工程施工合同中英文

合集下载

建设工程施工合同中英文对照版

建设工程施工合同中英文对照版中英文建设工程施工合同Contract for Construction Project本合同是由承包人（以下简称“甲方”）和业主（以下简称“乙方”）共同订立，旨在规定双方在建设工程项目中的权益和义务。

This contract is entered into by and between the Contractor (hereinafter referred to as "Party A") and the Owner (hereinafter referred to as "Party B") to regulate the rights and obligations of both parties in the construction project.总则 General Provisions第一条项目名称及工程地点：本工程名称为_________，位于_________。

Article 1: Project Name and Location: The name of the project is__________, located in __________.第二条总承包范围：甲方应按照乙方的要求，完成工程项目的设计、施工、验收等工作。

Article 2: Scope of General Contracting: Party A shall complete the design, construction, and acceptance of the project in accordance with PartyB's requirements.第三条施工期限：本工程的施工期限为_________，甲方必须按时完成工程，并交付乙方使用。

Article 3: Construction Period: The construction period of this project is __________. Party A must complete the project on time and deliver it to Party B for use.义务与责任 Obligations and Responsibilities第四条甲方责任：甲方应根据乙方的要求，制定合理的工程施工方案，并保证工程按照合同和法律法规的要求进行。

施工合同中英文模板

施工合同中英文模板CONSTRUCTION CONTRACTTHIS CONTRACT is made and entered into as of [Insert Date], by and between [Insert Client Name], hereinafter referred to as "Client," and [Insert Contractor Name], hereinafter referred to as "Contractor."1. SCOPE OF WORKThe Contractor agrees to perform the construction services described in the attached Statement of Work (SOW) for the project identified as [Insert Project Name].2. CONTRACT AMOUNTThe total contract price for the work described in the SOW is [Insert Total Contract Price]. This price includes all labor, materials, equipment, and services necessary to complete the work.3. PAYMENT TERMSThe Client shall make payments to the Contractor as follows: a. [Insert Percentage] percent of the total contract price upon signing of this contract.b. [Insert Percentage] percent of the total contract price upon completion of [Insert Milestone].c. The remaining balance upon satisfactory completion of the work and acceptance by the Client.4. SCHEDULEThe work shall commence on [Insert Start Date] and be completed by [Insert Completion Date].5. PERFORMANCE BONDThe Contractor shall provide a performance bond in the amount of [Insert Bond Amount] to guarantee the completion of the work.6. WARRANTYThe Contractor warrants that all work will be performed in a professional and workmanlike manner and in accordance with the SOW.7. TERMINATIONEither party may terminate this contract for cause upon written notice to the other party if there is a material breach of any of the terms of this contract.8. DISPUTESAny disputes arising out of or in connection with this contract shall be resolved by [Insert Method of Dispute Resolution, e.g., arbitration, mediation, etc.].9. APPLICABLE LAWThis contract shall be governed by and construed in accordance with the laws of [Insert Jurisdiction].10. ENTIRE AGREEMENTThis contract, including the attached SOW and any exhibits, constitutes the entire agreement between the parties andsupersedes all prior negotiations, representations, and agreements.11. AMENDMENTSThis contract may be amended only in writing signed by both parties.12. NOTICESAll notices required or permitted by this contract shall be in writing and delivered to the addresses set forth below or to such other addresses as either party may designate in writing.Client: [Insert Client Name and Address]Contractor: [Insert Contractor Name and Address]IN WITNESS WHEREOF, the parties have executed this contract as of the date first above written.CLIENT[Insert Client Name]By: [Insert Authorized Signature]CONTRACTOR[Insert Contractor Name]By: [Insert Authorized Signature]Title: [Insert Title]STATEMENT OF WORK (SOW)1. PROJECT DESCRIPTIONA detailed description of the project, including the objectives, deliverables, and any specific requirements.2. WORK SCHEDULEA detailed schedule of the work, including milestones and deadlines.3. QUALITY REQUIREMENTSThe quality standards that the work must meet.4. SAFETY REQUIREMENTSSafety protocols and procedures that must be followed during the project.5. SUBMISSIONSA list of all documents, reports, or other submissions required from the Contractor.6. INSPECTION AND ACCEPTANCEProcedures for the Client's inspection of the work and acceptance of the project.7. CHANGE ORDERSProcedures for requesting and implementing changes to the scope of work.8. COMPLETION AND FINAL PAYMENTCriteria for determining when the work is complete and the conditions for final payment.9. WARRANTY AND MAINTENANCEDetails of any warranties provided by the Contractor and any maintenance services included.10. ADDITIONAL TERMSAny other specific terms and conditions relevant to the project.Please note that this is a template and should be reviewed by a legal professional to ensure it meets the specific needs and legal requirements of your project.。

