英文建筑合同正式模版
英文建筑合同模板
英文建筑合同模板Building Contract Template。
This Building Contract ("Contract") is made and entered into as of [Date], by and between [Builder Name], with a principal place of business at [Address] ("Builder"), and [Owner Name], with a principal place of residence at [Address] ("Owner").1. Scope of Work。
Builder agrees to provide all labor, materials, equipment, and services necessary for the construction of [Description of Project] ("Project") in accordance with the plans and specifications attached hereto as Exhibit A. Builder shall complete the Project in a good and workmanlike manner, in compliance with all applicable laws, regulations, and codes.2. Payment。
Owner agrees to pay Builder the total contract price of [Total Contract Price] for the completion of the Project. The payment shall be made in installments as follows:a. [Percentage]% of the total contract price upon the execution of this Contract;b. [Percentage]% of the total contract price upon completion of [Milestone 1];c. [Percentage]% of the total contract price upon completion of [Milestone 2];d. [Percentage]% of the total contract price upon substantial completion of the Project; and。
英文建筑合同范本
英文建筑合同范本English Construction Contract TemplateParty A (Employer):[Name of Party A][Address of Party A]Party B (Contractor):[Name of Party B][Address of Party B]Article 1. Project DescriptionThe project involves [describe the specific construction work]. Article 2. Contract PriceThe total contract price is [amount in words and figures]. Article 3. Time for CompletionParty B agrees to complete the project by [specified date]. Article 4. Payment TermsPayment will be made in installments as follows: [detail the payment schedule].Article 5. Materials and WorkmanshipParty B shall use materials of good quality and perform the work in a workmanship-like manner.Article 6. Changes and ModificationsAny changes or modifications to the project shall be agreed upon in writing by both parties.Article 7. Warranties and GuaranteesParty B provides [duration] warranty for the work and materials.Article 8. InsuranceParty B is responsible for obtaining appropriate insurance coverage.Article 9. Dispute ResolutionIn case of any disputes, the parties shall attempt to resolve them through negotiation. If unsuccessful, arbitration shall be the final means of resolution.Article 10. TerminationEither party may terminate the contract under certain circumstances as stipulated herein.Article 11. MiscellaneousOther terms and conditions as mutually agreed upon.Party A: [Signature of Party A]Date: [Date of signature]Party B: [Signature of Party B]Date: [Date of signature]Please note that this is a basic template and may need to be customized and detailed according to the specific requirements of the actual construction project.。
建筑施工英文合同范本
建筑施工英文合同范本CONTRACT FOR CONSTRUCTIONThis Contract is made and entered into on [Date] between [Party A Name] (hereinafter referred to as "Owner") and [Party B Name] (hereinafter referred to as "Contractor").Article 1: Project DescriptionThe project involves the construction of [Project Name] located at [Project Location]. The scope of work includes but is not limited to [Describe the specific scope of the construction work].Article 2: Contract Price and Payment Terms2.1 The total contract price for the project is [Contract Price] (inclusive of all taxes and fees).2.2 Payment shall be made as follows:[Percentage] of the contract price as an advance payment upon the signing of this contract.Interim payments will be made based on the progress of the work as certified the architect/engineer at regular intervals.The final payment of [Percentage] will be made upon the pletion and acceptance of the project.Article 3: Project Schedule3.1 The Contractor shall mence the work on or before [Commencement Date] and plete the project [Completion Date].3.2 In the event of delay in the pletion of the project, the Contractor shall be liable for liquidated damages as specified in the contract.Article 4: Quality and Standards4.1 The Contractor shall carry out the construction work in accordance with the approved plans and specifications and in pliance with all applicable laws, regulations, and industry standards.4.2 The work shall be subject to inspection and approval the Owner or its representative at various stages of the construction.Article 5: Insurance and Bonds5.1 The Contractor shall obtn and mntn throughout the duration of the project all necessary insurance policies, including but not limited to workers' pensation, liability insurance, and property damage insurance.5.2 The Contractor shall provide a performance bond and a labor and materials payment bond in the amounts specified in the contract.Article 6: Changes and AmendmentsAny changes or amendments to the scope of work, contract price, or project schedule shall be made in writing and signed both parties.Article 7: Dispute ResolutionIn the event of any dispute or controversy arising out of or in connection with this contract, the parties shall attempt to resolve the matter through friendly negotiation. If the negotiation fls, the dispute shall be submitted to arbitration in accordance with the rules of [Arbitration Institution].Article 8: Termination of ContractThis contract may be terminated either party in the event of a material breach of the contract the other party or upon the occurrence of other circumstances as specified in the contract.Article 9: Miscellaneous Provisions9.1 This contract constitutes the entire agreement between the parties and supersedes all prior negotiations and understandings.9.2 Neither party shall assign or transfer this contract without the prior written consent of the other party.IN WITNESS WHEREOF, the parties hereto have executed this contract as of the date first above written.Owner: [Owner's Signature] [Owner's Name] [Owner's Address]Contractor: [Contractor's Signature] [Contractor's Name] [Contractor's Address]Please note that this is a basic template and should be reviewed and customized a legal professional to meet the specific requirements and circumstances of your construction project.。
英文建筑合同5篇
英文建筑合同5篇篇1English Construction ContractIntroductionA construction contract is a legally binding agreement between a client and a contractor outlining the terms and conditions of a construction project. It is crucial for both parties to understand and adhere to the contract to ensure a successful completion of the project. This document provides an overview of key components of an English construction contract.Parties InvolvedThe parties involved in a construction contract are the client and the contractor. The client is typically the individual or organization who owns the property and wishes to have a construction project completed. The contractor is the individual or company responsible for carrying out the construction work.Scope of WorkThe scope of work outlines the specific tasks and responsibilities of the contractor. This includes the timeline forcompletion, materials to be used, and any special requirements or considerations. It is important for both parties to agree on the scope of work before the project begins to prevent any misunderstandings or disputes down the line.Payment TermsPayment terms are a critical aspect of the construction contract. This section outlines the total cost of the project, the schedule for payments, and any penalties for late payments. It is important for both parties to agree on the payment terms to avoid any financial disputes during the project.Insurance and LiabilityInsurance and liability clauses are an essential part of the construction contract to protect both parties in case of accidents or damages. The contractor should have the appropriate insurance coverage to protect against any liability claims. Additionally, the client should understand their responsibilities in case of any damages or accidents on the construction site.Change OrdersChange orders are amendments to the original contract that outline any changes in the scope of work, timeline, or budget. It is common for changes to occur during the construction process,and both parties must agree on these changes in writing to ensure clarity and avoid disputes.Dispute ResolutionDispute resolution clauses outline the process for resolving any disputes that may arise during the construction project. This may include mediation, arbitration, or litigation. It is important for both parties to understand and agree on the dispute resolution process to prevent any delays in the project.ConclusionIn conclusion, an English construction contract is a crucial document that outlines the terms and conditions of a construction project. It is essential for both parties to understand and adhere to the contract to ensure a successful completion of the project. By including key components such as parties involved, scope of work, payment terms, insurance and liability, change orders, and dispute resolution, both the client and contractor can protect themselves and prevent any misunderstandings or disputes.