英文建筑合同_合同范本
英文建筑合同模板
英文建筑合同模板Building Contract Template。
This Building Contract ("Contract") is made and entered into as of [Date], by and between [Builder Name], with a principal place of business at [Address] ("Builder"), and [Owner Name], with a principal place of residence at [Address] ("Owner").1. Scope of Work。
Builder agrees to provide all labor, materials, equipment, and services necessary for the construction of [Description of Project] ("Project") in accordance with the plans and specifications attached hereto as Exhibit A. Builder shall complete the Project in a good and workmanlike manner, in compliance with all applicable laws, regulations, and codes.2. Payment。
Owner agrees to pay Builder the total contract price of [Total Contract Price] for the completion of the Project. The payment shall be made in installments as follows:a. [Percentage]% of the total contract price upon the execution of this Contract;b. [Percentage]% of the total contract price upon completion of [Milestone 1];c. [Percentage]% of the total contract price upon completion of [Milestone 2];d. [Percentage]% of the total contract price upon substantial completion of the Project; and。
fidic建筑合同范本
fidic建筑合同范本FIDIC 建筑合同范本第一部分：定义和解释1. 定义：本合同中使用的特定术语应具有下文赋予它们的含义。
2. 解释：单数包括复数，反之亦然。
除非上下文另有要求，否则：条款和条件是指本合同的条款和条件。
附件是指本合同的附件。
日是指日历日。
承包商是指签署本合同的当事人以及获得其权利和承担其义务的当事人的继任者和受让人。
工程师是指本合同中指定的工程师或工程师的继任者。
雇主是指本合同中指定的雇主或雇主的继任者。
费用是指承包商在履行本合同过程中发生的所有费用，包括但不限于直接费用、间接费用、利润和税金。
竣工是指承包商完成了本合同规定的所有工作，并使工程达到了本合同规定的竣工标准。
竣工日期是指本合同中规定的竣工日期。
缺陷是指工程中存在的任何不符合本合同规定的瑕疵或缺陷。
接收证书是指工程师颁发的证明工程已经竣工并可以接收的证书。
履约保证是指承包商向雇主提供的保证，保证其将按照本合同的规定履行其义务。
缺陷责任期是指本合同中规定的承包商对工程缺陷承担责任的期限。
本合同是指本合同及其附件。
第二部分：雇主的义务1. 雇主应按照本合同的规定向承包商支付款项。
2. 雇主应提供工程所需的场地、水、电等基础设施。
3. 雇主应协助承包商办理工程所需的批准和许可手续。
4. 雇主应按照本合同的规定进行工程变更。
第三部分：承包商的义务1. 承包商应按照本合同的规定进行工程施工，并确保工程的质量符合本合同的规定。
2. 承包商应按照本合同的规定提供履约保证。
3. 承包商应按照本合同的规定承担工程缺陷责任。
4. 承包商应按照本合同的规定进行工程保险。
5. 承包商应按照本合同的规定进行环境保护。
第四部分：工程变更1. 雇主可以对工程进行变更，但应提前通知承包商，并与承包商协商确定变更的费用和工期。
2. 承包商应按照工程师的指示进行工程变更，并确保变更后的工程质量符合本合同的规定。
3. 因工程变更导致合同价款的增减，由双方协商确定。
英文建筑工程合同范本
英文建筑工程合同范本THIS AGREEMENT is made on the __________ day of __________, 20__,BETWEEN:[Company Name], a company incorporated in [Country] with its registered office at [Address] (hereinafter referred to as "Contractor"), and[Client Name], a company incorporated in [Country] with its registered office at [Address] (hereinafter referred to as "Client").WHEREAS:The Client intends to engage the Contractor to carry out the construction works described in this Agreement ("the Works"), andThe Contractor has agreed to carry out the Works in accordance with the terms and conditions set out below.NOW IT IS HEREBY AGREED as follows:1. Scope of Works: The Contractor shall perform the Works as detailed in the attached Schedule of Works, which forms an integral part of this Agreement.2. Contract Price: The total contract price for the Worksshall be [Amount], as stated in the attached quotation,subject to any adjustments for variations as provided in this Agreement.3. Commencement and Completion: The Works shall commence onthe __________ day of __________, 20__, and shall becompleted within [Number] days from the commencement date.4. Variations: Any variation to the Works shall be agreedupon in writing by both parties and shall be subject to an adjustment in the Contract Price.5. Payment Terms: The Client shall make payments to the Contractor in accordance with the payment schedule attached hereto, which shall be based on the progress of the Works.6. Liability and Insurance: The Contractor shall maintain all necessary insurances, including but not limited to public liability, workers' compensation, and professional indemnity insurance.7. Warranty: The Contractor warrants that the Works shall be carried out in a proper and workmanlike manner and shall comply with all applicable laws and regulations.8. Dispute Resolution: Any disputes arising out of or in connection with this Agreement shall be resolved by mediation, failing which, by arbitration in accordance with the rules of the [Arbitration Institution].9. Termination: Either party may terminate this Agreement by written notice if the other party is in material breach and fails to remedy such breach within [Number] days afterreceipt of written notice.10. Confidentiality: Both parties shall keep confidential all information obtained from the other party in connection with this Agreement.11. Force Majeure: Neither party shall be liable for any delay or failure in performing its obligations under this Agreement to the extent that such delay or failure is caused by events beyond its reasonable control.12. Entire Agreement: This Agreement constitutes the entire agreement between the parties and supersedes all prior negotiations, representations, and agreements.13. Governing Law: This Agreement shall be governed by and construed in accordance with the laws of [Country].14. Notices: Any notice required or permitted to be given under this Agreement shall be in writing and shall be deemed to have been duly given when delivered or sent by registered post to the addresses of the parties as stated in this Agreement.IN WITNESS WHEREOF, the parties have executed this Agreement on the day and year first above written.[Company Name]By: ___________________________ [Authorized Signatory][Client Name]By: ___________________________ [Authorized Signatory]。
工程合同范本英文
工程合同范本英文---roject Construction Contractarty A (Emloyer): [Full Name]arty (Contractor): [Full Name]Article 1: roject OverviewThis contract is made on [Date] etween arty A and arty , regarding the construction roject of [roject Name]. The roject location is [Location], with a total construction area of [Area] square meters.Article 2: Scoe of WorkThe contractor shall e resonsile for the following scoe of work: [Detailed List of Work]. This includes all necessary laor, materials, equiment, and services required to comlete the roject according to the agreed secifications and standards.Article 3: Contract riceThe total contract rice for the roject is [Total rice] USD, which includes all costs associated with the comletion of the work as er the contract agreement.Article 4: ayment Termsayment shall e made in accordance with the following schedule: [ayment Schedule Details]. Any delay in ayment may result in interest charges or contract susension as er the terms outlined in this agreement.Article 5: Timeline and MilestonesThe roject must e comleted within [Timeframe]. Key milestones include [List of Milestones], with each milestone having its own deadline and requirements.Article 6: Quality StandardsAll work must meet the quality standards set y [Relevant Standards ody] and any additional requirements secified y arty A.Article 7: Change OrdersAny changes to the original scoe of work must e aroved in writing y oth arties and may result in adjustments to the contract rice and timeline.Article 8: Liaility and Insurancearty shall maintain liaility insurance covering all asects of the work erformed under this contract. In case of any claims, damages, losses, or exenses, arty shall e resonsile unless otherwise rovided in this contract.Article 9: Disute ResolutionAny disutes arising from or related to this contract shall first e addressed through negotiations etween the arties. If unresolved, the disute may e sumitted to [Mode of Aritration or Legal Jurisdiction].Article 10: TerminationEither arty may terminate this contract uon written notice to the other arty in the event of a material reach or failure to erform oligations as er the contract terms.Article 11: Governing LawThis contract shall e governed y and construed in accordance with the laws of [Governing Law Country].Article 12: MiscellaneousThis contract constitutes the entire agreement etween the arties and suersedes all rior negotiations, reresentations, and agreements. Any amendments or modifications must e in writing and signed y oth arties.IN WITNESS WHEREOF,arty A has signed this contract on [Date],ANDarty has signed this contract on [Date].---。
厂房建造合同英文模板
厂房建造合同英文模板This Manufacturing Facility Construction Agreement (the “Agreement”) is made effective as of [Date], by and between [Owner Name], having its principal place of business at [Owner Address] (“Owner”) and [Contractor Name], having its principal place of business at [Contractor Address] (“Contractor”).RecitalsWHEREAS, Owner desires to construct a manufacturing facility on the property located at [Property Address] (the “Property”); andWHEREAS, Contractor is a licensed general contractor with experience in constructing manufacturing facilities;NOW, THEREFORE, in consideration of the mutual covenants contained herein, the parties agree as follows:1. Scope of Work1.1. Contractor agrees to furnish all labor, materials, equipment, tools, services, and other facilities necessary for the construction of the manufacturing facility in accordance with the plans and specifications provided by Owner (the “Project”).1.2. The Project shall include, but not be limited to, the following:1.2.1. Site preparation, including clearing, grading, and excavation;1.2.2. Foundation construction;1.2.3. Structural steel erection;1.2.4. Roofing and siding installation;1.2.5. Electrical, plumbing, and HVAC installation;1.2.6. Interior finishing, including walls, ceilings, and flooring;1.2.7. Landscaping and site amenities.2. Construction Schedule2.1. Contractor shall commence construction of the Project on or before [Start Date] and shall diligently pursue completion within [Number] days of the start date.2.2. Owner may extend the completion date in writing for any reasonable cause, provided Contractor is not in default of its obligations under this Agreement.3. Payment3.1. Owner shall pay Contractor for the construction of the Project in accordance with the following schedule:3.1.1. [Payment Schedule]3.2. Owner shall retain [Percentage]% of the total contract amount as retainage, which shall be released upon satisfactory completion of the Project.3.3. Contractor shall