项目风险管理分析中英文对照外文翻译文献
外文翻译外文文献英文文献国际建设工程风险分析

外文文献:This analysis used a case study methodology to analyze the issues surrounding the partial collapse of the roof of a building housing the headquarters of the Standards Association of Zimbabwe (SAZ). In particular, it examined the prior roles played by the team of construction professionals. The analysis revealed that the SAZ’s traditional construction project was generally characterized by high risk. There was a clear indication of the failure of a contractor and architects in preventing and/or mitigating potential construction problems as alleged by the plaintiff. It was reasonable to conclude that between them the defects should have been detected earlier and rectified in good time before the partial roof failure. It appeared justified for the plaintiff to have brought a negligence claim against both the contractor and the architects. The risk analysis facilitated, through its multi-dimensional approach to a critical examination of a construction problem, the identification of an effective risk management strategy for future construction prject and riskThe structural design of the reinforced concrete elements was done by consulting engineers Knight Piesold (KP). Quantity surveying services were provided by Hawkins, Leshnick & Bath (HLB). The contract was awarded to Central African Building Corporation (CABCO) who was also responsible for the provision of a specialist roof structure using patented “gang nail” roof trusses. The building construction proceeded to completion and was handed over to the owners on Sept. 12, 1991. The SAZ took effective occupation of the headquarters building without a certificate of occupation. Also, the defects liability period was only three months .The roof structure was in place 10 years At first the SAZ decided to go to arbitration, but this failed to yield an immediate solution. The SAZ then decided toproceed to litigate in court and to bring a negligence claim against CABCO. The preparation for arbitration was reused for litigation. The SAZ’s quantified losses stood at approximately $ 6 million in Zimbabwe dollars (US $1.2m) .After all parties had examined the facts and evidence before them, it became clear that there was a great probability that the courts might rule that both the architects and the contractor were lia ble. It was at this stage that the defendants’ lawyers requested that the matter be settled out of court. The plaintiff agreed to this suxamined the prior roles played by the project management function and construction professionals in preventing/mitigating potential construction problems. It further assessed the extent to which the employer/client and parties to a construction contract are able to recover damages under that contract. The main objective of this critical analysis was to identify an effective risk management strategy for future construction projects. The importance of this study is its multidimensional examination approach.Experience sugge be misleading. All construction projects are prototypes to some extent and imply change. Change in the construction industry itself suggests that past experience is unlikely to be sufficient on its own. A structured approach is required. Such a structure can not and must not replace the experience and expertise of the participant. Rather, it brings additional benefits that assist to clarify objectives, identify the nature of the uncertainties, introduces effective communication systems, improves decision-making, introduces effective risk control measures, protects the project objectives and provides knowledge of the risk history .Construction professionals need to know how to balance the contingencies of risk with their specific contractual, financial, operational and organizational requirements. Many construction professionals look at risks in dividually with a myopic lens and donot realize the potential impact that other associated risks may have on their business operations. Using a holistic risk management approach will enable a firm to identify all of the organization’s business risks. This will increas e the probability of risk mitigation, with the ultimate goal of total risk elimination .Recommended key construction and risk management strategies for future construction projects have been considered and their explanation follows. J.W. Hinchey stated th at there is and can be no ‘best practice’ standard for risk allocation on a high-profile project or for that matter, any project. He said, instead, successful risk management is a mind-set and a process. According to Hinchey, the ideal mind-set is for the parties and their representatives to, first, be intentional about identifying project risks and then to proceed to develop a systematic and comprehensive process for avoiding, mitigat and its location. This is said to be necessary not only to allow alternative responses to be explored. But also to ensure that the right questions are asked and the major risks identified. Heads of sources of risk are said to be a convenient way of providing a structure for identifying risks to completion of a participant’s pa rt of the project. Effective risk management is said to require a multi-disciplinary approach. Inevitably risk management requires examination of engineering, legal and insurance related solutions .It is stated that the use of analytical techniques based on a statistical approach could be of enormous use in decision making . Many of these techniques are said to be relevant to estimation of the consequences of risk events, and not how allocation of risk is to be achieved. In addition, at the present stage of the development of risk management, Atkinson states that it must be recognized that major decisions will be made that can not be based solely on mathematical analysis. The complexity ofconstruction projects means that the project definition in terms of both physical form and organizational structure will be based on consideration of only a relatively small number of risks . This is said to then allow a general structured approach that can be applied to any construction project to increase the awareness of participants .The new, simplified Construction Design and Management Regulations (CDM Regulations) which came in to f 1996, into a single regulatory package.The new CDM regulations offer an opportunity for a step change in health and safety performance and are used to reemphasize the health, safety and broader business benefits of a well-managed and co-ordinated approach to the management of health and safety in construction. I believe that the development of these skills is imperative to provide the client with the most effective services available, delivering the best value project possible.Construction Management at Risk (CM at Risk), similar to established private sector methods of construction contracting, is gaining popularity in the public sector. It is a process that allows a client to select a construction manager (CM) based on qualifications; make the CM a member of a collaborative project team; centralize responsibility for construction under a single contract; obtain a bonded guaranteed maximum price; produce a more manageable, predictable project; save time and money; and reduce risk for the client, the architect and the CM.CM at Risk, a more professional approach to construction, is taking its place along with design-build, bridging and the more traditional process of design-bid-build as an established method of project delivery.The AE can review to get the projec. Competition in the community is more equitable: all subcontractors have a fair shot at the work .A contingency within the GMP covers unexpected but justifiable costs, and a contingency above the GMP allows for client changes. As long as the subcontractors are within the GMP they are reimbursed to the CM, so the CM represents the client in negotiating inevitable changes with subcontractors.There can be similar problems where each party in a project is separately insured. For this reason a move towards project insurance is recommended. The traditional approach reinforces adversarial attitudes, and even provides incentives for people to overlook or conceal risks in an attempt to avoid or transfer responsibility.A contingency within the GMP covers unexpected but justifiable costs, and a contingency above the GMP allows for client changes. As long as the subcontractors are within the GMP they are reimbursed to the CM, so the CM represents the client in negotiating inevitable changes with subcontractors.There can be similar problems where each party in a project is separately insured. For this reason a move towards project insurance is recommended. The traditional approach reinforces adversarial attitudes, and even provides incentives for people to overlook or conceal risks in an attempt to avoid or transfer responsibility.It was reasonable to assume that between them the defects should have been detected earlier and rectified in good time before the partial roof failure. It did appear justified for the plaintiff to have brought a negligence claim against both the contractor and the architects.In many projects clients do not understand the importance of their role in facilitating cooperation and coordination; the desi recompense. They do not want surprises, and are more likely to engage in litigation when things go wrong.中文译文:国际建设工程风险分析索赔看来是合乎情理的。
财务风险管理外文翻译英文文献

财务风险管理中英文资料翻译Financial Risk ManagementAlthough financial risk has increased significantly in recent years,risk and risk management are not contemporary issues. The resultof increasingly global markets is that risk may originate with eventsthousands of miles away that have nothing to do with the domesticmarket。
Information is available instantaneously,which means thatchange, and subsequent market reactions, occur very quickly.The economic climate and markets can be affected very quickly bychanges in exchange rates,interest rates, and commodity prices. Counterpartiescan rapidly become problematic. As a result,it is important toensure financial risks are identified and managed appropriately。
Preparationis a key component of risk management。
What Is Risk?Risk provides the basis for opportunity. The terms risk and exposure havesubtle differences in their meaning. Risk refers to the probability of loss,while exposure is the possibility of loss, although they are often usedinterchangeably。
中英文外文文献翻译中小企业财务风险管理研究