施工合同_英文版

Contract for ConstructionThis Contract for Construction (the "Contract") is made and entered into as of [Date], by and between [Contractor's Name], a [Contractor's Jurisdiction] corporation ("Contractor"), and [Owner's Name], a [Owner's Jurisdiction] individual ("Owner").1. Scope of Work1.1 The Contractor agrees to perform all labor and services necessary to complete the construction of the residential building located at [Project Address] (the "Project") in accordance with the plans and specifications provided by the Owner.1.2 The Contractor shall perform the work in a workmanlike manner and in accordance with all applicable laws, regulations, and industry standards.1.3 The Contractor shall be responsible for the procurement and installation of all materials, fixtures, and equipment necessary for the completion of the Project, unless otherwise specified by the Owner.2. Term and Commencement2.1 The term of this Contract shall commence on the date of execution and shall continue until the Project is completed, unless otherwise terminated in accordance with this Contract.2.2 The Contractor agrees to commence work on the Project within [number of days] after the execution of this Contract, and to complete the work within [number of days] after the commencement of work.3. Payment3.1 The Owner agrees to pay the Contractor the sum of [total contract price] for the completion of the Project, as set forth in the attached Schedule A.3.2 Payment shall be made by the Owner to the Contractor in accordance with the payment schedule set forth in the attached Schedule B.3.3 The Contractor shall be entitled to interest on any late payments at the rate of [interest rate] per annum, calculated from the date that the payment was due until the date of payment.3.4 The Contractor shall provide the Owner with a detailed account ofall payments made to the Contractor, which shall be submitted to the Owner on a monthly basis.4. Changes to the Scope of Work4.1 The Owner may request changes to the scope of work defined in this Contract. Any such changes must be submitted in writing to the Contractor and agreed upon by both parties prior to implementation.4.2 The Contractor shall provide the Owner with a written estimate of the additional costs and time required to complete the changes, and the Owner shall be responsible for the payment of such additional costs and the extension of the project timeline, as applicable.5. Termination5.1 either party may terminate this Contract upon written notice to the other party if the other party breaches any material provision of this Contract and fails to cure such breach within [number of days] after receipt of written notice from the other party.5.2 either party may terminate this Contract upon written notice to the other party if the Project is not completed within the timeframe specified in this Contract.6. Dispute Resolution6.1 Any disputes arising out of or in connection with this Contractshall be resolved by binding arbitration in accordance with the rules of the [arbitration association], and the decision of the arbitrator(s) shall be final and binding upon the parties.7. Governing Law and Jurisdiction7.1 This Contract shall be governed by and construed in accordance with the laws of the [governing jurisdiction].7.2 Any legal actions or proceedings arising out of or in connection with this Contract shall be brought exclusively in the courts of the [governing jurisdiction].8. Entire Agreement8.1 This Contract constitutes the entire agreement between the parties with respect to the subject matter hereof and supersedes all prior agreements, understandings, negotiations, and discussions, whether oral or written, of the parties.8.2 This Contract may be amended or modified only by a written instrument executed by both parties.IN WITNESS WHEREOF, the parties have executed this Contract as of the date first above written.[Contractor's Name] [Owner's Name]。

建筑施工合同中英文对照

建设工程施工合同发包方（甲方）xxxxParty A: xxxx承包方（乙方）xxxxParty B: xxxx本合同由如上列明的甲、乙双方按照《中华人民共和国合同法》、《建筑安装工程承包合同条例》以及国家相关法律法规的规定，结合本合同具体情况，于xx年x月x日在xx签订。

This contract is signed by the two Parties in xxxx on xxxx according to the “Contract Law of the People’s Republic of China”, the “Regulation on Building and Installation Contracting Contract”, and other relevant national laws and regulations, as well as the specific nature of this project第一条总则Article 1 General Principles1.1合同文件Contract Documents本合同包含合同、展示、施工图纸、作法说明、招投标文件以及合同所指的其他文件，它们均被视为合同的一部分。

