2017年建筑施工合同中英文对照

建设工程施工合同中英文对照版

建设工程施工合同中英文对照版中英文建设工程施工合同Contract for Construction Project本合同是由承包人（以下简称“甲方”）和业主（以下简称“乙方”）共同订立，旨在规定双方在建设工程项目中的权益和义务。

This contract is entered into by and between the Contractor (hereinafter referred to as "Party A") and the Owner (hereinafter referred to as "Party B") to regulate the rights and obligations of both parties in the construction project.总则 General Provisions第一条项目名称及工程地点：本工程名称为_________，位于_________。

Article 1: Project Name and Location: The name of the project is__________, located in __________.第二条总承包范围：甲方应按照乙方的要求，完成工程项目的设计、施工、验收等工作。

Article 2: Scope of General Contracting: Party A shall complete the design, construction, and acceptance of the project in accordance with PartyB's requirements.第三条施工期限：本工程的施工期限为_________，甲方必须按时完成工程，并交付乙方使用。

Article 3: Construction Period: The construction period of this project is __________. Party A must complete the project on time and deliver it to Party B for use.义务与责任 Obligations and Responsibilities第四条甲方责任：甲方应根据乙方的要求，制定合理的工程施工方案，并保证工程按照合同和法律法规的要求进行。

建设工程施工合同中英文对照版

建设工程施工合同发包方（甲方）xxxxParty A: xxxx承包方（乙方）xxxxParty B: xxxx本合同由如上列明的甲、乙双方按照《中华人民共和国合同法》、《建筑安装工程承包合同条例》以及国家相关法律法规的规定，结合本合同具体情况，于xx年x月x日在xx签订。

This contract is signed by the two Parties in xxxx on xxxx according to the “Contract Law of the People’s Republic of China”, the “Regulation on Building and Installation Contracting Contract”, and other relevant national laws and regulations, as well as the specific nature of this project第一条总则Article 1 General Principles1.1合同文件Contract Documents本合同包含合同、展示、施工图纸、作法说明、招投标文件以及合同所指的其他文件，它们均被视为合同的一部分。

合同文件应该能够相互解释，互为说明。

组成本合同的文件及优先解释的顺序如下：本合同、中标通知书、投标书及其附件、标准、规范及有关技术文件、图纸、工程量清单及工程报价单或预算书。

合同履行中，发包人承包人有关工程的洽商、变更等书面下一或文件视为本合同的组成部分。

This contract includes the contract itself, exhibits, construction drawings, explanations of work procedures, tender documents, as well as other documents specified by the contract. The contract documents should be mutually explainable and mutually descriptive. The documents that constituted the contract and the priority hierarchy of explanations of the documents are as follows: this contract; the official letter of winning the tender; Letter of bidding and its annex, standards, guidelines, and relevant technical documents, drawings, Bill of Quantity (BOQ), quotation of prices, and project budget. During the implementation of the contract, any written agreements or documents between two parties such as change-orders are also regarded will be deemed as part of this contract.1.1.1项目概况Project Introduction1.1.2工程名称：xxxxName of Project: xxxx1.1.3工程地点：xxxxLocation of Project: xxxx1.1.3.1工程范围：除了本合同其他条款另有说明外，乙方应提供为履行合同所需的所有服务，用品以及其他保障工程进行所需的必要花费以完成下列工作：Scope of the project: unless otherwise explained by other articles in this contract, Party B shall provide all services, utensils, and other necessary cost for the implementation of this contract; the scope of project includes, but not limited to:※室内装饰工程，详见附件一和附件二Inner decoration, see appendix 1 & 2※室外装饰工程（门窗、屋面、台阶等），详见附件一和附件二Façade(including doors, windows, roof and stairs) see appendix 1 & 2※电器工程，详见附件一和附件二Electronic Engineering, see appendix 1 & 2※空调工程，详见附件一和附件二Air Conditioning System, see appendix 1 & 2※给排水及采暖工程，详见附件一和附件二Water Supply, Sewage and Heating System, see appendix 1 & 2※消防工程Fire Control System, see appendix 1 & 2※其他图纸上所列项目（任何对原定设计的变更应提供新的图纸并有甲方的签字确认）以上所有的工程项目以下统称为“工程”。

建筑施工合同中英文对照

建设工程施工合同发包方（甲方）xxxxParty A: xxxx承包方（乙方）xxxxParty B: xxxx本合同由如上列明的甲、乙双方按照《中华人民共和国合同法》、《建筑安装工程承包合同条例》以及国家相关法律法规的规定，结合本合同具体情况，于xx年x月x 日在xx签订。

This contract is signed by the two Parties in xxxx on xxxx according to the “Contract Law of the People’s Republic of China”, the “Regulation on Building and Installation Contracting Contract”, and other relevant national laws and regulations, as well as the specific nature of this project第一条总则Article 1 General Principles1.1合同文件Contract Documents本合同包含合同、展示、施工图纸、作法说明、招投标文件以及合同所指的其他文件，它们均被视为合同的一部分。