submit invoices to Owner on a monthly basis for the work completed during that period.4. Change Orders4.1. Owner may request changes to the Project specifications or scope of work by issuing a change order in writing.4.2. Contractor shall provide Owner with a written estimate of the cost and time required to implement the change order.4.3. Change orders shall not be binding on the parties unless approved in writing by both Owner and Contractor.5. Quality Assurance5.1. Contractor shall ensure that all work performed on the Project meets or exceeds industry standards and complies with all applicable laws, regulations, and codes.5.2. Owner may inspect the work at any time to ensure compliance with the specifications and quality standards set forth in this Agreement.6. Warranty6.1. Contractor warrants that all work performed on the Project will be free from defects in materials and workmanship for a period of [Number] years from the date of substantial completion.6.2. Contractor agrees to promptly correct any defects or deficiencies identified by Owner during the warranty period at no additional cost to Owner.7. Indemnification7.1. Contractor shall indemnify, defend, and hold harmless Owner from and against any and all claims, damages, losses, liabilities, and expenses arising out of or in connection with the Project, including, but not limited to, personal injury, property damage, and breach of contract.8. Termination8.1. Either party may terminate this Agreement upon written notice if the other party materially breaches any provision of this Agreement and fails to cure such breach within [Number] days of receiving written notice of the breach.8.2. In the event of termination, Owner shall pay Contractor for all work completed and materials supplied up to the date of termination.9. General Provisions9.1. This Agreement constitutes the entire agreement between the parties with respect to the subject matter hereof and supersedes all prior agreements and understandings, whether written or oral.9.2. This Agreement may not be amended except in writing signed by both parties.9.3. This Agreement shall be governed by and construed in accordance with the laws of [State].IN WITNESS WHEREOF, the parties have executed this Agreement as of the date first above written.[Owner Name] [Contractor Name]By: ____________________ By: _____________________Name: Name:Title: Title:。
英文住房合同模板简单
英文住房合同模板简单This Residential Lease Agreement (the "Lease") is made and entered into on [Date], by and between [Landlord's Name] (the "Landlord") and [Tenant's Name] (the "Tenant").1. Property AddressThe Landlord hereby leases to the Tenant, and the Tenant hereby rents from the Landlord, the following described real property (the "Premises"): [Property Address], for use as a residential dwelling unit only.2. TermThe term of this Lease shall begin on [Start Date] and shall continue for a period of [Length of Lease] months. The Landlord shall have the right to terminate this Lease upon [Number of Days] days' written notice to the Tenant.3. RentThe Tenant agrees to pay the Landlord monthly rent in the amount of [Monthly Rent Amount], due on the [Day of the Month] day of each month. Rent shall be paid in [Payment Method] to the Landlord at [Landlord's Address].4. Security DepositThe Tenant shall deposit with the Landlord a security deposit in the amount of [Security Deposit Amount]. The security deposit shall be held by the Landlord as security for the performance of the Tenant's obligations under this Lease. The security deposit shall be returned to the Tenant within [Number of Days] days after the end of the Lease term, less any deductions for damages or unpaid rent.5. UtilitiesThe Tenant shall be responsible for all utilities and services for the Premises, including but not limited to electricity, gas, water, sewer, and trash removal.6. Maintenance and RepairsThe Landlord shall be responsible for all repairs and maintenance of the Premises, including but not limited to plumbing, electrical, heating, and air conditioning. The Tenant shall be responsible for any repairs or damages caused by the Tenant's negligence or misuse.7. Use of PremisesThe Tenant shall use the Premises only as a private residence for the Tenant and Tenant's immediate family. The Tenant shall not sublet or assign the Premises without the Landlord's prior written consent.8. PetsPets are not allowed on the Premises without the Landlord's prior written consent. If the Landlord consents to pets, the Tenant shall be responsible for any damage caused by the pets.9. Entry by LandlordThe Landlord or the Landlord's agents shall have the right to enter the Premises at reasonable times for the purpose of inspecting the Premises, making repairs, or showing the Premises to prospective tenants.10. Governing LawThis Lease shall be governed by the laws of [State]. Any disputes arising under this Lease shall be resolved in the courts of [County], [State].IN WITNESS WHEREOF, the Landlord and Tenant have executed this Lease as of the date first above written.Landlord:__________________________[Landlord's Name]Tenant:__________________________[Tenant's Name]。
英文建筑合同5篇
英文建筑合同5篇篇1English Construction ContractIntroductionA construction contract is a legally binding agreement between a client and a contractor outlining the terms and conditions of a construction project. It is crucial for both parties to understand and adhere to the contract to ensure a successful completion of the project. This document provides an overview of key components of an English construction contract.Parties InvolvedThe parties involved in a construction contract are the client and the contractor. The client is typically the individual or organization who owns the property and wishes to have a construction project completed. The contractor is the individual or company responsible for carrying out the construction work.Scope of WorkThe scope of work outlines the specific tasks and responsibilities of the contractor. This includes the timeline forcompletion, materials to be used, and any special requirements or considerations. It is important for both parties to agree on the scope of work before the project begins to prevent any misunderstandings or disputes down the line.Payment TermsPayment terms are a critical aspect of the construction contract. This section outlines the total cost of the project, the schedule for payments, and any penalties for late payments. It is important for both parties to agree on the payment terms to avoid any financial disputes during the project.Insurance and LiabilityInsurance and liability clauses are an essential part of the construction contract to protect both parties in case of accidents or damages. The contractor should have the appropriate insurance coverage to protect against any liability claims. Additionally, the client should understand their responsibilities in case of any damages or accidents on the construction site.Change OrdersChange orders are amendments to the original contract that outline any changes in the scope of work, timeline, or budget. It is common for changes to occur during the construction process,and both parties must agree on these changes in writing to ensure clarity and avoid disputes.Dispute ResolutionDispute resolution clauses outline the process for resolving any disputes that may arise during the construction project. This may include mediation, arbitration, or litigation. It is important for both parties to understand and agree on the dispute resolution process to prevent any delays in the project.ConclusionIn conclusion, an English construction contract is a crucial document that outlines the terms and conditions of a construction project. It is essential for both parties to understand and adhere to the contract to ensure a successful completion of the project. By including key components such as parties involved, scope of work, payment terms, insurance and liability, change orders, and dispute resolution, both the client and contractor can protect themselves and prevent any misunderstandings or disputes.篇2English Building ContractIntroductionA building contract is a legally binding agreement between the owner of a property and a contractor for the construction, renovation or repair of a building. It is crucial for both parties to have a clear understanding of the terms and conditions of the contract to ensure a successful and satisfactory project outcome.Key Components of a Building Contract1. Parties Involved: The building contract should clearly state the names and contact details of both the owner and the contractor. It should also include details of any subcontractors or suppliers involved in the project.2. Scope of Work: The contract should outline the specific work to be carried out, including the materials to be used, the timeline for completion, and any relevant drawings or specifications.3. Payment Terms: Details of the payment schedule, including the amount due at each stage of the project, should be clearly outlined in the contract. Any penalties for late payment or changes to the payment terms should also be included.4. Change Orders: Any changes to the scope of work or specifications should be documented in writing as change orders.These changes may impact the project timeline and budget, so it is important that both parties agree to any changes before work proceeds.5. Insurance and Liability: The contract should specify the insurance coverage required by both parties, including liability insurance, workers' compensation, and property insurance. It should also outline the responsibilities of each party in the event of accidents or damage to the property.6. Dispute Resolution: In the event of a dispute, the contract should outline the process for resolving disagreements, whether through mediation, arbitration, or litigation.Tips for a Successful Building Contract1. Clearly Define the Scope of Work: Make sure that all aspects of the project are clearly outlined in the contract, including the materials to be used, the timeline for completion, and any site-specific requirements.2. Review and Understand the Contract: Both parties should thoroughly review the contract and seek legal advice if necessary to ensure that they understand their rights and obligations under the agreement.3. Communicate Effectively: Open and regular communication between the owner and the contractor is essential for a successful project. Any changes to the scope of work or unexpected issues should be discussed and documented in writing.4. Monitor Progress: The owner should regularly inspect the work to ensure that it is being completed according to the contract specifications. Any concerns or issues should be addressed promptly to avoid delays or disputes.ConclusionA well-drafted building contract is essential for the successful completion of a construction project. It provides a clear framework for the work to be carried out, the payment terms, and the responsibilities of both parties. By following the key components of a building contract and communicating effectively throughout the project, both the owner and the contractor can ensure a smooth and satisfactory outcome.