施工合同中英文模板-construction-contract
建筑施工英文合同范本
建筑施工英文合同范本(CONSTRUCTION CONTRACT)甲方(Party A):____________________________地址(Address):____________________________电话(Tel):____________________________法定代表人(Legal Representative):____________________________乙方(Party B):____________________________地址(Address):____________________________电话(Tel):____________________________法定代表人(Legal Representative):____________________________鉴于甲方拟在____________(项目地点)建设____________(项目名称),并已通过招标或其他方式确定乙方为该项目的施工方,甲乙双方经友好协商,达成如下协议:第一条工程概况1. 工程名称:____________________________2. 工程地点:____________________________3. 工程内容:____________________________4. 工程承包范围:____________________________第二条工程期限1. 开工日期:______年______月______日2. 竣工日期:______年______月______日3. 总工期:______日历天第三条工程质量标准本工程质量标准为____________________________。
第四条合同价款及支付方式1. 合同价款为人民币(大写):____________________________元整(小写:¥__________元),此价款为固定总价,不因任何因素而调整。
建筑施工合同范本中英文
建筑施工合同范本中英文Building Construction Contract TemplateContract AgreementThis Building Construction Contract (the "Contract") is entered into on [Date] (the "Effective Date") by and between:[Contractor's Name] (the "Contractor"), a company duly registered and organized under the laws of [Country], having its principal place of business at [Address];And[Owner's Name] (the "Owner"), a company duly registered and organized under the laws of [Country], having its principal place of business at [Address];(collectively referred to as the "Parties").Whereas, the Owner intends to construct [Description of the Project] (the "Project"), and the Contractor possesses the necessary expertise, experience, and resources to perform the construction as required;Now, therefore, in consideration of the mutual promises and covenants herein contained, the Parties agree as follows:1. Scope of Work:The Contractor shall provide all necessary labor, materials, equipment, and services to complete the Project in accordance with the plans and specifications as agreed upon by the Parties (the "Scope of Work"). Anyproposed changes or modifications to the Scope of Work must be agreed upon in writing by both Parties.2. Project Timeline:The Contractor shall commence work on the Project on [Start Date] and shall complete the construction of the Project within [Number ofDays/Months] from the Effective Date, unless otherwise agreed upon in writing by both Parties.3. Payment Terms:3.1 The Owner agrees to pay the Contractor the total contract price of [Amount] (the "Contract Price") for the completion of the Project. The payment shall be made in installments as follows:- [Percentage]% of the Contract Price shall be paid upon signing this Contract as an upfront payment to initiate the construction process.- [Percentage]% of the Contract Price shall be paid upon completion of [Milestone/Phase].- [Percentage]% of the Contract Price shall be paid upon completion of [Milestone/Phase].- [Percentage]% of the Contract Price shall be paid upon final completion and acceptance of the Project.3.2 All payments made by the Owner shall be made in [Currency] and shall be made within [Number of Days] from the date of receipt of a properly invoiced payment request from the Contractor.4. Quality and Safety:The Contractor shall ensure that all materials, equipment, and workmanship used in the construction of the Project meet the highest industry standards. The Contractor shall also comply with all applicable laws, regulations, and safety standards to ensure the safety of the construction site and the workers involved.5. Termination:Either Party may terminate this Contract in the event of a material breach by the other Party. Notice of termination must be given in writing, specifying the reason for termination and providing the breaching Party with a reasonable opportunity to cure the breach.6. Governing Law and Jurisdiction:This Contract shall be governed by and construed in accordance with the laws of [Country]. Any disputes arising out of or in connection with this Contract shall be subject to the exclusive jurisdiction of the courts of [Country].7. Entire Agreement:This Contract constitutes the entire agreement between the Parties and supersedes any prior representations, understandings, or agreements, whether written or oral, relating to the subject matter herein.In witness whereof, the Parties have executed this Building Construction Contract as of the Effective Date.[Contractor's Name]By: [Authorized Representative]Title: [Title][Owner's Name]By: [Authorized Representative] Title: [Title]。
建筑施工合同英文翻译模板
建筑施工合同英文翻译模板Construction Contract Template。
This Construction Contract ("Contract") is entered into as of [Contract Date], by and between [Owner Name] ("Owner") and [Contractor Name] ("Contractor").1. Scope of Work。
Contractor agrees to perform all construction work necessary for the completion of [Project Name] ("Project") in accordance with the plans and specifications prepared by [Architect/Engineer Name] ("Architect/Engineer"). The scope of work includes but is not limited to:a. Site preparation。
b. Excavation and grading。
c. Foundation and structural work。
d. Framing and roofing。
e. Exterior and interior finishes。
f. Mechanical, electrical, and plumbing systems。
g. Landscaping and site improvements。
2. Contract Price。
The total contract price for the Project is [Contract Price]. This price includes all labor, materials, equipment, and overhead costs necessary for the completion of the Project.3. Payment Terms。
建筑施工合同范本英语
建筑施工合同范本英语Building Construction Contract范本PART 1: GENERAL PROVISIONSContract Number: [具体合同编号]Date: [签订日期]This Building Construction Contract (hereinafter referred to as "the Contract") is made and entered into between:Party A (the Employer):Name: [甲方名称]Address: [甲方地址]Contact Person: [甲方联系人]Contact Information: [甲方联系电话等]Party B (the Contractor):Name: [乙方名称]Address: [乙方地址]Contact Person: [乙方联系人]Contact Information: [乙方联系电话等]PART 2: PROJECT DESCRIPTION1. Project Name: [项目名称]2. Project Location: [项目地点]3. Project Scope: [详细描述项目范围,包括但不限于工程内容、工程规模等]PART 3: CONTRACT PRICE AND PAYMENT1. The total contract price for the Project is [具体金额].2. Payment terms and methods shall be stipulated in accordance with the agreed schedule.PART 4: CONSTRUCTION PERIODThe construction period of the Project starts from [起始日期] and is expected to be pleted within [预计完工日期].PART 5: QUALITY REQUIREMENTSThe Contractor shall ensure that the construction work meets the relevant national and industry standards and quality requirements.PART 6: SAFETY AND ENVIRONMENTAL PROTECTIONBoth parties shall jointly ensure the safety and pliance with environmental protection regulations during the construction process.PART 7: WARRANTY AND LIABILITYThe Contractor shall provide a certn warranty period for the pleted project and be liable for any defects or damages caused during the warranty period.PART 8: DISPUTE RESOLUTIONIn case of disputes arising during the performance of the Contract, the parties shall first attempt to resolve them through negotiation. If negotiation fls, the disputes may be submitted to arbitration or litigation in accordance with the relevant laws and regulations.PART 9: OTHER TERMSOther terms and conditions such as contract termination, amendment, and force majeure events shall also be clearly stipulated in the Contract.Both parties sign and seal this Contract in duplicate, each party holding one copy, with the same legal effect.Party A (Employer): [甲方盖章]Party B (Contractor): [乙方盖章]Contact Person: [甲方代表签字]Contact Person: [乙方代表签字]。