合同文件应该能够相互解释，互为说明。

组成本合同的文件及优先解释的顺序如下：本合同、中标通知书、投标书及其附件、标准、规范及有关技术文件、图纸、工程量清单及工程报价单或预算书。

合同履行中，发包人承包人有关工程的洽商、变更等书面下一或文件视为本合同的组成部分。

This contract includes the contract itself, exhibits, construction drawings, explanations of work procedures, tender documents, as well as other documents specified by the contract. The contract documents should be mutually explainable and mutually descriptive. The documents that constituted the contract and the priority hierarchy of explanations of the documents are as follows: this contract; the official letter of winning the tender; Letter of bidding and its annex, standards, guidelines, and relevant technical documents, drawings, Bill of Quantity (BOQ), quotation of prices, and project budget. During the implementation of the contract, any written agreements or documents between two parties such as change-orders are also regarded will be deemed as part of this contract.1.1.1项目概况Project Introduction1.1.2工程名称：xxxxName of Project: xxxx1.1.3工程地点：xxxxLocation of Project: xxxx1.1.3.1工程范围：除了本合同其他条款另有说明外，乙方应提供为履行合同所需的所有服务，用品以及其他保障工程进行所需的必要花费以完成下列工作：Scope of the project: unless otherwise explained by other articles in this contract, Party B shall provide all services, utensils, and other necessary cost for the implementation of this contract; the scope of project includes, but not limited to: ※室内装饰工程，详见附件一和附件二Inner decoration, see appendix 1 & 2※室外装饰工程（门窗、屋面、台阶等），详见附件一和附件二Façade(including doors, windows, roof and stairs) see appendix 1 & 2※电器工程，详见附件一和附件二Electronic Engineering, see appendix 1 & 2※空调工程，详见附件一和附件二Air Conditioning System, see appendix 1 & 2※给排水及采暖工程，详见附件一和附件二Water Supply, Sewage and Heating System, see appendix 1 & 2※消防工程Fire Control System, see appendix 1 & 2※其他图纸上所列项目（任何对原定设计的变更应提供新的图纸并有甲方的签字确认）以上所有的工程项目以下统称为“工程”。

建筑施工合同中英文对照版本

xxxx施工合同Construction Contract of xxxx发包方（甲方）xxxxParty A: xxxx承包方（乙方）xxxxParty B: xxxx本合同由如上列明的甲、乙双方按照《中华人民共和国合同法》、《建筑安装工程承包合同条例》以及国家相关法律法规的规定，结合本合同具体情况，于xx年x月x日在xx签订。

合同文件应该能够相互解释，互为说明。

合同履行中，发包人承包人有关工程的洽商、变更等书面下一或文件视为本合同的组成部分。

This contract includes the contract itself, exhibits, construction drawings, explanations of work procedures, tender documents, as well as other documents specified by the contract. The contract documents should be mutually explainable and mutually descriptive. The documents that constituted the contract and the priority hierarchy of explanations of the documents are as follows: this contract; the official letter of winning the tender; Letter of bidding and its annex, standards, guidelines, and relevant technical documents, drawings, Bill of Quantity (BOQ), quotation of prices, and project budget. During the implementation of the contract, any written agreements or documents between two parties such as change-orders are also regarded will be deemed as part of this contract.1.1.1项目概况Project Introduction1.1.2工程名称：xxxxName of Project: xxxx1.1.3工程地点：xxxxLocation of Project: xxxx1.1.3.1工程范围：除了本合同其他条款另有说明外，乙方应提供为履行合同所需的所有服务，用品以及其他保障工程进行所需的必要花费以完成下列工作：Scope of the project: unless otherwise explained by other articles in this contract, Party B shall provide all services, utensils, and other necessary cost for the implementation of this contract; the scope of project includes, but not limited to:※室内装饰工程，详见附件一和附件二Inner decoration, see appendix 1 & 2※室外装饰工程（门窗、屋面、台阶等），详见附件一和附件二Façade(including doors, windows, roof and stairs) see appendix 1 & 2※电器工程，详见附件一和附件二Electronic Engineering, see appendix 1 & 2※空调工程，详见附件一和附件二Air Conditioning System, see appendix 1 & 2※给排水及采暖工程，详见附件一和附件二Water Supply, Sewage and Heating System, see appendix 1 & 2※消防工程Fire Control System, see appendix 1 & 2※其他图纸上所列项目（任何对原定设计的变更应提供新的图纸并有甲方的签字确认）以上所有的工程项目以下统称为“工程”。

建筑施工合同中英文对照版本

建筑施工合同中英文对照版本甲方：Party A乙方：Party B根据《中华人民共和国合同法》及相关法律法规的规定，甲乙双方在平等、自愿、公平、诚信的原则基础上，就甲方委托乙方进行建筑施工事宜，经友好协商，达成以下协议：Article 1: General Provisions1.1 This Contract shall be effective from the date of signing by both Parties and shall expire upon the completion of the Construction Project.1.2除非本合同另有规定，本合同未尽事宜，可由双方另行协商达成补充协议，补充协议与本合同具有同等法律效力。