篇3英文建筑合同Building ContractThis Building Contract is made and entered into on this __ day of ___, 20__ between [Name of Owner], hereinafter referred to as the "Owner," and [Name of Contractor], hereinafter referred to as the "Contractor."I. Scope of WorkContractor agrees to furnish all materials, equipment, labor, and services necessary for the construction of [Description of Project] according to the plans and specifications prepared by [Architect/Engineer]. Contractor shall complete the work in a good and workmanlike manner and in compliance with all applicable laws and regulations.II. PaymentOwner agrees to pay Contractor the sum of [Dollar Amount] for the completion of the work. Payment shall be made in installments as follows:- [Percentage]% upon signing of this Contract- [Percentage]% upon completion of [Milestone]- [Percentage]% upon substantial completion- [Percentage]% upon final completion and acceptanceIII. ChangesOwner may make changes to the plans and specifications with the written consent of Contractor. Any changes in the scope of work shall be made by written Change Order and the contract sum and completion date shall be adjusted accordingly.IV. SubcontractorsContractor may use subcontractors to perform portions of the work. Contractor shall be responsible for the acts and omissions of subcontractors and shall ensure that they comply with the terms of this Contract.V. Time of CompletionContractor shall complete the work within [Number] days from the date of commencement. Owner may grant an extension of time for completion for reasons beyond Contractor's control.VI. WarrantyContractor warrants that all work shall be free from defects for a period of [Number] years from the date of final completion. Owner shall notify Contractor of any defects in writing and Contractor shall promptly correct them at no additional cost to Owner.VII. IndemnificationContractor shall indemnify and hold Owner harmless from any claims, damages, or liabilities arising from Contractor's performance under this Contract.VIII. TerminationEither party may terminate this Contract with written notice if the other party materially breaches any term or condition of this Contract. Upon termination, Contractor shall be entitled to payment for work completed up to the date of termination.IX. Entire AgreementThis Contract constitutes the entire agreement between the parties and supersedes all prior agreements and understandings, whether written or oral. Any amendments to this Contract must be in writing and signed by both parties.IN WITNESS WHEREOF, the parties have executed this Contract as of the date first above written.Owner: [Name of Owner]Contractor: [Name of Contractor]Date: ______, 20__This Building Contract is hereby accepted and approved:Architect/Engineer: [Name]Date: ______, 20__This document sets forth the terms and conditions of the agreement between the Owner and Contractor for the construction of the specified project. It is important for both parties to carefully review and understand the terms of the Contract before signing to ensure that all aspects of the project are clearly defined and agreed upon.篇4English Building ContractA building contract is a legally binding agreement between a client and a contractor for the construction or renovation of a building. The contract outlines the terms and conditions under which the project will be completed, including the scope of work, schedule, budget, and responsibilities of each party.The purpose of a building contract is to protect the interests of both parties by clearly defining the expectations and requirements of the project. By establishing a formal agreement, potential disputes and misunderstandings can be avoided, and the project can proceed smoothly and efficiently.Key Terms of a Building ContractWhen drafting a building contract, there are several key terms and clauses that should be included to ensure that both parties are protected and informed throughout the construction process. Some of the key terms that should be included in a building contract include:1. Scope of Work: The contract should clearly outline the scope of work to be performed, including details of the construction or renovation project, materials to be used, and any specific requirements or specifications.2. Schedule: The contract should include a timeline for the project, including start and completion dates, milestones, and deadlines for various stages of the construction process.3. Budget: The contract should include a detailed breakdown of the project costs, including labor, materials, equipment, and any additional expenses. The contract should also specify payment terms, including the amount of the initial deposit, progress payments, and final payment.4. Change Orders: The contract should include a provision for change orders, which allow for modifications to the scope of work or project timeline. Change orders should include details ofthe requested changes, costs, and any adjustments to the schedule.5. Insurance and Liability: The contract should specify the insurance requirements for the project, including liability insurance, workers' compensation, and any other insurance policies required by law. The contract should also include provisions for indemnification and liability for damages or injuries.6. Dispute Resolution: The contract should include provisions for resolving disputes, including the process for mediation, arbitration, or litigation if a disagreement arises between the parties.7. Termination: The contract should include provisions for terminating the agreement, including the circumstances under which either party can cancel the contract and any penalties or fees associated with early termination.ConclusionIn conclusion, a building contract is an essential document for any construction or renovation project. By clearly outlining the terms and conditions of the agreement, both parties can protect their interests and ensure that the project proceedssmoothly and efficiently. It is important for both the client and the contractor to carefully review and negotiate the terms of the contract before signing to avoid any misunderstandings or disputes during the construction process.篇5English Construction ContractA construction contract is a legally binding agreement between a client and a contractor, where the contractor agrees to build, renovate, or repair a structure in exchange for payment. The contract outlines the scope of work, timelines, payment terms, and responsibilities of both parties. In the UK, construction contracts are governed by the Housing Grants, Construction, and Regeneration Act 1996 (also known as the Construction Act) and the Scheme for Construction Contracts Regulations.Types of ContractsThere are several types of construction contracts, each with its own advantages and disadvantages:1. Lump Sum Contract: This is where the contractor agrees to complete the project for a fixed price. This type of contract is common for small projects with well-defined scopes of work.2. Cost Plus Contract: In this type of contract, the contractor is reimbursed for the actual costs of construction plus a fee for overhead and profit. This is often used for projects with uncertain scopes of work or where the client wants more control over the costs.3. Time and Materials Contract: In this type of contract, the client pays for the materials and labor costs plus a fee for overhead and profit. This type of contract is commonly used for small projects where it is difficult to define the scope of work.4. Design-Build Contract: In a design-build contract, the contractor is responsible for both the design and construction of the project. This type of contract can streamline the construction process and minimize conflicts between designers and contractors.Key Clauses in a Construction Contract1. Scope of Work: The contract should clearly define the scope of work, including the materials to be used, construction methods, and quality standards.2. Payment Terms: The contract should outline the payment schedule, including milestones for progress payments and the final payment upon completion of the project.3. Change Orders: The contract should address how changes to the scope of work will be handled, including any additional costs.4. Delays: The contract should outline how delays will be addressed, including extensions of time and liquidated damages for late completion.5. Dispute Resolution: The contract should include a mechanism for resolving disputes, such as mediation or arbitration.6. Insurance and Indemnity: The contract should detail the insurance requirements for the project and how liability will be allocated between the parties.ConclusionA well-drafted construction contract is essential for a successful construction project. It helps to protect the interests of both parties and minimizes the risk of disputes. By clearly defining the scope of work, payment terms, and responsibilities, a construction contract can help ensure that the project is completed on time and within budget.。