建筑施工合同范本英语
建筑施工合同范本英语Construction Contract TemplateThis Construction Contract (the "Contract") is made and entered into as of ____________ (the "Effective Date"), and between ____________ ("Owner"), with a ing address of ____________, and ____________ ("Contractor"), with a ing address of____________.WHEREAS, Owner desires to construct a building or structure (the "Project") on the property located at ____________ (the "Property"), and Owner desires to engage Contractor to perform the construction work for the Project; and WHEREAS, Contractor is willing to perform the construction work for the Project in accordance with the terms and conditions set forth in this Contract.NOW, THEREFORE, in consideration of the mutual covenants and agreements set forth herein, and for other good and valuable consideration, the receipt and sufficiency of which are here acknowledged, the parties agree as follows:1. Scope of Work. Contractor shall perform the construction work for the Project in accordance with the plans and specifications attached hereto as Exhibit A (the "Plans and Specifications"). Contractor shall be responsible for providing all labor, materials, equipment, and other services necessary to plete the Project in a good and workmanlike manner.2. Contract Price. The total contract price for the Project shall be ____________ (the "Contract Price"). The Contract Price shall include all labor, materials, equipment, and other services necessary to plete the Project in accordance with the Plans and Specifications.3. Payment Terms. Payment for the Project shall be made in accordance with the following schedule:(a) Initial Payment: Upon execution of this Contract, Owner shall pay Contractor an initial payment of ____________ (the "Initial Payment").(b) Progress Payments: Thereafter, on a monthly basis, Contractor shall submit a request for payment for the work performed during the precedingmonth. The request for payment shall include a statement of the work performed, the costs incurred, and the percentage of pletion of the Project. Owner shall pay Contractor the amount requested within ____________ days after receipt of the request for payment.(c) Final Payment: Upon substantial pletion of the Project, Contractor shall submit a final request for payment. The final request for payment shall include a statement of the work performed, the costs incurred, and the percentage of pletion of the Project. Owner shall pay Contractor the remning balance of the Contract Price within ____________ days after receipt of the final request for payment.4. Time of Completion. Contractor shall plete the Project in accordance with the construction schedule attached hereto as Exhibit B (the "Construction Schedule"). Time is of the essence with respect to the pletion of the Project. If Contractor fls to plete the Project the pletion date set forth in the Construction Schedule, Contractor shall pay Owner a penalty of ____________ per day for each day of delay.5. Changes to the Project. Owner may request changes to the Project at any time during the course of the construction work. Any changes requested Owner shall be in writing and shall include a description of the requested change and the impact of the change on the Contract Price and the Construction Schedule. Contractor shall provide Owner with a written estimate of the additional costs and time required to implement the requested change. If Owner approves the requested change, the Contract Price and the Construction Schedule shall be amended accordingly.6. Warranty. Contractor warrants that the Project will be free from defects in materials and workmanship for a period of ____________ years after the date of substantial pletion of the Project. If any defects in materials or workmanship arise during the warranty period, Contractor shall, at its own expense, repr or replace the defective materials or workmanship.7. Indemnification. Contractor shall indemnify and hold harmless Owner from and agnst any and all clms, losses, damages, liabilities, and expenses (includingreasonable attorneys' fees and costs) arising out of or relating to the performance of the construction work Contractor or its employees, subcontractors, or agents.8. Insurance. Contractor shall mntn mercial general liability insurance in an amount not less than ____________ per occurrence and workers' pensation insurance in accordance with applicable law. Upon request, Contractor shall provide Owner with proof of such insurance.9. Termination. Either party may terminate this Contract for convenience upon written notice to the other party. If Owner terminates this Contract for convenience, Owner shall pay Contractor for the work performed and the costs incurred up to the date of termination. If Contractor terminates this Contract for convenience, Contractor shall be liable for any additional costs incurred Owner to plete the Project.10. Governing Law. This Contract shall be governed and construed in accordance with the laws of the state of ____________.11. Dispute Resolution. Any disputes arising out of or relating to this Contract shall be resolved through binding arbitration in accordance with the rules of the American Arbitration Association. The decision of the arbitrator shall be final and binding upon the parties.12. Entire Agreement. This Contract constitutes the entire agreement between the parties with respect to the subject matter hereof and supersedes all prior agreements。
施工合同范本英文版