篇2English Building ContractIntroductionA building contract is a legally binding agreement between the owner of a property and a contractor for the construction, renovation or repair of a building. It is crucial for both parties to have a clear understanding of the terms and conditions of the contract to ensure a successful and satisfactory project outcome.Key Components of a Building Contract1. Parties Involved: The building contract should clearly state the names and contact details of both the owner and the contractor. It should also include details of any subcontractors or suppliers involved in the project.2. Scope of Work: The contract should outline the specific work to be carried out, including the materials to be used, the timeline for completion, and any relevant drawings or specifications.3. Payment Terms: Details of the payment schedule, including the amount due at each stage of the project, should be clearly outlined in the contract. Any penalties for late payment or changes to the payment terms should also be included.4. Change Orders: Any changes to the scope of work or specifications should be documented in writing as change orders.These changes may impact the project timeline and budget, so it is important that both parties agree to any changes before work proceeds.5. Insurance and Liability: The contract should specify the insurance coverage required by both parties, including liability insurance, workers' compensation, and property insurance. It should also outline the responsibilities of each party in the event of accidents or damage to the property.6. Dispute Resolution: In the event of a dispute, the contract should outline the process for resolving disagreements, whether through mediation, arbitration, or litigation.Tips for a Successful Building Contract1. Clearly Define the Scope of Work: Make sure that all aspects of the project are clearly outlined in the contract, including the materials to be used, the timeline for completion, and any site-specific requirements.2. Review and Understand the Contract: Both parties should thoroughly review the contract and seek legal advice if necessary to ensure that they understand their rights and obligations under the agreement.3. Communicate Effectively: Open and regular communication between the owner and the contractor is essential for a successful project. Any changes to the scope of work or unexpected issues should be discussed and documented in writing.4. Monitor Progress: The owner should regularly inspect the work to ensure that it is being completed according to the contract specifications. Any concerns or issues should be addressed promptly to avoid delays or disputes.ConclusionA well-drafted building contract is essential for the successful completion of a construction project. It provides a clear framework for the work to be carried out, the payment terms, and the responsibilities of both parties. By following the key components of a building contract and communicating effectively throughout the project, both the owner and the contractor can ensure a smooth and satisfactory outcome.篇3英文建筑合同Building ContractThis Building Contract is made and entered into on this __ day of ___, 20__ between [Name of Owner], hereinafter referred to as the "Owner," and [Name of Contractor], hereinafter referred to as the "Contractor."I. Scope of WorkContractor agrees to furnish all materials, equipment, labor, and services necessary for the construction of [Description of Project] according to the plans and specifications prepared by [Architect/Engineer]. Contractor shall complete the work in a good and workmanlike manner and in compliance with all applicable laws and regulations.II. PaymentOwner agrees to pay Contractor the sum of [Dollar Amount] for the completion of the work. Payment shall be made in installments as follows:- [Percentage]% upon signing of this Contract- [Percentage]% upon completion of [Milestone]- [Percentage]% upon substantial completion- [Percentage]% upon final completion and acceptanceIII. ChangesOwner may make changes to the plans and specifications with the written consent of Contractor. Any changes in the scope of work shall be made by written Change Order and the contract sum and completion date shall be adjusted accordingly.IV. SubcontractorsContractor may use subcontractors to perform portions of the work. Contractor shall be responsible for the acts and omissions of subcontractors and shall ensure that they comply with the terms of this Contract.V. Time of CompletionContractor shall complete the work within [Number] days from the date of commencement. Owner may grant an extension of time for completion for reasons beyond Contractor's control.VI. WarrantyContractor warrants that all work shall be free from defects for a period of [Number] years from the date of final completion. Owner shall notify Contractor of any defects in writing and Contractor shall promptly correct them at no additional cost to Owner.VII. IndemnificationContractor shall indemnify and hold Owner harmless from any claims, damages, or liabilities arising from Contractor's performance under this Contract.VIII. TerminationEither party may terminate this Contract with written notice if the other party materially breaches any term or condition of this Contract. Upon termination, Contractor shall be entitled to payment for work completed up to the date of termination.IX. Entire AgreementThis Contract constitutes the entire agreement between the parties and supersedes all prior agreements and understandings, whether written or oral. Any amendments to this Contract must be in writing and signed by both parties.IN WITNESS WHEREOF, the parties have executed this Contract as of the date first above written.Owner: [Name of Owner]Contractor: [Name of Contractor]Date: ______, 20__This Building Contract is hereby accepted and approved:Architect/Engineer: [Name]Date: ______, 20__This document sets forth the terms and conditions of the agreement between the Owner and Contractor for the construction of the specified project. It is important for both parties to carefully review and understand the terms of the Contract before signing to ensure that all aspects of the project are clearly defined and agreed upon.篇4English Building ContractA building contract is a legally binding agreement between a client and a contractor for the construction or renovation of a building. The contract outlines the terms and conditions under which the project will be completed, including the scope of work, schedule, budget, and responsibilities of each party.The purpose of a building contract is to protect the interests of both parties by clearly defining the expectations and requirements of the project. By establishing a formal agreement, potential disputes and misunderstandings can be avoided, and the project can proceed smoothly and efficiently.Key Terms of a Building ContractWhen drafting a building contract, there are several key terms and clauses that should be included to ensure that both parties are protected and informed throughout the construction process. Some of the key terms that should be included in a building contract include:1. Scope of Work: The contract should clearly outline the scope of work to be performed, including details of the construction or renovation project, materials to be used, and any specific requirements or specifications.2. Schedule: The contract should include a timeline for the project, including start and completion dates, milestones, and deadlines for various stages of the construction process.3. Budget: The contract should include a detailed breakdown of the project costs, including labor, materials, equipment, and any additional expenses. The contract should also specify payment terms, including the amount of the initial deposit, progress payments, and final payment.4. Change Orders: The contract should include a provision for change orders, which allow for modifications to the scope of work or project timeline. Change orders should include details ofthe requested changes, costs, and any adjustments to the schedule.5. Insurance and Liability: The contract should specify the insurance requirements for the project, including liability insurance, workers' compensation, and any other insurance policies required by law. The contract should also include provisions for indemnification and liability for damages or injuries.6. Dispute Resolution: The contract should include provisions for resolving disputes, including the process for mediation, arbitration, or litigation if a disagreement arises between the parties.7. Termination: The contract should include provisions for terminating the agreement, including the circumstances under which either party can cancel the contract and any penalties or fees associated with early termination.ConclusionIn conclusion, a building contract is an essential document for any construction or renovation project. By clearly outlining the terms and conditions of the agreement, both parties can protect their interests and ensure that the project proceedssmoothly and efficiently. It is important for both the client and the contractor to carefully review and negotiate the terms of the contract before signing to avoid any misunderstandings or disputes during the construction process.篇5English Construction ContractA construction contract is a legally binding agreement between a client and a contractor, where the contractor agrees to build, renovate, or repair a structure in exchange for payment. The contract outlines the scope of work, timelines, payment terms, and responsibilities of both parties. In the UK, construction contracts are governed by the Housing Grants, Construction, and Regeneration Act 1996 (also known as the Construction Act) and the Scheme for Construction Contracts Regulations.Types of ContractsThere are several types of construction contracts, each with its own advantages and disadvantages:1. Lump Sum Contract: This is where the contractor agrees to complete the project for a fixed price. This type of contract is common for small projects with well-defined scopes of work.2. Cost Plus Contract: In this type of contract, the contractor is reimbursed for the actual costs of construction plus a fee for overhead and profit. This is often used for projects with uncertain scopes of work or where the client wants more control over the costs.3. Time and Materials Contract: In this type of contract, the client pays for the materials and labor costs plus a fee for overhead and profit. This type of contract is commonly used for small projects where it is difficult to define the scope of work.4. Design-Build Contract: In a design-build contract, the contractor is responsible for both the design and construction of the project. This type of contract can streamline the construction process and minimize conflicts between designers and contractors.Key Clauses in a Construction Contract1. Scope of Work: The contract should clearly define the scope of work, including the materials to be used, construction methods, and quality standards.2. Payment Terms: The contract should outline the payment schedule, including milestones for progress payments and the final payment upon completion of the project.3. Change Orders: The contract should address how changes to the scope of work will be handled, including any additional costs.4. Delays: The contract should outline how delays will be addressed, including extensions of time and liquidated damages for late completion.5. Dispute Resolution: The contract should include a mechanism for resolving disputes, such as mediation or arbitration.6. Insurance and Indemnity: The contract should detail the insurance requirements for the project and how liability will be allocated between the parties.ConclusionA well-drafted construction contract is essential for a successful construction project. It helps to protect the interests of both parties and minimizes the risk of disputes. By clearly defining the scope of work, payment terms, and responsibilities, a construction contract can help ensure that the project is completed on time and within budget.。