1.3除非本合同另有规定，本合同一式两份，甲乙双方各执一份，两份合同具有同等法律效力。

Article 2: Construction Scope and Objectives2.1 Party A entrusts Party B with the Construction Project (hereinafter referred to as the "Project") located at ____________ (hereinafter referred to as the "Construction Site").2.2 The Construction Scope of the Project shall include, but not limited to, the following:(1)____________;(2)____________;(3)____________;2.3 The objectives of the Project are to complete the construction within the agreed timeand budget, and to achieve the required quality standards.Article 3: Construction Period3.1 The Construction Period of the Project shall be ____________ days from the date of signing this Contract.3.2 Party B shall notify Party A in writing if it expects to extend the Construction Period. The extension shall not be unreasonably denied by Party A. The extension period shall be agreed upon by both Parties.Article 4: Construction Cost4.1 The total Construction Cost of the Project shall be ____________ RMB (Renminbi), including taxes and other related fees.4.2 The payment schedule shall be as follows:(1)____________ RMB upon signing this Contract;(2)____________ RMB upon the completion ofthe____________ phase of the Project;(3)____________ RMB upon the finalcompletion of the Project.4.3 Party A shall pay Party B theConstruction Cost within 30 days after receiving the relevant invoices and supporting documents.Article 5: Quality and Standards5.1 The construction work shall comply with the relevant laws, regulations, codes, standards, and specifications required by the Construction Project.5.2 Party B shall be responsible for the quality of the construction work. Party B shall repair or replace any defective work within areasonable time after the completion of the Project at its own expense.Article 6: Safety and EnvironmentalProtection6.1 Party B shall ensure the safety of the construction site, and shall take necessary measures to protect the environment and prevent pollution.6.2 Party B shall be responsible for anyinjury or damage caused by its employees or agents during the performance of this Contract.Article 7: Force Majeure7.1 Neither Party shall be liable for the failure or delay in the performance of its obligations under this Contract due to force majeure events such as acts of God, war, strikes, riots, etc.7.2 The Party affected by the force majeure shall notify the other Party in writing as soon as possible, and shall take necessary measures to minimize the losses.Article 8: Dispute Resolution8.1 Any disputes arising out of or in connection with this Contract shall be firstly resolved through friendly negotiation.8.2 If the negotiation fails, the disputes shall be submitted to the____________ people's court with jurisdiction over the place of performance of this Contract.Article 9: Miscellaneous9.1 This Contract may not be assigned by either Party without the prior written consent of the other Party.9.2 This Contract shall be governed by and construed in accordance with the laws of the People's Republic of China.9.3 In case any clause of this Contract is found to be invalid or unenforceable, the validity and enforceability of the remaining clauses shall not be affected.9.4 The headings in this Contract are for convenience only and shall not be used to interpret the contents of the clauses.Article 10: SignatureThe Parties have executed this Contract as of the date first above written.Party A: ________________Representative: ________________Date: ________________Party B: ________________ Representative: ________________ Date: ________________。

工程施工合同英文翻译

Contract No.: [Contract Number]Date of Execution: [Date]Contractor: [Contractor's Name]Owner: [Owner's Name]1. Scope of WorkThe Contractor shall undertake the construction of [Project Name] located at [Project Address], in accordance with the terms and conditions set forth in this Contract. The scope of work includes, but is not limited to, the following:1.1 Civil Works:- Excavation and foundation construction.- Structural steelwork and concrete works.- Installation of electrical, mechanical, and plumbing systems.- Completion of external and internal finishes.1.2 Infrastructure:- Construction of roads, sidewalks, and drainage systems.- Installation of street lighting and signage.1.3 Utilities:- Connection to water, electricity, and gas supply lines.- Installation of utility poles and transformers.1.4 Environmental Protection:- Implementation of environmental protection measures as per the relevant regulations and standards.2. Contract PriceThe total contract price for the above-mentioned scope of work is [Contract Price], to be paid in [Currency] as follows:2.1 Advance Payment: [Percentage]% of the total contract price, to be paid upon the execution of this Contract.2.2 Progress Payments: [Percentage]% of the total contract price, to be paid at the completion of each major phase of work as agreed upon in the schedule.2.3 Retention: [Percentage]% of the total contract price, to be retained until the final acceptance of the work by the Owner.3. Duration of WorkThe construction work shall commence on [Start Date] and be completed within [Duration] months from the date of the commencement of work. Any delay in the completion of the work beyond the agreed duration shall be subject to liquidated damages as specified in Clause 6.4. Quality of WorkThe Contractor shall ensure that the construction work is carried out in accordance with the latest standards, specifications, and regulations. All materials, equipment, and labor used in the construction shall be of the highest quality and meet the requirements of the Contract.5. Insurance and Liability5.1 The Contractor shall maintain comprehensive general liability insurance for the duration of the Contract, covering all risks associated with the construction work, including third-party liability.5.2 The Contractor shall be responsible for any damage caused to the Owner's property or to any third party during the course of the construction work.6. Liquidated DamagesIn the event of any delay in the completion of the work beyond the agreed duration, the Contractor shall pay liquidated damages to the Owner at the rate of [Rate] per day for each day of delay.6.1 If the delay exceeds [Number of Days], the Owner shall have theright to terminate the Contract and claim damages for the breach.7. Termination7.1 Either party may terminate this Contract in the event of a breach of its obligations under the Contract, upon giving [Number of Days] days' written notice to the other party.7.2 Termination of the Contract shall not relieve the Contractor from any liability or obligation arising prior to the termination.8. Dispute ResolutionAny disputes arising out of or in connection with this Contract shall be resolved through friendly negotiations. If the parties fail to reach an amicable settlement within [Number of Days] days, the dispute shall be referred to arbitration in accordance with the rules of the [Arbitration Institution].9. Governing LawThis Contract shall be governed by and construed in accordance with the laws of [Jurisdiction].10. AmendmentsAny amendment to this Contract shall be in writing and shall be executed by both parties.11. Entire AgreementThis Contract constitutes the entire agreement between the parties and supersedes all prior agreements, negotiations, and understandings, whether written or oral.12. SignaturesThis Contract is executed in two copies, each party retaining one. [Contractor's Name]________________________Contractor's Authorized Signature[Owner's Name]________________________Owner's Authorized Signature。