施工合同范本英文版This Construction Contract ("Contract") is entered into on [insert date] by and between [Contractor Name], a company organized and existing under the laws of [insert jurisdiction], with its principal place of business at [Contractor Address], and [Owner Name], a company organized and existing under the laws of [insert jurisdiction], with its principal place of business at [Owner Address].1. Scope of Work: Contractor agrees to perform the construction work described in the project plans and specifications ("Work") at [Project Location]. The Work includes [describe in detail the scope of work to be performed].2. Time of Completion: Contractor agrees to complete the Work in a timely manner and in accordance with the schedule set forth in the project plans and specifications. Any delays in completion beyond the agreed-upon schedule shall be documented and agreed upon in writing by both parties.3. Payment: Owner agrees to pay Contractor the total contract price of [insert total contract price] for the completion of the Work. Payments shall be made in installments as follows: [insert payment schedule]. Owner shall make payments to Contractor within [insert number] days of receipt of an invoice.4. Changes: Any changes to the scope of work, specifications, or materials must be agreed upon in writing by both parties and may result in additional costs and/or time for completion.5. Insurance: Contractor shall maintain appropriate insurance coverage throughout the duration of the project, including but not limited to general liability insurance and workers' compensation insurance.6. Warranties: Contractor warrants that all work performed under this Contract shall be in accordance with industry standards and free from defects in workmanship and materials for a period of [insert warranty period].7. Termination: Either party may terminate this Contract upon written notice if the other party materially breaches any of its obligations under this Contract and fails to cure such breach within [insert cure period] days of receipt of written notice.8. Governing Law: This Contract shall be governed by the laws of [insert governing jurisdiction].IN WITNESS WHEREOF, the parties hereto have executed this Contract as of the date first above written.[Contractor Name]By: ________________________________Title: _______________________________ [Owner Name]By: ________________________________ Title: _______________________________ Date: _______________________________。
英语建筑施工合同范本
**Construction Contract**This Construction Contract (the "Contract") is made and entered into as of [Insert Date], by and between [Insert Contractor's Name], hereinafter referred to as the "Contractor," and [Insert Client's Name], hereinafter referred to as the "Client."**Recitals**WHEREAS, the Client desires to have certain construction services performed by the Contractor;WHEREAS, the Contractor is willing to perform such construction services upon the terms and conditions set forth herein;NOW, THEREFORE, in consideration of the mutual promises contained herein, the parties hereto agree as follows:**Article 1: Scope of Work**1.1 The Contractor agrees to perform all construction services necessary to complete the construction of [Insert Project Name] (the "Project") in accordance with the plans and specifications provided by the Client.1.2 The Contractor shall complete the Project within [Insert Completion Date], subject to any delays caused by Force Majeure events as definedin Article 12 of this Contract.**Article 2: Price and Payment Terms**2.1 The Contractor shall provide the Client with a detailed breakdown of the total cost of the Project, including labor, materials, equipment,and any other expenses (the "Price"). The Price shall be set forth inthe attached Schedule A.2.2 The Client shall pay the Contractor the Price for the completion of the Project, less any retainage as may be specified in Article 4 of this Contract, upon the satisfaction of the Contractor's performance of the Services.2.3 Payment shall be made by the Client to the Contractor in accordance with the payment schedule set forth in the attached Schedule B.**Article 3: Performance of Services**3.1 The Contractor shall perform the Services with reasonable care and skill, and in accordance with all applicable laws, regulations, and industry standards.3.2 The Contractor shall be responsible for the coordination and management of all subcontractors and suppliers involved in the performance of the Services.3.3 The Contractor shall provide the Client with regular updates on the progress of the Project, including but not limited to, weekly progress reports and milestone notifications.**Article 4: Retainage**4.1 The Client shall withhold a certain percentage of the Price as retainage ("Retainage") to ensure the satisfactory completion of the Project. The amount of Retainage shall be specified in the attached Schedule C.4.2 The Contractor shall be entitled to receive payment of the Retainage upon the satisfactory completion of the Project, as determined by the Client in its sole discretion.**Article 5: Default and Termination**5.1 If either party defaults in the performance of any material obligation provided in this Contract and such default continues for a period of [Insert Number] days after written notice thereof from the other party, the non-defaulting party may terminate this Contract by written notice to the defaulting party.5.2 In the event of termination, the Client shall be liable to pay the Contractor for any Services performed and expenses incurred up to the date of termination.**Article 6: Dispute Resolution**6.1 Any disputes arising out of or in connection with this Contractshall be referred to and finally resolved by arbitration in accordance with the rules of the [Insert Arbitration Association].6.2 The decision of the arbitrator(s) shall be final and binding upon the parties hereto, and judgment upon the award rendered by the arbitrator(s) may be entered in any court having jurisdiction thereof.**Article 7: Indemnification**7.1 The Contractor shall indemnify and hold harmless the Client against any and all claims, losses, damages, liabilities, and expenses (including but not limited to attorney's fees and court costs) arising out of or in connection with the performance of the Services.**Article 8: Governing Law and Jurisdiction**8.1 This Contract shall be governed by and construed in accordance with the laws of [Insert Jurisdiction].8.2 Any legal action or proceeding arising out of or in connection with this Contract shall be brought exclusively in the courts of [Insert Jurisdiction], and both parties hereby consent to the jurisdiction of such courts.**Article 9: Entire Agreement**9.1 This Contract constitutes the entire agreement between the parties with respect to the subject matter hereof and supersedes all prior agreements, understandings, negotiations, and discussions, whether oral or written, of the parties.**Article 10: Amendments**10.1 This Contract may be amended or modified only by a written instrument executed by both parties.**Article 11: Notices**11.1 All notices, requests, demands, and other communications under this Contract shall be in writing and shall be deemed to have been duly givenon the date of service if served personally on the party to whom notice is to be given, or on the third day after mailing if mailed to the party to whom notice is to be given, by first class mail, registered or certified, postage prepaid, and properly addressed as follows:To the Contractor:[Insert Contractor's Address]To the Client:[Insert Client's Address]**Article 12: Force Majeure**12.1 The parties agree that neither party shall be liable for anyfailure or delay in the performance of its obligations under this Contract due to any cause beyond its reasonable control, including but not limited to acts of God, labor disputes, or disruptions in transportation, provided that the affected party promptly notifies the other party of the existence and nature of such cause.**Schedule A: Detailed Breakdown of Price**[Attach detailed breakdown of the total cost of the Project, including labor, materials, equipment, and any other expenses]**Schedule B: Payment Schedule**[Attach payment schedule, including percentage of completion and corresponding payment amounts]**Schedule C: Retainage Amount**[Attach amount of Retainage to be withheld from the final payment]IN WITNESS WHEREOF, the parties have executed this Construction Contract as of the date first above written.[Insert Client's Name]By: ___________________________Name:Title:[Insert Contractor's Name]By: ___________________________ Name:Title:。
英语建筑施工合同范本