建筑标准合同范本英文
建筑标准合同范本英文BUILDING CONSTRUCTION STANDARD CONTRACT TEMPLATEContract AgreementThis Building Construction Contract (hereinafter referred to as the "Contract") is made and entered into and between the following parties:Party A (Owner/Employer):[Full Name of the Owner/Employer][Address of the Owner/Employer]Party B (Contractor):[Full Name of the Contractor][Address of the Contractor]Article 1: Scope of WorkThe scope of work under this Contract shall consist of the construction, pletion, and delivery of the building project as specified in the attached drawings, specifications, and any other documents agreed upon both parties (collectively referred to as the "Project Documents"). The Project Documents shall form an integral part of this Contract.Article 2: Contract Price and Payment TermsThe total contract price for the Project shall be [Amount in Words and Figures]. Payment shall be made in accordance with the following terms: An initial payment of [Percentage]% of the total contract price shall be made upon signing of this Contract.Progress payments shall be made at agreed-upon intervals based on the percentage of pletion of the Project, as certified Party A.The final payment, representing the balance of the total contract price, shall be made upon satisfactory pletion and acceptance of the Project Party A.Article 3: Project ScheduleThe Project shall be menced on [Start Date] and pleted [Completion Date], subject to any force majeure events or changes agreed upon both parties.Article 4: Quality StandardsThe construction work shall be performed in accordance with the Project Documents and shall ply with all relevant local building s, standards, and regulations. Any defects or deficiencies in the work shall be rectified Party B at its own cost.Article 5: WarrantyParty B warrants that the Project shall be free from defects in materials and workmanship for a period of [Number] years from the date of pletion. During this warranty period, Party B shall, upon notification Party A, promptly repr or replace any defective materials or workmanship.Article 6: TerminationThis Contract may be terminated either party in the event of a material breach the other party, provided that a written notice of default is given and a reasonable opportunity to rectify the breach is afforded. In the event of termination, the parties shall settle all outstanding payments and other obligations in accordance with the terms of this Contract.Article 7: Dispute ResolutionAny disputes arising out of or in connection with this Contract shall be resolved through amicable negotiations between the parties. If such negotiations fl to produce a settlement, the parties shall submit the dispute to [Arbitration Institute/Court] for arbitration/resolution.Article 8: MiscellaneousThis Contract shall be governed and construed in accordance with the laws of [Country/Jurisdiction].This Contract constitutes the entire agreement between the parties and supersedes any previous agreements or understandings.Any amendments or modifications to this Contract shall be made in writing and signed both parties.Signature:Party A (Owner/Employer):By: _______________________Name: _______________________Date: _______________________ Party B (Contractor):By: _______________________ Name: _______________________ Date: _______________________。
建筑合同范本英语版
建筑合同范本英语版Standard Blank ContractThis Contract (hereinafter referred to as the "Contract") is made and entered into this _____ day of ____________, 20____, and between:Party A:Name: ______________________________Address: ____________________________City: _______________________________Country: ____________________________Phone: ______________________________Party B:Name: ______________________________Address: ____________________________City: _______________________________Country: ____________________________Phone: ______________________________Both Party A and Party B shall be collectively referred to as the "Parties".WHEREAS, Party A is the owner of certn property located at______________________________ (hereinafter referred to as the "Property"); and WHEREAS, Party B is a professional construction pany with expertise in building and construction projects;NOW, THEREFORE, in consideration of the mutual covenants and agreements hereinafter set forth, and for other good and valuable consideration, the receipt and sufficiency of which is here acknowledged, the Parties agree as follows:1. Scope of Work1.1 Party B shall provide all labor, materials, tools, and equipment necessary for the pletion of the construction project as described in Exhibit A (attached hereto and incorporated herein reference) (hereinafter referred to as the "Project").1.2 The Project shall be pleted in accordance with the plans, specifications, and drawings as mutually agreed upon the Parties.2. Payment2.1 Party A agrees to pay Party B the total contract price of _______________ (__________________) in the currency of ____________________ for the pletion of the Project.2.2 The payment shall be made in installments as follows:a) ______% of the total contract price upon signing of this Contract;b) ______% of the total contract price upon pletion of ____________________;c) ______% of the total contract price upon pletion of ____________________;d) ______% of the total contract price upon final pletion and acceptance of the Project.2.3 All payments shall be made within ______ days of receipt of an invoice from Party B.3. Time of Completion3.1 Party B shall plete the Project within ______ days from the mencement date as specified in Exhibit A.3.2 Party B shall provide regular progress reports to Party A during the course of the Project.4. Changes and Modifications4.1 Any changes or modifications to the Project must be agreed upon in writing both Parties.4.2 Any changes or modifications to the contract price resulting from changes or modifications to the Project shall be mutually agreed upon both Parties in writing.5. Termination5.1 Either Party may terminate this Contract in the event of a material breach the other Party, provided that written notice of such breach is given and the breaching Party has fled to remedy the breach within ______ days of receiving such notice.5.2 In the event of termination, Party B shall be end to payment for all work performed and costs incurred up to the date of termination.6. Governing LawThis Contract shall be governed and construed in accordance with the laws of ____________________.7. Entire AgreementThis Contract contns the entire agreement between the Parties and supersedes all prior negotiations, understandings, or agreements, whether oral or written, relating to the subject matter hereof.IN WITNESS WHEREOF, the Parties hereto have executed this Contract as of the day and year first above written.Party A: _____________________________Party B: _____________________________。
建设工程英文合同范本
建设工程英文合同范本CONSTRUCTION CONTRACTThis Construction Contract (the "Contract") is made and entered into as of [Contract Date] and between [Owner's Name] (the "Owner") and [Contractor's Name] (the "Contractor").Article 1 Project DescriptionThe Owner intends to undertake a construction project (the "Project") at [Project Location]. The Project shall consist of [Brief description of the scope of work, including but not limited to the type of construction, structures to be built, and any other relevant detls].Article 2 Contract Price and Payment Terms2.1 The total contract price for the Project is [Contract Price] (inclusive of all taxes, duties, and other charges).2.2 The Owner shall make progress payments to the Contractor as follows:[Describe the payment schedule, including milestones and the percentage of the contract price to be pd at each milestone].Final payment shall be made upon pletion and acceptance of the Project, subject to the provisions of Article [Article Number] of this Contract.Article 3 Project Schedule3.1 The Contractor shall mence the Project on or before [Commencement Date] and shall plete the Project [Completion Date].3.2 The Contractor shall submit a detled project schedule to the Owner within [Number of Days] after the execution of this Contract. The schedule shall include the start and pletion dates of each major activity and shall be subject to the Owner's approval.Article 4 Workmanship and Materials4.1 The Contractor shall perform the work in a good and workmanlike manner, in accordance with the applicable industry standards and the requirements of this Contract.4.2 The Contractor shall use only new and quality materials in the performance of the work. All materials shall be subject to the Owner's inspection and approval prior to use.Article 5 Changes and Extra Work5.1 Any changes to the scope of