建筑房屋英文合同范本
建筑房屋英文合同范本Building Construction ContractThis Building Construction Contract (the "Contract") is made and entered into on [date] and between [Owner's Name] (the "Owner") and [Contractor's Name] (the "Contractor").1. Project DescriptionThe Contractor agrees to construct a residential building (the "Building") at the location specified the Owner at [Address]. The Building shall be constructed in accordance with the plans and specifications provided the Owner and approved the Contractor (the "Plans and Specifications").2. Contract Price and Payment TermsThe total contract price for the construction of the Building is [Total Contract Price] (the "Contract Price"). The Owner shall make the following payments to the Contractor:A deposit of [Deposit Amount] upon the signing of this Contract.Progress payments as the work progresses in accordance with the schedule set forth in the Plans and Specifications.The final payment of [Final Payment Amount] upon pletion of the Building and acceptance the Owner.3. Construction ScheduleThe Contractor shall mence construction on or before [Commencement Date] and shall plete the Building on or before [Completion Date]. The Contractor shall provide the Owner with a detled construction schedule showing the projected start and pletion dates of each phase of the project.4. Workmanship and MaterialsThe Contractor shall perform the work in a good and workmanlike manner and shall use materials of good quality that are in accordance with the Plans and Specifications. The Contractor shall warrant the workmanship and materials for a period of [Warranty Period] from the date of pletion.5. Changes and ModificationsAny changes or modifications to the Plans and Specifications shall be made in writing and signed both the Owner and the Contractor. Any additional costs resulting from such changes or modifications shall be agreed upon the parties before the work is menced.6. Inspection and AcceptanceThe Owner or the Owner's representative shall have the right to inspect the work at reasonable intervals during the construction process. Upon pletion of the Building, the Owner shall inspect the Building and, if satisfied with the work, shall issue a written acceptance. If the Owner finds any defects or deficiencies, the Contractor shall correct them within a reasonable time.7. Insurance and BondsThe Contractor shall obtn and mntn during the construction period insurance coverage for workers' pensation, liability, and property damage in amounts sufficient to cover the risks associated with the project. The Contractor shall also provide a performance bond in the amount of [Bond Amount] to ensure the pletion of the project in accordance with the Contract.8. Dispute ResolutionIn the event of a dispute between the parties arising out of or in connection with this Contract, the parties shall attempt to resolve the dispute through friendly negotiation. If the dispute cannot be resolved through negotiation, the parties agree to submit the dispute to arbitration in accordance with the rules of [Arbitration Institution].9. Governing LawThis Contract shall be governed and construed in accordance with the laws of [Jurisdiction].10. Entire AgreementThis Contract constitutes the entire agreement between the parties and supersedes all prior negotiations, representations, and agreements. No amendment or modification of this Contract shall be effective unless in writing and signed both parties.IN WITNESS WHEREOF, the parties have executed this Contract as of the date first above written.Owner: [Owner's Signature] [Owner's Name] [Owner's Address] [Owner's Contact Information]Contractor: [Contractor's Signature] [Contractor's Name] [Contractor's Address] [Contractor's Contact Information]。
建筑标准合同范本英文
建筑标准合同范本英文BUILDING CONSTRUCTION STANDARD CONTRACT TEMPLATEContract AgreementThis Building Construction Contract (hereinafter referred to as the "Contract") is made and entered into and between the following parties:Party A (Owner/Employer):[Full Name of the Owner/Employer][Address of the Owner/Employer]Party B (Contractor):[Full Name of the Contractor][Address of the Contractor]Article 1: Scope of WorkThe scope of work under this Contract shall consist of the construction, pletion, and delivery of the building project as specified in the attached drawings, specifications, and any other documents agreed upon both parties (collectively referred to as the "Project Documents"). The Project Documents shall form an integral part of this Contract.Article 2: Contract Price and Payment TermsThe total contract price for the Project shall be [Amount in Words and Figures]. Payment shall be made in accordance with the following terms: An initial payment of [Percentage]% of the total contract price shall be made upon signing of this Contract.Progress payments shall be made at agreed-upon intervals based on the percentage of pletion of the Project, as certified Party A.The final payment, representing the balance of the total contract price, shall be made upon satisfactory pletion and acceptance of the Project Party A.Article 3: Project ScheduleThe Project shall be menced on [Start Date] and pleted [Completion Date], subject to any force majeure events or changes agreed upon both parties.Article 4: Quality StandardsThe construction work shall be performed in accordance with the Project Documents and shall ply with all relevant local building s, standards, and regulations. Any defects or deficiencies in the work shall be rectified Party B at its own cost.Article 5: WarrantyParty B warrants that the Project shall be free from defects in materials and workmanship for a period of [Number] years from the date of pletion. During this warranty period, Party B shall, upon notification Party A, promptly repr or replace any defective materials or workmanship.Article 6: TerminationThis Contract may be terminated either party in the event of a material breach the other party, provided that a written notice of default is given and a reasonable opportunity to rectify the breach is afforded. In the event of termination, the parties shall settle all outstanding payments and other obligations in accordance with the terms of this Contract.Article 7: Dispute ResolutionAny disputes arising out of or in connection with this Contract shall be resolved through amicable negotiations between the parties. If such negotiations fl to produce a settlement, the parties shall submit the dispute to [Arbitration Institute/Court] for arbitration/resolution.Article 8: MiscellaneousThis Contract shall be governed and construed in accordance with the laws of [Country/Jurisdiction].This Contract constitutes the entire agreement between the parties and supersedes any previous agreements or understandings.Any amendments or modifications to this Contract shall be made in writing and signed both parties.Signature:Party A (Owner/Employer):By: _______________________Name: _______________________Date: _______________________ Party B (Contractor):By: _______________________ Name: _______________________ Date: _______________________。
工程项目英语合同
工程项目英语合同合同编号：[合同编号]签订日期：[签订日期]签订地点：[签订地点]甲方（业主）：[甲方全称]乙方（承包商）：[乙方全称]鉴于甲乙双方同意就[项目名称]工程项目（以下简称“本工程”）进行合作，经友好协商，达成如下合同条款：一、工程概述本工程位于[工程地点]，涉及[具体工程内容]。
工程预计开工日期为[开工日期]，竣工日期为[竣工日期]。
二、合同价款合同总价为[合同金额]美元，包含所有材料、劳务、设备以及相关的管理费用。
三、付款方式1. 预付款：甲方需在本合同签订后[指定天数]内支付合同总价的[百分比]作为预付款。
2. 进度付款：乙方完成特定工程阶段后，甲方将按照合同约定支付相应的进度款项。
3. 最终付款：工程竣工并经甲方验收合格后，甲方应支付剩余的合同款项。
四、工期与延期乙方应保证工程按计划进行，如遇不可抗力或甲方要求变更工程内容导致工期延误，双方应协商确定新的竣工日期。
五、质量保证乙方须确保工程质量符合国际标准及甲方要求，并为所提供工程提供[保修期限]年的质量保证期。
六、变更与调整任何对工程范围、质量要求或合同条件的变更，均需甲乙双方书面同意后方可执行。
七、争议解决因本合同引起的任何争议，应首先通过友好协商解决。
协商不成时，可提交至[指定的仲裁机构]进行仲裁。
八、法律适用本合同的签订、解释、执行和争议解决均适用[指定国家]的法律。
九、其他条款1. 保密条款：双方应对合同内容及在执行合同过程中获知的对方商业秘密予以保密。
2. 终止条款：如一方严重违约，另一方有权提前终止合同，并要求赔偿损失。
3. 附加条款：如有需要，双方可另行签订附加协议，该等协议构成本合同不可分割的一部分。
十、签字盖章本合同一式两份，甲乙双方各执一份，自双方代表签字盖章之日起生效。
甲方代表（签字）：_________ 日期：____年__月__日乙方代表（签字）：_________ 日期：____年__月__日。
英文建筑合同范本8篇
英文建筑合同范本8篇篇1This Building Contract is made and entered into on [Date] between [Builder], of [Builder's Address], and [Client], of [Client's Address].1. Definitions and InterpretationIn this Contract, the following words and expressions shall have the meanings assigned to them below:* “Builder” means [Builder's Name], the party engaged to carry out the Building Work;* “Client” means [Client's Name], the party commissionin g the Builder to carry out the Building Work;* “Building Work” means the building work described in Clause 2;* “Contract Price” means the price for the Building Work as set out in Clause 3;* “Commencement Date” means the date on which the Builder commences the Building Work, as notified to the Client in writing;* “Completion Date” means the date on which the Builder completes the Building Work, as notified to the Client in writing;* “Defects Liability Period” means the period of 12 months from the Completion Date, during which the Builder shall remedy any defects in the Building Work;* “Written Agreement” means any written agreement between the parties hereto, whether or not this Contract is varied or brought to an end;* “Force Majeure” means any cause beyond the reasonable control of a party to this Contract, including but not limited to war, riot, fire, explosion, storm, flood, drought, earthquake, or other natural disaster.2. Description of Building WorkThe Builder shall carry out the following building work at the site known as [Site Address]:* [Description of Building Work]3. Contract PriceThe Contract Price for the Building Work is [Contract Price]. This price includes:* [Inclusive Items in Contract Price]The Contract Price does not include:* [Exclusive Items in Contract Price]4. Payment of Contract PriceThe Client shall pay the Contract Price in full prior to the commencement of the Building Work. Payment shall be made by [Payment Method] to the account details provided by the Builder. The Builder shall provide a receipt for all payments made.5. Time for Completion6. Quality of Building Work7. Liability for Damage or Loss篇2This Building Contract is made and entered into between [Name of Employer], hereinafter called "the Employer", of [Address of Employer], and [Name of Contractor], hereinaftercalled "the Contractor", of [Address of Contractor], on this [Date of Contract].1. Definitions and Interpretation1.1 In this Contract, the following words and expressions shall have the meanings assigned to them:* "Site" means the location where the Building Work is to be carried out as described in the Contract Documents.