中英文版施工合同-xxx工程合同中英文版

中英文版施工合同-xxx工程合同中英文版甲方（业主）： [Party A (Owner)]乙方（承包商）： [Party B (Contractor)]第一部分：合同条款第一条工程概况1.1 工程名称：[Name of the Project]1.2 工程地点：[Location of the Project]1.3 工程范围：[Scope of the Project]1.4 工程内容：[Content of the Project]第二条合同价格2.1 合同总价：[Total Contract Price]2.2 价格调整：[Price Adjustment]第三条工程质量3.1 质量标准：[Quality Standards]3.2 质量保证：[Quality Assurance]第四条工程进度4.1 开工日期：[Commencement Date]4.2 竣工日期：[Completion Date]4.3 进度计划：[Progress Schedule]第五条工程变更5.1 变更通知：[Change Notification]5.2 变更费用：[Change Costs]第六条工程验收6.1 验收标准：[Acceptance Standards]6.2 验收程序：[Acceptance Procedures]第七条付款方式7.1 预付款：[Advance Payment]7.2 进度款：[Progress Payment]7.3 最终结算：[Final Settlement]第八条违约责任8.1 违约定义：[Definition of Breach]8.2 违约赔偿：[Compensation for Breach]第九条争议解决9.1 争议解决方式：[Dispute Resolution Method]9.2 适用法律：[Applicable Law]第十条其他条款10.1 保密协议：[Confidentiality Agreement]10.2 合同变更：[Contract Modification]10.3 合同终止：[Contract Termination]第二部分：附加条款[Additional Clauses as per the specific requirements of the project]第三部分：签字页甲方（业主）代表签字：[Signature of Party A's Representative]乙方（承包商）代表签字：[Signature of Party B's Representative]日期：[Date]Construction ContractContract No.: [Contract No.]Date of Contract: [Date of Contract]Party A (Owner): [Party A (Owner)]Party B (Contractor): [Party B (Contractor)] Part I: Contract TermsArticle 1: Project Overview1.1 Project Name: [Name of the Project]1.2 Project Location: [Location of the Project] 1.3 Project Scope: [Scope of the Project]1.4 Project Content: [Content of the Project]Article 2: Contract Price2.1 Total Contract Price: [Total Contract Price] 2.2 Price Adjustment: [Price Adjustment]Article 3: Project Quality3.1 Quality Standards: [Quality Standards]3.2 Quality Assurance: [Quality Assurance]Article 4: Project Schedule4.1 Commencement Date: [Commencement Date]4.2 Completion Date: [Completion Date]4.3 Progress Schedule: [Progress Schedule]Article 5: Project Changes5.1 Change Notification: [Change Notification]5.2 Change Costs: [Change Costs]Article 6: Project Acceptance6.1 Acceptance Standards: [Acceptance Standards]6.2 Acceptance Procedures: [Acceptance Procedures]Article 7: Payment Method7.1 Advance Payment: [Advance Payment]7.2 Progress Payment: [Progress Payment]7.3 Final Settlement: [Final Settlement]Article 8: Liability for Breach of Contract8.1 Definition of Breach: [Definition of Breach]8.2 Compensation for Breach: [Compensation for Breach]Article 9: Dispute Resolution9.1 Dispute Resolution Method: [Dispute Resolution Method] 9.2 Applicable Law: [Applicable Law]Article 10: Other Terms10.1 Confidentiality Agreement: [Confidentiality Agreement] 10.2 Contract Modification: [Contract Modification]10.3 Contract Termination: [Contract Termination]Part II: Additional Terms[Additional terms as per the specific requirements of the project]Part III: Signature PageSignature of Party A's Representative: [Signature of Party A's Representative]Signature of Party B's Representative: [。