合同文件应该能够相互解释，互为说明。

组成本合同的文件及优先解释的顺序如下：本合同、中标通知书、投标书及其附件、标准、规范及有关技术文件、图纸、工程量清单及工程报价单或预算书。

合同履行中，发包人承包人有关工程的洽商、变更等书面下一或文件视为本合同的组成部分。

This contract includes the contract itself, exhibits, construction drawings, explanations of work procedures, tender documents, as well as other documents specified by the contract. The contract documents should be mutually explainable and mutually descriptive. The documents that constituted the contract and the priority hierarchy of explanations of the documents are as follows: this contract; the official letter of winning the tender; Letter of bidding and its annex, standards, guidelines, and relevant technical documents, drawings, Bill of Quantity (BOQ), quotation of prices, and project budget. During the implementation of the contract, any written agreements or documents between two parties such as change-orders are also regarded will be deemed as part of this contract.1.1.1项目概况Project Introduction1.1.2工程名称：xxxxName of Project: xxxx1.1.3工程地点：xxxxLocation of Project: xxxx1.1.3.1工程范围：除了本合同其他条款另有说明外，乙方应提供为履行合同所需的所有服务，用品以及其他保障工程进行所需的必要花费以完成下列工作：Scope of the project: unless otherwise explained by other articles in this contract, Party B shall provide all services, utensils, and other necessary cost forthe implementation of this contract; the scope of project includes, but not limited to: ※室内装饰工程，详见附件一和附件二Inner decoration, see appendix 1 & 2※室外装饰工程（门窗、屋面、台阶等），详见附件一和附件二Façade(including doors, windows, roof and stairs) see appendix 1 & 2※电器工程，详见附件一和附件二Electronic Engineering, see appendix 1 & 2※空调工程，详见附件一和附件二Air Conditioning System, see appendix 1 & 2※给排水及采暖工程，详见附件一和附件二Water Supply, Sewage and Heating System, see appendix 1 & 2※消防工程Fire Control System, see appendix 1 & 2※其他图纸上所列项目（任何对原定设计的变更应提供新的图纸并有甲方的签字确认）以上所有的工程项目以下统称为“工程”。

fidic合同施工条件2017中英文

fidic合同施工条件2017中英文English:The FIDIC Conditions of Contract for Construction 2017, commonly known as the Red Book, is a widely used standard form contract in the construction industry. It provides a comprehensive set of rules and guidelines for the execution of construction projects, covering various aspects such as the rights and obligations of the parties, the management of the project, the procedures for variations and claims, and the resolution of disputes. The contract is divided into 20 clauses, with each clause setting out specific provisions related to different aspects of the construction process. Some of the key provisions include the contractor's obligations to carry out the works in accordance with the contract documents, the employer's obligations to provide access and possession of the site, the procedures for issuing instructions and variations, and the mechanisms for determining and resolving disputes. The FIDIC Red Book aims to achieve a fair balance of risk between the parties, promote good project management practices, and provide a structured framework for the successful completion of construction projects.中文翻译:《国际发展法律协会施工合同条件2017》，通常称为红皮书，是建筑行业中广泛使用的标准合同表格。

建设工程施工合同中英(3篇)

第1篇Contract No.: [Contract Number]Date: [Contract Date]Parties Involved:1. Contractor:- Name: [Contractor's Name]- Address: [Contractor's Address]- Contact Person: [Contractor's Contact Person]- Contact Information: [Contractor's Contact Information]2. Client:- Name: [Client's Name]- Address: [Client's Address]- Contact Person: [Client's Contact Person]- Contact Information: [Client's Contact Information]Scope of Work:1. Project Description: [Detailed description of the construction project, including type of project, location, and main objectives.]2. Work to be Performed: [List of all the specific tasks and activities to be carried out by the Contractor, including design, construction, and any other related services.]3. Deliverables: [Detailed list of all deliverables, including but not limited to drawings, specifications, progress reports, and final certificates of completion.]Contract Price and Payment Terms:1. Contract Price: [Total contract price including all costs, fees, and expenses.]2. Payment Schedule:- Progress Payments: [Details of progress payments, including payment milestones, percentage of work completed, and payment schedule.]- Final Payment: [Conditions and terms for the final payment, including completion and final inspection requirements.]3. Retention: [Percentage of the contract price to be retained until the project is completed and all conditions are met.]Duration of the Contract:1. Start Date: [Date when the work is to begin.]2. Completion Date: [Estimated completion date based on the project scope and schedule.]3. Extension of Time: [Conditions under which the completion date may be extended and the process for requesting an extension.]Quality Standards:1. Quality Requirements: [Specific quality standards to be adhered to during the construction process, including materials, workmanship, and compliance with relevant codes and regulations.]2. Inspection and Testing: [Provisions for regular inspections and testing to ensure compliance with quality standards.]Warranties and Liabilities:1. Warranties: [Details of warranties provided by the Contractor, including duration and scope of warranty coverage.]2. Liabilities: [Responsibilities and liabilities of the Contractor in the event of any defects, damages, or claims arising from the work performed under the contract.]Force Majeure:1. Definition: [Definition of force majeure events, including acts of God, war, strikes, labor disputes, and any other events beyond the reasonable control of the Contractor.]2. Effect: [Provisions regarding the suspension of the contract and the obligations of the parties in the event of a force majeure event.]Dispute Resolution:1. Arbitration: [Provisions for resolving disputes, including the procedure for arbitration and the appointment of an arbitrator.]2. Legal Actions: [Conditions under which legal actions may be taken and the jurisdiction of any disputes.]General Provisions:1. Governing Law: [The laws of the jurisdiction that will govern the interpretation and enforcement of the contract.]2. Amendments: [Provisions regarding the process for making amendments to the contract.]3. Termination: [Conditions under which the contract may be terminated and the consequences of termination.]Acknowledgment:The parties hereto acknowledge that they have read, understand, and agree to be bound by the terms and conditions of this Construction Engineering Contract.---Contract No.: [Contract Number]Date: [Contract Date]Contractor:[Signature of Contractor] ___________________________[Name of Contractor] ___________________________Client:[Signature of Client] ___________________________[Name of Client] ___________________________---Note: This is a general template for a construction engineering contract. Specific contracts may require additional details or clauses based onthe nature of the project and the requirements of the parties involved.It is recommended that legal advice be sought when drafting or entering into a construction contract.第2篇Contract No. __________Contract Date: __________Contractor: __________Client: __________1. IntroductionThis Construction Engineering Contract (hereinafter referred to as "the Contract") is entered into between __________ (hereinafter referred toas "the Contractor") and __________ (hereinafter referred to as "the Client") on the basis of mutual consultation, agreement, and mutual benefit. The Contractor agrees to construct and complete theconstruction project as specified in the Contract, and the Client agrees to pay the agreed contract price for the completed construction project. The Contract is binding on both parties and shall be strictly observed.2. Project Description2.1 Project Name: __________2.2 Project Location: __________2.3 Project Scope: The construction project includes the following scopes:a. Civil engineering works: __________b. Electrical engineering works: __________c. Mechanical engineering works: __________d. Other relevant works: __________3. Contract Price3.1 The total contract price for the construction project is __________ Yuan, which is subject to the following terms:a. The Contractor shall provide detailed project estimates and invoices for the Client's approval.b. The Client shall make payment in accordance with the agreed payment schedule.c. Any additional costs due to changes in the project scope or unforeseen circumstances shall be agreed upon by both parties in writing.4. Performance and Quality4.1 The Contractor shall ensure that the construction project is completed within the agreed time frame and meets the quality standards specified in the Contract.4.2 The Contractor shall adhere to the relevant national standards,local regulations, and industry practices during the construction process.4.3 The Client shall have the right to inspect and accept the construction project at any time during the construction process.5. Payment Schedule5.1 The payment schedule is as follows:a. Upon the signing of the Contract, the Client shall pay the Contractor a deposit of __________ Yuan.b. Upon the completion of each phase of the project, the Contractor shall submit an invoice to the Client for payment.c. The Client shall pay the invoice within __________ days upon receipt.6. Insurance6.1 The Contractor shall obtain and maintain all necessary insurance policies to cover the risks associated with the construction project, including but not limited to:a. Public liability insuranceb. Workers' compensation insurancec. Property insurance7. Termination of the Contract7.1 Either party may terminate the Contract in writing if the other party fails to comply with the terms and conditions of the Contract.7.2 Upon termination of the Contract, the Contractor shall immediately cease all construction activities and the Client shall pay the Contractor for the work completed up to the date of termination.8. Dispute Resolution8.1 Any disputes arising from the execution of the Contract shall be settled through friendly negotiations between the parties.8.2 If the parties fail to reach an agreement through negotiations, the dispute shall be submitted to the relevant arbitration commission for resolution.9. Governing LawThis Contract shall be governed by the laws of __________.10. Final Provisions10.1 This Contract constitutes the entire agreement between the parties and supersedes all prior agreements and understandings, whether written or oral.10.2 Any amendment or modification of this Contract shall be effective only if it is in writing and signed by both parties.Contractor Signature: ___________________________Client Signature: ___________________________Date: ___________________________---Construction Engineering ContractContract No. __________Contract Date: __________Contractor: __________Client: __________1. Introduction本建筑工程合同（以下简称“本合同”）由__________（以下简称“承包商”）与__________（以下简称“业主”）在相互协商、一致同意和互惠互利的基础上签订。