* "Building Work" means the construction, alteration, repair, maintenance or demolition work on any building or structure which is the subject matter of this Contract.* "Contract Documents" means the drawings, specifications, estimates, plans, samples, instructions and other documents issued by the Employer to the Contractor for the execution of the Building Work.* "Employer" means the person or entity who undertakes to pay the Contractor for the Building Work in accordance with the terms of this Contract.* "Contractor" means the person or entity who is engaged by the Employer to carry out the Building Work and who agrees to do so in accordance with the terms of this Contract.* "Workman" means any person employed by the Contractor or its sub-contractors to carry out the Building Work.* "Sub-Contractor" means any person or entity to whom the Contractor sub-contracts any part of the Building Work.* "Tools and Plant" means all plant, machinery, equipment and tools required for the execution of the Building Work.* "Commencement Date" means the date on which the Building Work is commenced in accordance with the terms of this Contract.* "Completion Date" means the date on which the Building Work is completed in accordance with the terms of this Contract.1.2 The Contract Documents shall take precedence over any other documents or agreements between the parties hereto, save as otherwise provided in this Contract. Any reference in the Contract Documents to any act, matter or thing as being done, omitted or having occurred shall be deemed to be a reference to such act, matter or thing having been so done, omitted or occurred as required to be done, omitted or occurred by this Contract.2. The Contract2.1 The Contractor shall carry out the Building Work in accordance with the terms of this Contract and in accordance with all applicable laws, regulations and standards in force from time to time.2.2 The Employer shall pay for the Building Work in accordance with the terms of this Contract.3. The Price and Payment3.1 The Contractor shall submit a detailed estimate of the cost of carrying out the Building Work to the Employer for approval prior to commencing the same. The approved estimate shall form part of this Contract and shall be binding on both parties hereto.3.2 The Employer shall pay for the Building Work in full on completion of the same in accordance with the terms of this Contract.4. Time for Completion4.1 The Contractor shall complete the Building Work within a reasonable time as determined by the Employer from time to time. The Employer may, at its discretion, grant extensions of time for completion in writing.4.2 The Contractor shall notify the Employer immediately upon completion of the Building Work.5. Warranty5.1 The Contractor shall provide a warranty that for a period of [Insert warranty period] years from the Completion Date, the Building Work shall be free from defects in materials and workmanship provided that:* The Building Work is used under normal conditions and in accordance with any instructions provided by the Contractor; and* The Building Work is maintained and stored properly.5.2 If any defect arises within the warranty period due to materials or workmanship, the Contractor shall repair or replace such defect at no additional cost to the Employer.6. Indemnity6.1 The Contractor shall indemnify and keep indemnified the Employer against all actions, claims, demands, losses and damages suffered or incurred by the Employer as a result of or in connection with any injury, death or damage to property caused by or arising out of the carrying out by the Contractor of the Building Work under this Contract.7. Termination7.1 Either party hereto may terminate this Contract immediately upon written notice to the other party if:* The other party commits a material breach of its obligations under this Contract and fails to remedy such breach within a reasonable time as determined by the party terminating; or* An order is made for the winding up of either party's business or either party篇3建筑合同协议书甲方（业主）：XXXX，身份证号码：XXXX乙方（承包商）：XXXX，身份证号码：XXXX根据《中华人民共和国合同法》及相关法律法规，甲乙双方在平等、自愿、公平、诚实信用的基础上，就乙方承包甲方建筑项目事宜，达成如下协议：一、工程概况1. 工程名称：XXXX建筑项目2. 工程地点：XXXX3. 工程内容：包括但不限于建筑物的设计、施工、装修等4. 承包范围：具体以甲方提供的施工图纸为准5. 承包方式：包工包料，但甲方需自行采购部分材料6. 施工工期：自本合同签订之日起至XXXX年XX月XX日止7. 工程质量：符合国家相关建筑质量标准8. 工程价款：详见本合同附件一《工程报价表》二、甲方权利和义务1. 甲方有权对乙方的施工进度、质量进行监督，并提出合理建议和意见。
建筑合同范本英语版
建筑合同范本英语版Building Contract Template。
This Building Contract ("Contract") is entered into on [Date] by and between [Owner's Name] ("Owner") and [Contractor's Name] ("Contractor").1. Scope of Work。
The Contractor agrees to provide all labor, materials, equipment, and services necessary for the construction of [Description of the Project] ("Project"), in accordance with the plans and specifications provided by the Owner.2. Payment。
The Owner agrees to pay the Contractor the total contract price of [Total Amount] for the completion of the Project. The payment shall be made in installments as follows: [Payment Schedule].3. Time of Completion。
The Contractor agrees to complete the Project within [Number ofDays/Weeks/Months] from the commencement date. Delays in completion may result in liquidated damages as specified in the Contract.4. Changes and Modifications。
英文建造合同模板
英文建造合同模板This Contract ("Contract") is made and entered into this [Insert Date] by and between [Insert Party A Name], a [Insert Party A Type, e.g., corporation], with its principal place of business at [Insert Party A Address] (hereinafter referred to as "Contractor"), and [Insert Party B Name], a [Insert Party B Type, e.g., individual], with its principal place of business at [Insert Party B Address] (hereinafter referred to as "Owner").WHEREAS, the Owner desires to engage the Contractor to perform certain construction services; andWHEREAS, the Contractor agrees to provide such services in accordance with the terms and conditions set forth herein.NOW, THEREFORE, in consideration of the mutual promises and covenants contained herein, the parties agree as follows:1. Scope of Work: The Contractor shall provide all labor, materials, and equipment necessary to complete the construction project as described in the attached specifications ("Scope of Work").2. Payment Terms: The Owner shall pay the Contractor for the services provided in accordance with the following payment schedule: [Insert Payment Terms, e.g., 30% upon signing, 50% upon completion of phase 1, 20% upon final completion andacceptance].3. Contract Price: The total price for the work to be performed under this Contract is [Insert Total Contract Price], which includes all costs associated with the Scope of Work.4. Change Orders: Any changes to the Scope of Work must be documented in writing and signed by both parties. Such changes may result in adjustments to the Contract Price.5. Warranty: The Contractor warrants that all work performed under this Contract will be free from defects in workmanship and materials for a period of [Insert Warranty Period, e.g., one year] from the date of final completion.6. Liability and Insurance: The Contractor shall maintain general liability insurance coverage of at least [Insert Minimum Amount, e.g., $1,000,000] during the term of this Contract. The Contractor shall indemnify and hold the Owner harmless from any claims arising from the Contractor's performance under this Contract.7. Termination: Either party may terminate this Contract for cause upon written notice if the other party breaches any material term of this Contract and fails to cure such breach within [Insert Cure Period, e.g., 30 days] after receipt of written notice.8. Dispute Resolution: Any disputes arising out of or in connection with this Contract shall be resolved byarbitration in accordance with the rules of [Insert Arbitration Institution, e.g., the American Arbitration Association].9. Governing Law: This Contract shall be governed by and construed in accordance with the laws of the [Insert Governing State or Country].10. Entire Agreement: This Contract constitutes the entire agreement between the parties and supersedes all prior negotiations, representations, and understandings between them.11. Amendments: This Contract may not be amended or modified except in writing signed by both parties.12. Notices: All notices required or permitted under this Contract shall be in writing and shall be deemed given when delivered personally or by overnight courier or mailed by registered or certified mail, postage prepaid, to the addresses set forth above or to such other address as either party may designate in writing.IN WITNESS WHEREOF, the parties have executed this Contract as of the date first above written.[Insert Party A Name] [Insert Party B Name]By: _________________________ By: _________________________ [Authorized Signature] [Authorized Signature]Date: _________________________ Date:_________________________[Authorized Signatory's Name] [Authorized Signatory's Name] [Authorized Signatory's Title] [Authorized Signatory's Title]。
建筑工程英文合同范本