本科毕业设计(论文)中英文对照翻译(此文档为word格式,下载后您可任意修改编辑!)作者:Bernard G期刊:International Journal of Information Business and Management 第5卷,第3期,pp:41-51.原文The research of financial Risk Management in SMESBernard GINTRUDUCTIONSmall and medium sized enterprises (SME) differ from large corporations among other aspects first of all in their size. Theirimportance in the economy however is large . SME sector of India is considered as the backbone of economy contributing to 45% of the industrial output, 40% of India’s exports, employing 60 million people, create 1.3 million jobs every year and produce more than 8000 quality products for the Indian and international markets. With approximately 30 million SMEs in India, 12 million people expected to join the workforce in next 3 years and the sector growing at a rate of 8% per year, Government of India is taking different measures so as to increase their competitiveness in the international market. There are several factors that have contributed towards the growth of Indian SMEs. Few of these include; funding of SMEs by local and foreign investors, the new technology that is used in the market is assisting SMEs add considerable value to their business, various trade directories and trade portals help facilitate trade between buyer and supplier and thus reducing the barrier to trade With this huge potential, backed up by strong government support; Indian SMEs continue to post their growth stories. Despite of this strong growth, there is huge potential amongst Indian SMEs that still remains untapped. Once this untapped potential becomes the source for growth of these units, there would be no stopping to India posting a GDP higher than that of US and China and becoming the world’s economic powerhouse. RESEARCH QUESTIONRisk and economic activity are inseparable. Every business decisionand entrepreneurial act is connected with risk. This applies also to business of small and medium sized enterprises as they are also facing several and often the same risks as bigger companies. In a real business environment with market imperfections they need to manage those risks in order to secure their business continuity and add additional value by avoiding or reducing transaction costs and cost of financial distress or bankruptcy. However, risk management is a challenge for most SME. In contrast to larger companies they often lack the necessary resources, with regard to manpower, databases and specialty of knowledge to perform a standardized and structured risk management. The result is that many smaller companies do not perform sufficient analysis to identify their risk. This aspect is exacerbated due to a lack in literature about methods for risk management in SME, as stated by Henschel: The two challenging aspects with regard to risk management in SME are therefore: 1. SME differ from large corporations in many characteristics 2. The existing research lacks a focus on risk management in SME The following research question will be central to this work: 1.how can SME manage their internal financial risk? 2.Which aspects, based on their characteristics, have to be taken into account for this? 3.Which mean fulfils the requirements and can be applied to SME? LITERA TURE REVIEWIn contrast to larger corporations, in SME one of the owners is oftenpart of the management team. His intuition and experience are important for managing the company. Therefore, in small companies, the (owner-) manager is often responsible for many different tasks and important decisions. Most SME do not have the necessary resources to employ specialists on every position in the company. They focus on their core business and have generalists for the administrative functions. Behr and Guttler find that SME on average have equity ratios lower than 20%. The different characteristics of management, position on procurement and capital markets and the legal framework need to be taken into account when applying management instruments like risk management. Therefore the risk management techniques of larger corporations cannot easily be applied to SME. In practice it can therefore be observed that although SME are not facing less risks and uncertainties than large companies, their risk management differs from the practices in larger companies. The latter have the resources to employ a risk manager and a professional, structured and standardized risk management system. In contrast to that, risk management in SME differs in the degree of implementation and the techniques applied. Jonen & Simgen-Weber With regard to firm size and the use of risk management. Beyer, Hachmeister & Lampenius observe in a study from 2010 that increasing firm size among SME enhances the use of risk management. This observation matches with the opinion of nearly 10% of SME, which are of the opinion, that risk management is onlyreasonable in larger corporations. Beyer, Hachmeister & Lampenius find that most of the surveyed SME identify risks with help of statistics, checklists, creativity and scenario analyses. reveals similar findings and state that most companies rely on key figure systems for identifying and evaluating the urgency of business risks. That small firms face higher costs of hedging than larger corporations. This fact is reducing the benefits from hedging and therefore he advises to evaluate the usage of hedging for each firm individually. The lacking expertise to decide about hedges in SME is also identified by Eckbo, According to his findings, smaller companies often lack the understanding and management capacities needed to use those instruments. METHODOLOGY USE OF FINANCIAL ANAL YSIS IN SME RISK MANAGEMENT How financial analysis can be used in SME risk management? Development of financial risk overview for SME The following sections show the development of the financial risk overview. After presenting the framework, the different ratios will be discussed to finally present a selection of suitable ratios and choose appropriate comparison data. Framework for financial risk overviewThe idea is to use a set of ratios in an overview as the basis for the financial risk management.This provides even more information than the analysis of historicaldata and allows reacting fast on critical developments and managing the identified risks. However not only the internal data can be used for the risk management. In addition to that also the information available in the papers can be used. Some of them state average values for the defaulted or bankrupt companies one year prior bankruptcy -and few papers also for a longer time horizon. Those values can be used as a comparison value to evaluate the risk situation of the company. For this an appropriate set of ratios has to be chosen. The ratios, which will be included in the overview and analysis sheet, should fulfill two main requirements. First of all they should match the main financial risks of the company in order to deliver significant information and not miss an important risk factor. Secondly the ratios need to be relevant in two different ways. On the one hand they should be applicable independently of other ratios. This means that they also deliver useful information when not used in a regression, as it is applied in many of the papers. On the other hand to be appropriate to use them, the ratios need to show a different development for healthy companies than for those under financial distress. The difference between the values of the two groups should be large enough to see into which the observed company belongs. Evaluation of ratios for financial risk overview When choosing ratios from the different categories, it needs to be evaluated which ones are the most appropriate ones. For this some comparison values are needed inorder to see whether the ratios show different values and developments for the two groups of companies. The most convenient source for the comparison values are the research papers as their values are based on large samples of annual reports and by providing average values outweigh outliers in the data. Altman shows a table with the values for 8 different ratios for the five years prior bankruptcy of which he uses 5, while Porporato & Sandin use 13 ratios in their model and Ohlson bases his evaluation on 9 figures and ratios [10]. Khong, Ong & Y ap and Cerovac & Ivicic also show the difference in ratios between the two groups, however only directly before bankruptcy and not as a development over time [9]. Therefore this information is not as valuable as the others ([4][15]).In summary, the main internal financial risks in a SME should be covered by financial structure, liquidity and profitability ratios, which are the main categories of ratios applied in the research papers.Financial structureA ratio used in many of the papers is the total debt to total assets ratio, analyzing the financial structure of the company. Next to the papers of Altman, Ohlson and Porporato & Sandin also Khong, Ong & Y ap and Cerovac & Ivicic show comparison values for this ratio. Those demonstrate a huge difference in size between the bankrupt andnon-bankrupt groups.Therefore the information of total debt/total assets is more reliable and should rather be used for the overview. The other ratios analyzing the financial structure are only used in one of the papers and except for one the reference data only covers the last year before bankruptcy. Therefore a time trend cannot be detected and their relevance cannot be approved.译文中小企业财务风险管理研究博纳德引言除了其他方面,中小型企业(SME)与大型企业的不同之处首先在于他们的规模不同,但是,他们在国民经济中同样具有重要的作用。
项目风险管理 外文翻译 外文文献 英文文献

外文翻译As one of the important subjects of project management originated the First World War, and now it has been becoming more and more systematic and professional. In China the systematic project risk management framework was developed by the end of last century, but the practical application of project risk management still needs further improvement. With above background, this thesis focused on the medium or large real estate project, research project character, project management, typical Chinese construction project process, risk management, and project risk management. The first chapter briefed the current international and domestic study status of the subject, thesis purpose, and thesis scope, which are risk and its countermeasures research for the implementation phase of medium or large real estate project. The second chapter briefed the concept and character of real estate project, risk of project, and project risk management, which is the theoretical foundation of further risk management study for the implementation phase of medium or large real estate project. Chapter3,4 and 5 are the project risk management practice on the implementation phase of medium or large real estate project. Chapter 3 is for project engineering risk management, which introduced the concept, purpode, and principle of project engineering at the beginning, and then analyzed the engineering objective, including schedule, cost, and quality, at last it identified and analyzed the project engineering risks and provided design change procedure and design company selection procedure as the risk response. Chapter 4 detailed the concept, principle, objective and key roles of project procurement, identified and assessed the project procurement risk, and also provided contractor selection procedure, vendor selection procedure, examples of procurement plans to response and monitor project risk. Chapter 