建筑施工合同中英文对照版本

建筑施工合同中英文对照版本甲方：Party A乙方：Party B根据《中华人民共和国合同法》及相关法律法规的规定，甲乙双方在平等、自愿、公平、诚信的原则基础上，就甲方委托乙方进行建筑施工事宜，经友好协商，达成以下协议：Article 1: General Provisions1.1 This Contract shall be effective from the date of signing by both Parties and shall expire upon the completion of the Construction Project.1.2除非本合同另有规定，本合同未尽事宜，可由双方另行协商达成补充协议，补充协议与本合同具有同等法律效力。

1.3除非本合同另有规定，本合同一式两份，甲乙双方各执一份，两份合同具有同等法律效力。

Article 2: Construction Scope and Objectives2.1 Party A entrusts Party B with the Construction Project (hereinafter referred to as the "Project") located at ____________ (hereinafter referred to as the "Construction Site").2.2 The Construction Scope of the Project shall include, but not limited to, the following:(1)____________;(2)____________;(3)____________;2.3 The objectives of the Project are to complete the construction within the agreed timeand budget, and to achieve the required quality standards.Article 3: Construction Period3.1 The Construction Period of the Project shall be ____________ days from the date of signing this Contract.3.2 Party B shall notify Party A in writing if it expects to extend the Construction Period. The extension shall not be unreasonably denied by Party A. The extension period shall be agreed upon by both Parties.Article 4: Construction Cost4.1 The total Construction Cost of the Project shall be ____________ RMB (Renminbi), including taxes and other related fees.4.2 The payment schedule shall be as follows:(1)____________ RMB upon signing this Contract;(2)____________ RMB upon the completion ofthe____________ phase of the Project;(3)____________ RMB upon the finalcompletion of the Project.4.3 Party A shall pay Party B theConstruction Cost within 30 days after receiving the relevant invoices and supporting documents.Article 5: Quality and Standards5.1 The construction work shall comply with the relevant laws, regulations, codes, standards, and specifications required by the Construction Project.5.2 Party B shall be responsible for the quality of the construction work. Party B shall repair or replace any defective work within areasonable time after the completion of the Project at its own expense.Article 6: Safety and EnvironmentalProtection6.1 Party B shall ensure the safety of the construction site, and shall take necessary measures to protect the environment and prevent pollution.6.2 Party B shall be responsible for anyinjury or damage caused by its employees or agents during the performance of this Contract.Article 7: Force Majeure7.1 Neither Party shall be liable for the failure or delay in the performance of its obligations under this Contract due to force majeure events such as acts of God, war, strikes, riots, etc.7.2 The Party affected by the force majeure shall notify the other Party in writing as soon as possible, and shall take necessary measures to minimize the losses.Article 8: Dispute Resolution8.1 Any disputes arising out of or in connection with this Contract shall be firstly resolved through friendly negotiation.8.2 If the negotiation fails, the disputes shall be submitted to the____________ people's court with jurisdiction over the place of performance of this Contract.Article 9: Miscellaneous9.1 This Contract may not be assigned by either Party without the prior written consent of the other Party.9.2 This Contract shall be governed by and construed in accordance with the laws of the People's Republic of China.9.3 In case any clause of this Contract is found to be invalid or unenforceable, the validity and enforceability of the remaining clauses shall not be affected.9.4 The headings in this Contract are for convenience only and shall not be used to interpret the contents of the clauses.Article 10: SignatureThe Parties have executed this Contract as of the date first above written.Party A: ________________Representative: ________________Date: ________________Party B: ________________ Representative: ________________ Date: ________________。