Contract for Construction WorkThis Contract (the "Contract") is made and entered into as of [Date], by and between [Client Name] ("Client"), a [Client's jurisdiction] corporation, and [Contractor Name] ("Contractor"), a [Contractor's jurisdiction] corporation.1. Scope of WorkThe Contractor agrees to perform all construction work (the "Work") as described in the attached Schedule A (the "Scope of Work"), which is incorporated into this Contract by reference. The Work shall be performed at the construction site located at [Location], as more particularly described in the Scope of Work.2. TermThe term of this Contract shall commence on the date hereof and shall continue until the Work is completed, or until the parties otherwise agree in writing to terminate this Contract (the "Term").3. Price and Payment Terms3.1 PriceIn consideration for the performance of the Work, the Client shall pay the Contractor the total amount of [Price], as set forth in the Scope of Work.3.2 Payment TermsThe Client shall make payments to the Contractor as follows:(a) [Percentage] of the total price shall be paid upon the signing of this Contract;(b) [Percentage] of the total price shall be paid upon the completion of [specify percentage of Work];(c) The remaining [Percentage] of the total price shall be paid upon the final completion of the Work, subject to the Client's approval as set forth in Section 6 below.4. Performance and Completion4.1 PerformanceThe Contractor shall perform the Work in accordance with the terms of this Contract, the applicable specifications and drawings, and all applicable laws, regulations, and standards.4.2 CompletionThe Contractor shall use commercially reasonable efforts to complete the Work on or before the completion date set forth in the Scope of Work (the "Completion Date"). The Contractor shall be responsible for any delays in completion of the Work, whether directly or indirectly caused by the Contractor's actions or inactions.5. WarrantiesThe Contractor warrants that the Work shall be performed in a workmanlike manner and in accordance with the applicable specifications and drawings. The Contractor further warrants that the Work shall be free from defects in materials and workmanship for a period of [Warranty Period], following the final completion of the Work.6. Approval of WorkThe Client reserves the right to inspect and approve the Work at any time during the performance of the Work. The Client's approval of the Work shall be deemed to have been given if the Client fails to object in writing to the Work within [specify number of days] after its completion.7. Default and Termination7.1 DefaultIf either party defaults in the performance of any material obligation under this Contract, the non-defaulting party may terminate this Contract by written notice to the defaulting party.7.2 Termination for ConvenienceThe Client may terminate this Contract at any time for any reason or no reason, upon written notice to the Contractor. In the event of such termination, the Contractor shall be entitled to payment for the Work performed up to the date of termination, subject to the Client's right to withhold any amounts due to the Contractor's default under this Contract.8. Dispute ResolutionAny disputes arising out of or in connection with this Contract shall be resolved by arbitration in accordance with the rules of the [Arbitration Association], and the decision of the arbitrator(s) shall be final and binding upon the parties.9. Governing LawThis Contract shall be governed by and construed in accordance with the laws of the [Governing Jurisdiction].10. Entire AgreementThis Contract constitutes the entire agreement between the parties with respect to the subject matter hereof, and supersedes all prior agreements, understandings, negotiations, and discussions, whether oral or written, of the parties.IN WITNESS WHEREOF, the parties have executed this Contract as of the date first above written.[Client Name] [Contractor Name]By:\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_ \_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_ \_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_ \_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_ \_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_ \_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_ \_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_ \_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_ \_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_ \_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_ \_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_ \_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_ \_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_ \_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_ \_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_ \_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_ \_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_ \_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_ \_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_ \_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_ \_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_ \_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_ \_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_ \_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_ \_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_ \_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_ \_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_ \_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_ \_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\。
英文建筑设计合同模板
英文建筑设计合同模板Effective Date: [Date]This agreement is made and entered into as of the Effective Date between [Client Name], located at [Client Address] (hereinafter referred to as the Client) and [Architect Name], located at [Architect Address] (hereinafter referred to as the Architect).WHEREAS, the Client desires to engage the services of the Architect to provide architectural design services for [Project Name], located at [Project Location]; andWHEREAS, the Architect is willing to provide architectural design services for the Project in accordance with the terms and conditions set forth in this Agreement.NOW, THEREFORE, in consideration of the mutual covenants contained herein and for other good and valuable consideration, the receipt and sufficiency of which are hereby acknowledged, the parties hereto agree as follows:1. Scope of WorkThe Architect shall provide architectural design services for the Project as outlined in Exhibit A attached hereto, which may be amended or supplemented by written agreement of the parties. The Architect shall use his professional skill and judgment to perform all necessary services in a timely and professional manner.2. CompensationThe Client shall pay the Architect a fee in the amount of [Fee Amount] for the Architect's services rendered under this Agreement. The fee shall be paid in installments as set forth in Exhibit B attached hereto. The Client shall also reimburse the Architect for any reasonable and necessary expenses incurred in the performance of services under this Agreement.3. ChangesAny changes to the scope of work or schedule shall be agreed upon by the parties in writing. The Architect shall be entitled to an adjustment in the fee and schedule as a result of any changes requested by the Client.4. Ownership of DocumentsAll drawings, specifications, reports, and other documents prepared by the Architect shall be the property of the Client upon full payment of the Architect's fee. The Client may use, modify, or reproduce the documents for the Project as necessary.5. TerminationEither party may terminate this Agreement upon written notice to the other party in the event of a material breach of this Agreement by the other party. Upon termination, theparties shall settle any financial obligations and the Architect shall deliver all documents and materials related to the Project to the Client.6. InsuranceThe Architect shall maintain professional liability insurance coverage in the amount of [Coverage Amount]. The Client shall be named as an additional insured on the policy. The Architect shall provide a certificate of insurance to the Client upon request.7. Governing LawThis Agreement shall be governed by the laws of the State of [State]. Any disputes arising out of or related to this Agreement shall be resolved by arbitration in accordance with the rules of the American Arbitration Association.IN WITNESS WHEREOF, the parties hereto have executed this Agreement as of the Effective Date.CLIENT: ARCHITECT:_______________________ ________________________[Client Name] [Architect Name]Exhibit A: Scope of WorkExhibit B: Fee ScheduleThis Agreement constitutes the entire agreement between the parties with respect to the subject matter hereof and supersedes all prior agreements and understandings, whether written or oral. This Agreement may not be modified or amended except in writing signed by both parties.。
建筑合同（中英版）（通用12篇）
建筑合同(中英版)（通用12篇）建筑(中英版) 篇1甲方：Party A：乙方：Party B：合同编号： Contract No日期：Date：签约地点：Signed at：特约定：甲方基于下文所列各种因素，特与乙方达成了协议并一致同意：由甲方在订约日期之翌日起_____天之内为乙方建造并完成_____（涉约建筑）。
涉约建筑之规模及所需的钢筋、水泥、砖块、石子和其它建筑材料之数量，均在作为附件的设计图和施工细则中予以说明。
Witnesses that the Party A for considerations hereinafter named, contracts and agrees with the Party B that Party A will, within_____ days, next following the date hereof, build and finish a Libarary Building for Party B. ( the building hereinafter is referred to as the said building.) The said building is of the following dimensions, with reinforced concrete, brick, stones and other materials, as are described in plans and specifications gereto annexed.基于上述情况，乙方及其法定代表郑重承诺向甲方支付人民币_____元整。
支付方法商定如下：In consideration of the foregoing, Party B shall, for itself and its legal representatives, promise to pay Party A the sum of one million RMB yuan in manner as follows, to wit：在上述工程开工之日，支付人民币_____元整在_____年_____月_____日，支付人民币_____元整在_____年_____月_____日，支付人民币_____元整在_____年_____月_____日，支付人民币_____元整在_____年_____月_____日，支付人民币_____元整余额人民币_____元整于工程完成之日付清。
英文建筑合同6篇
