质量标准进行施工。
4.2 工程验收按照国家及行业相关标准执行。
第五条安全与环保5.1 乙方应严格遵守安全生产法律法规，确保施工安全。
5.2 乙方应采取有效措施，减少施工对环境的影响。
第六条变更与索赔6.1 任何工程变更需甲方书面同意，并可能涉及合同价款的调整。
6.2 索赔应按照合同规定程序提出，并由双方协商解决。
第七条违约责任7.1 如乙方未能按照合同约定完成工程，应承担违约责任。
7.2 如甲方未能按照合同约定支付合同价款，应承担违约责任。
第八条争议解决8.1 合同执行过程中发生争议，双方应协商解决。
8.2 协商不成时，可提交甲方所在地人民法院诉讼解决。
第九条其他9.1 本合同一式两份，甲乙双方各执一份，具有同等法律效力。
承包地铁隧道工程合同范本
承包地铁隧道工程合同范本在城市轨道交通建设领域，地铁隧道工程是核心部分之一。
它不仅关乎城市交通的便捷性，还涉及到成千上万市民的日常出行安全。
因此，对于地铁隧道工程的承包，必须严格遵循相关法律法规，确保工程质量和安全。
下面，我们提供一个承包地铁隧道工程合同的范本，供各方参考使用。
甲方（发包方）：________乙方（承包方）：________鉴于甲方拟建设地铁隧道工程，乙方具备相应的资质和经验，双方本着平等自愿、诚实信用的原则，经友好协商，就地铁隧道工程的承包事宜达成如下协议：一、工程概况1. 工程名称：________地铁隧道工程2. 工程地点：________3. 工程规模：________4. 工程内容：________5. 工程期限：自________年__月__日起至________年__月__日止。
二、承包范围及要求1. 乙方负责地铁隧道工程的施工、管理、质量、安全等工作。
2. 乙方应按照国家和地方有关法律法规、标准规范进行施工，确保工程质量达到设计要求。
3. 乙方应遵守安全生产规定，加强现场安全管理，确保施工现场安全。
三、合同价款及支付方式1. 合同总价为人民币________元整（大写：________）。
2. 甲方应按合同约定向乙方支付工程款项，具体支付方式如下：- 预付款：合同签订后__日内支付合同总价的__%作为预付款。
- 进度款：根据工程进度，按月支付相应比例的工程款。
- 竣工款：工程竣工验收合格后支付剩余款项。
四、工程质量与验收1. 乙方应保证工程质量符合国家标准和设计要求。
2. 工程竣工后，甲方组织相关部门进行验收，验收合格后方可交付使用。
3. 如发现质量问题，乙方应及时整改并承担相应责任。
五、违约责任1. 双方应严格履行合同义务，任何一方违约应承担违约责任。
2. 如因乙方原因导致工程延期或质量问题，乙方应承担违约责任并赔偿甲方损失。
3. 如因甲方原因导致工程延期或无法正常施工，甲方应承担违约责任并赔偿乙方损失。
承包地铁隧道工程合同范本
承包地铁隧道工程合同范本甲方（以下简称“委托人”）：住所地：甲方法定代表人：职务：甲方法定代表人身份证号码：联系电话：乙方（以下简称“承包人”）：住所地：乙方法定代表人：职务：乙方法定代表人身份证号码：联系电话：鉴于委托人拟建设地铁隧道工程，经双方充分协商，同意由承包人承担该工程的施工，特订立本合同，以便共同遵守。
一、工程概况1.1 工程名称：地铁隧道工程1.2 工程地点：（具体起点和止点）1.3 工程内容：根据委托人提供的施工蓝图范围内涉及的所有施工内容，包括但不限于洞身开挖、衬砌施工、排水系统、通风系统、照明系统、供电系统、通信系统等。
1.4 工程规模：（根据实际情况填写）1.5 承包范围：乙方承担本工程的施工，包括施工图纸和施工方案所规定的所有工作内容。
二、合同工期2.1 开工日期：（根据实际情况填写）2.2 竣工日期：（根据实际情况填写）2.3 合同工期总日历天数：（根据实际情况填写）三、质量标准3.1 工程质量标准：本工程质量应达到国家及行业相关规范和标准，合格率为100%。
四、合同价款4.1 工程价款总金额：（大写：人民币整）（根据实际情况填写）4.2 最终结算按照乙方实际完成的工程量结算工程款。
4.3 施工中发现与设计图纸不一致进行变更的，由甲、乙双方及监理单位共同确定工程量后据实结算。
4.4 材料因价格波动引起价格变化不予调整价差，人工费调整按国家相关规定执行。
4.5 工程价款支付办法：按照双方约定的付款进度和比例进行支付。
五、违约责任5.1 乙方未按照约定的工期完成工程的，应按照逾期竣工的天数向甲方支付违约金，违约金计算方式为：违约金=工程价款总金额×逾期竣工天数×日违约金比例。
5.2 甲方未按照约定的付款进度和比例支付工程款的，应按照逾期付款的天数向乙方支付违约金，违约金计算方式为：违约金=应付款项×逾期付款天数×日违约金比例。
六、争议解决本合同履行过程中发生的争议，双方应友好协商解决；协商不成的，可以向有管辖权的人民法院提起诉讼。
- 1、下载文档前请自行甄别文档内容的完整性，平台不提供额外的编辑、内容补充、找答案等附加服务。
- 2、"仅部分预览"的文档,不可在线预览部分如存在完整性等问题,可反馈申请退款(可完整预览的文档不适用该条件!)。
- 3、如文档侵犯您的权益，请联系客服反馈,我们会尽快为您处理(人工客服工作时间：9:00-18:30)。
地铁隧道工程建设承包合同CONSTRUCTION CONTRACT OF SUBWAY TUNNEL签约日期：Signature Date of本合同系中译英翻译：张云军Translated from Chinese to Englishby Mr. Chang Yunejune.发包人：城市轨道交通（集团）有限公司 Employer: City Railway (Group)., Ltd.承包人：隧道工程建设有限公司 Contractor: Tunnel Construction Limited Company鉴于：轨道交通（集团）有限公司（以下简称：发包人）为实施轨道交通六号线隧道土建工程（项目名称），已接受隧道工程建设有限公司（以下简称：承包人）对该项目施工的投标；鉴于：承包方是具有隧道土建工程资质和技术能力的专业工程公司，愿意接受发包方提出的招标条件并中标；发包人和承包人依照招标文件共同达成如下协议。
Whereas: City Railway (Group)., Ltd. ( hereinafter referred to as employer), in the expectation of construction of tunnel earthwork for No. 6 railway traffic, has accept the bid of Contractor: Tunnel Construction Limited Company (hereinafter referred to as contractor ).Whereas: Contractor is a professional engineering company with the quality and technical ability of tunnel civil engineering, willing to accept the bidding conditions which are issued by employer and win the bid;NOW, THEREFORE, Parties of employer and contractor hereby, in accordance with bidding documents, enter into following agreement:第一部分协议书 Part One Agreement1.本协议书与下列文件一起构成合同文件：Contract documentation is constituted by this agreement and following documents: （1）中标通知书；Notice of Acceptance（2）投标函及投标函附录；Bid letter and Appendix therewith（3）专用合同条款及通用合同条款Particular provision and general provision（4）技术标准和要求及图纸；Technical standard, requirement and drawing（5）已标价工程量清单；Priced list of project amount（8）其他合同文件。