5 firstly introduced the construction concept, character, process and project construction objectives, including quality objective, schedule objective, and safety objective, and then identified and assessed construction quality risk, schedule risk, cost risk and safety risk, The postscript of this thesis briefed the dynamic project risk management concept, restriction and limitation of this thesis, and opportunities for further research. Totally there are 14 appendixes attached after the thesis. These appendixes could be used as guidance and reference of risk management for real estate project. They are provided to be very useful in term of risk management for real estate project implementation phases.Project risk management as a procedure of optimism and decision, in which information will come out gradually in the multistage construction. The key to the risk management is how to select the risk response plan. Directed by the system theory and combined the theory of option pricing and project risk management, this paper adopts criterion method to analyze the management and activity in the stage of engineering project implement on the base of comparison to relative documents. This paper emphatically argues the choice of response plans under the condition of risks according to the established analysis frame. These forecasts are hypotheses abstract form the similar project performed before, whether they are actual or not will hugely affect the success of project The implement stage means project period from the location to product whose target is transform the planto real and mark the aims. The implement stage occupies the most period of project, has huge work, consume the most resource. What is worth to mind is that the implement stage is process not only to form the real proprirty but also product information, for example, the knowledge of field status and the capability of contractor can only be obtained form implement. So in order to mark the target, the manager must test the hypotheses and use the new information assess the status of influence element, choose the best response plan according to the condition. This paper has value in instructing the project investor/manager in how to establish a risk management configuration and making decision under risk condition in the implement stage of construction project.This thesis begins with the knowledge system of project management, analyses the whole course of risk management and sets forth the method and program of project risk identification, risk appraisement and risk monitoring in project minutely. Finally, It shows a risk case of building project focal point for the investment decision of early stage with qualitative and quantitative analysis. Chapter 1 Discuss the important concept, method and knowledge system of project risk management, such as the definition of project, the knowledge system of project management PMBOKX the intension of risk, the content of risk management and so on ,carry out the risk analysis of building project emphatically. Chapter 2 Mainly introduce the tool and technology of project risk identification, such as checking table, the rules of systems analysis(WBS), the method of SWOT technology. Thinking of the demerit for every tool, hence author emphasize that we should appraise the gained information resource synthetically. Chapter 3 Explain how to go on the estimation and assessment of project risk, put forward the tool and technology of project risk analysis (as AHP, probability and sensitivity analysis ). When analyzing project risk quantitatively, first we should have definite warranty, do not surmise risk without foundation; Secondly, distinguish confirmed project from unconfirmed project in quantitative analysis. When using two important tools of quantitative risk analysis—probability and sensitivity analysis, one side is to estimate the probability of risk variable exactly; the other side is to judge and analyze the guidelines of probability analysis truly, as square margin, expected figure, disperse modulus. Through quantifying risk, it can strengthen our sense of risk management. Chapter 4 Elaborate the basic method of monitoring project risk. In order to carry into execution monitoring project risk, it is essential to establish perfect replying risk plan. The main steps is: lessening risk, take precautions against risk (as project method, instructing method, program method), conveying risk selling, inviting public bidding, the contract of absolving obligation, insurance and guarantee), avoidance, leave behind and measure in support. Chapter 5 A risk management example. First, analyze the various possible existent risk factors of this project systematically. Secondly, study its sensitivity factor thorough quantifying assessment risk for the project, as well as establishing and putting in practice a plan in order to control the negative influence in minimum level. The building has total 130500 square in architectural area, superior geographical location and tremendously potential value, its overall investment is 4.26 hundreds million. This chapter first studies the market from place environment all around traffic and market requirement, then analyzes systematically financing risk and organic risk of joint venture. On the basis of foregoing analysis, it establishes some parameter of risk quantifying analysis, calculates its selling revenue running expense and cash flow form, uses sensitivity analysis to gain best sensitivityfactor. As the uncertain essence of risk, it is extremely important to analyze probability factor of the project. So we confirm the probability form of every variable, then calculate present value of each possible event according to different constitutes of risk variable; and sort all possible events according to their present values from small to big, calculate accumulative probability, square margin and disperse modulus, thus analyze the risk of project quantitatively, provide quantitative support for supervisor when they will make a decision. Comparing with international advanced level, our country has great gap on the link of how to apply theory of project risk management to practice of project management, especially short of system research in project risk management. On the basis International project contracting is rather a complex project in the cooperation of international economy and technology, and the implementing of the projects will be influenced by political, economy and social situations Firstly, this paper systemically analyzed the market situation of the international project contracting, and concretely analyzed the market structure in Asia, America, Africa and Europe. It concluded the trend of the development of the international contracting market; projects are becoming large-scale and complex and the contracting pattern is diversified, and the management of the international project contracting is standardized. Secondly, this paper analyzed the development status and characteristic of the international project contracting in our country. Although the internationalization tendency of our country’s international project contracting firm is preferable, there is large gap in the whole strength when compared with firms from the developed countries, and also there are limitations in the distributing of the projects in different regions and industries. Thirdly, this paper summarized the technique of international project contracting risk identification, estimate and appraise in our country. Put forward to finance and non-finance risk treating means, and apply the energy release theory to international project contracting risk management, and research the dominating risk in the bid phase and construction and build the energy release model of each phrase. In the cases of Kun River Hydroelectric Station Project in Vietnam and Aromatic Plant Shali Irrigation Project in Nepal, this paper put forward to the technique of the international project contracting risk identification, estimation, appraise and reply in dealing with the project risk. Finally, in the risk estimation and risk appraise, this paper paid attention to evaluate the losing caused by the risk exactly; in the risk reply ,give attention to two aspects of cost and return, look after the economic and logical risk reply measure, in order to make the project risk least, the operating of companies most efficiently and the return highest外文翻译项目风险管理作为项目管理的重要内容之一,起源于第一次世界大战之后。
项目风险管理范文[英文版]
![项目风险管理范文[英文版]](https://img.taocdn.com/s3/m/fa9087672e60ddccda38376baf1ffc4fff47e257.png)
项目风险管理范文[英文版]Risk Management Plan1. IntroductionThe purpose of this risk management plan is to identify, evaluate, and mitigate risks associated with our project. It aims to ensure that potential risks are understood, and appropriate measures are taken to minimize their impact on the project's success.2. Risk IdentificationIn this phase, all possible risks are identified by involving project team members, stakeholders, and subject matter experts. Risks can be categorized as technical, financial, operational, or legal risks. Some of the risks identified for this project include:- Technical risks: unexpected system failures, integration issues.- Financial risks: cost overruns, budget constraints.- Operational risks: resource unavailability, changes in requirements.- Legal risks: non-compliance with regulations, intellectual property disputes.3. Risk EvaluationOnce the risks are identified, they are evaluated based on their impact and likelihood of occurrence. This evaluation helps prioritize risks and allocate resources accordingly. The evaluation criteria include the severity of impact, likelihood of occurrence, and ability to detect the risk early. A risk matrix is used to categorize risks as high, medium, or low risk.4. Risk MitigationTo mitigate identified risks, appropriate strategies and actions must be defined. The risk mitigation plan includes the following steps: - Technical risks: regular system checks and maintenance, implementing redundancy measures.- Financial risks: regular budget monitoring, proactive cost management.- Operational risks: resource allocation and planning, maintaining clear communications with stakeholders.