work or additional work required the Owner shall be subject to a written change order. The change order shall specify the nature and extent of the change, the impact on the contract price and project schedule, and any other relevant terms and conditions.5.2 The Contractor shall not proceed with any change or extra work withouta written change order from the Owner.Article 6 Inspection and Acceptance6.1 The Owner or its representative shall have the right to inspect the work at any time during the progress of the Project.6.2 Upon pletion of the Project, the Contractor shall notify the Owner in writing that the Project is ready for final inspection and acceptance. The Owner shall conduct the final inspection within [Number of Days] after receipt of the notice.6.3 If the Project is found to be in pliance with the requirements of this Contract, the Owner shall issue a written acceptance certificate. If the Project is not in pliance, the Contractor shall be required to make the necessary corrections and resubmit the Project for final inspection.Article 7 Warranties and Guarantees7.1 The Contractor warrants that the work performed under this Contract shall be free from defects in workmanship and materials for a period of [Warranty Period] from the date of final acceptance.7.2 The Contractor shall also guarantee that the Project will meet the performance specifications and requirements set forth in this Contract for a period of [Guarantee Period] from the date of final acceptance.Article 8 Insurance and Bonds8.1 The Contractor shall obtn and mntn, at its own expense, the following insurance policies:Workers' pensation insurance as required law.General liability insurance with a minimum coverage of [Insurance Amount].Builder's risk insurance to cover the Project during the construction period.8.2 The Contractor shall also provide a performance bond and a payment bond in the amounts of [Bond Amount] to guarantee the fthful performance of the Contract and the payment of all subcontractors and suppliers.Article 9 Dispute Resolution9.1 In the event of a dispute arising out of or in connection with this Contract, the parties shall attempt to resolve the dispute through friendly negotiation.9.2 If the dispute cannot be resolved through negotiation within [Number of Days], either party may submit the dispute to arbitration in accordance with the rules of the [Arbitration Institution]. The arbitration award shall be final and binding on both parties.Article 10 Termination of Contract10.1 Either party may terminate this Contract in the event of a material breach the other party. A material breach shall include, but not be limited to, the flure to perform the work in accordance with the requirements of this Contract, the flure to meet the project schedule, or the flure to make progress payments.10.2 In the event of termination, the parties shall follow the procedures set forth in Article [Article Number] of this Contract.Article 11 Miscellaneous Provisions11.1 This Contract constitutes the entire agreement between the parties and supersedes all prior negotiations, representations, and agreements, whether written or oral.11.2 This Contract shall be governed and construed in accordance with the laws of [Jurisdiction].11.3 Any notices required or permitted under this Contract shall be in writing and shall be delivered to the other party at the address specified in this Contract or at such other address as may be designated the party in writing.IN WITNESS WHEREOF, the parties have executed this Contract as of the date first above written.[Owner's Signature] [Owner's Name and Address] [Contractor's Signature] [Contractor's Name and Address]。
建筑合同范本英语
建筑合同范本英语Building Contract TemplateTHIS AGREEMENT is made the DAY of ________, 20__.BETWEEN:1. ABC Construction Company, a company registered under the laws of the United States, having its registered office at123 Main Street, Anytown, USA (hereinafter called the "Contractor").2. XYZ Property Development, a company registered under the laws of the United States, having its registered office at456 Elm Street, Anytown, USA (hereinafter called the "Owner").WHEREAS:The Owner intends to construct a building (hereinafterreferred to as the "Project") at the site located at 789 Oak Avenue, Anytown, USA.AND WHEREAS:The Contractor is a company engaged in the business of construction and has agreed to carry out the construction of the Project.NOW IT IS HEREBY AGREED as follows:1. Scope of Work:The Contractor shall carry out and complete the constructionof the Project as per the specifications and drawingsprovided by the Owner.2. Contract Price:The total contract price for the Project is US Dollars($ ________ ) (hereinafter referred to as the "Contract Price").3. Payment Terms:The Owner shall pay the Contractor the Contract Price in installments as follows:- A deposit of 10% of the Contract Price upon signing this Agreement.- 30% of the Contract Price upon completion of the foundation. - 30% of the Contract Price upon completion of the superstructure.- The balance of 30% of the Contract Price upon completionand handover of the Project.4. Commencement and Completion:The Contractor shall commence the work within 30 days of the signing of this Agreement and shall complete the Projectwithin a period of 12 months from the date of commencement.5. Delays:The Contractor shall not be liable for any delay caused by force majeure or any other cause beyond the Contractor's control. In such cases, the completion date shall be extended accordingly.6. Liability and Insurance:The Contractor shall maintain adequate insurance coverage for the Project, including but not limited to worker's compensation, general liability, and property damage.7. Termination:Either party may terminate this Agreement by giving 30 days' written notice to the other party in case of breach of any term of this Agreement by the other party.8. Dispute Resolution:Any dispute arising out of or in connection with this Agreement shall be resolved by arbitration in accordance with the rules of the American Arbitration Association.9. Governing Law:This Agreement shall be governed by and construed in accordance with the laws of the State of ________.10. Entire Agreement:This Agreement constitutes the entire agreement between the parties and supersedes any prior negotiations, representations, or agreements.IN WITNESS WHEREOF the parties have executed this Agreement on the day and year first above written.ABC Construction CompanyBy: ________________________Date: ________________________XYZ Property DevelopmentBy: ________________________Title: ________________________Date: ________________________Note: This template is for illustrative purposes only and should not be used as a legal document without consulting with a qualified attorney.。
建筑工程英文合同范本
Contract for Construction WorkThis Contract (the "Contract") is made and entered into as of [Date], by and between [Client Name] ("Client"), a [Client's jurisdiction] corporation, and [Contractor Name] ("Contractor"), a [Contractor's jurisdiction] corporation.1. Scope of WorkThe Contractor agrees to perform all construction work (the "Work") as described in the attached Schedule A (the "Scope of Work"), which is incorporated into this Contract by reference. The Work shall be performed at the construction site located at [Location], as more particularly described in the Scope of Work.2. TermThe term of this Contract shall commence on the date hereof and shall continue until the Work is completed, or until the parties otherwise agree in writing to terminate this Contract (the "Term").3. Price and Payment Terms3.1 PriceIn consideration for the performance of the Work, the Client shall pay the Contractor the total amount of [Price], as set forth in the Scope of Work.3.2 Payment TermsThe Client shall make payments to the Contractor as follows:(a) [Percentage] of the total price shall be paid upon the signing of this Contract;(b) [Percentage] of the total price shall be paid upon the completion of [specify percentage of Work];(c) The remaining [Percentage] of the total price shall be paid upon the final completion of the Work, subject to the Client's approval as set forth in Section 6 below.4. Performance and Completion4.1 PerformanceThe Contractor shall perform the Work in accordance with the terms of this Contract, the applicable specifications and drawings, and all applicable laws, regulations, and standards.4.2 CompletionThe Contractor shall use commercially reasonable efforts to complete the Work on or before the completion date set forth in the Scope of Work (the "Completion Date"). The Contractor shall be responsible for any delays in completion of the Work, whether directly or indirectly caused by the Contractor's actions or inactions.5. WarrantiesThe Contractor warrants that the Work shall be performed in a workmanlike manner and in accordance with the applicable specifications and drawings. The Contractor further warrants that the Work shall be free from defects in materials and workmanship for a period of [Warranty Period], following the final completion of the Work.6. Approval of WorkThe Client reserves the right to inspect and approve the Work at any time during the performance of the Work. The Client's approval of the Work shall be deemed to have been given if the Client fails to object in writing to the Work within [specify number of days] after its completion.7. Default and Termination7.1 DefaultIf either party defaults in the performance of any material obligation under this Contract, the non-defaulting party may terminate this Contract by written notice to the defaulting party.7.2 Termination for ConvenienceThe Client may terminate this Contract at any time for any reason or no reason, upon written notice to the Contractor. In the event of such termination, the Contractor shall be entitled to payment for the Work performed up to the date of termination, subject to the Client's right to withhold any amounts due to the Contractor's default under this Contract.8. Dispute ResolutionAny disputes arising out of or in connection with this Contract shall be resolved by arbitration in accordance with the rules of the [Arbitration Association], and the decision of the arbitrator(s) shall be final and binding upon the parties.9. Governing LawThis Contract shall be governed by and construed in accordance with the laws of the [Governing Jurisdiction].10. Entire AgreementThis Contract constitutes the entire agreement between the parties with respect to the subject matter hereof, and supersedes all prior agreements, understandings, negotiations, and discussions, whether oral or written, of the parties.IN WITNESS WHEREOF, the parties have executed this Contract as of the date first above written.