英语建筑施工合同范本This Construction Contract (the "Contract") is entered into as of [Date] by and between [Contractor Name], hereinafter referred to as the "Contractor", and [Owner Name], hereinafter referred to as the "Owner".1. Scope of Work: Contractor agrees to provide all labor, materials, equipment, and services necessary for the construction of [Description of Project] in accordance with the plans and specifications attached to this Contract.2. Time of Performance: The Contractor shall commence work on [Start Date] and complete the project by [Completion Date].3. Payment: The Owner agrees to pay the Contractor the total contract price of [Total Amount] in accordance with the following payment schedule: 50% upon signing of the Contract, 25% upon substantial completion of the project, and 25% upon final completion and acceptance by the Owner.4. Changes: Any changes to the scope of work must be agreed upon in writing by both parties and may result in a change to the contract price and/or completion date.5. Warranties: The Contractor warrants that all work will be performed in a good and workmanlike manner and will be free from defects for a period of [Warranty Period] from the date of completion.6. Indemnification: The Contractor agrees to indemnify and hold harmless the Owner from any claims, damages, or liabilities arising from the Contractor's work on the project.7. Termination: Either party may terminate this Contract with written notice if the other party breaches any terms of the Contract. Upon termination, the Contractor shall be entitled to payment for work completed up to the termination date.8. Governing Law: This Contract shall be governed by the laws of [State] and any disputes arising from the Contract shall be resolved through arbitration.In Witness Whereof, the parties have executed this Contract as of the date first above written.Owner: _______________________Contractor: _______________________。
施工合同中英文模板-construction-contract
资料可以编辑修改使用资料可以编辑修改使用资料可以编辑修改使用致力于数据挖掘,合同简历、论文写作、PPT设计、计划书、策划案、学习课件、各类模板等方方面面,打造全网一站式需求主要经营:网络软件设计、图文设计制作、发布广告等,公司秉着以优质的服务对待每一位客户,做到让客户满意Construction Contract工程合同PO No.: XXXXXXXBuyer:. Date of signature:甲方:签约日期:Seller:乙方:This Purchase Order is made by and between the Buyer and the Seller: Whereby the Buyer agrees to buy and the Seller agrees to sell the under mentioned commodity according to the terms and conditions stipulated below:甲乙双方经友好协商,一致就供应下列产品,达成如下条款:1. Scope of Supply and Price工作范围及价格明细2. Technical Requirement, Quality Requirement, Standard & Warranty Period:Seller shall carried out the construction in strict accordance with the National Standard and the requirements stipulated in the Technical Agreement No. ________which both party signed (see attached documents). The warranty period shall be 1 year after placement of Goods in service.技术要求、质量要求、技术标准和质保期限: 按国家标准和双方签定的技术协议(编号:______见附件)施工,质保期为投产后1年。
41-施工合同中英文模板-construction-contract
1Construction Contract工程合同PO No.:Buyer:. Date of signature:甲方: 签约日期:Seller:乙方:This Purchase Orderis made by and between the Buyer and the Seller:Whereby the Buyer agrees to buy and the Seller agrees to sell the undermentioned commodity according to the terms and conditions stipulated below: 甲乙双方经友好协商,一致就供应下列产品,达成如下条款:1. Scope of Supply and Price工作范围及价格明细ItemNo.Codes & StandardQtyUnit单位Unit Price Total Price(RMB)总金额(元)1Item, etc. 材料16530KG2.9047,93.002Item, etc. 材料5070KG4.8024,336.003Constructioncost 邯郸施工费18,000.004Freight 运费6,000.005Export packing cost 出口包装费13,000.006Third party inspection 第三方检测费9,500.00合计人民币金额大写:壹拾壹万捌仟柒佰柒拾叁圆整小写:¥118,773.002. Technical Requirement, Quality Requirement, Standard & Warranty Period:Seller shall carried out the construction in strict accordance withNational Standard and the requirements stipulated in Technical AgreementNo. ________which both party signed(see attached documents)The warranty2period shall be1 yearafter placement of Goods in service.技术要求、质量要求、技术标准和质保期限:按国家标准和双方签定的技术协议(编号:______见附件)施工,质保期为投产后1年。
建筑施工合同中英文对照版本
xxxx施工合同Construction Contract of xxxx发包方(甲方)xxxxParty A: xxxx承包方(乙方)xxxxParty B: xxxx本合同由如上列明的甲、乙双方按照《中华人民共和国合同法》、《建筑安装工程承包合同条例》以及国家相关法律法规的规定,结合本合同具体情况,于xx年x月x日在xx签订。
This contract is signed by the two Parties in xxxx on xxxx according to the “Contract Law of the People’s Republic of China”, the “Regulation on Building and Installation Contracting Contract”, and other relevant national laws and regulations, as well as the specific nature of this project第一条总则Article 1 General Principles1.1合同文件Contract Documents本合同包含合同、展示、施工图纸、作法说明、招投标文件以及合同所指的其他文件,它们均被视为合同的一部分。
合同文件应该能够相互解释,互为说明。
组成本合同的文件及优先解释的顺序如下:本合同、中标通知书、投标书及其附件、标准、规范及有关技术文件、图纸、工程量清单及工程报价单或预算书。
合同履行中,发包人承包人有关工程的洽商、变更等书面下一或文件视为本合同的组成部分。
This contract includes the contract itself, exhibits, construction drawings, explanations of work procedures, tender documents, as well as other documents specified by the contract. The contract documents should be mutually explainable and mutually descriptive. The documents that constituted the contract and the priority hierarchy of explanations of the documents are as follows: this contract; the official letter of winning the tender; Letter of bidding and its annex, standards, guidelines, and relevant technical documents, drawings, Bill of Quantity (BOQ), quotation of prices, and project budget. During the implementation of the contract, any written agreements or documents between two parties such as change-orders are also regarded will be deemed as part of this contract.1.1.1项目概况Project Introduction1.1.2工程名称:xxxxName of Project: xxxx1.1.3工程地点:xxxxLocation of Project: xxxx1.1.3.1工程范围:除了本合同其他条款另有说明外,乙方应提供为履行合同所需的所有服务,用品以及其他保障工程进行所需的必要花费以完成下列工作:Scope of the project: unless otherwise explained by other articles in this contract, Party B shall provide all services, utensils, and other necessary cost for the implementation of this contract; the scope of project includes, but not limited to:※室内装饰工程,详见附件一和附件二Inner decoration, see appendix 1 & 2※室外装饰工程(门窗、屋面、台阶等),详见附件一和附件二Façade(including doors, windows, roof and stairs) see appendix 1 & 2※电器工程,详见附件一和附件二Electronic Engineering, see appendix 1 & 2※空调工程,详见附件一和附件二Air Conditioning System, see appendix 1 & 2※给排水及采暖工程,详见附件一和附件二Water Supply, Sewage and Heating System, see appendix 1 & 2※消防工程Fire Control System, see appendix 1 & 2※其他图纸上所列项目(任何对原定设计的变更应提供新的图纸并有甲方的签字确认)以上所有的工程项目以下统称为“工程”。