建设工程施工合同中英文对照版

建设工程施工合同中英文对照版建设工程施工合同Construction Contract for Building Projects 甲方：________（中文名称）Party A：________ (Chinese Name)乙方：________（中文名称）Party B：________ (Chinese Name)第一章项目概况1.1 项目名称：________（中文名称）Project Name：________ (Chinese Name)1.2 项目地质：________（中文地质）Project Address：________ (Chinese Address) 1.3 项目内容：________Project Scope：________1.4 项目规模：________Project Scale：________1.5 工程进度：________Project Schedule：________第二章合同签订2.1 合同签署日期：________ Contract Signing Date：________ 2.2 合同有效期：________ Contract Duration：________2.3 合同价款：________Contract Price：________2.4 付款方式：________Payment Terms：________第三章工程设计及施工图纸3.1 设计文件：________Design Documents：________3.2 施工图纸：________ Construction Drawings：________ 3.3 变更设计：________Design Changes：________第四章工程质量4.1 施工质量标准：________Construction Quality Standards：________ 4.2 质量检验与验收：________Quality Inspection and Acceptance：________ 4.3 保修期限：________Warranty Period：________第五章施工进度5.1 工期计划：________Construction Schedule：________5.2 施工延期：________Construction Delays：________5.3 里程碑节点：________Milestone Points：________第六章安全与环境保护6.1 安全管理：________Safety Management：________6.2 环境保护：________Environmental Protection：________第七章分包与进场7.1 分包合同：________Subcontracting Contracts：________7.2 分包管理：________Subcontracting Management：________7.3 进场准备：________Site Mobilization：________第八章合同变更8.1 变更范围：________Scope of Changes：________8.2 变更手续：________Change Procedures：________8.3 变更后价款及工期调整：________ Adjustment of Price and Schedule：________第九章履行保证9.1 甲方履行保证：________Party A's Performance Guarantee：________9.2 乙方履行保证：________Party B's Performance Guarantee：________第十章违约责任10.1 甲方违约责任：________Party A's Breach of Contract Liability：________ 10.2 乙方违约责任：________Party B's Breach of Contract Liability：________十第一章争议解决11.1 合同争议解决方式：________Contract Dispute Resolution Mechanism：________ 11.2 适用法律：________Applicable Laws：________11.3 仲裁地点：________Arbitration Venue：________附件：________附件一：________设计文件附件二：________施工图纸附件三：________分包合同法律名词及注释：________1.甲方：________建筑工程的委托方，负责支付合同价款和提供项目要求。

建筑施工合同中英文对照版本

xxxx施工合同Construction Contract of xxxx发包方（甲方）xxxxParty A: xxxx承包方（乙方）xxxxParty B: xxxx本合同由如上列明的甲、乙双方按照《中华人民共和国合同法》、《建筑安装工程承包合同条例》以及国家相关法律法规的规定，结合本合同具体情况，于xx年x月x日在xx签订。

矚慫润厲钐瘗睞枥庑赖賃軔朧。

This contract is signed by the two Parties in xxxx on xxxx according to the “Contract Law of the People’s Republic of China”, the “Regulation on Building and Installation Contracting Contract”, and other relevant national laws and regulations, as well as the specific nature of this project聞創沟燴鐺險爱氇谴净祸測樅。

第一条总则Article 1 General Principles1.1合同文件Contract Documents本合同包含合同、展示、施工图纸、作法说明、招投标文件以及合同所指的其他文件，它们均被视为合同的一部分。

合同文件应该能够相互解释，互为说明。

组成本合同的文件及优先解释的顺序如下：本合同、中标通知书、投标书及其附件、标准、规范及有关技术文件、图纸、工程量清单及工程报价单或预算书。

合同履行中，发包人承包人有关工程的洽商、变更等书面下一或文件视为本合同的组成部分。

残骛楼諍锩瀨濟溆塹籟婭骒東。

This contract includes the contract itself, exhibits, construction drawings, explanations of work procedures, tender documents, as well as other documents specified by the contract. The contract documents should be mutually explainable and mutually descriptive. The documents that constituted the contract and the priority hierarchy of explanations of the documents are as follows: this contract; the official letter of winning the tender; Letter of bidding and its annex, standards, guidelines, and relevant technical documents, drawings, Bill of Quantity (BOQ), quotation of prices, and project budget. During the implementation of the contract, any written agreements or documents between two parties such as change-orders are also regarded will be deemed as part of this contract.酽锕极額閉镇桧猪訣锥顧荭钯。

建筑施工合同中英文对照

建设工程施工合同发包方（甲方）xxxxParty A: xxxx承包方（乙方）xxxxParty B: xxxx本合同由如上列明的甲、乙双方按照《中华人民共和国合同法》、《建筑安装工程承包合同条例》以及国家相关法律法规的规定，结合本合同具体情况，于xx年x月x日在xx签订。

This contract is signed by the two Parties in xxxx on xxxx according to the “Contract Law of the People’s Republic of China”, the “Regulation on Building and Installation Contracting Contract”, and other relevant national laws and regulations, as well as the specific nature of this project第一条总则Article 1 General Principles1.1合同文件Contract Documents本合同包含合同、展示、施工图纸、作法说明、招投标文件以及合同所指的其他文件，它们均被视为合同的一部分。