[Client Name] [Contractor Name]By:\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_ \_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_ \_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_ \_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_ \_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_ \_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_ \_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_ \_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_ \_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_ \_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_ \_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_ \_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_ \_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_ \_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_ \_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_ \_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_ \_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_ \_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_ \_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_ \_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_ \_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_ \_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_ \_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_ \_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_ \_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_ \_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_ \_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_ \_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_ \_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\_\。
英文建筑设计合同模板
英文建筑设计合同模板Effective Date: [Date]This agreement is made and entered into as of the Effective Date between [Client Name], located at [Client Address] (hereinafter referred to as the Client) and [Architect Name], located at [Architect Address] (hereinafter referred to as the Architect).WHEREAS, the Client desires to engage the services of the Architect to provide architectural design services for [Project Name], located at [Project Location]; andWHEREAS, the Architect is willing to provide architectural design services for the Project in accordance with the terms and conditions set forth in this Agreement.NOW, THEREFORE, in consideration of the mutual covenants contained herein and for other good and valuable consideration, the receipt and sufficiency of which are hereby acknowledged, the parties hereto agree as follows:1. Scope of WorkThe Architect shall provide architectural design services for the Project as outlined in Exhibit A attached hereto, which may be amended or supplemented by written agreement of the parties. The Architect shall use his professional skill and judgment to perform all necessary services in a timely and professional manner.2. CompensationThe Client shall pay the Architect a fee in the amount of [Fee Amount] for the Architect's services rendered under this Agreement. The fee shall be paid in installments as set forth in Exhibit B attached hereto. The Client shall also reimburse the Architect for any reasonable and necessary expenses incurred in the performance of services under this Agreement.3. ChangesAny changes to the scope of work or schedule shall be agreed upon by the parties in writing. The Architect shall be entitled to an adjustment in the fee and schedule as a result of any changes requested by the Client.4. Ownership of DocumentsAll drawings, specifications, reports, and other documents prepared by the Architect shall be the property of the Client upon full payment of the Architect's fee. The Client may use, modify, or reproduce the documents for the Project as necessary.5. TerminationEither party may terminate this Agreement upon written notice to the other party in the event of a material breach of this Agreement by the other party. Upon termination, theparties shall settle any financial obligations and the Architect shall deliver all documents and materials related to the Project to the Client.6. InsuranceThe Architect shall maintain professional liability insurance coverage in the amount of [Coverage Amount]. The Client shall be named as an additional insured on the policy. The Architect shall provide a certificate of insurance to the Client upon request.7. Governing LawThis Agreement shall be governed by the laws of the State of [State]. Any disputes arising out of or related to this Agreement shall be resolved by arbitration in accordance with the rules of the American Arbitration Association.IN WITNESS WHEREOF, the parties hereto have executed this Agreement as of the Effective Date.CLIENT: ARCHITECT:_______________________ ________________________[Client Name] [Architect Name]Exhibit A: Scope of WorkExhibit B: Fee ScheduleThis Agreement constitutes the entire agreement between the parties with respect to the subject matter hereof and supersedes all prior agreements and understandings, whether written or oral. This Agreement may not be modified or amended except in writing signed by both parties.。
英文建造合同模板
英文建造合同模板This Construction Contract (the "Contract") is entered into as of [Date], by and between [Contractor Name], with an address of [Contractor Address] (the "Contractor"), and [Owner Name], with an address of [Owner Address] (the "Owner").RECITALSA. The Owner is the legal owner of certain real property located at [Property Address] (the "Property").B. The Owner desires to construct certain improvements on the Property.C. The Contractor is a licensed contractor with experience in construction and has agreed to perform the construction work according to the terms and conditions set forth in this Contract.AGREEMENT1. Scope of Work. The Contractor shall provide all labor, materials, equipment, and services necessary for the construction of the improvements described in Exhibit A (the "Work"). The Contractor shall complete the Work in accordance with the plans and specifications attached as Exhibit B.2. Time of Performance. The Contractor shall commence the Work on [Commencement Date] and shall complete the Work within [Number] days from the Commencement Date.3. Payments. The Owner shall pay the Contractor the sum of [Contract Amount] for the performance of the Work, which shall be paid in accordance with the payment schedule attached as Exhibit C. The Contractor shall submit invoices to the Owner for payment, which shall be due [Number] days after receipt of the invoice.4. Changes. The Owner may request changes or additions to the Work by written change order. The Contractor shall provide a written proposal for the change or addition, including any additional costs or time needed to complete the change. The Owner shall approve the change order in writing before the Contractor proceeds with the change.5. Warranties. The Contractor warrants that all work performed under this Contract shall be performed in a good workmanlike manner and in accordance with the plans and specifications. The Contractor further warrants that all materials used in the construction of the improvements shall be of good quality and free from defects.6. Insurance. The Contractor shall maintain insurance coverage including commercial general liability insurance, workers' compensation insurance, and automobile liability insurance during the term of the Contract. The Owner shall be named as an additional insured on the insurance policies.7. Indemnification. The Contractor shall indemnify, defend, and hold harmless the Owner from and against any claims, losses, damages, liabilities, and expenses arising out of or related to the Contractor's performance of the Work under this Contract.8. Termination. The Owner may terminate the Contract for cause if the Contractor fails to perform the Work in accordance with the plans and specifications, or if the Contractor breaches any other term of the Contract. The Contractor may terminate the Contract for cause if the Owner fails to make payments in accordance with the payment schedule.9. Dispute Resolution. Any disputes arising out of or related to this Contract shall be resolved through mediation or arbitration in accordance with the rules of the American Arbitration Association.10. Governing Law. This Contract shall be governed by and construed in accordance with the laws of the state of [State].IN WITNESS WHEREOF, the parties have executed this Construction Contract as of the date first written above.[Owner Name] [Contractor Name]__________________________ __________________________[Owner Signature] [Contractor Signature]EXHIBITSExhibit A - Description of WorkExhibit B - Plans and SpecificationsExhibit C - Payment Schedule。
建筑合同(中英版)(通用12篇)
建筑合同(中英版)(通用12篇)建筑(中英版) 篇1甲方:Party A:乙方:Party B:合同编号: Contract No日期:Date:签约地点:Signed at:特约定:甲方基于下文所列各种因素,特与乙方达成了协议并一致同意:由甲方在订约日期之翌日起_____天之内为乙方建造并完成_____(涉约建筑)。
涉约建筑之规模及所需的钢筋、水泥、砖块、石子和其它建筑材料之数量,均在作为附件的设计图和施工细则中予以说明。
Witnesses that the Party A for considerations hereinafter named, contracts and agrees with the Party B that Party A will, within_____ days, next following the date hereof, build and finish a Libarary Building for Party B. ( the building hereinafter is referred to as the said building.) The said building is of the following dimensions, with reinforced concrete, brick, stones and other materials, as are described in plans and specifications gereto annexed.基于上述情况,乙方及其法定代表郑重承诺向甲方支付人民币_____元整。