建设工程施工合同中英文对照版

建设工程施工合同中英文对照版建设工程施工合同Construction Contract for Building Projects 甲方：________（中文名称）Party A：________ (Chinese Name)乙方：________（中文名称）Party B：________ (Chinese Name)第一章项目概况1.1 项目名称：________（中文名称）Project Name：________ (Chinese Name)1.2 项目地质：________（中文地质）Project Address：________ (Chinese Address) 1.3 项目内容：________Project Scope：________1.4 项目规模：________Project Scale：________1.5 工程进度：________Project Schedule：________第二章合同签订2.1 合同签署日期：________ Contract Signing Date：________ 2.2 合同有效期：________ Contract Duration：________2.3 合同价款：________Contract Price：________2.4 付款方式：________Payment Terms：________第三章工程设计及施工图纸3.1 设计文件：________Design Documents：________3.2 施工图纸：________ Construction Drawings：________ 3.3 变更设计：________Design Changes：________第四章工程质量4.1 施工质量标准：________Construction Quality Standards：________ 4.2 质量检验与验收：________Quality Inspection and Acceptance：________ 4.3 保修期限：________Warranty Period：________第五章施工进度5.1 工期计划：________Construction Schedule：________5.2 施工延期：________Construction Delays：________5.3 里程碑节点：________Milestone Points：________第六章安全与环境保护6.1 安全管理：________Safety Management：________6.2 环境保护：________Environmental Protection：________第七章分包与进场7.1 分包合同：________Subcontracting Contracts：________7.2 分包管理：________Subcontracting Management：________7.3 进场准备：________Site Mobilization：________第八章合同变更8.1 变更范围：________Scope of Changes：________8.2 变更手续：________Change Procedures：________8.3 变更后价款及工期调整：________ Adjustment of Price and Schedule：________第九章履行保证9.1 甲方履行保证：________Party A's Performance Guarantee：________9.2 乙方履行保证：________Party B's Performance Guarantee：________第十章违约责任10.1 甲方违约责任：________Party A's Breach of Contract Liability：________ 10.2 乙方违约责任：________Party B's Breach of Contract Liability：________十第一章争议解决11.1 合同争议解决方式：________Contract Dispute Resolution Mechanism：________ 11.2 适用法律：________Applicable Laws：________11.3 仲裁地点：________Arbitration Venue：________附件：________附件一：________设计文件附件二：________施工图纸附件三：________分包合同法律名词及注释：________1.甲方：________建筑工程的委托方，负责支付合同价款和提供项目要求。

工程施工合同中英对照

工程施工合同中英对照【合同名称】Contract Name: Construction roject Agreement甲方（业主）arty A (Owner): _________________乙方（承包商）arty (Contractor): _________________鉴于双方基于平等、自愿的原则，经过友好协商，就________项目的建设达成如下协议：Whereas oth arties, on the asis of equality and voluntariness, have reached the following agreement through friendly negotiation concerning the construction of the ________ roject.一、项目概述 roject Overview:1. 工程名称 Name of the roject: _____________2. 工程地点 Location of the roject: _____________3. 工程规模 Scale of the roject: _____________4. 工程内容 Content of the roject: _____________5. 工期要求 Duration Requirements: _____________二、合同金额 Contract Amount:1. 合同总价 Total Contract rice: _____________2. 付款方式 ayment Method: _____________3. 付款条件 ayment Conditions: _____________三、工程进度 roject Schedule:1. 开工日期 Start Date: _____________2. 竣工日期 Comletion Date: _____________3. 进度安排 Schedule Arrangement: _____________四、质量要求 Quality Requirements:1. 标准规范 Standard Secifications: _____________2. 验收标准 Accetance Criteria: _____________3. 质量保证措施 Quality Assurance Measures: _____________五、变更与索赔 Changes and Claims:1. 变更程序 Change rocedures: _____________2. 索赔条件 Claim Conditions: _____________3. 处理流程 Handling rocess: _____________六、违约责任 Liaility for reach:1. 违约定义 Definition of reach: _____________2. 违约处罚 enalties for reach: _____________3. 解决方式 Resolution Methods: _____________七、争议解决 Disute Resolution:1. 协商解决 Negotiated Settlement: _____________2. 仲裁条款 Aritration Clauses: _____________3. 适用法律 Alicale Law: _____________八、其他事宜 Miscellaneous:1. 附加条款 Additional rovisions: _____________2. 通知方式 Notice Method: _____________3. 合同生效条件 Effective Conditions of the Contract: _____________九、附件 Annexes:1. 设计图纸 Design Drawings: _____________2. 技术规范 Technical Secifications: _____________3. 相关文件 Relevant Documents: _____________本合同一式两份，甲乙双方各执一份，自双方签字盖章之日起生效。