合同文件应该能够相互解释，互为说明。

组成本合同的文件及优先解释的顺序如下：本合同、中标通知书、投标书及其附件、标准、规范及有关技术文件、图纸、工程量清单及工程报价单或预算书。

合同履行中，发包人承包人有关工程的洽商、变更等书面下一或文件视为本合同的组成部分。

This contract includes the contract itself, exhibits, construction drawings, explanations of work procedures, tender documents, as well as other documents specified by the contract. The contract documents should be mutually explainable and mutually descriptive. The documents that constituted the contract and the priority hierarchy of explanations of the documents are as follows: this contract; the official letter of winning the tender; Letter of bidding and its annex, standards, guidelines, and relevant technical documents, drawings, Bill of Quantity (BOQ), quotation of prices, and project budget. During the implementation of the contract, any written agreements or documents between two parties such as change-orders are also regarded will be deemed as part of this contract.1.1.1项目概况Project Introduction1.1.2工程名称：xxxxName of Project: xxxx1.1.3工程地点：xxxxLocation of Project: xxxx1.1.3.1工程范围：除了本合同其他条款另有说明外，乙方应提供为履行合同所需的所有服务，用品以及其他保障工程进行所需的必要花费以完成下列工作：Scope of the project: unless otherwise explained by other articles in this contract, Party B shall provide all services, utensils, and other necessary cost for the implementation of this contract; the scope of project includes, but not limited to:※室内装饰工程，详见附件一和附件二Inner decoration, see appendix 1 & 2※室外装饰工程（门窗、屋面、台阶等），详见附件一和附件二Façade(including doors, windows, roof and stairs) see appendix 1 & 2※电器工程，详见附件一和附件二Electronic Engineering, see appendix 1 & 2※空调工程，详见附件一和附件二Air Conditioning System, see appendix 1 & 2※给排水及采暖工程，详见附件一和附件二Water Supply, Sewage and Heating System, see appendix 1 & 2※消防工程Fire Control System, see appendix 1 & 2※其他图纸上所列项目（任何对原定设计的变更应提供新的图纸并有甲方的签字确认）以上所有的工程项目以下统称为“工程”。

建筑施工合同中英文对照

建设工程施工合同发包方（甲方）xxxxParty A: xxxx承包方（乙方）xxxxParty B: xxxx本合同由如上列明的甲、乙双方按照《中华人民共和国合同法》、《建筑安装工程承包合同条例》以及国家相关法律法规的规定，结合本合同具体情况，于xx年x月x日在xx签订。

This contract is signed by the two Parties in xxxx on xxxx according to the “Contract Law of the People’s Republic of China”, the “Regulation on Building and Installation Contracting Contract”, and other relevant national laws and regulations, as well as the specific nature of this project第一条总则Article 1 General Principles1.1合同文件Contract Documents本合同包含合同、展示、施工图纸、作法说明、招投标文件以及合同所指的其他文件，它们均被视为合同的一部分。

合同文件应该能够相互解释，互为说明。

组成本合同的文件及优先解释的顺序如下：本合同、中标通知书、投标书及其附件、标准、规范及有关技术文件、图纸、工程量清单及工程报价单或预算书。

合同履行中，发包人承包人有关工程的洽商、变更等书面下一或文件视为本合同的组成部分。

This contract includes the contract itself, exhibits, construction drawings, explanations of work procedures, tender documents, as well as other documents specified by the contract. The contract documents should be mutually explainable and mutually descriptive. The documents that constituted the contract and the priority hierarchy of explanations of the documents are as follows: this contract; the official letter of winning the tender; Letter of bidding and its annex, standards, guidelines, and relevant technical documents, drawings, Bill of Quantity (BOQ), quotation of prices, and project budget. During the implementation of the contract, any written agreements or documents between two parties such as change-orders are also regarded will be deemed as part of this contract.1.1.1项目概况Project Introduction1.1.2工程名称：xxxxName of Project: xxxx1.1.3工程地点：xxxxLocation of Project: xxxx1.1.3.1工程范围：除了本合同其他条款另有说明外，乙方应提供为履行合同所需的所有服务，用品以及其他保障工程进行所需的必要花费以完成下列工作：Scope of the project: unless otherwise explained by other articles in this contract, Party B shall provide all services, utensils, and other necessary cost for the implementation of this contract; the scope of project includes, but not limited to: ※室内装饰工程，详见附件一和附件二Inner decoration, see appendix 1 & 2※室外装饰工程（门窗、屋面、台阶等），详见附件一和附件二Façade(including doors, windows, roof and stairs) see appendix 1 & 2※电器工程，详见附件一和附件二Electronic Engineering, see appendix 1 & 2※空调工程，详见附件一和附件二Air Conditioning System, see appendix 1 & 2※给排水及采暖工程，详见附件一和附件二Water Supply, Sewage and Heating System, see appendix 1 & 2※消防工程Fire Control System, see appendix 1 & 2※其他图纸上所列项目（任何对原定设计的变更应提供新的图纸并有甲方的签字确认）以上所有的工程项目以下统称为“工程”。

建筑施工合同中英文对照

建设工程施工合同发包方（甲方）xxxxParty A: xxxx承包方（乙方）xxxxParty B: xxxx本合同由如上列明的甲、乙双方按照《中华人民共和国合同法》、《建筑安装工程承包合同条例》以及国家相关法律法规的规定，结合本合同具体情况，于xx年x月x 日在xx签订。

This contract is signed by the two Parties in xxxx on xxxx according to the “Contract Law of the People’s Republic of China”, the “Regulation on Building and Installation Contracting Contract”, and other relevant national laws and regulations, as well as the specific nature of this project第一条总则Article 1 General Principles1.1合同文件Contract Documents本合同包含合同、展示、施工图纸、作法说明、招投标文件以及合同所指的其他文件，它们均被视为合同的一部分。