建设工程施工合同中英(3篇)
第1篇Contract No.: [Contract Number]Date: [Contract Date]Parties Involved:1. Contractor:- Name: [Contractor's Name]- Address: [Contractor's Address]- Contact Person: [Contractor's Contact Person]- Contact Information: [Contractor's Contact Information]2. Client:- Name: [Client's Name]- Address: [Client's Address]- Contact Person: [Client's Contact Person]- Contact Information: [Client's Contact Information]Scope of Work:1. Project Description: [Detailed description of the construction project, including type of project, location, and main objectives.]2. Work to be Performed: [List of all the specific tasks and activities to be carried out by the Contractor, including design, construction, and any other related services.]3. Deliverables: [Detailed list of all deliverables, including but not limited to drawings, specifications, progress reports, and final certificates of completion.]Contract Price and Payment Terms:1. Contract Price: [Total contract price including all costs, fees, and expenses.]2. Payment Schedule:- Progress Payments: [Details of progress payments, including payment milestones, percentage of work completed, and payment schedule.]- Final Payment: [Conditions and terms for the final payment, including completion and final inspection requirements.]3. Retention: [Percentage of the contract price to be retained until the project is completed and all conditions are met.]Duration of the Contract:1. Start Date: [Date when the work is to begin.]2. Completion Date: [Estimated completion date based on the project scope and schedule.]3. Extension of Time: [Conditions under which the completion date may be extended and the process for requesting an extension.]Quality Standards:1. Quality Requirements: [Specific quality standards to be adhered to during the construction process, including materials, workmanship, and compliance with relevant codes and regulations.]2. Inspection and Testing: [Provisions for regular inspections and testing to ensure compliance with quality standards.]Warranties and Liabilities:1. Warranties: [Details of warranties provided by the Contractor, including duration and scope of warranty coverage.]2. Liabilities: [Responsibilities and liabilities of the Contractor in the event of any defects, damages, or claims arising from the work performed under the contract.]Force Majeure:1. Definition: [Definition of force majeure events, including acts of God, war, strikes, labor disputes, and any other events beyond the reasonable control of the Contractor.]2. Effect: [Provisions regarding the suspension of the contract and the obligations of the parties in the event of a force majeure event.]Dispute Resolution:1. Arbitration: [Provisions for resolving disputes, including the procedure for arbitration and the appointment of an arbitrator.]2. Legal Actions: [Conditions under which legal actions may be taken and the jurisdiction of any disputes.]General Provisions:1. Governing Law: [The laws of the jurisdiction that will govern the interpretation and enforcement of the contract.]2. Amendments: [Provisions regarding the process for making amendments to the contract.]3. Termination: [Conditions under which the contract may be terminated and the consequences of termination.]Acknowledgment:The parties hereto acknowledge that they have read, understand, and agree to be bound by the terms and conditions of this Construction Engineering Contract.---Contract No.: [Contract Number]Date: [Contract Date]Contractor:[Signature of Contractor] ___________________________[Name of Contractor] ___________________________Client:[Signature of Client] ___________________________[Name of Client] ___________________________---Note: This is a general template for a construction engineering contract. Specific contracts may require additional details or clauses based onthe nature of the project and the requirements of the parties involved.It is recommended that legal advice be sought when drafting or entering into a construction contract.第2篇Contract No. __________Contract Date: __________Contractor: __________Client: __________1. IntroductionThis Construction Engineering Contract (hereinafter referred to as "the Contract") is entered into between __________ (hereinafter referred toas "the Contractor") and __________ (hereinafter referred to as "the Client") on the basis of mutual consultation, agreement, and mutual benefit. The Contractor agrees to construct and complete theconstruction project as specified in the Contract, and the Client agrees to pay the agreed contract price for the completed construction project. The Contract is binding on both parties and shall be strictly observed.2. Project Description2.1 Project Name: __________2.2 Project Location: __________2.3 Project Scope: The construction project includes the following scopes:a. Civil engineering works: __________b. Electrical engineering works: __________c. Mechanical engineering works: __________d. Other relevant works: __________3. Contract Price3.1 The total contract price for the construction project is __________ Yuan, which is subject to the following terms:a. The Contractor shall provide detailed project estimates and invoices for the Client's approval.b. The Client shall make payment in accordance with the agreed payment schedule.c. Any additional costs due to changes in the project scope or unforeseen circumstances shall be agreed upon by both parties in writing.4. Performance and Quality4.1 The Contractor shall ensure that the construction project is completed within the agreed time frame and meets the quality standards specified in the Contract.4.2 The Contractor shall adhere to the relevant national standards,local regulations, and industry practices during the construction process.4.3 The Client shall have the right to inspect and accept the construction project at any time during the construction process.5. Payment Schedule5.1 The payment schedule is as follows:a. Upon the signing of the Contract, the Client shall pay the Contractor a deposit of __________ Yuan.b. Upon the completion of each phase of the project, the Contractor shall submit an invoice to the Client for payment.c. The Client shall pay the invoice within __________ days upon receipt.6. Insurance6.1 The Contractor shall obtain and maintain all necessary insurance policies to cover the risks associated with the construction project, including but not limited to:a. Public liability insuranceb. Workers' compensation insurancec. Property insurance7. Termination of the Contract7.1 Either party may terminate the Contract in writing if the other party fails to comply with the terms and conditions of the Contract.7.2 Upon termination of the Contract, the Contractor shall immediately cease all construction activities and the Client shall pay the Contractor for the work completed up to the date of termination.8. Dispute Resolution8.1 Any disputes arising from the execution of the Contract shall be settled through friendly negotiations between the parties.8.2 If the parties fail to reach an agreement through negotiations, the dispute shall be submitted to the relevant arbitration commission for resolution.9. Governing LawThis Contract shall be governed by the laws of __________.10. Final Provisions10.1 This Contract constitutes the entire agreement between the parties and supersedes all prior agreements and understandings, whether written or oral.10.2 Any amendment or modification of this Contract shall be effective only if it is in writing and signed by both parties.Contractor Signature: ___________________________Client Signature: ___________________________Date: ___________________________---Construction Engineering ContractContract No. __________Contract Date: __________Contractor: __________Client: __________1. Introduction本建筑工程合同(以下简称“本合同”)由__________(以下简称“承包商”)与__________(以下简称“业主”)在相互协商、一致同意和互惠互利的基础上签订。