支付方法商定如下:In consideration of the foregoing, Party B shall, for itself and its legal representatives, promise to pay Party A the sum of one million RMB yuan in manner as follows, to wit:在上述工程开工之日,支付人民币_____元整在_____年_____月_____日,支付人民币_____元整在_____年_____月_____日,支付人民币_____元整在_____年_____月_____日,支付人民币_____元整在_____年_____月_____日,支付人民币_____元整余额人民币_____元整于工程完成之日付清。
英文建筑合同6篇
英文建筑合同6篇全文共6篇示例,供读者参考篇1English Building ContractA building contract is a legally binding agreement between a contractor and a client for the construction, renovation, or repair of a building or structure. It outlines the terms and conditions of the project, including the scope of work, schedule, payment terms, and responsibilities of each party.Scope of WorkThe scope of work section of the contract outlines the specific tasks and responsibilities that the contractor will perform. This includes everything from the materials and methods used in construction to the timeline for completion. It is important for both parties to have a clear understanding of what is expected in order to avoid disputes later on.ScheduleThe schedule section of the contract details the timeline for the project, including start and finish dates, milestones, anddeadlines for completion of specific tasks. It is important to include provisions for delays or extensions so that both parties are aware of their rights and responsibilities if the project falls behind schedule.Payment TermsThe payment terms section of the contract outlines how and when the client will pay the contractor for their services. This includes details on the amount of the contract, the payment schedule, and any penalties for late payment. It is important for both parties to agree on payment terms upfront to avoid misunderstandings or disputes during the course of the project.ResponsibilitiesThe responsibilities section of the contract outlines the duties of both parties during the course of the project. This includes everything from obtaining necessary permits and approvals to providing access to the site and ensuring safety and security measures are in place. It is important for both parties to understand their responsibilities in order to ensure a smooth and successful project.Dispute ResolutionThe dispute resolution section of the contract outlines how any disputes that may arise during the course of the project will be resolved. This may include mediation, arbitration, or litigation, depending on the terms of the contract. It is important for both parties to have a clear understanding of the dispute resolution process in order to avoid costly and time-consuming legal battles.Insurance and LiabilityThe insurance and liability section of the contract outlines the insurance coverage required for the project and the liability limits for both parties. This may include general liability insurance, workers' compensation insurance, and professional liability insurance. It is important for both parties to have adequate insurance coverage in place to protect against unforeseen events or accidents.ConclusionIn conclusion, a building contract is an essential document for any construction project. It outlines the terms and conditions of the project, including the scope of work, schedule, payment terms, and responsibilities of each party. By having a clear and comprehensive contract in place, both parties can avoid misunderstandings, disputes, and costly legal battles.篇2A standard form of contract in the construction industry is the JCT Design and Build contract, which is widely used in the UK. This type of contract is suitable for projects where the client wants to transfer the design and construction responsibilities to the contractor.The JCT Design and Build contract is a comprehensive document that sets out the rights and obligations of both parties in a clear and concise manner. It covers all aspects of the project, including the scope of work, the design and construction requirements, the schedule of work, and the payment terms.One of the key features of the JCT Design and Build contract is the provision for the contractor to carry out the design work. This means that the contractor takes on the responsibility for both the design and construction of the project, which can help to streamline the process and reduce the risk of disputes arising.The contract also includes provisions for the management of changes to the scope of work, as well as mechanisms for dealing with delays and disputes. It is important for both parties to understand their rights and obligations under the contract, aswell as the procedures for resolving any issues that may arise during the course of the project.In addition to the JCT Design and Build contract, there are a number of other standard forms of contract that are commonly used in the construction industry. These include the NEC Engineering and Construction contract, the FIDIC contract, and the ICE Conditions of Contract. Each of these contracts has its own specific terms and conditions, and it is important for both parties to be familiar with the particular requirements of the contract that they are using.Overall, a well-drafted construction contract is essential for ensuring that the rights and obligations of both parties are clearly defined and understood. By using a standard form of contract such as the JCT Design and Build contract, both parties can benefit from a clear and structured framework for the project, which can help to minimize the risk of disputes and delays.篇3English Construction Contract1. Parties InvolvedThis construction contract ("Contract") is made and entered into on [Date] by and between [Owner's Name] (hereinafterreferred to as "Owner"), and [Contractor's Name] (hereinafter referred to as "Contractor"). The Owner and Contractor are collectively referred to as the "Parties".2. Scope of WorkThe Contractor agrees to provide all labor, materials, equipment, permits, and services necessary for the construction of [Description of Project] (the "Project"). The Contractor shall complete the Project in accordance with the plans, specifications, and other documents outlined in Appendix A.3. PaymentThe Owner agrees to pay the Contractor the total contract price of [Contract Price] for the completion of the Project. The payment will be made as follows:- [Payment Schedule]4. Change OrdersAny changes or modifications to the Project shall be made in writing and signed by both Parties. The Contractor shall not proceed with any changes unless a change order has been executed.5. Time of CompletionThe Contractor agrees to complete the Project within [Timeframe] from the effective date of this Contract. If the Contractor fails to complete the Project within the specified time frame, the Owner may terminate the Contract and seek damages.6. WarrantyThe Contractor warrants that all work performed under this Contract shall be free from defects in workmanship and materials. The Contractor agrees to make any necessary repairs or replacements at no additional cost to the Owner.7. IndemnificationThe Contractor agrees to indemnify and hold harmless the Owner from any claims, damages, or liabilities arising from the Contractor's performance under this Contract.8. TerminationEither Party may terminate this Contract with written notice if the other Party fails to perform its obligations under this Contract. The terminating Party shall provide thenon-terminating Party with a notice of default and a reasonable opportunity to cure the default.9. Dispute ResolutionAny disputes arising from this Contract shall be resolved through mediation or arbitration. The prevailing Party in any dispute shall be entitled to recover its reasonable attorney's fees and costs.10. Governing LawThis Contract shall be governed by the laws of[State/Country], and any disputes shall be resolved in the courts of [City/County].IN WITNESS WHEREOF, the Parties hereto have executed this Contract as of the date first above written.Owner: ______________________________Contractor: ______________________________[Signatures]This Construction Contract constitutes the entire agreement between the Parties and supersedes any prior agreements or understandings, whether written or verbal. Any amendments to this Contract shall be made in writing and signed by both Parties.[Date]篇4Contract for construction of Residential BuildingThis agreement is entered into on this ____ day of _______, 20__ between Mr. John Smith, the owner of the property located at ________ (hereinafter referred to as the "Owner") and XYZ Construction Company, having its registered office at ______ (hereinafter referred to as the "Contractor").1. Scope of Work: The Contractor agrees to construct a residential building at the above-mentioned property in accordance with the plans, specifications, and drawings provided by the Owner. The Contractor shall be responsible for obtaining all necessary permits and approvals for the construction.2. Timeframe: The construction shall commence on ______ and shall be completed within ______ days from the commencement date. Any delays in the completion of the project shall be notified to the Owner in writing.3. Payment: The Owner agrees to pay the Contractor a total sum of $________ for the construction of the residential building. The payment shall be made in installments as follows:- 25% of the total sum upon signing of this agreement- 25% upon completion of the foundation work- 25% upon completion of the superstructure- 25% upon completion of the finishing work4. Changes: Any changes or modifications to the plans, specifications, or drawings shall be agreed upon in writing by both parties and shall be subject to additional charges.5. Warranties: The Contractor warrants that all work shall be carried out in a good and workmanlike manner and