建筑施工合同中英文对照

合同文件应该能够相互解释，互为说明。

合同履行中，发包人承包人有关工程的洽商、变更等书面下一或文件视为本合同的组成部分。

This contract includes the contract itself, exhibits, construction drawings, explanations of work procedures, tender documents, as well as other documents specified by the contract. The contract documents should be mutually explainable and mutually descriptive. The documents that constituted the contract and the priority hierarchy of explanations of the documents are as follows: this contract; the official letter of winning the tender; Letter of bidding and its annex, standards, guidelines, and relevant technical documents, drawings, Bill of Quantity (BOQ), quotation of prices, and project budget. During the implementation of the contract, any written agreements or documents between two parties such as change-orders are also regarded will be deemed as part of this contract.1.1.1项目概况Project Introduction1.1.2工程名称：xxxxName of Project: xxxx1.1.3工程地点：xxxxLocation of Project: xxxx1.1.3.1工程范围：除了本合同其他条款另有说明外，乙方应提供为履行合同所需的所有服务，用品以及其他保障工程进行所需的必要花费以完成下列工作：Scope of the project: unless otherwise explained by other articles in this contract, Party B shall provide all services, utensils, and other necessary cost for the implementation of this contract; the scope of project includes, but not limited to:※室内装饰工程，详见附件一和附件二Inner decoration, see appendix 1 & 2※室外装饰工程（门窗、屋面、台阶等），详见附件一和附件二Façade(including doors, windows, roof and stairs) see appendix 1 & 2※电器工程，详见附件一和附件二Electronic Engineering, see appendix 1 & 2※空调工程，详见附件一和附件二Air Conditioning System, see appendix 1 & 2※给排水及采暖工程，详见附件一和附件二Water Supply, Sewage and Heating System, see appendix 1 & 2※消防工程Fire Control System, see appendix 1 & 2※其他图纸上所列项目（任何对原定设计的变更应提供新的图纸并有甲方的签字确认）以上所有的工程项目以下统称为“工程”。

施工合同中英文模板-construction-contract-精校.doc

Construction Contract工程合同PO No.: XXXXXXXBuyer:. Date of signature:甲方:签约日期：Seller:乙方:This Purchase Order is made by and between the Buyer and the Seller: Whereby the Buyer agrees to buy and the Seller agrees to sell the under mentioned commodity according to the terms and conditions stipulated below:甲乙双方经友好协商，一致就供应下列产品，达成如下条款：1. Scope of Supply and Price工作范围及价格明细2. Technical Requirement, Quality Requirement, Standard & Warranty Period:Seller shall carried out the construction in strict accordance with the National Standard and the requirements stipulated in the Technical Agreement No. ________which both party signed (see attached documents). The warranty period shall be 1 year after placement of Goods in service.技术要求、质量要求、技术标准和质保期限: 按国家标准和双方签定的技术协议（编号：______见附件）施工，质保期为投产后1年。

3. Job Sites:施工地点：4. Construction Equipment, Tools & Field Personnel Management:施工设备工具及现场人员管理：(1) All the construction equipment and tools shall be provided by Seller.所有施工用设备及工具由乙方自带。

建筑施工合同中英文对照

合同文件应该能够相互解释，互为说明。

合同履行中，发包人承包人有关工程的洽商、变更等书面下一或文件视为本合同的组成部分。

建设工程施工合同中英文翻译件范本8篇

建设工程施工合同中英文翻译件范本8篇篇1建设工程施工合同Contract of Construction Engineering一、合同当事人The Parties to the Contract1. 发包方（甲方）：- 单位名称：江苏某某建设集团有限公司- 地址：南京市某某区某某街某某号- 法定代表人：张先生- 电话：+86-12345678901- 电子邮箱：[*****************](mailto:*****************)2. 承包方（乙方）：- 单位名称：南京某某建筑有限公司- 地址：南京市某某区某某街某某号- 法定代表人：李女士- 电话：+86-10987654321- 电子邮箱：[**************](mailto:**************)二、合同标的The Subject of the Contract本合同标的为江苏某某建设集团有限公司委托南京某某建筑有限公司承建的“某某花园”住宅楼建设项目。