合同文件应该能够相互解释，互为说明。

组成本合同的文件及优先解释的顺序如下：本合同、中标通知书、投标书及其附件、标准、规范及有关技术文件、图纸、工程量清单及工程报价单或预算书。

合同履行中，发包人承包人有关工程的洽商、变更等书面下一或文件视为本合同的组成部分。

This contract includes the contract itself, exhibits, construction drawings, explanations of work procedures, tender documents, as well as other documents specified by the contract. The contract documents should be mutually explainable and mutually descriptive. The documents that constituted the contract and the priority hierarchy of explanations of the documents are as follows: this contract; the official letter of winning the tender; Letter of bidding and its annex, standards, guidelines, and relevant technical documents, drawings, Bill of Quantity (BOQ), quotation of prices, and project budget. During the implementation of the contract, any written agreements or documents between two parties such as change-orders are also regarded will be deemed as part of this contract.1.1.1项目概况Project Introduction1.1.2工程名称：xxxxName of Project: xxxx1.1.3工程地点：xxxxLocation of Project: xxxx1.1.3.1工程范围：除了本合同其他条款另有说明外，乙方应提供为履行合同所需的所有服务，用品以及其他保障工程进行所需的必要花费以完成下列工作：Scope of the project: unless otherwise explained by other articles in this contract, Party B shall provide all services, utensils, and other necessary cost for the implementation of this contract; the scope of project includes, but not limited to:※室内装饰工程，详见附件一和附件二Inner decoration, see appendix 1 & 2※室外装饰工程（门窗、屋面、台阶等），详见附件一和附件二Fa?ade(including doors, windows, roof and stairs) see appendix 1 & 2※电器工程，详见附件一和附件二Electronic Engineering, see appendix 1 & 2※空调工程，详见附件一和附件二Air Conditioning System, see appendix 1 & 2※给排水及采暖工程，详见附件一和附件二Water Supply, Sewage and Heating System, see appendix 1 & 2※消防工程Fire Control System, see appendix 1 & 2※其他图纸上所列项目（任何对原定设计的变更应提供新的图纸并有甲方的签字确认）以上所有的工程项目以下统称为“工程”。

2017年xxx工程合同中英文版(word版可编辑合同协议范文精品)

xxx engineering contract xxx工程合同Contract No.:合同编号：Party A: xxxCompany Limited甲方：xxx有限公司Party B:xxxCompany Limited乙方：xxx有限公司This contract is made and entered into on the day of , 2014 by the following Parties in .本合同于2014年月日由以下当事方在签署。

Party A: xxx Company Limited,甲方：xxx有限公司，xxx经营的公司，住所地为xxx，（下称“甲方”），法定代表人：xxxParty B:xxx Company Limited,乙方：xxx有限公司，一家xxx经营的公司，注册地址是：xxx，（下称“乙方”），法定代表人：xxxParty A and Party B are called by a joint name of Both Parties under this contract, each of which is called as A Party.甲方和乙方在本合同项下统称为“双方”，单独称为“一方”。

1. Work Content and Requirements1. 工作内容、要求1.1 In accordance with the items stipulated in this Contract, Party B shall conduct the project as per the Projectstandard and quality standard stipulated by Ministry of Engineering of the Union of xx.1.1 依据本合同所限定的条款，乙方应以xx工程部规定的建筑标准和质量要求执行本工程。

中英文对照工程施工合同

中英文对照工程施工合同Contract No.: [合同编号] Date: [日期] arty A: [甲方名称] arty : [乙方名称]---Contract No.: [合同编号] Date: [日期] arty A: [甲方名称] arty : [乙方名称]---Article 1: roject Information1.1 roject Name: [项目名称]1.2 roject Location: [项目地点]1.3 Scoe of Work: [工作范围描述]---Article 2: Oligations and Rights of arty A2.1 rovide necessary construction conditions and ensure unimeded access to the site.2.2 ay construction fees in accordance with the contract terms and conditions.---Article 3: Oligations and Rights of arty3.1 Comlete the construction work within the agreed timeframe, ensuring quality standards are met.3.2 Sumit rogress reorts on schedule and resond to any issues romtly.---Article 4: Construction eriod4.1 Start Date: [开始日期]4.2 Comletion Date: [完成日期]4.3 Should there e any delay, arty must rovide written notice and reasons to arty A.---Article 5: Quality Requirements5.1 The construction must meet national standards and industry norms.5.2 Uon comletion, oth arties shall conduct a joint insection; any discreancies should e resolved through negotiation.---Article 6: Safety roduction6.1 arty is resonsile for safety management and must comly with all relevant safety regulations.6.2 In case of an accident, immediate measures must e taken, and arty A should e informed without delay.---Article 7: rice and ayment Method7.1 Total contract rice: [合同总价]7.2 ayment schedule: [付款计划描述]---Article 8: Changes and Rescission of the Contract8.1 Any changes or amendments to the contract must e in writing and agreed uon y oth arties.8.2 Either arty may rescind the contract under certain conditions as stiulated y law.---Article 9: Settlement of Disutes9.1 Disutes arising from the contract shall e settled through friendly consultation.9.2 If consultation fails, either arty may sumit the disute to aritration or ursue legal action in court.---Article 10: Force Majeure10.1 Force majeure includes natural disasters and other unforeseeale events that revent erformance of the contract.10.2 The affected arty must immediately inform the other arty and rovide suorting evidence. ---Article 11: Miscellaneous11.1 Confidentiality clauses, intellectual roerty rights, etc., shall e detailed searately.11.2 This contract is executed in two counterarts, each held y one arty, and ecomes effective uon signing.---Article 12: Signatures and Seals[甲方签名盖章处] [乙方签名盖章处]Authorized Reresentative: [授权代表人姓名] Authorized Reresentative: [授权代表人姓名] Seal: [公司印章] Seal: [公司印章]Date: [日期] Date: [日期]。

2017年建设工程施工合同中英文翻译件范本

工程编号：__________________Project No.:合同编号：__________________Contract No.:建设工程施工合同Construction Contract for Construction Projects（GF-2013-0201）工程名称：Name of project:工程地点：Location of project:发包人：Client:承包人：Contractor:住房和城乡建设部制定国家工商行政管理总局Made byMinistry of Housing Urban-Rural DevelopmentState Administration for Industry & Commerce of the P. R.C目录Table of Contents第一部分合同协议书……………………………………………………......................…...错误!未定义书签。

Part I Contract Agreement ………………………………………......................…...错误!未定义书签。

一、工程概况 (17)I. Project Overview (17)二、合同工期 (18)II. Project Duration under Contract (18)三、质量标准 (18)III. Quality Standard (18)四、签约合同价与合同价格形式 (18)IV. Contract Price and Form of Contract Price (18)五、项目经理 ..........…..........…..........…..........…..........…..........…..........…..........…错误!未定义书签。