- Legal risks: adherence to relevant regulations, obtaining necessary permissions and licenses.5. Risk Monitoring and ControlMonitoring and control of risks are crucial throughout the project's lifecycle. This includes monitoring the progress of risk mitigation actions, identifying new risks, and evaluating the effectiveness of implemented mitigation strategies. Risk logs will be maintained, which will document all identified risks and their status. Regular risk review meetings will be conducted to ensure that risks are managed effectively.6. ReportingRegular risk reports will be generated and shared with project stakeholders and senior management. These reports will provide information on the identified risks, their current status, and progress on risk mitigation efforts. Reporting will help keep all stakeholders informed about the project's risk profile.7. ConclusionEffective risk management is an essential aspect of project management. This risk management plan provides a framework foridentifying, evaluating, and mitigating risks associated with our project. By proactively addressing potential risks, we can ensure the smooth execution and successful completion of our project.8. Risk Response PlanningOnce the risks have been evaluated, it is important to develop a response plan for each identified risk. The response plan should include proactive measures to minimize the impact of risks and reactive actions to be taken in case the risk occurs. The response plans should be documented and shared with the project team members and stakeholders.The response plan for technical risks may include regular system checks and maintenance to ensure that any potential failures or system issues are identified and resolved promptly. Additionally, implementing redundancy measures such as backup systems or redundant components can help mitigate the impact of technical risks.For financial risks, the response plan may involve regular budget monitoring and proactive cost management. This can include closely tracking expenses, identifying cost-saving opportunities, and re-evaluating budget allocation if necessary. The team should also be prepared to take immediate action in case of cost overruns by reallocating resources or seeking additional funding. Operational risks can be mitigated through effective resource allocation and planning. This includes properly assessing and assigning resources to different tasks, and maintaining clear communication channels with stakeholders. Regular meetings and updates can help identify any potential changes in requirements orresource availability, allowing the team to adjust plans accordingly and minimize the impact of operational risks.Legal risks can be managed by ensuring compliance with relevant regulations and obtaining the necessary permissions and licenses. This may involve consulting with legal experts or involving regulatory bodies early in the project. Intellectual property (IP) disputes can be mitigated by properly documenting and protecting the project's IP and seeking legal counsel if necessary.9. Risk Monitoring and ControlThe risk management process does not end with the development of response plans. It is important to continuously monitor and control risks throughout the project's lifecycle. This includes regularly reviewing and updating the risk register, tracking the progress of risk mitigation actions, and identifying new risks that may arise during project execution.Regular risk review meetings should be conducted to assess the effectiveness of implemented mitigation strategies and identify any changes in the risk environment. These meetings provide an opportunity for the project team members to discuss and share updates on risk management activities. Any new risks that are identified should be carefully evaluated, and appropriate response plans should be developed.In addition to risk review meetings, project progress reports should include updates on the status of identified risks and the progress of risk mitigation efforts. This enables stakeholders and senior management to stay informed about the project's risk profile andmake informed decisions based on the current risk situation.10. Communication and Stakeholder EngagementEffective communication and stakeholder engagement are critical components of successful risk management. All stakeholders should be kept informed about the identified risks, potential impacts, and mitigation strategies. This includes project team members, sponsors, clients, and external partners.Regular communication channels should be established to ensure that all stakeholders are provided with timely updates on risk management activities. This can be done through project meetings, progress reports, and dedicated risk communication sessions.Engaging stakeholders in the risk management process can also help in identifying new risks or potential mitigation strategies. Stakeholders often have valuable insights and experiences that can contribute to the project's risk management efforts. Their input and feedback should be actively sought, and any concerns or suggestions should be carefully considered and addressed.11. ConclusionAn effective risk management plan is an essential tool for any project. By proactively identifying, evaluating, and mitigating risks, project teams can minimize the impact of potential issues and increase the chances of project success.This risk management plan provides a comprehensive framework for managing risks throughout the project lifecycle. It includes the identification and evaluation of risks, the development of responseplans, and the ongoing monitoring and control of risks. Regular communication and stakeholder engagement are also emphasized to ensure that all relevant parties are kept informed and involved in the risk management process.By following this plan and regularly reviewing and updating it as necessary, project teams can effectively manage risks and improve their ability to deliver successful outcomes.。
工程管理专业外文文献翻译(中英文)【精选文档】

xxxxxx 大学本科毕业设计外文翻译Project Cost Control: the Way it Works项目成本控制:它的工作方式学院(系): xxxxxxxxxxxx专业: xxxxxxxx学生姓名: xxxxx学号: xxxxxxxxxx指导教师: xxxxxx评阅教师:完成日期:xxxx大学项目成本控制:它的工作方式在最近的一次咨询任务中,我们意识到对于整个项目成本控制体系是如何设置和应用的,仍有一些缺乏理解。
所以我们决定描述它是如何工作的.理论上,项目成本控制不是很难跟随。
首先,建立一组参考基线。
然后,随着工作的深入,监控工作,分析研究结果,预测最终结果并比较参考基准。
如果最终的结果不令人满意,那么你要对正在进行的工作进行必要的调整,并在合适的时间间隔重复。
如果最终的结果确实不符合基线计划,你可能不得不改变计划.更有可能的是,会 (或已经) 有范围变更来改变参考基线,这意味着每次出现这种情况你必须改变基线计划。
但在实践中,项目成本控制要困难得多,通过项目数量无法控制成本也证明了这一点。
正如我们将看到的,它还需要大量的工作,我们不妨从一开始启用它。
所以,要跟随项目成本控制在整个项目的生命周期.同时,我们会利用这一机会来指出几个重要文件的适当的地方。
其中包括商业案例,请求(资本)拨款(执行),工作包和工作分解结构,项目章程(或摘要),项目预算或成本计划、挣值和成本基线。
所有这些有助于提高这个组织的有效地控制项目成本的能力。
业务用例和应用程序(执行)的资金重要的是要注意,当负责的管理者对于项目应如何通过项目生命周期展开有很好的理解时,项目成本控制才是最有效的。
这意味着他们在主要阶段的关键决策点之间行使职责。
他们还必须识别项目风险管理的重要性,至少可以确定并计划阻止最明显的潜在风险事件。
在项目的概念阶段•每个项目始于确定的机会或需要的人.通常是有着重要性和影响力的人,如果项目继续,这个人往往成为项目的赞助。
商业银行风险管理中英文对照外文翻译文献

商业银行风险管理中英文对照外文翻译文献(文档含英文原文和中文翻译)“RISK MANAGEMENT IN COMMERCIAL BANKS”(A CASE STUDY OF PUBLIC AND PRIVATE SECTOR BANKS) - ABSTRACT ONLY1. PREAMBLE:1.1 Risk Management:The future of banking will undoubtedly rest on risk management dynamics. Only those banks that have efficient risk management system will survive in the market in the long run. The effective management of credit risk is a critical component of comprehensive risk management essential for long-term success of a banking institution. Credit risk is the oldest and biggest risk that bank, by virtue of its very nature of business, inherits. This has however, acquired a greater significance in the recent past for various reasons. Foremost among them is the wind of economic liberalization that is blowing across the globe. India is no exception to this swing towards market driven economy. Competition from within and outside the country has intensified. This has resulted in multiplicity of risks both in number and volume resulting in volatile markets. A precursor to successful management of credit risk is a clear understanding about risks involved in lending, quantifications of risks within each item of the portfolio and reaching a conclusion as to the likely composite credit risk profile of a bank.The corner stone of credit risk management is the establishment of a framework that defines corporate priorities, loan approval process, credit risk rating system, risk-adjusted pricing system, loan-review mechanism and comprehensive reporting system.1.2 Significance of the study:The fundamental business of lending has brought trouble to individual banks and entire banking system. It is, therefore, imperative that the banks are adequate systems for credit assessment of individual projects and evaluating risk associated therewith as well as the industry as a whole. Generally, Banks in India evaluate a proposal through the traditional tools of project financing, computing maximum permissible limits, assessing management capabilities and prescribing a ceiling for an industry exposure. As banks move in to a new high powered world of financial operations and trading, with new risks, the need is felt for more sophisticated and versatile instruments for risk assessment, monitoring and controlling risk exposures. It is, therefore, time that banks managements equip themselves fully to grapple with the demands of creating tools and systems capable of assessing, monitoring and controlling risk exposures in a more scientific manner.Credit Risk, that is, default by the borrower to repay lent money, remains the most important risk to manage till date. The predominance of credit risk is even reflected in the composition of economic capital, which banks are required to keep a side for protection against various risks. According to one estimate, Credit Risk takes about 70% and 30%remaining is shared between the other two primary risks, namely Market risk (change in the market price and operational risk i.e., failure of internal controls, etc.). Quality borrowers (Tier-I borrowers) were able to access the capital market directly without going through the debt route. Hence, the credit route is now more open to lesser mortals (Tier-II borrowers).With margin levels going down, banks are unable to absorb the level of loan losses. There has been very little effort to develop a method where risks could be identified and measured. Most of the banks have developed internal rating systems for their borrowers, but there hasbeen very little study to compare such ratings with the final asset classification and also to fine-tune the rating system. Also risks peculiar to each industry are not identified and evaluated openly. Data collection is regular driven. Data on industry-wise, region-wise lending, industry-wise rehabilitated loan, can provide an insight into the future course to be adopted.Better and effective strategic credit risk management process is a better way to Manage portfolio credit risk. The process provides a framework to ensure consistency between strategy and implementation that reduces potential volatility in earnings and maximize shareholders wealth. Beyond and over riding the specifics of risk modeling issues, the challenge is moving towards improved credit risk management lies in addressing banks’readiness and openness to accept change to a more transparent system, to rapidly metamorphosing markets, to more effective and efficient ways of operating and to meet market requirements and increased answerability to stake holders.There is a need for Strategic approach to Credit Risk Management (CRM) in Indian Commercial Banks, particularly in view of;(1) Higher NPAs level in comparison with global benchmark(2) RBI’ s stipulation about dividend distribution by the banks(3) Revised NPAs level and CAR