英文建筑合同6篇全文共6篇示例，供读者参考篇1English Building ContractA building contract is a legally binding agreement between a contractor and a client for the construction, renovation, or repair of a building or structure. It outlines the terms and conditions of the project, including the scope of work, schedule, payment terms, and responsibilities of each party.Scope of WorkThe scope of work section of the contract outlines the specific tasks and responsibilities that the contractor will perform. This includes everything from the materials and methods used in construction to the timeline for completion. It is important for both parties to have a clear understanding of what is expected in order to avoid disputes later on.ScheduleThe schedule section of the contract details the timeline for the project, including start and finish dates, milestones, anddeadlines for completion of specific tasks. It is important to include provisions for delays or extensions so that both parties are aware of their rights and responsibilities if the project falls behind schedule.Payment TermsThe payment terms section of the contract outlines how and when the client will pay the contractor for their services. This includes details on the amount of the contract, the payment schedule, and any penalties for late payment. It is important for both parties to agree on payment terms upfront to avoid misunderstandings or disputes during the course of the project.ResponsibilitiesThe responsibilities section of the contract outlines the duties of both parties during the course of the project. This includes everything from obtaining necessary permits and approvals to providing access to the site and ensuring safety and security measures are in place. It is important for both parties to understand their responsibilities in order to ensure a smooth and successful project.Dispute ResolutionThe dispute resolution section of the contract outlines how any disputes that may arise during the course of the project will be resolved. This may include mediation, arbitration, or litigation, depending on the terms of the contract. It is important for both parties to have a clear understanding of the dispute resolution process in order to avoid costly and time-consuming legal battles.Insurance and LiabilityThe insurance and liability section of the contract outlines the insurance coverage required for the project and the liability limits for both parties. This may include general liability insurance, workers' compensation insurance, and professional liability insurance. It is important for both parties to have adequate insurance coverage in place to protect against unforeseen events or accidents.ConclusionIn conclusion, a building contract is an essential document for any construction project. It outlines the terms and conditions of the project, including the scope of work, schedule, payment terms, and responsibilities of each party. By having a clear and comprehensive contract in place, both parties can avoid misunderstandings, disputes, and costly legal battles.篇2A standard form of contract in the construction industry is the JCT Design and Build contract, which is widely used in the UK. This type of contract is suitable for projects where the client wants to transfer the design and construction responsibilities to the contractor.The JCT Design and Build contract is a comprehensive document that sets out the rights and obligations of both parties in a clear and concise manner. It covers all aspects of the project, including the scope of work, the design and construction requirements, the schedule of work, and the payment terms.One of the key features of the JCT Design and Build contract is the provision for the contractor to carry out the design work. This means that the contractor takes on the responsibility for both the design and construction of the project, which can help to streamline the process and reduce the risk of disputes arising.The contract also includes provisions for the management of changes to the scope of work, as well as mechanisms for dealing with delays and disputes. It is important for both parties to understand their rights and obligations under the contract, aswell as the procedures for resolving any issues that may arise during the course of the project.In addition to the JCT Design and Build contract, there are a number of other standard forms of contract that are commonly used in the construction industry. These include the NEC Engineering and Construction contract, the FIDIC contract, and the ICE Conditions of Contract. Each of these contracts has its own specific terms and conditions, and it is important for both parties to be familiar with the particular requirements of the contract that they are using.Overall, a well-drafted construction contract is essential for ensuring that the rights and obligations of both parties are clearly defined and understood. By using a standard form of contract such as the JCT Design and Build contract, both parties can benefit from a clear and structured framework for the project, which can help to minimize the risk of disputes and delays.篇3English Construction Contract1. Parties InvolvedThis construction contract ("Contract") is made and entered into on [Date] by and between [Owner's Name] (hereinafterreferred to as "Owner"), and [Contractor's Name] (hereinafter referred to as "Contractor"). The Owner and Contractor are collectively referred to as the "Parties".2. Scope of WorkThe Contractor agrees to provide all labor, materials, equipment, permits, and services necessary for the construction of [Description of Project] (the "Project"). The Contractor shall complete the Project in accordance with the plans, specifications, and other documents outlined in Appendix A.3. PaymentThe Owner agrees to pay the Contractor the total contract price of [Contract Price] for the completion of the Project. The payment will be made as follows:- [Payment Schedule]4. Change OrdersAny changes or modifications to the Project shall be made in writing and signed by both Parties. The Contractor shall not proceed with any changes unless a change order has been executed.5. Time of CompletionThe Contractor agrees to complete the Project within [Timeframe] from the effective date of this Contract. If the Contractor fails to complete the Project within the specified time frame, the Owner may terminate the Contract and seek damages.6. WarrantyThe Contractor warrants that all work performed under this Contract shall be free from defects in workmanship and materials. The Contractor agrees to make any necessary repairs or replacements at no additional cost to the Owner.7. IndemnificationThe Contractor agrees to indemnify and hold harmless the Owner from any claims, damages, or liabilities arising from the Contractor's performance under this Contract.8. TerminationEither Party may terminate this Contract with written notice if the other Party fails to perform its obligations under this Contract. The terminating Party shall provide thenon-terminating Party with a notice of default and a reasonable opportunity to cure the default.9. Dispute ResolutionAny disputes arising from this Contract shall be resolved through mediation or arbitration. The prevailing Party in any dispute shall be entitled to recover its reasonable attorney's fees and costs.10. Governing LawThis Contract shall be governed by the laws of[State/Country], and any disputes shall be resolved in the courts of [City/County].IN WITNESS WHEREOF, the Parties hereto have executed this Contract as of the date first above written.Owner: ______________________________Contractor: ______________________________[Signatures]This Construction Contract constitutes the entire agreement between the Parties and supersedes any prior agreements or understandings, whether written or verbal. Any amendments to this Contract shall be made in writing and signed by both Parties.[Date]篇4Contract for construction of Residential BuildingThis agreement is entered into on this ____ day of _______, 20__ between Mr. John Smith, the owner of the property located at ________ (hereinafter referred to as the "Owner") and XYZ Construction Company, having its registered office at ______ (hereinafter referred to as the "Contractor").1. Scope of Work: The Contractor agrees to construct a residential building at the above-mentioned property in accordance with the plans, specifications, and drawings provided by the Owner. The Contractor shall be responsible for obtaining all necessary permits and approvals for the construction.2. Timeframe: The construction shall commence on ______ and shall be completed within ______ days from the commencement date. Any delays in the completion of the project shall be notified to the Owner in writing.3. Payment: The Owner agrees to pay the Contractor a total sum of $________ for the construction of the residential building. The payment shall be made in installments as follows:- 25% of the total sum upon signing of this agreement- 25% upon completion of the foundation work- 25% upon completion of the superstructure- 25% upon completion of the finishing work4. Changes: Any changes or modifications to the plans, specifications, or drawings shall be agreed upon in writing by both parties and shall be subject to additional charges.5. Warranties: The Contractor warrants that all work shall be carried out in a good and workmanlike manner and in accordance with the prevailing industry standards. The Contractor shall rectify any defects in the workmanship or materials at no additional cost to the Owner.6. Indemnity: The Contractor shall indemnify and hold harmless the Owner from any claims, damages, or liabilities arising out of the construction work.7. Termination: Either party may terminate this agreement with a written notice of ______ days. In the event of termination, the Contractor shall be entitled to payment for work completed up to the date of termination.8. Dispute Resolution: Any disputes arising out of or in connection with this agreement shall be resolved through arbitration in