V. Project Manager (19)六、合同文件构成...................................................................................... . (19)VI. Composition of Contract Prices (19)七、承诺 (20)VII. Undertakings (20)八、词语含义 (20)VIII. Meanings of Terms (20)九、签订时间..........…..........…..........…........................................ 2错误!未定义书签。

建筑施工合同中英文对照

建设工程施工合同发包方（甲方）xxxxParty A: xxxx承包方（乙方）xxxxParty B: xxxx本合同由如上列明的甲、乙双方按照《中华人民共和国合同法》、《建筑安装工程承包合同条例》以及国家相关法律法规的规定，结合本合同具体情况，于xx年x月x日在xx签订。

This contract is signed by the two Parties in xxxx on xxxx according to the “Contract Law of the People’s Republic of China”, the “Regulation on Building and Installation Contracting Contract”, and other relevant national laws and regulations, as well as the specific nature of this project第一条总则Article 1 General Principles1.1合同文件Contract Documents本合同包含合同、展示、施工图纸、作法说明、招投标文件以及合同所指的其他文件，它们均被视为合同的一部分。

合同文件应该能够相互解释，互为说明。

组成本合同的文件及优先解释的顺序如下：本合同、中标通知书、投标书及其附件、标准、规范及有关技术文件、图纸、工程量清单及工程报价单或预算书。

合同履行中，发包人承包人有关工程的洽商、变更等书面下一或文件视为本合同的组成部分。

This contract includes the contract itself, exhibits, construction drawings, explanations of work procedures, tender documents, as well as other documents specified by the contract. The contract documents should be mutually explainable and mutually descriptive. The documents that constituted the contract and the priority hierarchy of explanations of the documents are as follows: this contract; the official letter of winning the tender; Letter of bidding and its annex, standards, guidelines, and relevant technical documents, drawings, Bill of Quantity (BOQ), quotation of prices, and project budget. During the implementation of the contract, any written agreements or documents between two parties such as change-orders are also regarded will be deemed as part of this contract.1.1.1项目概况Project Introduction1.1.2工程名称：xxxxName of Project: xxxx1.1.3工程地点：xxxxLocation of Project: xxxx1.1.3.1工程范围：除了本合同其他条款另有说明外，乙方应提供为履行合同所需的所有服务，用品以及其他保障工程进行所需的必要花费以完成下列工作：Scope of the project: unless otherwise explained by other articles in this contract, Party B shall provide all services, utensils, and other necessary cost for the implementation of this contract; the scope of project includes, but not limited to:※室内装饰工程，详见附件一和附件二Inner decoration, see appendix 1 & 2※室外装饰工程（门窗、屋面、台阶等），详见附件一和附件二Façade(including doors, windows, roof and stairs) see appendix 1 & 2※电器工程，详见附件一和附件二Electronic Engineering, see appendix 1 & 2※空调工程，详见附件一和附件二Air Conditioning System, see appendix 1 & 2※给排水及采暖工程，详见附件一和附件二Water Supply, Sewage and Heating System, see appendix 1 & 2※消防工程Fire Control System, see appendix 1 & 2※其他图纸上所列项目（任何对原定设计的变更应提供新的图纸并有甲方的签字确认）以上所有的工程项目以下统称为“工程”。

建筑施工合同中英文对照

建设工程施工合同发包方（甲方）xxxxParty A: xxxx承包方（乙方）xxxxParty B: xxxx本合同由如上列明的甲、乙双方按照《中华人民共和国合同法》、《建筑安装工程承包合同条例》以及国家相关法律法规的规定，结合本合同具体情况，于xx年x月x日在xx签订。

This contract is signed by the two Parties in xxxx on xxxx according to the “Contract Law of the People’s Republic of China”, the “Regulation on Building and Installation Contracting Contract”, and other relevant national laws and regulations, as well as the specific nature of this project第一条总则Article 1 General Principles1.1合同文件Contract Documents本合同包含合同、展示、施工图纸、作法说明、招投标文件以及合同所指的其他文件，它们均被视为合同的一部分。

合同文件应该能够相互解释，互为说明。

组成本合同的文件及优先解释的顺序如下：本合同、中标通知书、投标书及其附件、标准、规范及有关技术文件、图纸、工程量清单及工程报价单或预算书。

合同履行中，发包人承包人有关工程的洽商、变更等书面下一或文件视为本合同的组成部分。

This contract includes the contract itself, exhibits, construction drawings, explanations of work procedures, tender documents, as well as other documents specified by the contract. The contract documents should be mutually explainable and mutually descriptive. The documents that constituted the contract and the priority hierarchy of explanations of the documents are as follows: this contract; the official letter of winning the tender; Letter of bidding and its annex, standards, guidelines, and relevant technical documents, drawings, Bill of Quantity (BOQ), quotation of prices, and project budget. During the implementation of the contract, any written agreements or documents between two parties such as change-orders are also regarded will be deemed as part of this contract.1.1.1项目概况Project Introduction1.1.2工程名称：xxxxName of Project: xxxx1.1.3工程地点：xxxxLocation of Project: xxxx1.1.3.1工程范围：除了本合同其他条款另有说明外，乙方应提供为履行合同所需的所有服务，用品以及其他保障工程进行所需的必要花费以完成下列工作：Scope of the project: unless otherwise explained by other articles in this contract, Party B shall provide all services, utensils, and other necessary cost for the implementation of this contract; the scope of project includes, but not limited to: ※室内装饰工程，详见附件一和附件二Inner decoration, see appendix 1 & 2※室外装饰工程（门窗、屋面、台阶等），详见附件一和附件二Façade(including doors, windows, roof and stairs) see appendix 1 & 2※电器工程，详见附件一和附件二Electronic Engineering, see appendix 1 & 2※空调工程，详见附件一和附件二Air Conditioning System, see appendix 1 & 2※给排水及采暖工程，详见附件一和附件二Water Supply, Sewage and Heating System, see appendix 1 & 2※消防工程Fire Control System, see appendix 1 & 2※其他图纸上所列项目（任何对原定设计的变更应提供新的图纸并有甲方的签字确认）以上所有的工程项目以下统称为“工程”。