norms(4) New Basel Capital Accord (Basel –II) revolutionAccording to the study conducted by ICRA Limited, the gross NPAs as a proportion of total advances for Indian Banks was 9.40 percent for financial year 2003 and 10.60 percent for financial year 20021. The value of the gross NPAs as ratio for financial year 2003 for the global benchmark banks was as low as 2.26 percent. Net NPAs as a proportion of net advances of Indian banks was 4.33 percent for financial year 2003 and 5.39 percent for financial year 2002. As against this, the value of net NPAs ratio for financial year 2003 for the global benchmark banks was 0.37 percent. Further, it was found that, the total advances of the banking sector to the commercial and agricultural sectors stood at Rs.8,00,000 crore. Of this, Rs.75,000 crore, or 9.40 percent of the total advances is bad and doubtful debt. The size of the NPAs portfolio in the Indian banking industry is close to Rs.1,00,000 crore which is around 6 percent of India’ s GDP2.The RBI has recently announced that the banks should not pay dividends at more than 33.33 percent of their net profit. It has further provided that the banks having NPA levels less than 3 percent and having Capital Adequacy Reserve Ratio (CARR) of more than 11 percent for the last two years will only be eligible to declare dividends without the permission from RBI3. This step is for strengthening the balance sheet of all the banks in the country. The banks should provide sufficient provisions from their profits so as to bring down the net NPAs level to 3 percent of their advances.NPAs are the primary indicators of credit risk. Capital Adequacy Ratio (CAR) is another measure of credit risk. CAR is supposed to act as a buffer against credit loss, which isset at 9 percent under the RBI stipulation4. With a view to moving towards International best practices and to ensure greater transparency, it has been decided to adopt the ’ 90 days’ ‘ over due’ norm for identification of NPAs from the year ending March 31, 2004.The New Basel Capital Accord is scheduled to be implemented by the end of 2006. All the banking supervisors may have to join the Accord. Even the domestic banks in addition to internationally active banks may have to conform to the Accord principles in the coming decades. The RBI as the regulator of the Indian banking industry has shown keen interest in strengthening the system, and the individual banks have responded in good measure in orienting themselves towards global best practices.1.3 Credit Risk Management(CRM) dynamics:The world over, credit risk has proved to be the most critical of all risks faced by a banking institution. A study of bank failures in New England found that, of the 62 banks in existence before 1984, which failed from 1989 to 1992, in 58 cases it was observed that loans and advances were not being repaid in time 5 . This signifies the role of credit risk management and therefore it forms the basis of present research analysis.Researchers and risk management practitioners have constantly tried to improve on current techniques and in recent years, enormous strides have been made in the art and science of credit risk measurement and management6. Much of the progress in this field has resulted form the limitations of traditional approaches to credit risk management and with the current Bank for International Settlement’ (BIS) regulatory model. Even in banks which regularly fine-tune credit policies and streamline credit processes, it is a real challenge for credit risk managers to correctly identify pockets of risk concentration, quantify extent of risk carried, identify opportunities for diversification and balance the risk-return trade-off in their credit portfolio.The two distinct dimensions of credit risk management can readily be identified as preventive measures and curative measures. Preventive measures include risk assessment, risk measurement and risk pricing, early warning system to pick early signals of future defaults and better credit portfolio diversification. The curative measures, on the other hand, aim at minimizing post-sanction loan losses through such steps as securitization, derivative trading, risk sharing, legal enforcement etc. It is widely believed that an ounce of prevention is worth a pound of cure. Therefore, the focus of the study is on preventive measures in tune with the norms prescribed by New Basel Capital Accord.The study also intends to throw some light on the two most significant developments impacting the fundamentals of credit risk management practices of banking industry – New Basel Capital Accord and Risk Based Supervision. Apart from highlighting the salient features of credit risk management prescriptions under New Basel Accord, attempts are made to codify the response of Indian banking professionals to various proposals under the accord. Similarly, RBI proposed Risk Based Supervision (RBS) is examined to capture its direction and implementation problems。
计划风险管理中英文对照外文翻译文献

计划风险管理中英文对照外文翻译文献(文档含英文原文和中文翻译)原文:Schedule Risk Management INTRODUCTIONSchedule risks are both threats and opportunities to the success of a project. Threats tend to reduce the success of meeting the project goals and opportunities tend to increase the success. Risk management is the process of identifying, analyzing, qualifying and quantifying the risks, and developing a plan to deal with them. This is routinely done during baseline schedule development as well as during schedule updates. Implementation of riskmanagement starts with early planning in both budgetary cost estimating and preliminary master scheduling in order to determine budgets and schedules with a comfortable level of confidence in the completion date and final cost. While there are entire volumes addressing risk in construction projects, it is important to note that the issue of time-related risk has not been universally incorporated into planning. Assessing cost risk is more intuitive, and very often addressed through the use of heuristics, so it has become more of a standard of the industry than time-related risk management. Most estimators will automatically add a contingency toa cost estimate to cover the risk of performance based on the type of project and circumstances pertaining to the undertaking of the project. Estimators estimate this contingency using their own rules of thumb developed over years of estimating as well as estimate ingmanuals,such as Means’ Cost Data or Cost Works. However, when it comes todeveloping the critical path method (CPM) schedules, risk management is often overlooked or underestimated.The purpose of this chapter is to provide an overview of risk management and the assessment process as well as best practices for incorporation of risk management into CPM schedule development and maintenance. For more detailed information about schedule risk, the reader should refer to risk management books, particularly those that focus on project management. One of the best resources available is David Hulett’s new book, Practical ScheduleRisk Analysis.Any risk management program starts with a good and accurate CPM schedule, created through the use of best practices and checked for quality, reasonableness, and appropriateness of the network model. Without a well-designed and developed CPM baseline schedule, a risk management process will not be effective. The risk analysis depends upon accurate and consistent calculations of the network logic, the appropriateness of the sequencing and phasing, and a reasonable approach to estimating activity durations.Most CPM schedules are not adjusted for risk but rather are developed as if there were one right answer for the schedule’s numerical data. Generally, activity durations are established by calculation of the quantity of work represented by an activity divided by the production rate, or by sheer ‘‘gut feeling’’ of the project manager or crew leader. This production rate is normally established by the contractor’s historical records or an estimating system, such as Means’, that provides an accurate data base of average production rates. Once those durations are calculated, they are often used as deterministic values, which assumes that the durations are accurate and unlikely to change. This assumption ignores the fact that the schedule is attempting to predict how long it will take to complete an activity at some unknown time in the future,using an unknown crew composition, with variable experience, and workingin unknown conditions. Risk management recognizes the uncertainty in duration estimating and provides a system to brain storm other risks that may occur during the project. Probability distributions are the best way to model planned activity durations, as noted by Hulett ‘‘The best way to understand the activity durations that are included in the schedule is as probabilistic statements of possible durations rather than a deterministic statement about how long the future activity will take.’’DEFINITION OF RISK TERMSThe Project Management Institute (PMI) defines project risk in its Project Management Body of Knowledge (PMBOK) as ‘‘an uncertain event or condition that, if it occurs, has a positive or negative effect on at least one project objective, such as time, cost, scope, or quality. A risk may have one or m ore causes and, if it occurs, one or more impacts.’’ PMBOK adds ‘‘Risk conditions could include aspects of the project’s or organization’s environment that may contribute to project risk, such as poor project management practices, or dependency on external participants who cannot be controlled.’’Risk Management: A process designed to examine uncertainties occurring during project delivery and to implement actions dealing with those uncertainties in order to achieve project objectives The definition of risk management in PMBOK, 4th Edition, is: ‘‘systematic process of identifying, analyzing, and responding to project risk.’’Risk definition by AACEi Cost Engineering Terminology7 is: ‘‘the degree of dispersion or variability around the expected or ‘best’ val ue, which is estimated to exist for the economic variable in question, e.g., a quantitative measure of the upper and lower limits which are considered reasonable for the factor being estimated.’’Time Contingency: An amount of time added to the base estimated duration to allow for unknown impacts to the project schedule, or to achieve a certain level of confidence in the estimated duration.Probability: A measure of the likelihood of occurrence of an event.Risk register: A checklist of potential risks developed during the risk identification phase of risk management.Risk allocation: A determination of how to respond to risks, which can include shifting risk, avoiding risks, preventing or eliminating risks, and incorporating risks into the schedule.Deterministic: A calculated approach to estimating single activity duration using work quantity divided by estimated production rate.Probabilistic: The determination of risk likelihood and consequences to establish duration ranges or risk-adjusted durations that can be used in a schedule in recognition that there are no certainties in estimating future durations.Monte Carlo analysis: A probabilistic approach to determining confidence levels of completion dates for a project schedule by calculating durations asprobability distributions.Probability distribution: The spread of durations in a statistically significant population that is used for the range of durations in probabilistic scheduling approaches.Confidence level: A measure of the statistical reliability of the prediction of project completion.What-if scenario: A modeling of a risk for use in a CPM schedule in order to predict the ramifications of an identified risk.Qualitative analysis: Occurring on the project, as well as assessing the severity of that risk should it occur and prioritizing the resultant list of risks. Quantitative analysis: The assigning of a probability to the qualitative description of the risk, ranking the risks, and calculating the potential impact from both individual risks as well as the cumulative effect of all risks identified.Exculpatory clauses: Disclaimer verbiage that is designed to shift risk. TYPES OF RISK IN CONSTRUCTION PROJECTSEverything that has ever gone wrong on a construction project is a potential risk on the next project. Many project managers instinctively develop a lessons-learned list of historical risks and take steps to minimize their exposure to those risks in the future.Risks vary by industry and even by construction project type as well as by personnel involved with the project. A roadway or bridge project has adifferent group of risks than a facility or building, and the selected contractors may have different degrees of influence on the level of risks to performance. If an owner attempts to save money in preconstruction services by limiting the extent of field investigation or development of as-built data, there will be a higher risk of discovery of unknown problems. The experience and competence of the architects and engineers handling the design of the project, as well as their quality control indevelopment of working drawings, directly affect the construction effort and, consequently, the risk associated with the plans and specifications.Even if the owner has been proactive in preconstruction investigation, there is always a risk of unforeseen conditions. This can be a function of the type of soils encountered, the local municipality, and its culture and history of keeping good records of obsolete utilities. If the city in which the project is to be built has a history of requiring contractors to remove all abandoned underground lines, there is a much lower risk of underground conflicts.The selection of the project team can impact positively or negatively the probability of successful project completion. Design-bid-build projects that use procurement philosophies allowing all financially capable contractors to participate will likely experience a much higher level of risk to on-time performance than a procurement philosophy that requires qualification of proposed contractors to ensure that they have the appropriate experience and resources to construct the project. A single weak subcontractor on a projectwill increase risk of performance and require more management than may be anticipated. If this is not considered, everyone will be surprised when that subcontractor fails and has to have their work augmented or corrected. Problems related to the management and possible termination of a failing subcontractor usually has serious negative impacts on the project.The reputation of the construction manager (CM) as well as the corporate culture will affect project performance. If the CM defines success with minimum time extensions as the only benchmark, there will likely be more conflict and a higher need for dispute resolution efforts. In addition, the management abilities of the CM directly affect many project tasks, such as review of shop drawings and response to requests for information in order to resolve questions about the construction.Work by outside or third parties can carry significant risks of influence on the project’s success. For example, a light rail station to be built on top of a parking garage under construction by a different contractor will run an increased risk of completion on time. The project has no control over—and little ability to influence—the completion of the parking garage, which quickly becomes vital to completion of the light rail project.Most projects are affected by local weather conditions, which, when adverse, can significantly impede progress. Most specifications require the contractor to take into account the normal local weather conditions in his schedule planning, which includes normal adverse weather, but also allow fortime extensions when unusually adverse weather occurs. Best practices would require the contractor to research the local historical weather records in order to plan for three to five year average weather conditions. Different parts of the country and the world have a wide variance in weather conditions, so planning or failure to plan for the risk of local weather can significantly affect project success.Local political situations, especially in volatile political climates, may hamper all efforts to construct a project efficiently. Countries with unstable political or economical systems will have higher risks in successful project completion than those with more stable systems. Countries or regions subject to wars, terrorism, turmoil, or other typesof violence also run greater risks to successful project completion than others. If the locality has a policy of requiring deep investigation into environmental issues or stringent or complicated bureaucracy, projects built in that locality will have a higher risk of late permits and conflict during construction. Another large risk on any project is the experience and reputation of the project team for safe construction practices. Safety violations and accidents can shut down a job completely. Even minor safety failures can distract the project team and impede timely performance. If a contractor has a poor safety record, the risk of delays because of safety violations is increased and should be taken into account during schedule development.A large volume of change orders on a project will affect employee morale;there is nothing worse than asking a craftsman to rip out recently installed high-quality woodwork for a requested change. If the CM has a good change management program in place, including most importantly good planning, the risks of negative pressure from changes are lowered. Without the program, the risks may be significant enough to derail project completion. Most conversations about risk are related to negative risks that impair successful performance, but often there are opportunities that would be overlooked without good risk assessment. A renovation project that calls for a three-story masonry wall to be demolished to the foundation in order to install a beam and column system might be redesigned with a pin beam temporary support structure, allowing the upper two stories to remain in place, saving time and money, as well as removing some risk. The brainstorming about risks needs to include looking for opportunities that could positively impact the project time for completion.It seems obvious that failure to plan for the myriad of risks that often affect project performance will render the planning less accurate. Without risk management, every item that might appear on a risk register (a checklist of potential risks) is a surprise to the project team should it happen, diverting attention and emphasis from the project management and consuming valuable resources. Most disputes arise from risks that likely were not considered at the inception of the project and might have been eliminated or mitigated with good risk planning.Once a company develops a regular risk management culture, the risk register generates many of the same risks on project after project. However, a company’s ‘‘risk register’’ should not be a fixed template, used as is on all its projects. The list must be updated and customized for each project taking into consideration its own risks. These lessons learned, when incorporated into the project schedule through the risk managementprogram, are invaluable in helping to minimize threats that carry negative impacts and take advantage of opportunities that bring positive impacts to project comp.IMPORTANCE OF GOOD PLANNING FOR RISK MANAGEMENT The quality of the risk management plan will control the usefulness of the risk analysis. This quality is achieved through developing a good and encompassing master risk register in a brainstorming workshop with experienced attendees, and following that process with analysis and risk allocation. This is combined with a process of continuing risk monitoring during updates as well as continuous cycles of risk management. Participants in the workshop will often comment that they cannot take certain risks into account because they do not have control of the risks or they have no idea if that risk will actually happen. One of the typical issues is repeated cycles of shop drawings, where experience tells us that a complicated design may cause structural steel shop drawings to be rejected, requiring revision and resubmission. Some stakeholders feel that this isbeyond their ability to plan for and therefore, the schedule should ignore it and assume the risk will not happen. Accepting this assumption minimizes the risk identification and analysis process. This type of risk should be identified, and then during the qualitative analysis, it will be weeded out as a low priority or incorporated as a high priority. However, if the risk is just not included on the risk register, the opportunity to analyze it is lost.With a thorough and organized risk workshop, based on a good master risk register, and participation by the major stakeholders as well as the project management team, the output of the risk analysis will be very useful. The most likely risks will be identified and analyzed, and with the rest of the risk management steps, the schedule will evolve into a risk-adjusted schedule, capable of reasonable analysis and realistic completion predictions.RISK SHIFTING IN CONTRACTSContract language may have a significant impact on how much of the risk each party carries. Sometimes called exculpatory clauses, this language attempts to shift or apportion undetermined risk. Contracts are often used to control or assign risk to various parties, or just to assign it to a party other than the owner. Many owners, developers, and contractors prefer using standard contract forms, such as those specially developed by organizations such as the American Institute of Architecture (AIA), the