施工合同中英文合同范本
施工合同中英文合同范本CONSTRUCTION CONTRACTThis Construction Contract (the "Contract") is made and entered into as of the _____ day of ______, 20__, by and between:[Company Name], a [State] corporation with its principal place of business at [Address] (hereinafter referred to as "Owner"), and[Contractor Name], a [State] corporation with its principal place of business at [Address] (hereinafter referred to as "Contractor").WHEREAS, the Owner desires to engage the Contractor to perform certain construction work, and the Contractor is willing to perform such work upon the terms and conditions set forth herein.NOW, THEREFORE, in consideration of the mutual promises and covenants contained herein and other good and valuable consideration, the receipt and sufficiency of which are hereby acknowledged, the parties agree as follows:1. SCOPE OF WORKThe Contractor shall perform the construction work (the "Work") as described in the attached specifications (the"Specifications") and in accordance with the drawings and plans attached hereto (the "Plans").2. CONTRACT PRICEThe total price for the Work shall be [$_____] (the "Contract Price"), which shall be paid by the Owner to the Contractorin accordance with the payment schedule set forth in Exhibit A.3. PERFORMANCE PERIODThe Work shall commence on the _____ day of ______, 20__, and shall be completed by the _____ day of ______, 20__ (the "Completion Date").4. CHANGE ORDERSAny changes to the Work shall be documented in writing and signed by both parties (a "Change Order"). The Contractor shall provide a revised estimate of the Contract Price for any Change Order.5. WARRANTYThe Contractor warrants that all Work will be performed in a good and workmanlike manner and will conform to the Specifications and Plans. The warranty period shall be [___] years from the date of Substantial Completion.6. DEFAULTIf either party defaults in the performance of any of its obligations under this Contract, the non-defaulting party may terminate this Contract upon written notice and may pursue any and all legal remedies available.7. DISPUTE RESOLUTIONAny disputes arising out of or in connection with this Contract shall be resolved by arbitration in accordance with the rules of the American Arbitration Association.8. ASSIGNMENTThis Contract and the rights and obligations hereunder may not be assigned by either party without the prior written consent of the other party, except that the Owner may assign this Contract to a subsequent owner of the property.9. NOTICESAll notices required or permitted under this Contract shall be in writing and shall be deemed given when delivered personally or by overnight courier or mailed by registered or certified mail, return receipt requested, to the addresses set forth above or to such other address as either party may designate in writing.10. GOVERNING LAWThis Contract shall be governed by and construed in accordance with the laws of the State of [State].11. ENTIRE AGREEMENTThis Contract, including all exhibits and attachments hereto, constitutes the entire agreement between the parties and supersedes all prior negotiations, representations, and understandings between the parties.12. AMENDMENTSThis Contract may be amended only in writing signed by both parties.IN WITNESS WHEREOF, the parties have executed this Contract as of the date first above written.[Owner's Name] [Contractor's Name]By: _______________________ By: _______________________ [Title] [Title][Date] [Date]EXHIBIT APayment Schedule1. A deposit of [___%] of the Contract Price shall be paid upon execution of this Contract.2. Progress payments shall be made as follows:- [___%] upon completion of [milestone].- [___%] upon completion of [milestone].- [___%] upon substantial completion of the Work.3. The final payment, including any retention, shall be made upon final completion and acceptance of the Work.(The rest of this page is intentionally left blank)[Signature Page]。
施工合同范本英文
施工合同范本英文Construction Contract TemplateThis Construction Contract (the "Contract") is made and entered into as of [date] and between [Party A's name] (hereinafter referred to as "Party A") and [Party B's name] (hereinafter referred to as "Party B").Article 1. Project DescriptionThe project to be constructed under this Contract is described as [detled project description].Article 2. Contract PriceThe total contract price for the project is [amount in words and figures].Article 3. Time for CompletionParty B undertakes to plete the construction within [specified time period].Article 4. Payment TermsParty A shall make payments to Party B in accordance with the following schedule: [list specific payment terms and amounts].Article 5. Quality AssuranceParty B guarantees the quality of the construction work and shall be responsible for any defects or deficiencies that may occur within [period of warranty].Article 6. Force MajeureIn the event of force majeure circumstances beyond the control of either party, such as natural disasters, war, etc., the parties shall negotiate in good fth to determine an appropriate course of action.Article 7. Dispute ResolutionIn the event of any disputes or differences arising out of or in connection with this Contract, the parties shall attempt to resolve them through friendly negotiation. If such negotiation fls, the dispute shall be submitted to [designated arbitration body or court] for resolution.Article 8. TerminationEither party may terminate this Contract in the event of a material breach the other party, subject to the provisions of this Article.Article 9. MiscellaneousThis Contract contns the entire agreement between the parties and supersedes all prior agreements and understandings. Any amendments or modifications to this Contract must be in writing and signed both parties.IN WITNESS WHEREOF, the parties have signed this Contract as of the date first above written.Party A: [signature]Party B: [signature]。
建筑施工英文合同范本