建筑施工合同中英文对照

建设工程施工合同发包方（甲方）xxxxParty A: xxxx承包方（乙方）xxxxParty B: xxxx本合同由如上列明的甲、乙双方按照《中华人民共和国合同法》、《建筑安装工程承包合同条例》以及国家相关法律法规的规定，结合本合同具体情况，于xx年x月x日在xx签订。

This contract is signed by the two Parties in xxxx on xxxx according to the “Contract Law of the People’s Republic of China”, the “Regulation on Building and Installation Contracting Contract”, and other relevant national laws and regulations, as well as the specific nature of this project第一条总则Article 1 General Principles1.1合同文件Contract Documents本合同包含合同、展示、施工图纸、作法说明、招投标文件以及合同所指的其他文件，它们均被视为合同的一部分。

合同文件应该能够相互解释，互为说明。

组成本合同的文件及优先解释的顺序如下：本合同、中标通知书、投标书及其附件、标准、规范及有关技术文件、图纸、工程量清单及工程报价单或预算书。

合同履行中，发包人承包人有关工程的洽商、变更等书面下一或文件视为本合同的组成部分。

This contract includes the contract itself, exhibits, construction drawings, explanations of work procedures, tender documents, as well as other documents specified by the contract. The contract documents should be mutually explainable and mutually descriptive. The documents that constituted the contract and the priority hierarchy of explanations of the documents are as follows: this contract; the official letter of winning the tender; Letter of bidding and its annex, standards, guidelines, and relevant technical documents, drawings, Bill of Quantity (BOQ), quotation of prices, and project budget. During the implementation of the contract, any written agreements or documents between two parties such as change-orders are also regarded will be deemed as part of this contract.1.1.1项目概况Project Introduction1.1.2工程名称：xxxxName of Project: xxxx1.1.3工程地点：xxxxLocation of Project: xxxx1.1.3.1工程范围：除了本合同其他条款另有说明外，乙方应提供为履行合同所需的所有服务，用品以及其他保障工程进行所需的必要花费以完成下列工作：Scope of the project: unless otherwise explained by other articles in this contract, Party B shall provide all services, utensils, and other necessary cost for the implementation of this contract; the scope of project includes, but not limited to:※室内装饰工程，详见附件一和附件二Inner decoration, see appendix 1 & 2※室外装饰工程（门窗、屋面、台阶等），详见附件一和附件二Façade(including doors, windows, roof and stairs) see appendix 1 & 2※电器工程，详见附件一和附件二Electronic Engineering, see appendix 1 & 2※空调工程，详见附件一和附件二Air Conditioning System, see appendix 1 & 2※给排水及采暖工程，详见附件一和附件二Water Supply, Sewage and Heating System, see appendix 1 & 2※消防工程Fire Control System, see appendix 1 & 2※其他图纸上所列项目（任何对原定设计的变更应提供新的图纸并有甲方的签字确认）以上所有的工程项目以下统称为“工程”。

建筑施工合同中英文对照

建设工程施工合同发包方（甲方）xxxxParty A: xxxx承包方（乙方）xxxxParty B: xxxx本合同由如上列明的甲、乙双方按照《中华人民共和国合同法》、《建筑安装工程承包合同条例》以及国家相关法律法规的规定，结合本合同具体情况，于xx年x月x日在xx签订。

This contract is signed by the two Parties in xxxx on xxxx according to the “Contract Law of the People’s Republic of China”, the “Regulation on Building and Installation Contracting Contract”, and other relevant national laws and regulations, as well as the specific nature of this project第一条总则Article 1 General Principles1.1合同文件Contract Documents本合同包含合同、展示、施工图纸、作法说明、招投标文件以及合同所指的其他文件，它们均被视为合同的一部分。

合同文件应该能够相互解释，互为说明。

组成本合同的文件及优先解释的顺序如下：本合同、中标通知书、投标书及其附件、标准、规范及有关技术文件、图纸、工程量清单及工程报价单或预算书。

合同履行中，发包人承包人有关工程的洽商、变更等书面下一或文件视为本合同的组成部分。

This contract includes the contract itself, exhibits, construction drawings, explanations of work procedures, tender documents, as well as other documents specified by the contract. The contract documents should be mutually explainable and mutually descriptive. The documents that constituted the contract and the priority hierarchy of explanations of the documents are as follows: this contract; the official letter of winning the tender; Letter of bidding and its annex, standards, guidelines, and relevant technical documents, drawings, Bill of Quantity (BOQ), quotation of prices, and project budget. During the implementation of the contract, any written agreements or documents between two parties such as change-orders are also regarded will be deemed as part of this contract.1.1.1项目概况Project Introduction1.1.2工程名称：xxxxName of Project: xxxx1.1.3工程地点：xxxxLocation of Project: xxxx1.1.3.1工程范围：除了本合同其他条款另有说明外，乙方应提供为履行合同所需的所有服务，用品以及其他保障工程进行所需的必要花费以完成下列工作：Scope of the project: unless otherwise explained by other articles in this contract, Party B shall provide all services, utensils, and other necessary cost for the implementation of this contract; the scope of project includes, but not limited to:※室内装饰工程，详见附件一和附件二Inner decoration, see appendix 1 & 2※室外装饰工程（门窗、屋面、台阶等），详见附件一和附件二Façade(including doors, windows, roof and stairs) see appendix 1 & 2※电器工程，详见附件一和附件二Electronic Engineering, see appendix 1 & 2※空调工程，详见附件一和附件二Air Conditioning System, see appendix 1 & 2※给排水及采暖工程，详见附件一和附件二Water Supply, Sewage and Heating System, see appendix 1 & 2※消防工程Fire Control System, see appendix 1 & 2※其他图纸上所列项目（任何对原定设计的变更应提供新的图纸并有甲方的签字确认）以上所有的工程项目以下统称为“工程”。