项目位于南京市某某区，合同总价为人民币壹亿元整（￥1,000,000,000元）。

三、工程范围和内容Scope and Content of the Works1. 土建工程：包括基础工程、主体结构、屋面工程等。

2. 装饰工程：包括内外装饰、门窗安装等。

3. 水电安装：包括给水、排水、电气照明等。

4. 其他附属设施：包括道路、绿化、景观等。

四、工期和进度Time Limit and Progress of the Works1. 开工日期：本合同自签订之日起生效，工期为36个月。

2. 进度要求：乙方需按照甲方提供的施工进度计划表执行，确保每月完成计划工程量。

3. 延期处理：如因乙方原因造成工期延误，乙方需承担相应的违约责任和赔偿责任。

五、质量与验收Quality and Acceptance1. 质量标准：乙方必须按照国家和地方现行施工规范及标准施工，确保工程质量达到合格标准。

中英文版建设工程施工合同

中英文版建设工程施工合同Construction Engineering Contract合同编号： [Contract No.]合同日期： [Date of Contract]甲方（业主）： [Party A (Owner)]乙方（承包商）： [Party B (Contractor)]第一部分通用条款Part I General Provisions第1条定义Article 1 Definitions本合同中使用的术语和表达，除非另有明确说明，应按照本合同的规定解释。

The terms and expressions used in this contract shall be interpreted in accordance with the provisions of this contract, unless otherwise expressly stated.第2条合同文件Article 2 Contract Documents构成本合同的文件包括但不限于：本合同协议书、中标通知书、投标书及其附件、本合同专用条款、本合同通用条款、标准、规范及有关技术文件、图纸、工程量清单和工程报价单或预算书。

The documents constituting this contract include, but are not limited to: this contract agreement, the notice of award, the tender and its attachments, the special provisions of this contract, the general provisions of this contract, standards, specifications and relevant technical documents, drawings,bill of quantities, and the engineering quotation or budget.第3条语言和法律Article 3 Language and Law本合同使用中文和英文两种语言，两种文本具有同等法律效力。

中英文版施工合同：工程合同中英文版

xxx engineering contract xxx工程合同Contract No.:合同编号：Party A: xxxCompany Limited甲方：xxx有限公司Party B:xxx Company Limited乙方：xxx有限公司This contract is made and entered into on the day of , 2014 by the following Parties in .本合同于2014年月日由以下当事方在签署。

Party A: xxx Company Limited,甲方：xxx有限公司，xxx经营的公司，住所地为xxx，（下称“甲方”），法定代表人：xxxParty B:xxx Company Limited,乙方：xxx有限公司，一家xxx经营的公司，注册地址是：xxx，（下称“乙方”），法定代表人：xxx Party A and Party B are called by a joint name of Both Parties under this contract, each of which is called as A Party.甲方和乙方在本合同项下统称为“双方”，单独称为“一方”。

1. Work Content and Requirements1. 工作内容、要求1.1 In accordance with the items stipulated in this Contract, Party B shall conduct the project as per the Projectstandard and quality standard stipulated by Ministry of Engineering of the Union of xx.1.1 依据本合同所限定的条款，乙方应以xx工程部规定的建筑标准和质量要求执行本工程。

工程施工合同中英文版

编号：_______________本资料为word版本，可以直接编辑和打印，感谢您的下载工程施工合同中英文版甲方：___________________乙方：___________________日期：___________________Construction ContractPO No.: XXXXXXXBuyer:. Date of signature:甲方：签约日期：Seller:乙方：This Purchase Order is made by and between the Buyer and the Seller: Whereby the Buyer agrees to buy and the Seller agrees to sell the under mentioned commodity according to the terms and conditions stipulated below: 甲乙双方经友好协商，一致就供应下列产品，达成如下条款：1. Scope of Supply and Price工作范围及价格明细2. Technical Requirement, Quality Requirement, Standard & Warranty Period:Seller shall carried out the construction in strict accordance with the National Standard andthe requirements stipulated in the Technical Agreement No.which both party signed (see attached documents). The warranty period shall be 1 year after placement of Goods in service.技术要求、质量要求、技术标准和质保期限：按国家标准和双方签定的技术协议(编号：附件)施工，质保期为投产后1年。