Construction Management Association of America (CMAA), and theAssociated General Contractors (AGC) in the United States and FIDIC orNEC in Europe and the Middle East, because such contract forms were written and updated by professionals and are widely known and used. However, many others insist on writing their own contracts or making amendments to the standard forms so that they can change certain conditions, which may—and usually does—affect the risk ofthe contracting parties.One example of this risk shifting is the use of clauses stating that geotechnical reports and information are provided to bidders for information only, and the owner is not responsible for any usage or interpretation of the geotechnical information. This is an attempt to limit the owner’s exposure to delays because of differing site conditions.Another example is that of the typical ‘‘no damages for delay’’ language that sometimes shows up in contracts, which does not typically shift the time performance risk, but only the costs for the delay. This language attempts to move the risk of the costs of delays from the responsibility of the owner to the contractor, so that the sole remedy is a time extension.Construction manager and contractor insurances are means to handle the shifted risk of contracts and limit the liability of those parties. These types of insurance can provide some level of protection against the adverse consequences of unknown problems that might affect the completion of the project. Builder’s risk policies provide insurance that will replace materials and provide for damage repair that can be invoked fairly quickly in the eventof vandalism or property losses, allowing the project to resume production and minimize delayed completion risks.An astute owner realizes that the more that risk is shifted to the contractor, the higher the cost and, sometimes, the longer the performance time of the project will be. A fair risk allocation is essential for a successful, economical, and timely completed project. Unfair risk allocation results in risks being distributed among the construction team, creating disharmony and adversarial relationships among the very team members that are needed to resolve the problems at hand.The risk management plan is the place to identify all risks and determine how to deal with these risks. This provides much better protection through a fair and objective allocation of risk, producing a clear understanding of the risk objectives by the entire project team. In some contracts, owners may try to shift some risks to the contractor as part of what they perceive as negotiation. Contractor’s prof it is usually proportional to the risk taken by the contractor. It is important for any owner to understand that there is always a price for shifting the risk, whether declared or hidden. Perhaps in some instances if the owner knew the real cost of shifting certain risks, he would have preferred not to shift them.An example of the above is when buying a new car or home. A standard warranty comes usually with every new vehicle and covers manufacturer’s defects up to a certain time period (e.g.36 months) or mileage (e.g.36,000miles), whichever comes first. Of course, the salesperson will try to sell the buyer (owner) an ‘‘extended warranty’’policy that extends most of the original warranty terms in time and mileage and perhaps adds a few attractive items. A buyer who considers himself a good negotiator may manage to obtain this extended warranty policy at ‘‘no extra cost.’’ This is a myth! In most cases, the buyer would have received a price discount on the vehicle, roughly equivalent to the dealer’s cost on the extended warranty policy, in lieu of the policy itself.中文:计划风险管理介绍进度风险对于一个项目的成功既是威胁又是机遇。
- 1、下载文档前请自行甄别文档内容的完整性,平台不提供额外的编辑、内容补充、找答案等附加服务。
- 2、"仅部分预览"的文档,不可在线预览部分如存在完整性等问题,可反馈申请退款(可完整预览的文档不适用该条件!)。
- 3、如文档侵犯您的权益,请联系客服反馈,我们会尽快为您处理(人工客服工作时间:9:00-18:30)。
中英文对照外文翻译文献(文档含英文原文和中文翻译)原文:Project Risk AnalysisChapter 1 Introduction1.1 About this compendiumThis course compendium is to be used in the course “Risikostyring is projector”. The focus will be on the following topics:• R isk identification• Risk structuring• Risk modeling in the light of a time schedule and a cost model• Risk follows upWe will also discuss elements related to decision analysis where risk is involved, and use of life cycle cost and life cycle profit models. The course compendium comprises a large number of exercises, and it is recommended to do most of the exercises in order to get a good understanding of the topics and methods described. A separate MS Excel program, pRisk.xls has been developed in order to assist numerical calculations and to conduct Monte Carlo simulation.1.2 DefinitionsAleatory uncertaintyVariation of quantities in a population. We sometimes use the word variability rather than aleatory uncertainty.Epistemic uncertaintyLack of knowledge about the “world”, and observable quantities in particular. DependencyThe relation between the sequences of the activities in a project.Observable quantityA quantity expressing a state of the “world”, i.e. a quantity of the p hysical reality or nature, that is unknown at the time of the analysis but will, if the system being analyzed is actually implemented, take some value in the future, and possibly become known. ParameterWe use the term parameter in two ways in this report. The main use of a parameter is that it is a quantity that is a part of the risk analysis models, and for which we assign numerical values. The more academic definition of a parameter used in a probabilitystatement about an observable quantity, X, is that a parameter is a construct where the value of the parameter is the limiting value where we are not able to saturate our understanding about the observable quantity X whatsoever new information we could get hold of. Parameter estimateThe numeric value we assess to a parameter.ProbabilityA measure of uncertainty of an event.RiskRisk is defined as the answer to the three questions [14]: i) what can go wrong? ii) How likely is it? And if it goes wrong, iii) what are the consequences? To describe the risk is a scenarioRisk acceptanceA decision to accept a risk.Risk acceptance criterionA reference by which risk is assessed to be acceptable or unacceptable.ScheduleA plan which specifies the start and finalization point of times for the activities in a project.Stochastic dependencyTwo or more stochastic variables are (stochastically) dependent if the expectation of one stochastic variable depends on the value of one or more of the other stochastic variables. Stochastic variableA stochastic variable, or random quantity, is a quantity for which we do not know the value it will take. However, we could state statistical properties of the variable or make probability statement about the value of the quantity.1.3 DEFINITIONSUncertaintyLack of knowledge about the performance of a system, and observable quantities in particular.Chapter 2Risk ManagementGenerally, risk management is defined (IEC 60300-3-9) as a “systematic application ofmanagement policies, procedures and practices to the tasks of analyzing, evaluating and controlling risk”. It will comprise (IEC definitions in parentheses):• Risk assessment, i.e.–Risk analysis (“Systematic use of available information to identify hazards and to estimate the r isk to individuals or populations, property or the environment”)–Risk evaluation (“Process in which judgments are made on the tolerability of the risk on the basis of risk analysis and taking into account factors such as socio-economic and environmental aspects”)• Risk reduction/control (Decision making, implementation and risk monitoring).There exists no common definition of risk, but for instance IEC 60300-3-9 defines risk as a “combination of the frequency, or probability, of occurrence and the consequence of a specified hazardous events”. Most definitions comprise the elements of probabilities and consequences. However, some as Klinke and Renn suggest a very wide definition, stating: “Risk refers to the possibility that human actions or events lead to consequences that affect aspects of what humans value”. So the total risk comprises the possibility of number (“all”)unwanted/hazardous events. It is part of the risk analysis to delimit which hazards to include. Further, risk usually refers to threats in the future, involving a (high) degree of uncertainty. In the following we will present the basic elements of risk management as it is proposed to be an integral part of project management.2.1 Project objectives and criteriaIn classical risk analysis of industrial systems the use of so-called risk acceptance criteria has played a central role in the last two or tree decades. Basically use of risk acceptance criteria means that some severe consequences are defined, e.g. accident with fatalities. Then we try to set an upper limit for the probability of these consequences that could be accepted, i.e. we could not accept higher probabilities in any situations. Further these probabilities could only be accepted if risk reduction is not possible, or the cost of risk reduction is very high.In recent years it has been a discussion in the risk analysis society whether it is fruitful or not to use risk acceptance criteria according to the principles above. It is argued that very often risk acceptance criteria are set arbitrary, and these do not necessarily support the overall best solutions. Therefore, it could be more fruitful to use some kind of risk evaluation criteria, rather than strict acceptance criteria. In project risk management we could establish acceptance criteria related to two types of events:• Events with severe consequences related to health, environment and safety.