建筑施工英文合同范本Construction ContractThis Construction Contract (the "Contract") is made and entered into as of [date] and between [Contractor's Name] (the "Contractor") and [Client's Name] (the "Client").1. Project DescriptionThe Contractor shall undertake the construction project described as follows: [Describe the project in detl, including location, scope, and specifications]2. Contract PriceThe total contract price for the pletion of the project is agreed to be [amount in figures] ($[amount in words]). This price includes all materials, labor, equipment, and other costs associated with the project, unless otherwise specified.3. Payment ScheduleThe Client shall make payments to the Contractor as follows:[Percentage or amount] upon the signing of this Contract.[Percentage or amount] upon the pletion of [specific milestone or stage].The remning balance upon the substantial pletion and acceptance of the project.4. Project TimelineThe Contractor shall mence work on or before [start date] and shall plete the project [pletion date], subject to extensions for causes beyond the Contractor's control as provided herein.5. Workmanship and MaterialsThe Contractor shall perform the work in a good and workmanlike manner and shall use materials of good quality that conform to the project specifications.6. Changes and AmendmentsAny changes or amendments to the scope of work, specifications, or contract price shall be made in writing and signed both parties.7. Inspection and AcceptanceThe Client shall have the right to inspect the work at reasonable intervals. The project shall be considered accepted upon the Client's written notice of acceptance or upon the expiration of [number of days] after substantial pletion without written notice of rejection.8. WarrantiesThe Contractor warrants that the work will be free from defects in materials and workmanship for a period of [warranty period] from the date of acceptance.9. Force MajeureNeither party shall be liable for delays or flures in performance caused events beyond their reasonable control, such as natural disasters, wars, or government actions.10. TerminationThis Contract may be terminated either party in the event of a material breach the other party, subject to prior written notice and an opportunity to cure.11. Dispute ResolutionAny disputes arising under this Contract shall be resolved through arbitration or litigation as mutually agreed the parties.12. Governing LawThis Contract shall be governed and construed in accordance with the laws of [jurisdiction].IN WITNESS WHEREOF, the parties have executed this Contract as of the date first above written.Contractor: [Contractor's Name]Signature: [Contractor's Signature]Date: [Date]Client: [Client's Name]Signature: [Client's Signature]Date: [Date]。
施工合同中英文
施工合同中英文Construction Contract 施工合同Contract No: XXXX 合同编号:XXXXThis Construction Contract (hereinafter referred to as "the Contract") is made and entered into by and between:Party A: [Name of the Client] (甲方:[客户名称])Address: [Address of the Client] (住址:[客户地址])Contact Person: [Contact Person's Name] (联系人:[联系人姓名])Contact Number: [Contact Person's Phone Number] (联系电话:[联系人电话])Party B: [Name of the Contractor] (乙方:[承包商名称])Address: [Address of the Contractor] (住址:[承包商地址])Contact Person: [Contact Person's Name] (联系人:[联系人姓名])Contact Number: [Contact Person's Phone Number] (联系电话:[联系人电话])Whereas Party A intends to construct [Description of the Project] (hereinafter referred to as "the Project"), and Party B possesses the expertise and resources necessary to complete the construction, the Parties agree to enter into this Contract based on the following terms and conditions:1. Project Scope 项目范围1.1 Party B shall be responsible for the construction of the Project according to the plans, specifications, and drawings provided by Party A.1.2 The Project includes, but is not limited to, the following:- [List of major components or tasks involved]2. Duration 工期2.1 The construction period shall be from [Start Date] to [Completion Date]. Party B shall exert its best efforts to complete the construction within the agreed timeframe.2.2 In the event that unforeseen circumstances arise, resulting in delays or hindrances to the construction progress, Party B shall promptly notify Party A and propose a revised timeline for completion.3. Payment 付款方式3.1 The total contract price for the Project is [Total Contract Price], payable according to the following schedule:- [Payment milestones and amounts]3.2 Party A shall make payments to Party B within [Number of days] days upon receipt of the corresponding invoice or payment request.4. Quality Assurance and Warranty 质量保证与保修期4.1 Party B shall ensure that all construction work and materials used in the Project comply with relevant laws, regulations, and industry standards.4.2 Party B shall provide a warranty period of [Warranty Period], during which it shall be responsible for any defects or deficiencies discovered in the construction work. Party B shall promptly rectify such issues at no additional cost to Party A.5. Termination 终止5.1 Either Party may terminate this Contract in the event of a material breach by the other Party. The terminating Party shall provide written notice specifying the breach and allowing the breaching Party a period of [Number of days] days to rectify the breach.5.2 In the event of termination, both Parties shall settle any outstanding payments or liabilities in accordance with the terms of this Contract.6. Confidentiality 保密性6.1 Both Parties agree to keep any non-public information obtained during the execution of this Contract confidential and not disclose, reproduce, or distribute such information without the other Party's prior written consent.7. Governing Law and Jurisdiction 适用法律与管辖权7.1 This Contract shall be governed by and construed in accordance with the laws of [Jurisdiction]. Any disputes arising out of or in connection with this Contract shall be submitted to the exclusive jurisdiction of the courts of [Jurisdiction].8. Entire Agreement 完整协议8.1 This Contract constitutes the entire agreement between the Parties and supersedes any prior understandings, agreements, or representations, whether oral or written, relating to the subject matter hereof.In witness whereof, the Parties have executed this Construction Contract as of the Effective Date first written above.Party A:Signature: _____________________Printed Name: __________________Date: _________________________Party B:Signature: _____________________Printed Name: __________________Date: _________________________。
施工合同中英文模板-construction-contract (2)
Construction Contract工程合同PO No.: XXXXXXXBuyer:. Date of signature:甲方:签约日期:Seller:乙方:This Purchase Order is made by and between the Buyer and the Seller: Whereby the Buyer agrees to buy and the Seller agrees to sell the under mentioned commodity according to the terms and conditions stipulated below:甲乙双方经友好协商,一致就供应下列产品,达成如下条款:1. Scope of Supply and Price工作范围及价格明细2. Technical Requirement, Quality Requirement, Standard & Warranty Period:Seller shall carried out the construction in strict accordance with the National Standard and the requirements stipulated in the Technical Agreement No. ________which both party signed (see attached documents). The warranty period shall be 1 year after placement of Goods in service.技术要求、质量要求、技术标准和质保期限: 按国家标准和双方签定的技术协议(编号:______见附件)施工,质保期为投产后1年。