in accordance with the prevailing industry standards. The Contractor shall rectify any defects in the workmanship or materials at no additional cost to the Owner.6. Indemnity: The Contractor shall indemnify and hold harmless the Owner from any claims, damages, or liabilities arising out of the construction work.7. Termination: Either party may terminate this agreement with a written notice of ______ days. In the event of termination, the Contractor shall be entitled to payment for work completed up to the date of termination.8. Dispute Resolution: Any disputes arising out of or in connection with this agreement shall be resolved through arbitration in accordance with the laws of the jurisdiction.This document constitutes the entire agreement between the Owner and the Contractor and supersedes any prioragreements or understandings. This agreement shall be binding upon the parties, their successors, and assigns.Owner's Signature: ______________ Date:Contractor's Signature: ______________ Date:Witnessed by:___________________(Name)(Signature)___________________(Name)(Signature)篇5英文建筑合同Contract for Construction WorkThis agreement is entered into on [date], by and between [owner’s name], hereinafter referred to as the “Owner,” and [contractor’s name], hereinafter referred to as the “Contractor,” for the purpose of specifying the terms and conditions for theconstruction work to be undertaken on the property located at [address].1. Scope of Work: The Contractor agrees to perform all necessary labor, materials, and equipment required for the completion of the construction work as specified in the attached plans and drawings. The work shall be carried out in accordance with all applicable codes, regulations, and industry standards.2. Payment: The Owner agrees to pay the Contractor the sum of [total contract amount] for the completion of the construction work. Payments shall be made in installments as follows: [payment schedule]. The final payment shall be made upon completion of the work and acceptance by the Owner.3. Timeframe: The Contractor agrees to commence work on [start date] and to complete the project by [completion date]. Any delays in the completion of the work due to factors beyond the Contractor’s control shall not be considered a breach of contract.4. Changes: Any changes to the scope of work must be agreed upon in writing by both parties. The Owner shall be responsible for any additional costs incurred as a result of changes to the original plans.5. Insurance: The Contractor shall maintain liability insurance for the duration of the project and shall provide a certificate of insurance to the Owner upon request. The Owner shall be responsible for obtaining any necessary permits and approvals for the construction work.6. Warranties: The Contractor warrants that all work performed under this agreement shall be of good quality and free from defects in materials and workmanship. Any defects that arise within one year of completion shall be repaired by the Contractor at no additional cost to the Owner.7. Termination: Either party may terminate this agreement upon written notice if the other party fails to meet their obligations under the contract. In the event of termination, the Owner shall pay the Contractor for any work completed up to that point.8. Dispute Resolution: Any disputes arising from this agreement shall be resolved through mediation or arbitration, as agreed upon by both parties.This agreement constitutes the entire understanding between the Owner and Contractor with respect to the construction work and supersedes any prior agreements or understandings. This agreement shall be governed by the laws of[state].IN WITNESS WHEREOF, the parties hereto have executed this agreement on the date first above written.Owner:Contractor:篇6英文建筑合同是一种法律文件,用于约定建筑项目的各种条款和条件。
建筑合同(中英版)6篇
建筑合同(中英版)6篇篇1Building ContractA building contract is a legal agreement between the owner of a property and a building contractor, outlining the terms and conditions under which a construction project will be carried out. This document is essential for ensuring that both parties understand their rights and responsibilities throughout the construction process. In this article, we will discuss the key components of a building contract and its importance in the construction industry.1. Parties involvedThe building contract will identify the parties involved in the project, including the owner of the property and the building contractor. It may also include subcontractors, architects, engineers, and other professionals who will be involved in the construction process.2. Scope of workThe contract will outline the scope of work to be performed, including the specific tasks that the building contractor is responsible for, such as site preparation, construction, and cleanup. It will also specify the materials and equipment to be used in the project.3. ScheduleThe contract will include a timeline for the completion of the project, including key milestones and deadlines. This is important for both parties to ensure that the project stays on track and is completed in a timely manner.4. Payment termsThe contract will outline the payment terms for the project, including the total cost of the construction, payment schedule, and any additional costs that may arise during the project. This is essential for avoiding disputes over payment and ensuring that the project stays within budget.5. Changes and disputesThe contract will include provisions for handling changes to the project scope, as well as procedures for resolving disputes that may arise during the construction process. This is important for maintaining a positive working relationship between theparties and ensuring that any issues are resolved quickly and fairly.6. Insurance and liabilityThe contract will specify the insurance coverage required for the project, including liability insurance for the building contractor and any subcontractors. This is essential for protecting both parties in the event of accidents or damages during the construction process.Building contracts are critical documents in the construction industry, as they provide a legal framework for the building project and ensure that both parties understand their rights and responsibilities. It is important for both owners and building contractors to carefully review and negotiate the terms of the contract before signing to avoid any misunderstandings or disputes later on. By having a clear and comprehensive building contract in place, both parties can work together to successfully complete the construction project on time and within budget.篇2Architecture ContractBuilding a new structure involves a lot of planning, designing, and execution. In order to ensure that a project is completedsuccessfully, it is essential to have a proper agreement in place. This agreement, known as an architecture contract, outlines the responsibilities of both the client and the architect, as well as the terms and conditions of the project.An architecture contract is a legal document that establishes the scope of work, the schedule, and the cost of a construction project. It also specifies the roles and responsibilities of the architect, the client, and any other parties involved in the project. By signing this contract, both parties agree to abide by the terms and conditions laid out in the document.There are several key components that should be included in an architecture contract. These include:1. Scope of Work: This section outlines the specific tasks that the architect will be responsible for, such as creating designs, obtaining permits, and overseeing construction.2. Schedule: The contract should include a timeline for the project, including milestones and deadlines for completion.3. Fees: The contract should detail the architect's fees, including how they will be calculated and when they are due.4. Changes: This section should outline the procedure for making changes to the project scope, schedule, or budget.5. Termination: The contract should specify the conditions under which either party can terminate the agreement.In addition to these components, an architecture contract should also address issues such as insurance, liability, and dispute resolution. It is important for both parties to fully understand and agree to the terms of the contract before signing it.In conclusion, an architecture contract is a crucial document that helps to ensure the success of a construction project. By clearly outlining the responsibilities and expectations of both parties, this agreement helps to minimize misunderstandings and disputes, and provides a framework for the successful completion of the project.篇3Architecture Contract (中英版)Introduction建筑合同是指项目委托方和承包方之间所签订的协议,规定了双方在建筑项目中的权利和义务。
建筑合同范本 英语