• Events with severe consequences related to project costs, project quality, project duration, oreven termination of the project. In this course we will have main focus on the project costs and the duration of the project. Note that both project cost and project duration are stochastic variables and not events. Thus it is not possible to establish acceptance criteria to project cost or duration directly. Basically, there are three types of numeric values we could introducein relation to such stochastic variables describing the project:1. Target. The target expresses our ambitions in the project. The target shall be something we are striving at, and it should be possible to reach the target. It is possible to introduce (internal) bonuses, or other rewards in order to reach the targets in a project.2. Expectation. The expectations are the value the stochastic variables will achieve in the long run, or our expectation about the outcome. The expectation is less ambitious than the target. The expectation will in a realistic way account for hazards, and threats and conditions which often contribute to the fact that the targets are not met.3. Commitment. The commitments are values related to the stochastic variables which are regulated in agreements and contracts. For example it could be stated in the contract that a new bridge shall be completed within a given date. If we are not able to fulfill the commitments, this will usually result in economical consequences, for example penalties for defaults, or in the worst case canceling of the contract.2.2 Risk identificationA scenario is a description of a imagined sequence or chain of events, e.g. we have a water leakage, and we are not able to stop this leakage with ordinary tightening medium due to the possible environmental aspects which is not clarified at the moment. Further the green movement is also likely to enter the scene in this case. A hazard is typically related to energies, poisonous media etc, and if they are released this will result in an accident or a severe event. A threat is a wider term than hazard, and we include also aspects as “wrong” method applied, “lack of competence and experience”. The term threat is also very often used in connection with security problems, e.g. sabotage, terrorism, and vandalism.2.3 Structuring and modeling of riskIn Section 2.2 we have identified methods to identify events and threats. We now want to relate these events and threats to the explicit models we have for project costs and project duration.2.3.1 Model for project execution time/schedule modelingWhen analyzing the execution time for a project we will have a project plan and typicallya Gantt diagram as a starting point. The Gantt diagram is transformed into a so-called flow network where the connections between the activities are explicitly described. Such a flow network also comprises description of duration of the activities in terms of probability statements. The duration of each activity is stochasticVariables, which we denote Ti for activity in a flow network we might also have uncertain activities which will be carried out only under special conditions. These conditions could be described in terms of events, and we need to describe the probability of occurrence of such events. Thus, there is a set of quantities, i.e. time variables and events in the model. The objective is now to link the undesired events and threats discussed in Section 2.2 to these time variables and events. Time variables are described by a probability distribution function. Such a distribution function comprises parameters that characterize the time variable. Often a parametric probability distribution is described by the three quantities L (low), M (most likely) and H high. If an undesired event occur, it is likely that the values of L, M and H will be higher than in case this event does not occur. A way to include the result from the risk identification process is then to express the different values of L, M and H depending on whether the critical event occurs or not. If we in addition are able to assess the probability of occurrence of the critical event, the knowledge about this critical event has been completely included into the risk model. Based on such an explicit modeling of the critical event, we could also easily update the model in case of new information about the critical event is obtained, for example new information could be available at a later stage in the process and changes of the plan could still be possible in light of the new information.2.3.2 Cost modelingThe cost model is usually based on the cost breakdown structure, and the cost elements will again be functions of labor cost, overtime cost, purchase price, hour cost of renting equipment, material cost, amount of material etc. The probabilistic modeling of cost is usually easier than for modeling project execution time. The principle is just to add a lot of cost terms, where each cost term is the product of the unit price and the number of units. We introduce price and volume as stochastic variables to describe the unit price and the number of units. The price and volume variables should also be linked to the undesired events and threats we have identified in Section 2.2. Often it is necessary to link the cost model to the schedule model. For example in case of delays it might be necessary to put more effort into the project to catch up with the problems, and these efforts could be very costly. Also, if the project is delayed we may need to pay extra cost to sub-contractors that have to postpone their support into the project.2.3.3 Uncertainty in schedule and cost modelingAs indicated above we will establish probabilistic models to describe the duration and cost of a project. The result of such a probabilistic modeling is that we treat the duration and cost as stochastic variables. Since duration and costs are stochastic variables, this means that there is uncertainty regarding the values they will take in the real project we are evaluating. Sometimes we split this uncertainty into three different categories, i) Aleatory uncertainty (variability due to e.g. weather conditions, labor conflicts, breakdown of machines etc.), ii) para meter or epistemic uncertainty due to lack of knowledge about “true” parameter values, and iii) model uncertainty due to lack of detailed, or wrong modeling. Under such thinking, the aleatory uncertainty could not be reduced; it is believed to be the result of the variability in the world which we cannot control. Uncertainty in the parameters is, however, believed to be reducible by collecting more information. Also uncertainty in the models is believed to be reducible by more detailed modeling, and decomposition of the various elements that go into the model. It is appealing to have a mental model where the uncertainty could be split into one part which we might not reduce (variability), and one part which we might reduce by thorough analysis and more investigation (increased knowledge). If we are able to demonstrate that the part of the uncertainty related to lack of knowledge and understanding has been reduced to a sufficient degree, we could then claim high confidence in the analysis. In some situation the owner or the authorities put forward requirements. Which could be interpreted as confidence regarding the quality of the analysis? It is though not always clear what is meant by such a confidence level. As an example, let E(C) be the expected cost of ap roject. A confidence statement could now be formulated as “The probability that the actual project cost is within an interval E(C) ± 10% should at least be 70%”. It is, however, not straight forward to document such a confidence level in a real analysis. T he “Successive process (trinnvisprosessen)” [4] is an attempt to demonstrate how to reduce the “uncertainty” in the result to a certain level of confidence.We also mention that Even [12] has recently questioned such an approach where there exist model uncertainty and parameter uncertainty, and emphasizes that we in the analysis should focus on the observable quantities which will become evident for us if the project is executed, e.g. the costs, and that uncertainty in these quantities represent the lack of knowledge about which values they will take in the future. This discussion is not pursuit any more in this presentation.2.4 Risk elements for follow up: Risk and opportunity registerAs risk elements and threats are identified in Section 2.2 these have to be controlled as far as possible. It is not sufficient to identify these conditions and model them in the schedule and cost models, we also have to mitigate the risk elements and threats. In order to ensure a systematic follow up of risk elements and threats it is recommended to establish a so-called threat log. The terms ‟Risk Register…and ‟Risk & Opportunity Register…(R&OR) is sometimes used rather than the term ‟threat log.… A R&OR is best managed by a database solution, for example an MS-Access Database. Each row in the database represents one risk element or threat. The fields in such a database could vary, but the following fields seems reasonable: • ID. An identifier is required in order to keep track of the threat in relation to the quantitative risk models, to follow up actions ET.• Description. A description of the threat is necessary in order to understand the content of the problem. It could be necessary to state the immediate consequences (e.g. occupational accident), but also consequences in terms of the main objectives of the project, e.g. time and costs.• Likelihood or probability. A judgment regarding how probable it is that the threat or the risk condition will be released in terms of e.g. undesired or critical events.• Impact. If possible, give a direct impact on cost and schedule if the event occurs, either by an expected impact, or by L, M and H values.• References to cost and schedule. In order to update the schedule and cost models it is convenient to give an explicit reference from the R&OR into the schedule and cost models. • Manageability. Here it is descried how the threat could be influenced, either by implementing measures to eliminate the threat prior to it reveals it self, or measures in orderto reduce the consequences in case of the threat will materialize.• Alert information. It is important to be aware of information that could indicate the development of the threat before it eventually will materialize. If such information is available we could implement relevant measures if necessary. For example it could be possible to take ground samples at a certain cost, but utilizing the information from such samples could enable us to choose appropriate methods for tunnel penetration.• Measures. List of measures that could be implemented to reduce the risk.• Deadline and responsible. Identification of who is responsible for implementing and follow up of the measure or threat, and any deadlines.• Status. Both with respect to the threat and any measure it is valuable to specify the development, i.e. did the treat reveal it self into undesired events with unwanted consequences, did the measure play any positive effect etc.2.5 Correction and controlAs the project develops the R&OR is the primary control tool for risk follow up. By following the status of the various threats, risk elements and measures we could monitor the risk in the project. This information should of course be linked to the time and cost plans. If a given threat does not reveal in terms of undesired events, the time and cost estimates could be lowered and this gain could be utilized in other part of the project, or in other projects. In the opposite situation it is necessary to increase the time and cost estimates, and we need to consider new measures, and maybe spend some of the reserves to catch up in case of an expected delay. During the life cycle of a project it will occur new threats and risk elements which we did not foresee in the initial risk identification process. Such threats must continuously be entered into the R&OR, and measures need to be considered.一、介绍(一)关于本纲要本课程纲要过程中研究的是“风险也是一种项目”。