Other contract documentation2. 上述文件互相补充和解释，如有不明确或不一致之处，以合同约定次序在先者为准。
The documents above should be taken as mutually complementary and explanatoryof one another. In the event of any indefinite, vague or inconsistency among them, the order in front by contract agreement will be prevail.3. 签约合同价： Contracted price4. 承包人承诺按合同约定承担工程的实施、完成及缺陷修复。
Contractor promise to undertake pursuant to the stipulation of contract the implement, complement and defect repair of project.5. 发包人承诺按合同约定的条件、时间和方式向承包人支付合同价款。
Employer promise to effect payment of contracted price pursuant to the conditions, time and ways which stipulated in contract.6. 承包人应按照监理人指示开工，工期为595日历天。
Contractor should make commencement subject to supervisor’s order. Work’s period is 595 calendar days.7. 本协议书一式壹拾伍份，合同双方各执柒份，公证机关壹份。
This agreement in made fifteen original copies, each party hold seven copies and notarization authority hold one copy.8. 合同未尽事宜，双方另行签订补充协议。
补充协议是合同的组成部分。
Outstanding issues herein will be with supplementary agreement by parties separately. Supplementary agreement is the integral part of contract.第二部分专用合同条款 Part Two Particular Provision1.一般约定 General Provision1.1.工程和设备 Project and Equipment永久工程：隧道工程（包括局部路基段、区间）、隧道入洞口区间工程、出入段线工程以及施工进出场道路的拓宽和施工用水、电的安装等辅助工程。
Permanent Works: tunnel engineering including local roadbed, interval zones, the interval zones of tunnel entrance, entry section, road expanding to construction site, and auxiliary projects such as installation of water, power for work, and so on.临时工程：隧道、高架区间、路基工程及出入段线的主体工程及附属工程，以及实施以上工程必须的施工进出场道路的拓宽和施工用水、电的安装等临时工程。
Temporary Projects: Tunnel, elevated section, roadbed, main project and auxiliary project for in and out of section / line, and road expanding to construction site, and temporary projects such as installation of water, power , which are necessary for Work implementation, and so on.1.1.2 缺陷责任期：结构工程两年，防水工程五年。
Defect Liability Period: Two years for structure project and five years for water proof project.1.2 合同生效的条件 Effective Condition合同生效的条件：经双方法定代表人或委托代理人签字盖章且承包人提供合同总价款12%的履约担保后生效。
Effective condition: This contract will come into force and effect upon the signature and seal by legal representatives of parties or authorized agent in addition to Performance Guarantee issued by contractor, of 12% of total contract price.1.3 图纸和承包人文件 Drawings and Contractor’s Documentation发包人提供图纸的期限、数量：开工前提供满足施工需要的全套图纸一式六套。
The time limited and number of drawings issued by employer: Six copies of full set drawings will be supplied, before commencement, for necessity of construction.2.发包人义务 Employer’s Liability2.1 提供施工场地 Provision of Construction Site发包人提供施工场地和有关资料的时间：The time of provisions of site and concerned materials by employer.3. 监理人的职责和权力 Liability and Authority of Supervisor须经发包人事先批准行使的权力：对本工程项目的施工质量、进度、投资、安全施工、合同及信息管理等实施全过程监理和控制。
对隐蔽工程及施工质量进行验收和工程量签认，对施工环境进行协调。
The authority subject to pre-approval of employer: Whole process supervision and control on quality, progress, investment, safe work of this project, in addition to the management of contract and information. The acceptance of hidden works and quality thereof, confirmation of work amount and coordination of engineering environment.4. 承包人的一般义务 Contractor’s General Liability4.1 应提供计划、报表的名称及完成时间：（1）审批后一周内提供本工程施工进度总计划及本年度施工进度计划。