3. Job Sites:施工地点:4. Construction Equipment, Tools & Field Personnel Management:施工设备工具及现场人员管理:(1) All the construction equipment and tools shall be provided by Seller.所有施工用设备及工具由乙方自带。
建设工程施工合同中英文翻译件范本8篇
建设工程施工合同中英文翻译件范本8篇篇1建设工程施工合同Contract of Construction Engineering一、合同当事人The Parties to the Contract1. 发包方(甲方):- 单位名称:江苏某某建设集团有限公司- 地址:南京市某某区某某街某某号- 法定代表人:张先生- 电话:+86-12345678901- 电子邮箱:[*****************](mailto:*****************)2. 承包方(乙方):- 单位名称:南京某某建筑有限公司- 地址:南京市某某区某某街某某号- 法定代表人:李女士- 电话:+86-10987654321- 电子邮箱:[**************](mailto:**************)二、合同标的The Subject of the Contract本合同标的为江苏某某建设集团有限公司委托南京某某建筑有限公司承建的“某某花园”住宅楼建设项目。
项目位于南京市某某区,合同总价为人民币壹亿元整(¥1,000,000,000元)。
三、工程范围和内容Scope and Content of the Works1. 土建工程:包括基础工程、主体结构、屋面工程等。
2. 装饰工程:包括内外装饰、门窗安装等。
3. 水电安装:包括给水、排水、电气照明等。
4. 其他附属设施:包括道路、绿化、景观等。
四、工期和进度Time Limit and Progress of the Works1. 开工日期:本合同自签订之日起生效,工期为36个月。
2. 进度要求:乙方需按照甲方提供的施工进度计划表执行,确保每月完成计划工程量。
3. 延期处理:如因乙方原因造成工期延误,乙方需承担相应的违约责任和赔偿责任。
五、质量与验收Quality and Acceptance1. 质量标准:乙方必须按照国家和地方现行施工规范及标准施工,确保工程质量达到合格标准。
英文建设工程施工合同范本
英文建设工程施工合同范本合同编号:[Contract Numer]合同名称:[roject Name] Construction Contract合同日期:[Date]甲方(业主):[Owner's Name]乙方(承包商):[Contractor's Name]鉴于甲乙双方同意按照以下条款和条件进行合作,现达成如下合同:一、合同目的本合同旨在规范甲乙双方在[工程名称]建设工程施工过程中的权利、义务和责任,确保工程质量、安全和进度,保障双方的合法权益。
二、工程描述本工程位于[Location],包括[Descrition of the Work]。
工程将按照[Standards and Codes]进行施工,并满足[Secifications]的要求。
三、合同价格合同总价为[Total Contract rice],包含所有必要的材料、劳动力、设备和管理费用。
价格根据[ricing asis]确定,并在附录中详细列出。
四、工期与进度工程计划开工日期为[Start Date],竣工日期为[Comletion Date]。
乙方应提交详细的施工进度计划,并定期更新进度报告。
五、质量要求乙方必须遵守所有适用的国家和行业标准,确保工程质量符合合同要求。
甲方有权对工程进行检查,以确保质量标准得到满足。
六、变更与调整如遇设计变更或不可预见的条件,双方应及时协商,对合同内容进行相应的调整。
所有变更需书面形式确认,并作为合同的一部分。
七、支付条款乙方按合同约定完成工程阶段后,可向甲方提出支付申请。
甲方应在收到发票后的[Numer of Days]天内完成付款。
八、保险与责任乙方应投保包括但不限于工程一切险、第三方责任险等保险。
双方应明确各自的风险和责任范围,并在发生争议时,通过协商或仲裁解决。
九、违约与终止如一方未能履行合同义务,另一方有权要求补救或终止合同。
终止合同需提前通知,并说明终止原因。
十、法律与争议解决本合同受[Governing Law]的管辖。
- 1、下载文档前请自行甄别文档内容的完整性,平台不提供额外的编辑、内容补充、找答案等附加服务。
- 2、"仅部分预览"的文档,不可在线预览部分如存在完整性等问题,可反馈申请退款(可完整预览的文档不适用该条件!)。
- 3、如文档侵犯您的权益,请联系客服反馈,我们会尽快为您处理(人工客服工作时间:9:00-18:30)。
Construction Contract工程合同PO No.: XXXXXXXBuyer:. Date of signature:甲方:签约日期:Seller:乙方:This Purchase Order is made by and between the Buyer and the Seller: Whereby the Buyer agrees to buy and the Seller agrees to sell the under mentioned commodity according to the terms and conditions stipulated below:甲乙双方经友好协商,一致就供应下列产品,达成如下条款:1. Scope of Supply and Price工作范围及价格明细2. Technical Requirement, Quality Requirement, Standard & Warranty Period:Seller shall carried out the construction in strict accordance with the National Standard and the requirements stipulated in the Technical Agreement No. ________which both party signed (see attached documents). The warranty period shall be 1 year after placement of Goods in service.技术要求、质量要求、技术标准和质保期限: 按国家标准和双方签定的技术协议(编号:______见附件)施工,质保期为投产后1年。
3. Job Sites:施工地点:4. Construction Equipment, Tools & Field Personnel Management:施工设备工具及现场人员管理:(1) All the construction equipment and tools shall be provided by Seller.所有施工用设备及工具由乙方自带。
(2) Buyer will coordinate and arrange the electricity and water supply on the site.现场施工用水电由甲方协调安排。
(3) Buyer will be responsible for all the lifting work during the construction on site.现场施工过程中的吊装工作由甲方负责。
(4) Seller shall be responsible for the management of its field personnel safety; Seller should provide reasonable protection and insurance for its personnel’s safety. All the personnel injury and property damage caused by Seller’s failure of management shall be borne by Seller.现场施工人员管理由乙方负责。
乙方应对人员的安全等方面提供合理的保障,由于乙方管理原因造成的人身伤亡及财产损失由乙方承担。
5. Construction Time, delay and Postpone合同工期、工期延误、工期顺延:(1) Buyer shall issue a Notice to Seller about the construction one week prior the date of the construction start.甲方提前一周通知乙方施工时间。
(2) Construction period will be 15 days from the date of issuance of the order to commence the construction from Buyer.自甲方发出开工令之日算起,工程工期15天。
(3) Construction period may be postponed as Buyer agreed after he certified that the delay not caused by Seller.非乙方原因造成工期延误,须经甲方确认后工期顺延。
(4) The start time of the construction shall be subject to the order to commence by Buyer. Seller shall unconditionally follow the overall project schedule of Buyer. Buyer shall be entitled to evaluate and adjust Seller’s construction plan.开工时间以甲方开工令为准。
乙方应无条件服从甲方的整体进度计划,甲方有权对乙方制定的工期安排进行审核、调整。
(5) Liquidated Damage: If seller fails to complete the construction on time as stipulated in the Contract, Seller agrees to pay a penalty at the rate of 1% of the Total Value per day of delay. No bonus for early completion.合同工期的延期损失赔偿费:工期每延期一天,乙方承担的工期违约罚款为乙方承包范围内的工程结算价款的1%。
提前工期不予奖励。
6. Standard and method of acceptance inspection:Subject to the requirement in the Attached Technical Agreement.验收标准、方法: 按照技术协议的要求进行验收。
7. Payment Term 结算方式和期限: *(1) 50% of the Total Contract Value will be paid by T/T within 10 working days after the first lot of material arrived at the site and accepted by Buyer, Seller shall provide VAT invoice with the total contract value to Buyer. *第一批材料到现场后经甲方验收合格,乙方开具合同全额的17%增值税发票10个工作日内,付合同总金额50%。
*(2) 40% of the Total Contract Value will be paid by T/T within 10 working days after the construction completed and accepted by Buyer.*施工完成经甲方验收合格10个工作日内支付合同总金额的40%。
(3) 10% of the Total Contract Value will be paid by T/T after one year normal operation of the facility and theWarranty Period expired. *剩下的10%作为质保金,设备正常运行1年后付清。
(4) In case of the site construction in Iran, Buyer will be responsible for visa, round-trip fares and traveling expense, food and accommodation, and 30 US Dollar daily subsidies for each of Seller’s construction personnel on Iran Site. All of the cost will be paid by T/T within 10 working days after the construction completed and Buyer received related bills provided by Seller and accepted these bills..若需乙方前往伊朗项目现场施工,甲方负责乙方施工人员的签证、往返车旅费、食宿,并补助乙方每人30美金/天。
以上费用于现场施工完毕后,乙方提交相关票据,甲方收到票据核实无误10个工作日内结算。
8. Delay and Penalty 违约责任:(1) If there is any defect or mistake of construction quality, Seller shall repair and replace immediately at its own cost. If Seller fails to solve defect or mistake could not be , Buyer shall have right to return the Goods and claim to Seller for loss there caused.如果乙方施工质量出现问题,乙方需无偿即时修复或更换,如再不能解决,甲方可向乙方退货、索赔。
(2) In case Seller’s construction can not accomplish as per Buyer’s project schedule, and failed to keep up with the schedule, thus to seriously influence the whole schedule, or Seller’s poor quality of construction resulted Buyer’s whole project quality could not satisfy Owner’s quality standard, Seller shall compensate all Buyer’s loss there caused in addition to the normal delay penalty..如因乙方的原因使该项目的施工不能按照甲方的进度计划完成,并经甲方纠偏无效且实际影响了甲方的整个工程进度,或因该项目的验收质量导致甲方整个工程的质量达不到业主质量标准,除扣除正常的工期延期罚款外,经业主认定后乙方应赔偿由此给甲方造成的损失。