accordance with the laws of the jurisdiction.This document constitutes the entire agreement between the Owner and the Contractor and supersedes any prioragreements or understandings. This agreement shall be binding upon the parties, their successors, and assigns.Owner's Signature: ______________ Date:Contractor's Signature: ______________ Date:Witnessed by:___________________(Name)(Signature)___________________(Name)(Signature)篇5英文建筑合同Contract for Construction WorkThis agreement is entered into on [date], by and between [owner’s name], hereinafter referred to as the “Owner,” and [contractor’s name], hereinafter referred to as the “Contractor,” for the purpose of specifying the terms and conditions for theconstruction work to be undertaken on the property located at [address].1. Scope of Work: The Contractor agrees to perform all necessary labor, materials, and equipment required for the completion of the construction work as specified in the attached plans and drawings. The work shall be carried out in accordance with all applicable codes, regulations, and industry standards.2. Payment: The Owner agrees to pay the Contractor the sum of [total contract amount] for the completion of the construction work. Payments shall be made in installments as follows: [payment schedule]. The final payment shall be made upon completion of the work and acceptance by the Owner.3. Timeframe: The Contractor agrees to commence work on [start date] and to complete the project by [completion date]. Any delays in the completion of the work due to factors beyond the Contractor’s control shall not be considered a breach of contract.4. Changes: Any changes to the scope of work must be agreed upon in writing by both parties. The Owner shall be responsible for any additional costs incurred as a result of changes to the original plans.5. Insurance: The Contractor shall maintain liability insurance for the duration of the project and shall provide a certificate of insurance to the Owner upon request. The Owner shall be responsible for obtaining any necessary permits and approvals for the construction work.6. Warranties: The Contractor warrants that all work performed under this agreement shall be of good quality and free from defects in materials and workmanship. Any defects that arise within one year of completion shall be repaired by the Contractor at no additional cost to the Owner.7. Termination: Either party may terminate this agreement upon written notice if the other party fails to meet their obligations under the contract. In the event of termination, the Owner shall pay the Contractor for any work completed up to that point.8. Dispute Resolution: Any disputes arising from this agreement shall be resolved through mediation or arbitration, as agreed upon by both parties.This agreement constitutes the entire understanding between the Owner and Contractor with respect to the construction work and supersedes any prior agreements or understandings. This agreement shall be governed by the laws of[state].IN WITNESS WHEREOF, the parties hereto have executed this agreement on the date first above written.Owner:Contractor:篇6英文建筑合同是一种法律文件，用于约定建筑项目的各种条款和条件。
建筑合同(中英版)6篇
建筑合同(中英版)6篇篇1Building ContractA building contract is a legal agreement between the owner of a property and a building contractor, outlining the terms and conditions under which a construction project will be carried out. This document is essential for ensuring that both parties understand their rights and responsibilities throughout the construction process. In this article, we will discuss the key components of a building contract and its importance in the construction industry.1. Parties involvedThe building contract will identify the parties involved in the project, including the owner of the property and the building contractor. It may also include subcontractors, architects, engineers, and other professionals who will be involved in the construction process.2. Scope of workThe contract will outline the scope of work to be performed, including the specific tasks that the building contractor is responsible for, such as site preparation, construction, and cleanup. It will also specify the materials and equipment to be used in the project.3. ScheduleThe contract will include a timeline for the completion of the project, including key milestones and deadlines. This is important for both parties to ensure that the project stays on track and is completed in a timely manner.4. Payment termsThe contract will outline the payment terms for the project, including the total cost of the construction, payment schedule, and any additional costs that may arise during the project. This is essential for avoiding disputes over payment and ensuring that the project stays within budget.5. Changes and disputesThe contract will include provisions for handling changes to the project scope, as well as procedures for resolving disputes that may arise during the construction process. This is important for maintaining a positive working relationship between theparties and ensuring that any issues are resolved quickly and fairly.6. Insurance and liabilityThe contract will specify the insurance coverage required for the project, including liability insurance for the building contractor and any subcontractors. This is essential for protecting both parties in the event of accidents or damages during the construction process.Building contracts are critical documents in the construction industry, as they provide a legal framework for the building project and ensure that both parties understand their rights and responsibilities. It is important for both owners and building contractors to carefully review and negotiate the terms of the contract before signing to avoid any misunderstandings or disputes later on. By having a clear and comprehensive building contract in place, both parties can work together to successfully complete the construction project on time and within budget.篇2Architecture ContractBuilding a new structure involves a lot of planning, designing, and execution. In order to ensure that a project is completedsuccessfully, it is essential to have a proper agreement in place. This agreement, known as an architecture contract, outlines the responsibilities of both the client and the architect, as well as the terms and conditions of the project.An architecture contract is a legal document that establishes the scope of work, the schedule, and the cost of a construction project. It also specifies the roles and responsibilities of the architect, the client, and any other parties involved in the project. By signing this contract, both parties agree to abide by the terms and conditions laid out in the document.There are several key components that should be included in an architecture contract. These include:1. Scope of Work: This section outlines the specific tasks that the architect will be responsible for, such as creating designs, obtaining permits, and overseeing construction.2. Schedule: The contract should include a timeline for the project, including milestones and deadlines for completion.3. Fees: The contract should detail the architect's fees, including how they will be calculated and when they are due.4. Changes: This section should outline the procedure for making changes to the project scope, schedule, or budget.5. Termination: The contract should specify the conditions under which either party can terminate the agreement.In addition to these components, an architecture contract should also address issues such as insurance, liability, and dispute resolution. It is important for both parties to fully understand and agree to the terms of the contract before signing it.In conclusion, an architecture contract is a crucial document that helps to ensure the success of a construction project. By clearly outlining the responsibilities and expectations of both parties, this agreement helps to minimize misunderstandings and disputes, and provides a framework for the successful completion of the project.篇3Architecture Contract (中英版)Introduction建筑合同是指项目委托方和承包方之间所签订的协议，规定了双方在建筑项目中的权利和义务。
- 1、下载文档前请自行甄别文档内容的完整性，平台不提供额外的编辑、内容补充、找答案等附加服务。
- 2、"仅部分预览"的文档,不可在线预览部分如存在完整性等问题,可反馈申请退款(可完整预览的文档不适用该条件!)。
- 3、如文档侵犯您的权益，请联系客服反馈,我们会尽快为您处理(人工客服工作时间：9:00-18:30)。
英文建筑合同_合同范本
Party A：Party B：
Contract No
Date：
Signed at：
Witnesses that the Party A for considerations hereinafter named, contracts and agrees with the Party B that Party A will, within_____ days, next following the date hereof, build and finish a Libarary Building for Party B. （the building hereinafter is referred to as the said building.）The said building is of the following dimensions, with reinforced concrete, brick, stones and other materials, as are described in plans and specifications gereto annexed.
In consideration of the foregoing, Party B shall, for itself and its legal representatives, promise to pay Party A the sum of one million RMB yuan in manner as follows, to wit：
RMB_____at the beginning of the said work.
RMB_____on _____/ _____/_____（for example：3/21/2001）RMB_____ on_____/ _____/_____
RMB_____ on_____/ _____/_____
RMB_____ on_____/ _____/_____
And the remaining sum will be paid upon the completion of the work.
It is further agreed that in order to be entitled to the said payments （the first one excepted, which is otherwise secured ）, Party A or its legal representatives shall, according to the architect’’s appraisement, have expended, in labor and material, the value of the payments already received by Party A, on the building, at the time of payment.
〖您正浏览的文章由第一＇范文网整理，版权归原、原出处所有。
〗
For failure to accomplish the faithful performance of the agreement aforesaid, the party so failing agrees to forfeit and pay to the other_____RMB yuan as fixed and settled damages, within one month form the time so failing.
In witness whereof we have hereunto set our hands and seals the day and year first above written.
Signed, sealed and delivered
in the presence of
Party A ：Party B：。