建筑合同范本英语Construction Contract TemplateThis Construction Contract ("Contract") is made and entered into on [date] and between [Party A Name], a pany incorporated and existing under the laws of [jurisdiction], with its registered address at [address] ("Party A"), and [Party B Name], a pany incorporated and existing under the laws of [jurisdiction], with its registered address at [address] ("Party B").1. Project DescriptionParty A intends to undertake a construction project located at [project location] (the "Project"), and Party B agrees to undertake the construction works in accordance with the requirements and specifications set forth in this Contract.2. Scope of WorkThe scope of work to be performed Party B includes but is not limited to [list the specific work to be done, such as foundation construction, building structure, plumbing, electrical work, etc.].3. Project TimelineThe Project is expected to mence on [start date] and be pleted [pletion date]. However, the timeline may be adjusted due to unforeseen circumstances or with mutual agreement between the parties.4. Contract Price and Payment TermsThe total contract price for the Project is [amount] (inclusive of all taxes and fees). Party A shall make payments to Party B in the following manner: [Describe the payment schedule and milestones]5. Quality AssuranceParty B shall ensure that the construction works are carried out in accordance with industry standards and the agreed-upon specifications. Any defects or deficiencies discovered within the warranty period shall be rectified Party B at no additional cost to Party A.6. Changes and AmendmentsAny changes or amendments to the scope of work, project timeline, or contract price shall be mutually agreed upon in writing both parties.7. Force MajeureNeither party shall be liable for any delay or flure in performing its obligations under this Contract if such delay or flure is caused events beyond its reasonable control, such as natural disasters, wars, or government actions.8. Dispute ResolutionIn the event of any dispute arising out of or in connection with this Contract, the parties shall attempt to resolve the dispute through friendly negotiation. If the negotiation fls, the dispute shall be submitted to arbitration in accordance with the rules of [arbitration institution].9. TerminationThis Contract may be terminated either party in the event of a material breach of its terms and conditions the other party, provided that written notice of the breach and an opportunity to rectify it are given.10. MiscellaneousThis Contract constitutes the entire agreement between the parties and supersedes all prior negotiations, understandings, and agreements. Any notices required under this Contract shall be in writing and delivered to the respective parties at the addresses specified herein.IN WITNESS WHEREOF, the parties have executed this Construction Contract as of the date first above written.Party A: [Party A Signature] [Party A Name] [Date]Party B: [Party B Signature] [Party B Name] [Date]Please note that the above is a basic template and should be tlored to the specific circumstances and requirements of the construction project. It is remended to consult with a legal professional before finalizing and signing any contract.。
建筑合同范本英语
建筑合同范本英语建筑合同(Construction Contract)一、合同双方甲方(Party A):名称(Name):____________________地址(Address):____________________法定代表人(Legal Representative):____________________联系电话(Contact Telephone):____________________乙方(Party B):名称(Name):____________________地址(Address):____________________法定代表人(Legal Representative):____________________联系电话(Contact Telephone):____________________二、工程概况1. 工程名称:____________________2. 工程地点:____________________3. 工程内容:____________________4. 工程规模:____________________三、工程期限1. 开工日期:预计于____年__月__日开工,具体开工日期以甲方书面通知为准。
2. 竣工日期:预计于____年__月__日竣工,如遇不可抗力等特殊情况,工期相应顺延。
3. 总工期:____日历天。
四、工程质量标准1. 乙方应按照国家和地方相关标准及甲方要求进行施工,确保工程质量达到合格标准。
2. 工程竣工后,乙方应提交竣工验收报告,甲方应在收到报告后[具体期限]内组织验收。
如验收不合格,乙方应在规定的时间内整改完毕,直至验收合格。
五、工程造价及付款方式1. 工程造价:本工程总造价为人民币____元(大写:____元整)。
2. 付款方式:预付款:合同签订后[具体期限]内,甲方向乙方支付工程总造价的[具体比例]作为预付款。
进度款:乙方按照工程进度完成相应工作量后,经甲方审核确认,甲方向乙方支付工程进度款。
英文建筑合同范本
英文建筑合同范本Construction ContractThis Construction Contract (the "Contract") is made and entered into as of [date] (the "Effective Date") and between [Owner's Name] (the "Owner") and [Contractor's Name] (the "Contractor").1. Project DescriptionThe Contractor agrees to undertake the construction project described as follows: [Describe the project in detl, including the location, scope, and specific requirements of the construction work].2. Contract Price and Payment TermsThe total contract price for the project is agreed to be $[amount] (the "Contract Price"). The Owner shall make payments to the Contractor in accordance with the following schedule:[Describe the payment milestones and amounts].3. Work ScheduleThe Contractor shall mence work on or before [start date] and shall plete the project [pletion date], subject to any extensions of time as provided herein.4. Changes and AmendmentsAny changes or amendments to the scope of work or contract price shall be made in writing and signed both parties.5. Materials and WorkmanshipThe Contractor shall use materials of good quality and perform the work in a workmanlike manner in accordance with industry standards.6. Inspection and AcceptanceThe Owner or its representatives shall have the right to inspect the work at reasonable intervals. The project shall be considered accepted upon written notification from the Owner.7. WarrantiesThe Contractor warrants that the work will be free from defects in materials and workmanship for a period of [warranty period] from the date of acceptance.8. Insurance and IndemnificationThe Contractor shall mntn appropriate insurance coverage throughout the project and shall indemnify the Owner agnst any clms arising from the Contractor's work.9. TerminationThis Contract may be terminated either party in the event of a material breach the other party, subject to notice and cure periods as provided herein.10. Dispute ResolutionAny disputes arising under this Contract shall be resolved through arbitration or litigation in accordance with the laws of [applicable jurisdiction].IN WITNESS WHEREOF, the parties have executed this Contract as of the date first above written.Owner: [Owner's Signature] [Owner's Name] [Owner's Address] [Contact Information]Contractor: [Contractor's Signature] [Contractor's Name] [Contractor's Address] [Contact Information]。
建筑合同范本 英语
建筑合同范本英语Construction Contract TemplateThis construction contract (the "Contract") is made and entered into on [date] between [Party A's name] (the "Owner") and [Party B's name] (the "Contractor").1. Project DescriptionThe Contractor agrees to undertake the construction project described as [project detls] (the "Project") at the location specified as [project location].2. Project TimelineThe Project is expected to mence on [start date] and be pleted [pletion date], subject to any extensions agreed upon in writing both parties.3. Contract PriceThe total contract price for the Project is [amount in figures] and [amount in words] (the "Contract Price"). This price includes all materials, labor, equipment, and other costs associated with the pletion of the Project.4. Payment TermsThe Owner will make payments to the Contractor as follows:[Percentage or amount] upon signing of this Contract.[Percentage or amount] upon reaching certn milestones as defined in the Contract.The remning balance upon satisfactory pletion and acceptance of the Project.5. Workmanship and MaterialsThe Contractor shall perform the work in a professional and workmanlike manner and shall use materials of good quality that conform to the specifications and standards set forth in this Contract.6. Changes and AmendmentsAny changes or amendments to the scope of work, specifications, or Contract Price must be made in writing and signed both parties.7. WarrantyThe Contractor warrants that the work performed under this Contract will be free from defects in workmanship and materials for a period of [warranty period] from the date of pletion.8. TerminationEither party may terminate this Contract in the event of a material breach the other party, provided that written notice of the breach and an opportunity to cure are given.9. Dispute ResolutionIn the event of a dispute arising out of or in connection with this Contract, the parties shall attempt to resolve the dispute through amicable negotiation. If negotiation fls, the dispute shall be submitted to arbitration in accordance with the rules of [arbitration institution].10. Governing LawThis Contract shall be governed and construed in accordance with the laws of [jurisdiction].This Contract constitutes the entire agreement between the parties and supersedes all prior negotiations, understandings, and agreements.IN WITNESS WHEREOF, the parties have executed this Contract as of the date first above written.Party A (Owner): [Owner's Name and Signature]Party B (Contractor): [Contractor's Name and Signature]Date: [Date of Execution]。
- 1、下载文档前请自行甄别文档内容的完整性,平台不提供额外的编辑、内容补充、找答案等附加服务。
- 2、"仅部分预览"的文档,不可在线预览部分如存在完整性等问题,可反馈申请退款(可完整预览的文档不适用该条件!)。
- 3、如文档侵犯您的权益,请联系客服反馈,我们会尽快为您处理(人工客服工作时间:9:00-18:30)。
英文建筑合同正式模版
Contracts concluded in accordance with the law have legal effect and regulate the behavior of
the parties to the contract
( 合同范本 )
甲方:______________________
乙方:______________________
日期:_______年_____月_____日
编号:MZ-HT-019773
英文建筑合同正式模版
Party A:Party B:
Contract No
Date:
Signed at:
Witnesses that the Party A for considerations hereinafter named, contracts and agrees with the Party B that Party A will, within_____ days, next following the date hereof, build and finish a Libarary Building for Party B. ( the building hereinafter is referred to as the said building.) The said building is of the following dimensions, with reinforced concrete, brick, stones and other materials, as are described in plans and specifications gereto annexed.
In consideration of the foregoing, Party B shall, for itself and its legal representatives, promise to pay Party A the sum of one million RMB yuan in manner as follows, to wit:RMB_____at the beginning of the said work.
RMB_____on _____/ _____/_____( for example: 3/21/2001)RMB_____ on_____/ _____/_____
RMB_____ on_____/ _____/_____
RMB_____ on_____/ _____/_____
And the remaining sum will be paid upon the completion of the work.
It is further agreed that in order to be entitled to the said payments ( the first one excepted, which is otherwise secured ), Party A or its legal representatives shall, according to the architect''s appraisement, have expended, in labor and material, the value of the payments already received by Party A, on the building, at the time of payment.
For failure to accomplish the faithful performance of the agreement aforesaid, the party so failing agrees to forfeit and pay to the other_____RMB yuan as fixed and settled damages, within one month form the time so failing.
In witness whereof we have hereunto set our hands and seals the day and year first above written.
Signed, sealed and delivered
in the presence of
Party A : Party B:
云博图文设计
本文档文字均可以自由修改。